AMD1_Specs_FINAL.pdf

PAF 160600 BULK FUEL STORAGE TANKS 1581218

RAAF BASE DARWIN, AUSTRALIA

DOCUMENT 00 01 15

LIST OF DRAWINGS

PART 1 GENERAL

1.1 SUMMARY

This section lists the drawings for the project pursuant to contract clause "DFARS 252.236-7001, Contract Drawings, Maps and Specifications."

1.2 CONTRACT DRAWINGS

Contract drawings are as follows:

Drawing No.

Revision No.

NAVFAC

DWG No.

Title

G-001 17224483 TITLE SHEET

G-002 17224484 SHEET INDEX 1

G-003 17224485 SHEET INDEX 2

G-004 17224486 NOTES, LEGEND AND ABBREVIATIONS

G-005 17224487 FACILITY MAP

G-006 17224488 WORK RESTRICTIONS

G-007 0001 17224489 TEMPORARY LDBO FACILITY SITE PLAN

G-008 17224490 EROSION AND SEDIMENT CONTROL PLAN

V-101 17224491 EXISTING CONDITIONS

D-101 17224492 DEMOLITION PLAN

D-101 17224493 LDBO FACILITY DEMOLITION PLAN

D-103 17224494 DEMOLITION PHOTOS 1

D-104 17224495 DEMOLITION PHOTOS 2

D-105 17224496 DEMOLITION PHOTOS 3

B-101 17224497 SOIL BORING LOCATION MAP

B-102 17224498 BORING LOGS 1 OF 3

B-103 17224499 BORING LOGS 2 OF 3

DOCUMENT 00 01 15 Page 1

AMENDMENT 0001

B-104 17224500 BORING LOGS 3 OF 3

C-001 17224501 GENERAL CIVIL NOTES

C-101 17224502 OVERALL SITE PLAN

C-102 17224503 FUEL FARM #8 SURFACING PLAN

C-103 17224504 NORTHWEST SITE PLAN

C-104 17224505 NORTHEAST SITE PLAN

C-105 17224506 SOUTHWEST SITE PLAN

C-106 0001 17224507 SOUTHEAST SITE PLAN

C-107 0001 17224508 EAST SITE PLAN

C-108 0001 17224509 LDBO FACILITY WEST SITE PLAN

C-109 17224510 LDBO FACILITY EAST SITE PLAN

C-110 17224511 OVERALL POL PIPING PLAN

C-111 17224512 TRUCK OFFLOAD PIPING PLAN

C-112 17224513 TRUCK UPLOAD PIPING PLAN

C-113 17224514 MINOR PIPING PLAN

C-114 17224515 TANK PIPING PLAN

C-115 17224516 POL TRANSFER LINE PROFILE

C-121 17224517 OVERALL DOMESTIC AND FIRE WATER PLAN

C-122 0001 17224518 WATER PLAN AND PROFILE 1

C-123 17224519 WATER PLAN AND PROFILE 2

C-124 17224520 WATER PLAN AND PROFILE 3

C-125 17224521 FIRE WATER PLAN AND PROFILE 4

C-126 17224522 FIRE WATER PLAN AND PROFILE 5

C-127 0001 17224523 FIRE WATER PLAN AND PROFILE 6

C-128 17224524 FIRE WATER PLAN AND PROFILE 7

C-129 17224525 FIRE WATER PLAN AND PROFILE 8

C-130 17224526 FIRE WATER PLAN AND PROFILE 9

DOCUMENT 00 01 15 Page 2

C-131 17224527 WATER PLAN AND PROFILE 10

C-141 17224528 OVERALL SANITARY SEWER PLAN

C-142 17224529 FORCE MAIN PLAN AND PROFILE 1

C-143 17224530 FORCE MAIN PLAN AND PROFILE 2

C-144 17224531 FORCE MAIN PLAN AND PROFILE 3

C-145 0001 17224532 FORCE MAIN PLAN AND PROFILE 4

C-146 0001 17224533 POL OPERATIONS SANITARY SEWER PLAN AND PROFILE

C-147 17224534 LDBO SANITARY SEWER PLAN AND PROFILE

C-203 17224535 NORTHWEST GRADING AND DRAINAGE PLAN

C-204 17224536 NORTHEAST GRADING AND DRAINAGE PLAN

C-205 17224537 SOUTHWEST GRADING AND DRAINAGE PLAN

C-206 17224538 SOUTHEAST GRADING AND DRAINAGE PLAN

C-207 0001 17224539 EAST GRADING AND DRAINAGE PLAN

C-208 0001 17224540 LDBO FACILITY WEST GRADING AND DRAINAGE PLAN

C-209 17224541 LDBO FACILITY EAST GRADING AND DRAINAGE PLAN

C-301 0001 17224542 SITE SECTIONS 1

C-302 0001 17224543 SITE SECTIONS 2

C-303 0001 17224544 SITE SECTIONS 3

C-304 0001 17224545 SITE SECTIONS 4

C-305 0001 17224546 SITE SECTIONS 5

C-401 17224547 FILTER BUILDING SITE, GRADING AND DRAINAGE PLAN

C-402 0001 17224548 SITE, GRADING AND DRAINAGE PLAN 2

C-403 17224549 POL OPERATIONS BUILDING SITE, GRADING AND DRAINAGE PLAN

C-404 0001 17224550 GANTRY SITE, GRADING AND DRAINAGE PLAN 1

C-405 0001 17224551 GANTRY SITE, GRADING AND DRAINAGE PLAN 2

C-406 0001 17224552 CAR PARK SITE, GRADING AND DRAINAGE PLAN

C-407 17224553 ENLARGED PLANS 1

DOCUMENT 00 01 15 Page 3

C-408 17224554 ENLARGED PLANS 2

C-409 17224555 DRIP PAD PLANS

C-410 17224556 SUBSTATION SITE, GRADING AND DRAINAGE PLAN

C-501 0001 17224557 CIVIL DETAILS 1

C-502 17224558 CIVIL DETAILS 2

C-503 17224559 CIVIL DETAILS 3

C-504 17224560 CIVIL DETAILS 4

C-505 17224561 CIVIL DETAILS 5

C-506 0001 17224562 CIVIL DETAILS 6

C-507 17224563 CIVIL DETAILS 7

C-601 0001 17224564 TABLES

C-602 17224565 SIGNAGE TABLE

M-001 17224566 ABBREVIATIONS AND LEGENDS

M-002 17224567 SEQUENCE OF OPERATIONS 1

M-003 17224568 SEQUENCE OF OPERATIONS 2

M-004 17224569 SEQUENCE OF OPERATIONS 3

M-005 17224570 SEQUENCE OF OPERATIONS 4

M-010 17224571 BULK STORAGE TANK 1 FLOW DIAGRAM

M-011 17224572 BULK STORAGE TANK 2 FLOW DIAGRAM

