Solicitation Amendment 0001 N6660426R00110001.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

Created On:

28 Oct 2025, 14:37 PM Greenwich Mean Time

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Block 14 (Description of Amendment/Modification): Distribution: FILE, KR, NUWC, DCMA, DFAS, COR, PI, TDAA, DCM

NUWCDIVNPT PID #: N66604-25-RFPREQ-NPT-15-0081

NUWCDIVNPT POC: Hannah Sherron, hannah.r.sherron.civ@us.navy.mil

Solicitation Amendment 0001:

The purpose of this amendment is to:

1. Answer Industry Questions

2. Update Attachment #3 Section L, all revisions are in red text

3. Update Attachment #4 Section M, all revisions are in red text

3. Update clause 52.209-3 Section (b)

4. Extend solicitation closing date two (2) weeks to 21 November 2025

NOTE: Due to fleet needs, the Government will not provide any further extensions to this solicitation.

Section A - Solicitation/Contract Form

The following changes have been made:

INFORMATION FROM TO

Response Due Date 07 Nov 2025 21 Nov 2025

N6660426R00110001

Section B - Supplies or Services & Prices or Costs

The following CLIN(s) / SLIN(s) / ELIN(s) were modified:

INFORMATION FROM TO CHANGED

BY

Description

Post-award Conference Attendance. The Contractor shall attend the Post-award Conference either virtually or in person with a Government Furnished schedule and attendance information to follow within seven (7) days of award.

Post-award Conference Attendance. The Contractor shall attend the Post-award Conference either virtually or in person with a Government Furnished schedule and attendance information to follow within seven (7) days of award. NOTE: Offerors shall propose a total ceiling value of $2,500 for this CLIN.

INFORMATION FROM TO CHANGED

BY

Description DataData in accordance with Contract Data Requirements Lists (CDRLs), DD Form 1423, Exhibit A.

DataData in accordance with Contract Data Requirements Lists (CDRLs), DD Form 1423, Exhibit A. Not Separately Priced

Section I - Contract Clauses

Additional Information/Notes

The following clauses were modified:

52.209-3 First Article Approval-Contractor Testing. Sep 1989 hereby reads as follows:

First Article Approval-Contractor Testing (Sept 1989)

(a) The Contractor shall test unit(s) of Lot/Item as specified in this contract. At least ninety calendar days before the beginning twelve (12) 0002 (90) of first article tests, the Contractor shall notify the Contracting Officer, in writing, of the time and location of the testing so that the Government may witness the tests.

(b) The Contractor shall submit the first article test report within calendar days from the date of this contract to TBD TO BE PROVIDED AT marked "First Article Test Report: Contract No. , Lot/Item No. " Within calendar days after the Government receives AWARD TBD 0002 seven (7) the test report, the Contracting Officer shall notify the Contractor, in writing, of the conditional approval, approval, or disapproval of the first article.

The notice of conditional approval or approval shall not relieve the Contractor from complying with all requirements of the specifications and all other terms and conditions of this contract. A notice of conditional approval shall state any further action required of the Contractor. A notice of disapproval shall cite reasons for the disapproval.

(c) If the first article is disapproved, the Contractor, upon Government request, shall repeat any or all first article tests. After each request for additional tests, the Contractor shall make any necessary changes, modifications, or repairs to the first article or select another first article for testing.

All costs related to these tests are to be borne by the Contractor, including any and all costs for additional tests following a disapproval. The Contractor shall then conduct the tests and deliver another report to the Government under the terms and conditions and within the time specified by the Government. The Government shall take action on this report within the time specified in paragraph (b) of this subsection. The Government reserves the right to require an equitable adjustment of the contract price for any extension of the delivery schedule, or for any additional costs to the Government related to these tests.

(d) If the Contractor fails to deliver any first article report on time, or the Contracting Officer disapproves any first article, the Contractor shall be deemed to have failed to make delivery within the meaning of the Default clause of this contract.

(e) Unless otherwise provided in the contract, and if the approved first article is not consumed or destroyed in testing, the Contractor may deliver the approved first article as part of the contract quantity if it meets all contract requirements for acceptance.

(f) If the Government does not act within the time specified in paragraph (b) or (c) of this subsection, the Contracting Officer shall, upon timely written request from the Contractor, equitably adjust under the changes clause of this contract the delivery or performance dates and/or the contract price, and any other contractual term affected by the delay.

(g) Before first article approval, the acquisition of materials or components for, or the commencement of production of, the balance of the contract quantity is at the sole risk of the Contractor. Before first article approval, the costs thereof shall not be allocable to this contract for (1) progress payments, or (2) termination settlements if the contract is terminated for the convenience of the Government.

(h) The Government may waive the requirement for first article approval test where supplies identical or similar to those called for in the schedule have been previously furnished by the offeror/contractor and have been accepted by the Government. The offeror/contractor may request a waiver.

(End of clause)

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. Sep 2000 hereby reads as follows:

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $ per calendar day of delay.TO BE DETERMINED AT ORDER LEVEL

(b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

Section J - List of Attachments

The following attachments were added:

Questions and Answers Amendment 0001 Section L - Amendment 0001 Section M - Amendment 0001

The following attachments were deleted:

Section L Section M.

Section L - Instructions, Conditions, & Notices to Offerors or Quoters

The following clauses were modified:

L-215-H007 SUBMISSION OF QUESTIONS BY OFFERORS—ALTERNATE I (NAVSEA) (NOV

2021)

Nov 2021 hereby reads as follows:

(a) Offerors may submit questions or request clarification of any aspect of this solicitation. It is the Offeror's responsibility to bring to the attention of the Contracting Officer at the earliest possible time, but prior to the closing date, any ambiguities, discrepancies, inconsistencies, or conflicts between the SOW or PWS (as applicable) and other solicitation documents attached hereto or incorporated by reference. Each question should identify solicitation number, document, page number, paragraph number or other identifier relating to the question. Questions without this information may not be answered. Acknowledgment of questions received will not be made.

(b) The deadline for receipt of questions is . Although calendar days prior to the closing date of the solicitationfourteen (14) every effort will be made, the Government makes no guarantee that questions received after the date above will be answered.

(c) All questions shall be submitted via email to the point of contact listed for this solicitation. Responses will be posted to the SAM web page at https://www.SAM.gov.

(End of Provision)

N6660426R00110001 https://www.sam.gov/

1176 HOWELL ST, NEWPORT RI 02841-1703

NEWPORT, RI 02841-1703

UNITED STATES

HANNAH SHERRON, Email: hannah.r.sherron.civ@us.navy.mil Telephone: 401-832-3039 AdminBy:

SCD: PAS: