N6660424Q0144 Amendment 0002.pdf

1301126989

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See section A.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 09-Feb-2024

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X N6660424Q0144

X 9B. DATED (SEE ITEM 11)

17-Jan-2024

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

09-Feb-2024

CODE

NAVAL UNDERSEA WARFARE CENTER

JAY PARKER, CODE 0221

CONTRACTS DEPARTMENT

1176 HOWELL STREET

NEWPORT RI 02841

N66604 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N6660424Q0144

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION A - SOLICITATION/CONTRACT FORM

The required response date/time has changed from 13-Feb-2024 02:00 PM to 01-Mar-2024 02:00 PM.

The required performance has changed from PROJECT TITLE AND DESCRIPTION: Bldg 1319 Stairwell RenovationsProposal Due: 13 Feb 2024 before 2:00 pm ET. Email to jay.a.parker2.civ@us.navy.mil and michael.n.ouellette.civ@us.navy.mil. Questions accepted up to 6 Feb 2024. Offeror MUST be registered in the System for Award Management to be considered for award.This requirement is 100% Small Business Set-Aside:

NAICS 236220; $45 MillionMagnitude per FAR 36.204: Between $100,000 and $250,000.Method of Payment: If no surcharge is applicable, the Government’s preferred method of payment is via credit card. Otherwise, Electronic Payment through Wide Area Workflow will be used. Please confirm Government Purchase Card is an acceptable form of payment within the proposal.Site Visit: 2:00 PM ET 31 Jan 2024. See Section A for complete details.IMPORTANT: PLEASE NOTE THAT TECHNICAL INFORMATION IS REQUIRED, PLEASE SEE

SECTIONS L AND M FOR SPECIFIC REQUIRMENTS. OFFERORS NOT SUBMITTING THIS

INFORMATION RISK BEING EXCLUDED FROM CONSIDERATION FOR AWARD. to PROJECT TITLE AND DESCRIPTION: Bldg 1319 Stairwell RenovationsProposal Due: 1 Mar 2024 before 2:00 pm ET. Email to jay.a.parker2.civ@us.navy.mil and michael.n.ouellette.civ@us.navy.mil. Questions accepted up to 23 Feb 2024.

Offeror MUST be registered in the System for Award Management to be considered for award.This requirement is 100% Small Business Set-Aside: NAICS 236220; $45 MillionMagnitude per FAR 36.204: Between $100,000 and $250,000.Method of Payment: If no surcharge is applicable, the Government’s preferred method of payment is via credit card. Otherwise, Electronic Payment through Wide Area Workflow will be used. Please confirm Government Purchase Card is an acceptable form of payment within the proposal.Site Visit: 2:00 PM ET 31 Jan 2024. See Section A for complete details.IMPORTANT: PLEASE NOTE THAT TECHNICAL INFORMATION IS

REQUIRED, PLEASE SEE SECTIONS L AND M FOR SPECIFIC REQUIRMENTS. OFFERORS NOT

SUBMITTING THIS INFORMATION RISK BEING EXCLUDED FROM CONSIDERATION FOR AWARD..

The following have been modified:

GENERAL INFORMATION:

Distribution: To be provided at award NUWCDIVNPT PR Number: To be provided at award

NUWCDIVNPT PID: N66604-24-SIMACQ-NPT-10-0121

NUWCDIVNPT Point of Contact: Jay Parker, jay.a.parker2.civ@us.navy.mil, (401) 832 2687

Amendment 0002: The purpose of this amendment it to:

1. Extend the proposal due date from 13 Feb 2024 @ 1400 EST to 01 Mar 2024 @1400 EST.

2. Add clause 52.211-12 Liquidated Damages.

3. Provide answers to RFI 0002 listed below.

RFIs 0002: N6660423Q0207: B1319 Stairwell Renovation

1. Has environmental testing been done for this job, will be getting done, or needs to be accounted for?

Response: Sample testing will be provided in follow on ammendment.

N6660424Q0144

2. What is the preference on staging for the stairwells for painting?

Response: There is no governmental requirements for any specific type of staging other than that they must comply with both USACE EM 385-1-1 and OSHA standards.

3. Can extension ladders with the Pivit ladder tools be used?

Response: The Pivit ladder tool is not acceptable for use per USACE EM 385-1-1 Section 22.A.04.

4. Are there any considerations for ladder safety classes that we should consider into our cost?

Response: Refer to USACE EM 385-1-1 Fall Protection and Scaffolding sections for training requirements. Review for any additional training requirements that are called out.

5. Is baker staging permissible?

Response: Baker staging is permissible as long as it meets USACE EM 385-1-1 and OSHA requirements.

All other terms and conditions remain unchanged.

SECTION I - CONTRACT CLAUSES

The following have been added by full text:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $200 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)