M-012 17224573 FILTER BUILDING ISSUE PIPING FLOW DIAGRAM

M-013 17224574 FILTER BUILDING RECEIPT PIPING FLOW DIAGRAM

M-014 17224575 QCI/DROP TANK 1 FLOW DIAGRAM

M-015 17224576 QCI/DROP TANK 2 FLOW DIAGRAM

M-016 17224577 GANTRY OFFLOAD AND RTB FLOW DIAGRAM

M-017 17224578 GANTRY FILLSTAND FLOW DIAGRAM

M-018 17224579 PRODUCT RECOVERY TANK AND WASTE TANK FLOW DIAGRAM

M-019 17224580 FUEL FARM #7 STORAGE TANKS PARTIAL FLOW DIAGRAM

DOCUMENT 00 01 15 Page 4

M-020 17224581 FUEL FARM #7 HYDRANT PUMPS PARTIAL FLOW DIAGRAM 1

M-021 17224582 FUEL FARM #7 HYDRANT PUMPS PARTIAL FLOW DIAGRAM 2

M-022 17224583 GENERATOR FLOW DIAGRAM

M-101 17224584 OVERALL POL PIPING PLAN

M-102 17224585 PUMP VAULT 1 PIPING PLAN

M-103 17224586 PUMP VAULT 2 PIPING PLAN

M-104 17224587 FILTER BUILDING PIPING PLAN

M-105 17224588 NORTHWEST GANTRY AND QCI/DROP TANK PIPING PLAN

M-106 17224589 NORTHEAST GANTRY AND QCI/DROP TANK PIPING PLAN

M-107 17224590 SOUTHWEST GANTRY AND QCI/DROP TANK PIPING PLAN

M-108 17224591 SOUTHEAST GANTRY AND QCI/DROP TANK PIPING PLAN

M-109 17224592 FUEL FARM #7 PIPING PLAN

M-201 17224593 PUMP VAULT PIPING SECTIONS

M-202 17224594 PUMP VAULT PIPING ELEVATIONS

M-203 17224595 FILTER BUILDING PIPING ELEVATIONS 1

M-204 17224596 FILTER BUILDING PIPING ELEVATIONS 2

M-205 17224597 QCI/DROP TANK SECTION

M-206 17224598 QCI/DROP TANK ELEVATIONS 1

M-207 17224599 QCI/DROP TANK ELEVATIONS 2

M-208 17224600 TRUCK FILLSTAND PIPING ELEVATIONS

M-209 17224601 TRUCK LANE 1 OFFLOAD PIPING ELEVATIONS

M-210 17224602 TRUCK LANE 2 OFFLOAD PIPING ELEVATIONS

M-211 17224603 PRODUCT RECOVERY TANK SECTION

M-212 17224604 WASTE TANK SECTION

M-213 17224605 FUEL FARM #7 PIPING ELEVATIONS 1

M-214 17224606 FUEL FARM #7 PIPING ELEVATIONS 2

M-215 17224607 FUEL FARM #7 PIPING ELEVATIONS 3

DOCUMENT 00 01 15 Page 5

M-501 17224608 MECHANICAL DETAILS 1

M-502 17224609 MECHANICAL DETAILS 2

M-503 17224610 MECHANICAL DETAILS 3

M-504 17224611 MECHANICAL DETAILS 4

M-505 17224612 MECHANICAL DETAILS 5

M-506 17224613 MECHANICAL DETAILS 6

M-507 17224614 MECHANICAL DETAILS 7

M-508 17224615 MECHANICAL DETAILS 8

M-509 17224616 MECHANICAL DETAILS 9

M-510 17224617 MECHANICAL DETAILS 10

M-601 17224618 MECHANICAL POL EQUIPMENT SCHEDULE 1

M-602 17224619 MECHANICAL POL EQUIPMENT SCHEDULE 2

M-603 17224620 MECHANICAL POL EQUIPMENT SCHEDULE 3

EK101 17224621 OVERALL CATHODIC PROTECTION PLAN

EK102 17224622 FILTER BUILDING/ GANTRY CATHODIC PROTECTION PLAN

EK501 17224623 CATHODIC PROTECTION DETAILS 1

EK502 17224624 CATHODIC PROTECTION DETAILS 2

E-001 17224625 ABBREVIATIONS AND NOTES

E-002 17224626 ELECTRICAL LEGENDS

E-003 0001 17224627 TEMPORARY LDBO FACILITY PLAN

E-101 17224628 FUEL FARM #8 SITE PLAN

E-102 17224629 LDBO FACILITY SITE PLAN

E-103 17224630 FUEL FARM #7 SITE PLAN

E-104 17224631 INCOMING COMMUNICATIONS SITE PLAN

E-411 17224632 POL OPERATIONS BUILDING LIGHTING PLAN

E-412 17224633 POL OPERATIONS BUILDING POWER PLAN

E-413 17224634 POL OPERATIONS BUILDING GROUNDING PLAN

DOCUMENT 00 01 15 Page 6

E-414 17224635 POL OPERATIONS BUILDING LIGHTNING PROTECTION PLAN

E-421 17224636 FILTER BUILDING LIGHTING PLAN

E-422 0001 17224637 FILTER BUILDING POWER AND CONTROLS PLAN

E-423 17224638 FILTER BUILDING GROUNDING PLAN

E-424 17224639 FILTER BUILDING LIGHTNING PROTECTION PLAN

E-431 17224640 PUMP VAULT LIGHTING AND GROUNDING PLANS

E-432 0001 17224641 PUMP VAULT POWER AND CONTROL PLANS

E-433 17224642 BULK TANK ACCESS TUNNEL

E-441 17224643 LDBO LIGHTING PLAN

E-442 17224644 LDBO POWER PLAN

E-443 17224645 LDBO GROUNDING AND LIGHTNING PROTECTION PLAN

E-451 0001 17224646 GANTRY LIGHTING PLAN

E-452 0001 17224647 GANTRY POWER PLAN

E-453 17224648 GANTRY GROUNDING PLAN

E-454 17224649 GANTRY CONTROLS PLAN

E-461 17224650 SUBSTATION G PLANS

E-471 0001 17224651 FUEL FARM #7 PARTIAL PLANS

E-481 0001 17224652 WASTE TANK AND GENERATOR PARTIAL PLANS

E-501 17224653 DETAILS 1

E-502 17224654 DETAILS 2

E-503 17224655 DETAILS 3

E-504 17224656 DETAILS 4

E-601 0001 17224657 ONE-LINE DIAGRAMS 1

E-602 0001 17224658 ONE-LINE DIAGRAMS 2

E-603 0001 17224659 ONE-LINE DIAGRAMS 3

E-604 0001 17224660 ONE-LINE DIAGRAMS 4

E-605 0001 17224661 ONE-LINE DIAGRAMS 5

DOCUMENT 00 01 15 Page 7

E-611 0001 17224662 WIRING DIAGRAMS 1

E-612 17224663 WIRING DIAGRAMS 2

E-613 0001 17224664 WIRING DIAGRAMS 3

E-614 17224665 WIRING DIAGRAMS 4

E-615 0001 17224666 WIRING DIAGRAMS 5

E-616 17224667 WIRING DIAGRAMS 6

E-621 0001 17224668 SCHEDULES 1

E-622 0001 17224669 SCHEDULES 2

E-623 0001 17224670 SCHEDULES 3

E-624 0001 17224671 SCHEDULES 4

E-631 17224672 PUMP CONTROL PANEL ELEVATION

E-632 17224673 ANNUNCIATOR PANEL LAYOUT

E-633 0001 17224674 TERMINAL BLOCK CONNECTIONS 1

E-634 0001 17224675 TERMINAL BLOCK CONNECTIONS 2

E-635 0001 17224676 TERMINAL BLOCK CONNECTIONS 3

E-636 0001 17224677 TERMINAL BLOCK CONNECTIONS 4

E-701 17224678 PLATES 1

E-702 17224679 PLATES 2

E-703 17224680 PLATES 3

E-704 0001 17224681 HAZARDOUS AREA CLASSIFICATIONS 1

E-705 0001 17224682 HAZARDOUS AREA CLASSIFICATIONS 2

E-706 0001 17224683 HAZARDOUS AREA CLASSIFICAITONS 3

A-001 17224684 LEGEND, ABBREVIATIONS, AND NOTES

A-111 17224685 POL OPERATIONS BUILDING FLOOR PLAN

A-112 17224686 POL OPERATIONS BUILDING ROOF PLAN

A-113 17224687 POL OPERATIONS BUILDING REFLECTED CEILING PLAN

A-121 17224688 FILTER BUILDING FLOOR PLAN

DOCUMENT 00 01 15 Page 8

A-122 17224689 FILTER BUILDING ROOF PLAN

A-123 17224690 FILTER BUILDING REFLECTED CEILING PLAN

A-131 17224691 PUMP VAULT FLOOR PLANS

A-132 17224692 PUMP VAULT ROOF PLANS

A-141 17224693 LDBO FACILITY FL0OR PLAN

A-142 17224694 LDBO FACILITY ROOF PLAN

A-151 17224695 GANTRY FLOOR PLAN

A-152 17224696 GANTRY ROOF PLAN

A-161 17224697 SUBSTATION FLOOR AND ROOF PLAN

A-211 17224698 POL OPERATIONS BUILDING ELEVATIONS

A-221 17224699 FILTER BUILDING ELEVATIONS

A-231 17224700 PUMP VAULT ELEVATIONS

A-241 17224701 LDBO FACILITY ELEVATIONS

A-251 17224702 GANTRY ELEVATIONS

A-261 17224703 SUBSTATION ELEVATIONS

A-311 17224704 POL OPERATIONS BUILDING SECTIONS

A-312 17224705 POL OPERATIONS BUILDING SECTIONS AND DETAILS

A-321 17224706 FILTER BUILDING SECTIONS

A-322 17224707 FILTER BUILDING SECTIONS AND DETAILS

A-331 17224708 PUMP VAULT SECTIONS

A-332 17224709 PUMP VAULT SECTIONS AND DETAILS

A-341 17224710 LDBO FACILITY SECTIONS

A-342 17224711 LDBO FACILITY SECTIONS

A-351 17224712 GANTRY SECTION

A-361 17224713 SUBSTATION SECTION

A-411 17224714 POL OPERATIONS BUILDING ENLARGED PLANS

A-412 17224715 POL OPERATIONS BUILDING INTERIOR ELEVATIONS

DOCUMENT 00 01 15 Page 9

A-413 17224716 LDBO FACILITY INTERIOR ELEVATIONS

A-501 17224717 POL OPERATIONS BUILDING CASEWORK DETAILS

A-502 17224718 DOOR AND WINDOW DETAILS

A-503 17224719 WALL TYPES AND DETAILS

A-601 17224720 DOOR SCHEDULE AND TYPES

A-602 0001 17224721 WINDOW TYPES AND BUILDING SCHEDULES

S-001 17224722 LEGEND, ABBREVIATIONS, AND NOTES

S-002 17224723 GENERAL STRUCTURAL NOTES

S-101 17224724 TANK 1 PLAN

S-102 17224725 TANK 2 PLAN

S-103 17224726 TANK COLUMN LAYOUT

S-104 17224727 TANK 1 ROOF PLAN

S-111 0001 17224728 POL OPERATIONS BUILDING FOUNDATION AND SLAB PLAN

S-112 17224729 POL OPERATIONS BUILDING ROOF PLAN

S-121 17224730 FILTER BUILDING FOUNDATION AND SLAB PLAN

S-122 17224731 FILTER BUILDING PIPE SUPPORT PLAN

S-123 17224732 FILTER BUILDING ROOF PLAN AND DETAILS

S-124 17224733 FILTER BUILDING TRUSS PLAN AND DETAILS

S-131 17224734 PUMP VAULT FOUNDATION PLANS

S-132 17224735 PUMP VAULT ROOF PLANS AND DETAILS

S-141 17224736 LDBO FACILITY FOUNDATION AND SLAB PLAN

S-142 17224737 LDBO FACILITY ROOF PLAN

S-151 17224738 GANTRY FOUNDATION PLAN

S-152 17224739 GANTRY ROOF PLAN

S-153 17224740 DROP TANKS CANOPY FOUNDATION AND ROOF PLANS

S-161 17224741 SUBSTATION FOUNDATION AND SLAB, AND ROOF PLANS

S-211 17224742 POL OPERATIONS BUILDING ELEVATIONS 1

DOCUMENT 00 01 15 Page 10

S-212 17224743 POL OPERATIONS BUILDING ELEVATIONS 2

S-221 17224744 FILTER BUILDING ELEVATIONS

S-231 17224745 PUMP VAULT ELEVATIONS

S-241 17224746 LDBO FACILITY ELEVATIONS

S-242 17224747 LDBO MASONRY BUILDING ELEVATIONS

S-251 17224748 GANTRY ELEVATION AND DETAILS

S-261 17224749 SUBSTATION ELEVATIONS

S-301 17224750 TANK SECTIONS 1 AND 2

S-302 17224751 TANK 1 AND 2 STAIR SECTION

S-303 17224752 FILTER BUILDING OUTDOOR STAIR

S-304 17224753 TUNNEL SECTIONS

S-311 17224754 POL OPERATIONS BUILDING SECTIONS

S-321 17224755 FILTER BUILDING SECTIONS

S-322 17224756 FILTER BUILDING PIPE SUPPORT DETAILS 1

S-323 17224757 FILTER BUILDING PIPE SUPPORT DETAILS 2

S-324 17224758 FILTER BUILDING PIPE SUPPORT DETAILS 3

S-341 17224759 LDBO FACILITY SECTIONS

S-351 17224760 GANTRY SECTION

S-352 17224761 DROP TANKS CANOPY SECTION

S-401 17224762 TANK 1 FLOOR SLAB REINFORCING PLAN

S-402 17224763 TANK 1 RADIAL GUTTER FLOOR PLAN

S-403 17224764 TANK 1 ROOF SLAB REINFORCING PLAN

S-501 17224765 TANK DETAILS 1

S-502 0001 17224766 TANK DETAILS 2

S-503 17224767 TANK DETAILS 3

S-504 17224768 TANK DETAILS 4

S-505 17224769 ROLLING PIT COVER DETAILS 1

DOCUMENT 00 01 15 Page 11

S-506 17224770 ROLLING PIT COVER DETAILS 2

S-507 17224771 ROLLING PIT COVER DETAILS 3

S-508 17224772 TUNNEL DETAILS 1

S-509 17224773 TUNNEL DETAILS 2

S-511 17224774 POL OPERATIONS BUILDING DETAILS

S-512 0001 17224775 POL OPERATIONS BUILDING DETAILS 2

S-531 17224776 PUMP VAULT DETAILS

S-541 17224777 LDBO FACILITY DETAILS

S-542 17224778 LDBO MASONRY BUILDING DETAILS

S-551 17224779 GANTRY DETAILS

S-552 17224780 DROP TANKS CANOPY DETAILS

S-561 17224781 SUBSTATION DETAILS 1

S-562 17224782 SUBSTATION DETAILS 2

S-571 17224783 REMOTE CONTAINMENT BASIN AND GENERATOR PAD DETAILS

S-572 17224784 MECHANICAL STRUCTURE DETAILS

MH001 17224785 LEGEND, ABBREVIATIONS, AND NOTES

MH411 17224786 POL OPERATIONS BUILDING DUCT PLAN

MH412 17224787 POL OPERATIONS BUILDING PIPING PLAN

MH421 17224788 FILTER BUILDING DUCT AND PIPING PLAN

MH431 17224789 PUMP VAULT FLOOR PLAN

MH441 17224790 LDBO BUILDING FLOOR PLAN

MH451 17224791 SUBSTATION G FLOOR PLAN

MH461 17224792 TUNNEL SECTIONS

MH501 17224793 DETAILS

P-001 17224794 LEGEND, ABBREVIATIONS, AND NOTES

P-411 17224795 POL OPERATIONS BUILDING DRAIN, WASTE AND VENT PLAN

P-412 17224796 POL OPERATIONS BUILDING DOMESTIC WATER PLAN

DOCUMENT 00 01 15 Page 12

P-421 17224797 FILTER BUILDING DOMESTIC WATER PLAN

P-441 17224798 LDBO BUILDING DRAIN, WASTE AND VENT PLAN

P-442 17224799 LDBO DOMESTIC WATER PLAN

P-501 17224800 PLUMBING DETAILS

P-611 17224801 SCHEDULES

F-001 17224802 FIRE PROTECTION SYMBOLS AND ABBREVIATIONS

F-002 17224803 FUEL FARM #7 FIRE PUMP HOUSE - ZONE BLOCK PLAN

F-003 17224804 FILTER BUILDING - FIRE ZONE BLOCK PLAN

F-004 17224805 POL OPERATIONS BUILDING - FIRE ZONE BLOCK PLAN

F-005 17224806 LDBO FACILITY - FIRE ZONE BLOCK PLAN

F-006 17224807 FIRE ALARM SYSTEM FIBER OPTIC/COPPER CABLE AND CONDUIT

SITE PLAN

F-007 17224808 TEMPORARY LDBO FACILITY FIRE ALARM PLAN

F-101 17224809 POL OPERATIONS BUILDING AND LABORATORY - LIFE SAFETY

PLAN

F-102 17224810 FILTER BUILDING - LIFE SAFETY PLAN

F-103 17224811 PUMP VAULT TANK 1 AND 2 - LIFE SAFETY PLAN

F-104 17224812 GANTRY - LIFE SAFETY PLAN

F-105 17224813 LDBO FACILITY - LIFE SAFETY PLAN

F-106 17224814 POL OPERATIONS BUILDING AND LABORATORY - FIRE

PROTECTION PLAN

F-107 17224815 FILTER BUILDING - FIRE PROTECTION PLAN

F-108 17224816 PUMP VAULT TANK 1 AND 2 - FIRE PROTECTION PLAN

F-109 17224817 GANTRY - FIRE PROTECTION PLAN

F-110 17224818 LDBO FACILITY - FIRE PROTECTION PLAN

F-111 17224819 BUILDING 907 FIRE PUMP HOUSE - PIPING PLAN /RISER

DIAGRAM

F-112 17224820 ELECTRICAL SUBSTATION - LIFE SAFETY PLAN

F-113 17224821 ELECTRICAL SUBSTATION - FIRE PROTECTION PLAN

DOCUMENT 00 01 15 Page 13

F-501 17224822 FIRE PROTECTION DETAILS

-- End of Document --

DOCUMENT 00 01 15 Page 14

PAF 160600 BULK FUEL STORAGE TANKS

AMENDMENT 0001 1581218

Section 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 GENERAL REQUIREMENTS

The Contractor acknowledges and agrees that:

a. the Contractor is a party to the contract with the Naval Facilities

Engineering Command, Pacific (NAVFAC Pacific) to carry out the Contractor's Activities and Works on the Royal Australian Air Force base;

b. the Contracting Officer is an employee of the Naval Facilities

Engineering Command, Marianas who NAVFAC Pacific has assigned administration and enforcement authority and responsibility for this contract;

c. Australian Requirements are laws, codes, decrees, labor standards, and regulations of the host country, Commonwealth, State and Territory, currently in effect, that the Contractor is required to comply with, including but not limited to the Australian Requirements Schedule attached at the end of this section;

d. the Contractor is responsible for ensuring it complies with all requirements of the contract, including the Division 01 (General Requirements), Australian Requirements, and any other laws, codes, decrees, labor standards, and/or regulations of the host country, Commonwealth, State and Territory in accordance with Contract Clause Contractor Licensing Requirements for Work Outside the United States;

Federal Acquisition Regulation (FAR) 52.236-7, Permits and Responsibilities, Defense Federal Acquisition Regulation Supplement (DFARS) 252.225-7042, Authorization to Perform; and DFARS 252.222-7002, Compliance with Local Labor Laws (Overseas) of the Request For Proposal, Document 00700;

e. if the Contractor identifies any ambiguity, discrepancy or inconsistency between the requirements of the contract, including the requirements of Division 01, Australian Requirements, and any other laws, codes, decrees, labor standards, and/or regulations of the host country, Commonwealth, State and Territory, the Contractor shall immediately submit a Request for Information (RFI) to the Contracting Officer clearly describing the ambiguity, discrepancy and/or inconsistency and offer a proposed solution;

f. Immediately notify the Contracting Officer if the Commonwealth or any person authorised by the Commonwealth impedes, disrupts, or frustrates the Contractor's performance of the Contract, or otherwise causes potential Contractor delay; and

g. when an Australian standard or requirement is offered as an equivalent to a U.S. standard or requirement, the Contractor shall furnish documentation proving equivalency.

Section 01 11 00 Page 2

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes two nominal 8 million liter cut-and-cover bulk fuel storage tanks with pump vaults, truck unloading and loading gantry, filter equipment and building, operations facility with laboratory, modifications Fuel Farm #7, fuel system controls, pipelines, demolition, site preparation, pavements, grading and drainage improvements, supporting utility infrastructure, and incidental work. The work also includes a new Liquid Dry Breathing Oxygen (LDBO) Facility and demolition of the existing LDBO Facility.

In addition to the requirements specified in the Contract Documents, all work shall also be conducted in accordance with the applicable Australian legislation, Australian codes of practice, applicable AS/NZS standards, Australian Defence policies, and relevant Australian Defence authorization.

All work on any bulk fuel installation shall also be conducted in accordance with the Bulk Fuel Installation manifest and the Australian Defence Fuel Installation Maintenance Instruction (DFIMI).

1.2.2 Location

The work is located at the Royal Australian Air Force (RAAF) Base Darwin, Northern Territory, Australia, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.5 LOCATION OF UNDERGROUND UTILITIES

Obtain permit to work for excavation prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities. Contact the Contracting Officer to coordinate with the RAAF Base Darwin Estate and Infrastructure Group (E&IG) Base Support Services for utility information prior to excavating, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

Section 01 11 00 Page 3

Identify and mark all other utilities. Scan the construction site with Ground Penetrating Radar (GPR), electromagnetic, or sonic equipment, and mark the surface of the ground or paved surface where existing underground utilities are discovered. Verify the elevations of existing piping, utilities, and any type of underground or encased obstruction not indicated, or specified to be removed, that is indicated or discovered during scanning, in locations to be traversed by piping, ducts, and other work to be conducted or installed. Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.5.1 Notification Prior to Excavation

Notify the Contracting Officer at least 15 days prior to starting excavation work.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

Version 1.2

Amendment No. 0001 dated June 20, 2019

Australian Requirements Schedule

1. Definitions For the purposes of this Australian Requirements Schedule:

(a) ACM means asbestos containing material.

(b) Approvals means any licence, permit, consent, approval, determination, certificate, notice or other requirement any authority, body or organisation having any jurisdiction in connection with the Site, the Contractor's Activities or the Works or under any applicable Statutory Requirement, which must be obtained or satisfied to:

(i) carry out the Contractor's Activities or the Works; or

(ii) occupy, use, maintain or operate the completed Works.

(c) Classified Information includes:

(i) any Commonwealth document marked with a national security classification; and

(ii) any information that the Contractor knows or ought to know is subject to, or ought to be treated in accordance with, the provisions of the Defence Security Manual.

(d) Code of Federal Regulations (CFR) means the codification of the general and permanent rules and regulations (administrative law) published in the Federal Register by the executive departments and agencies of the federal government of the United States.

(e) Code of Practice means a code of practice approved in accordance with the WHS Legislation.

(f) Commonwealth means the Commonwealth of Australia.

(g) Contamination means the presence in, on or under land, air or water of a substance (whether a solid, liquid, gas, odour, heat, sound, vibration or radiation) at a concentration above the concentration at which the substance is normally present in, on or under land, air or water in the same locality, that presents a risk of Environmental Harm, including harm to human health or any other aspect of the Environment, or could otherwise give rise to a risk of non-compliance with any Statutory Requirement for the protection of the Environment.

(h) Contractor's Activities means all things or tasks which the Contractor is, or may be, required to do to comply with its obligations under the Contract.

(i) Dangerous Goods has the meaning given in the Australian Code for the Transport of Dangerous Goods by Road and Rail, 7th edition.

(j) Defence means the Commonwealth Department of Defence.

(k) Defence Environmental Requirements means the Defence Environmental Management System and Defence Environmental Plan applicable to the Site, the Contractor's Activities or the Works, including any procedures, instructions, requirements and standing orders which have been developed or issued under the Defence Environmental Management System or Defence Environmental Plan.

Amendment No. 0001 dated June 20, 2019

(l) Defence Environmental Management System means the environmental management system applicable to the Site (if any).

(m) Defence Environmental Plan means the environmental plan applicable to the Site (if any).

(n) Defence Requirements means include all policies, plans, manuals, guidelines, instructions (including departmental procurement policy instructions) and other Commonwealth or Defence requirements which are, or may become, applicable to the Site, the Contractor's Activities or the Works. To the extent that any of the requirements would require or suggest the insertion of provisions into the Contract, then those provisions will be incorporated by reference into the Contract.

(o) Defence Security Manual is a reference to that document as amended from time to time.

(p) Defense Federal Acquisition Regulation Supplement means the Department of Defense supplement to the Federal Acquisition Regulation (FAR) that contains requirements of U.S. law, DoD-wide policies, delegations of FAR authorities, deviations from FAR requirements, and DoD policies/procedures.

(q) DEQMS means the Defence Estate Quality Management System website available at www.defence.gov.au/estatemanagement.

(r) Effective Date means the date shown in Block 31C. AWARD DATE of the Standard Form (SF) 1442, SOLICITATION, OFFER, AND AWARD.

(s) EM 385-1-1 means the latest version of the U.S. Army Corps of Engineers manual in effect on the date the solicitation was issued (refer to Block 3. DATE ISSUED on the SF1442) and prescribing the safety and health requirements for construction contract work.

(t) Environment includes:

(i) ecosystems and their constituent parts, including people and communities;

(ii) natural and physical resources;

(iii) the qualities and characteristics of locations, places and areas; and

(iv) the social, economic, aesthetic and cultural aspects of a thing mentioned in paragraphs (i), (ii) or (iii).

(u) Environmental Clearance Certificate means the Environmental Clearance Certificate issued by the Commonwealth relating to the Contractor's Activities or the Works and any conditions incorporated in that certificate.

(v) Environmental Harm means any actual or threatened adverse impact on, or damage to, the Environment.

(w) Environmental Incident means any Environmental Harm or Contamination arising out of or in connection with the Contractor's Activities or the Works.

(x) Environmental Requirements includes the:

(i) Environmental Clearance Certificate; and

(ii) Defence Environmental Requirements.

Amendment No. 0001 dated June 20, 2019

(y) Federal Acquisition Regulation means the primary document of the United States Government Federal Acquisition Regulations System for the codification and publication of uniform policies and procedures for acquisition.

(z) GHS means the Globally Harmonised System of Classification and Labelling of Chemicals published by the United Nations, Third Revised Edition, as modified by the relevant WHS Legislation.

(aa) GHS Material means material suspected of containing or likely to contain a substance defined or listed in the GHS.

(bb) Government means the United States Government.

(cc) GST the tax payable on taxable supplies under the GST Legislation.

(dd) GST Legislation means A New Tax System (Goods and Services Tax) Act 1999 (Cth) and any related Act imposing such tax or legislation that is enacted to validate, recapture or recoup such tax.

(ee) Hazardous Chemical has the meaning given in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth) and includes:

(i) prohibited carcinogen, as defined in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth);

(ii) restricted carcinogen, as defined in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth);

(iii) hazardous chemicals the use of which is restricted under regulation 382 of the Work Health and Safety Regulations 2011 (Cth), including polychlorinated biphenyls;

(iv) Schedule 11 Hazardous Chemicals;

(v) hazardous chemicals listed in Table 14.1 of Schedule 14 of the Work Health and Safety Regulations 2011(Cth);

(vi) Schedule 15 Chemicals; and

(vii) lead as defined in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth).

(ff) Hazardous Substances means Ozone Depleting Substances, Synthetic Greenhouse Gases, Hazardous Chemicals or Dangerous Goods.

(gg) NATA means National Association of Testing Authorities Australia.

(hh) MFPE means the Defence Manual of Fire Protection Engineering, as that document is amended from time to time.

(ii) National Construction Code means the National Construction Code that applies in the Northern Territory, as amended from time to time, produced and maintained by the Australian Building Codes Board on behalf of the Commonwealth Government and each Australian State and Territory Government.

(jj) Ozone Depleting Substance means any substance identified as having ozone depleting potential in the Ozone Protection and Synthetic Greenhouse Gas Management Act 1989 (Cth) or any regulations made under that Act.

Amendment No. 0001 dated June 20, 2019

(kk) Other Contractor means any other contractor, consultant, artist, tradesperson or other person engaged to do work at or in the vicinity of the Site other than the Contractor and its subcontractors.

(ll) PFAS means per- and poly-fluoroalkyl substances.

(mm) Plant, Equipment and Work means those things used, or work undertaken, by the Contractor to construct the Works but which will not form part of the Works.

(nn) Project Documents includes:

(i) Design documentation (shop drawings), Project Plans;

(ii) Approvals;

(iii) any other data, documents, drawings, records, information, and material produced or provided (or required to be provided) to the Contracting Officer, under or in connection with the Contract, the Contractor's Activities or the Works by, for or on behalf of the Contractor (including by subcontractors); and

(iv) all material at any time derived (under or in connection with the Contract, the Contractor's Activities or the Works) from, or based on, the material described in subparagraphs (i) and (iii).

(oo) Project Plans (also referred to in the Contract as Outline Project Plans) means Commissioning and Handover Plan, Environmental Management Plan, Site Management Plan and Work Health and Safety Management Plan.

(pp) Request for Information is a written request for information submitted by the Contractor to the Contracting Officer. NAVFAC form is available from the Contracting Officer.

(qq) Schedule 11 Hazardous Chemical has the meaning given in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth).

(rr) Schedule 15 Chemical has the meaning given in subregulation 5(1) of the Work Health and Safety Regulations 2011 (Cth).

(ss) Site means the site or sites for the Works as set out in the Contract.

(tt) Smart Infrastructure Manual means the Defence Smart Infrastructure Manual Design and Construction available on DEQMS, as amended from time to time.

(uu) Statutory Requirements means:

(i) any law applicable to the Contractor's Activities or the Works (including Acts, ordinances, regulations, by-laws and other subordinate legislation) including those of the Commonwealth and the Northern Territory;

(ii) Approvals (including any condition or requirement under an Approval);

(iii) Defence Requirements; and

(iv) Environment Requirements.

(vv) Synthetic Greenhouse Gas means any gas identified as a Synthetic Greenhouse Gas in the Ozone Protection and Synthetic Greenhouse Gas Management Act 1989 (Cth) or in any regulations made under that Act.

Amendment No. 0001 dated June 20, 2019

(ww) WHS Legislation means:

(i) Work Health and Safety (National Uniform Legislation) Act 2011 (NT) and Work Health and Safety (National Uniform Legislation) Regulations

2011 (NT);

(ii) Work Health and Safety Act 2011 (Cth) and Work Health and Safety Regulations 2011 (Cth); and

(iii) any other legislation and Codes of Practice in the Northern Territory addressing work health and safety.

(xx) Work Health and Safety Plan is

(i) included as part of the Accident Prevention Plan submitted in accordance with Section 01 35 26 Government Safety Requirements and refers to Australian safety requirements in addition to those in the Contract; and

(ii) prepared by the Contractor and finalised under paragraph 5.2 of this Australian Requirements Schedule which must set out in adequate detail the procedures the Contractor will implement to manage the Contractor's Activities and the Works from a work health and safety perspective to ensure compliance with all Statutory Requirements (including the WHS Legislation).

(yy) Works means the physical work, which the Contractor must (to the extent required by the Contract), design, construct, commission, complete and hand over in accordance with the Contract.

2. Statutory Requirements Pursuant to Document 00700, Contract Clauses, Division 01 Specification Section 01 11 00 Paragraph 1.1, FAR 52.236-7, and DFARS 252.225-7042, the Contractor must:

(a) comply with all applicable Statutory Requirements;

without limiting paragraph (a):

(i) apply for and obtain all Approvals;

(ii) give all notices and pay all fees and other amounts which it is required to pay in respect of the carrying out of its Contract obligations; and

(iii) promptly give the Contracting Officer copies of all documents (including Approvals and other notices) that any authority, body, or organisation having jurisdiction over the Site, the Contractor's Activities or the Works issues to the Contractor.

3. Environmental Requirements The Contractor must:

(a) ensure that in carrying out the Contractor's Activities:

(i) it complies with Statutory Requirements for the protection of the Environment;

(ii) it does not cause or contribute to any Environmental Incident;

Amendment No. 0001 dated June 20, 2019

(iii) without limiting subparagraph (ii), it does not cause or contribute to Contamination of the Site or any other land, air or water or cause or contribute to any Contamination emanating from the Site;

(iv) it immediately notifies the Contracting Officer of:

A. any non-compliance with the requirements of this paragraph 3;

B. any breach of a Statutory Requirement for the protection of the Environment;

C. any Environmental Incident; or

D. the receipt of any notice, order or communication received from an authority for the protection of the Environment; and

(v) its subcontractors comply with the requirements in this paragraph 3; and

(b) clean up and restore the Environment, including any Contamination or Environmental Harm, arising out of or in connection with, the Contractor's Activities or the Works, whether or not it has complied with all Statutory Requirements and other requirements of the Contract for the protection of the Environment.

4. Project Plans

4.1 Contents of Project Plans

Each Project Plan must set out in adequate detail the following:

(a) the procedure for preparing (including tailoring) and finalising the Project Plans under Paragraph 4.2;

(b) the procedure for regularly reviewing, updating and amending the Project Plan under Paragraph 4.2;

(c) the procedure for ensuring subcontractor compliance with the Project Plans;

(d) the procedure for regularly auditing or other monitoring of Contractor and subcontractor compliance with the Project Plan; and

4.2 Preparation of Project Plans

4.2.1 The Contractor:

(a) must carry out the Contractor's Activities in accordance with, and otherwise implement, the Project Plans; and

(b) for the purposes of paragraph (a), must:

(i) prepare Project Plans in accordance with the requirements of the Contract and this Australian Requirements Schedule and submit them to the Contracting Officer for review in accordance with the Contract;

(ii) submit Project Plan information included in or supplement to the relevant required submittals identified in the Contract Division 01 specifications including, but not limited to, 01 35 26 Accident Prevention Plan, 01 57 19 Environmental Protection Plan, 01 74 19 Waste Management Plan, 01 78 00 Warranty Management Plan;

Amendment No. 0001 dated June 20, 2019

(iii) not commence any of the Contractor's Activities to which any Project Plan applies until Contracting Officer Approval is obtained and all other preconstruction requirements per Contract are satisfied;

(iv) if any Project Plan is rejected, submit an amended Project Plan to the Contracting Officer whereupon subparagraphs (i) to (iv) will reapply;

(v) after each Project Plan has been approved:

A. regularly review, update and amend each Project Plan and otherwise at least on each anniversary of the Effective Date;

B. update or amend a Project Plan on request of the Contracting Officer; and

C. continue to correct any defects in or omissions from a Project Plan (whether identified by the Contracting Officer or the Contractor), and submit an updated or amended Project Plan to the Contracting Officer, after which:

D. the Contractor must continue to comply with the requirements of the then current Project Plan until the process in this paragraph (b) has been completed in respect of the updated or amended Project Plan; and

E. subparagraphs (i) to (iv) will apply (to the extent applicable);

and

(c) The Contractor will not be relieved from compliance with any of its obligations under this contract (including this Australian Requirements Schedule) or otherwise at law or in equity, as a result of:

(i) the implementation of, and compliance with, the requirements of any Project Plan;

(ii) any direction by the Contracting Officer to update, amend, modify or otherwise implement and comply with a Project Plan or the Contractor's compliance or non-compliance with a Project Plan; and

(iii) any failure by the Contracting Officer , to detect any defect in or omission from a Project Plan.

5. Safety Requirements

5.1 Work Health and Safety

(a) Without limiting the Contractor’s obligation under the Contract to comply with EM 385-1-1, Division 01 Specification Section 01 35 26 Governmental Safety Requirements, 29 CFR 1910 Occupational Safety and Health Standards, the Contractor shall:

(i) ensure that in carrying out the Contractor's Activities:

A. it complies with all Statutory Requirements and other requirements of the Contract in respect of work health and safety; and

Amendment No. 0001 dated June 20, 2019

B. it complies with its duty under the WHS Legislation to consult, cooperate and coordinate activities with all other persons who have a work health and safety duty in relation to the same matter;

(ii) Where more stringent safety and occupational health standards are set forth in these Australian requirements and regulations and it satisfies the U.S. safety requirements, the Australian standards shall apply.

(b) without limiting the Contractor's obligations under the Contract or otherwise at law or in equity, notify the Contracting Officer:

(i) in respect of notifiable incidents within the meaning of the WHS Legislation, immediately (and in any event within 12 hours of such notifiable incident occurring);

(ii) in respect of work health and safety incidents or accidents (which are not notifiable incidents) where the nature of the incident or accident indicates a potential systemic failure to identify hazards and manage risks to health and safety, so far as is reasonably practicable, within 24 hours of the incident or accident occurring; and

(iii) in respect of all other work health and safety matters arising out of or in connection with the Contractor's Activities and the Works, including the occurrence of any other incident or accident (not required to be reported in accordance with subparagraphs (i) or (ii)), by a monthly report;

(c) for the purposes of paragraph (b), in respect of any notifiable incident:

(i) immediately provide the Contracting Officer and Commonwealth with a copy of the notice required to be provided to the relevant Commonwealth or Northern Territory regulator;

(ii) promptly provide the Contracting Officer and Commonwealth with a copy of all witness statements and the investigation report relating to the notifiable incident;

(iii) promptly provide the Contracting Officer and Commonwealth with copies of any notice(s) or other documentation issued by the relevant Commonwealth or Northern Territory regulator; and

(iv) within 10 days of the date of notification to the relevant Commonwealth or Northern Territory regulator, provide the Contracting Officer with a summary of the related investigations, actions to be taken and any impact on the Contract that may result from the notifiable incident;

(d) institute systems to:

(i) obtain regular written assurances from each Other Contractor and subcontractor about their ongoing compliance with the WHS Legislation;

and

(ii) provide, in a format approved by the Contracting Officer, the written assurances regarding the Contractor's ongoing compliance with the WHS Legislation:

A. on a monthly basis; and

B. as otherwise directed by the Contracting Officer;

Amendment No. 0001 dated June 20, 2019

(e) provide the written assurances obtained under paragraph (d) to the Contracting Officer in accordance with paragraph (d);

(f) without limiting the Contractor's obligations under the Contract or otherwise at law or in equity, within 10 days of receipt provide to the Contracting Officer copies of:

(i) all formal notices and written communications issued by a regulator or agent of the regulator under or in compliance with the applicable WHS Legislation to the Contractor or subcontractor relating to work health and safety matters;

(ii) all formal notices issued by a health and safety representative of the Contractor or subcontractor under or in compliance with the applicable WHS Legislation; and

(iii) all formal notices, written communications and written undertakings given by the Contractor or subcontractor to the regulator or agent of the regulator under or in compliance with the applicable WHS Legislation, arising out of or in connection with the Contractor's Activities or the Works;

(g) exercise a duty of the utmost good faith in carrying out the Contractor's Activities and discharging its duties under the WHS Legislation;

(h) ensure all subcontracts include provisions equivalent to the obligations of the Contractor in this paragraph 5.1;

(i) ensure that, if the Statutory Requirement requires that:

(i) a person:

A. be authorised or licensed (in accordance with the WHS Legislation) to carry out any work at that workplace, that person is so authorised or licensed, and complies with any conditions of such authorisation or licence; and

B. has prescribed qualifications or experience, or if not, is to be supervised by a person who has prescribed qualifications or experience (as defined in the WHS Legislation), that person has the required qualifications or experience or is so supervised; or

(ii) a workplace, plant or substance (or design), or work (or class of work) be authorised or licensed, that workplace, plant or substance, or work is so authorised or licensed;

(iii) However, refer to The Force Posture Agreement Between the Government of the United States of America and the Government of Australia, Article XI, paragraph 3.

(j) not direct or allow a person to carry out work, or use plant or a substance at a workplace unless, the authorisation, licensing, prescribed qualifications or experience required by any Statutory Requirement and paragraph (i) are met;

(k) without limiting the Contractor's obligations under the Contract (including paragraph

(c) in respect of notifiable incidents) or otherwise at law or in equity, within 10 days of a request by the Contracting Officer, provide all information or copies of documentation held by the Contractor or a subcontractor to enable NAVFAC to comply with its obligations under the WHS Legislation;

Amendment No. 0001 dated June 20, 2019

(l) if requested by the Contracting Officer or required by the WHS Legislation, produce evidence of any Approvals including any authorisations, licences, registrations, prescribed qualifications or experience, or any other information relevant to work health and safety to the satisfaction of the Contracting Officer before the Contractor or any subcontractor commences such work;

(m) where the Contractor is a supplier, manufacturer, designer or importer for the purposes of the WHS Legislation, provide to the Contracting Officer as a condition precedent to completion of the Works and before the expiry of any defects liability period (however described) specified in the Contract information concerning:

(i) the purpose for which any plant, structure or substance (as defined in the WHS Legislation) has been designed or manufactured;

(ii) the results of any calculations, analysis, testing or examination carried out concerning the safety of the plant, substances or structures referred to in subparagraph (i) (and the risks to the health and safety of persons);

and

(iii) any conditions necessary to ensure the plant, substances or structures are without risks to health and safety when used for the purpose for which they were designed or manufactured;

(n) if the Contractor is responsible for any design, ensure its design documentation eliminates or minimises the need for any hazardous manual tasks to be carried out in connection with a plant or structure;

(o) not use asbestos or ACM in carrying out the Contractor's Activities;

(p) not use, install or incorporate asbestos or ACM into the Works;

(q) provide a certificate to the Contracting Officer in a form satisfactory to the Contracting Officer as a condition precedent to completion of the Works which states that:

(i) all materials, goods, products, equipment and plant (including any imported materials, goods, products, equipment and plant) used, installed or incorporated into the Works are entirely (meaning 100%) free of asbestos and ACM; and

(ii) the Contractor has otherwise complied with all Statutory Requirements in relation to asbestos and ACM in carrying out the Contractor's Activities and the Works;

(r) without limiting paragraph (q), if any imported materials, goods, products, equipment and plant have or has been used, installed or incorporated into the Works, the Contractor must provide to the Contracting Officer as a condition precedent to completion of the Works:

(i) sample test reports; and

(ii) test report information, in the form of an analysis certificate from a NATA accredited laboratory or an equivalent international laboratory (listed at the NATA website) accredited for the relevant test method,

(s) in relation to the imported materials, goods, products, equipment or plant which have or has been used, installed or incorporated into the Works; and

(t) if the Contractor is a designer of a structure or part of a structure for the purposes of the WHS Legislation, the Contractor must provide to the Contracting Officer, with

Amendment No. 0001 dated June 20, 2019 each submission of design documentation under the Contract, a written report that specifies the hazard relating to the design of the structure (or part) which, as far as the Contractor is reasonably aware:

(i) create a risk to health or safety to those carrying out construction work on the structure (or part); and

(ii) are associated only with the particular design.

5.2 Work Health and Safety Plan

(a) Without limiting its obligations under the Contract, the Contractor must:

(i) prepare a Work Health and Safety Plan in accordance with the requirements in the Contract and submit it to the Contracting Officer so as to ensure there is no delay or disruption to the Contractor's Activities;

(ii) if the Work Health and Safety Plan is rejected by the Contracting Officer, submit an amended Work Health and Safety Plan to the Contracting Officer;

(iii) in any event, finalise the Work Health and Safety Plan in accordance with the requirements of the Contract to the satisfaction of the Contracting Officer;

(iv) carry out the Contractor's Activities in accordance with, and otherwise implement, the Work Health and Safety Plan; and

(v) after the Work Health and Safety Plan has been finalised:

A. regularly review, update and amend the Work Health and Safety Plan in accordance with the process set out in the Work Health and Safety Plan;

B. update or amend the Work Health and Safety Plan on request of the Contracting Officer; and

C. submit any updated or amended Work Health and Safety Plan prepared under subparagraphs B or C to the Contracting Officer and finalise the updated or amended Work Health and Safety Plan to the satisfaction of the Contracting Officer.

(b) The Work Health and Safety Plan must address, at a minimum:

(i) the names, positions and responsibilities of all persons at the workplace whose positions or roles involve specific health and safety responsibilities in connection with the Contractor's Activities and the Works;

(ii) the arrangements in place, or to be implemented, between any persons conducting a business or undertaking at the workplace where the Contractor's Activities and the Works are being undertaken;

(iii) the arrangements in place, or to be implemented, for managing any work health and safety incidents that occur at a workplace where the Contractor's Activities and the Works are carried out, including:

A. incident (including notifiable incident) reporting procedures;

Amendment No. 0001 dated June 20, 2019

B. preventative and corrective action procedures; and

C. record-keeping and reporting requirements, including reporting to the Contracting Officer with respect to incidents and accidents under paragraph 5.1 of this Australian Requirements Schedule;

(iv) any Site-specific health and safety rules, and the arrangements for ensuring that all persons at the workplace are informed of these rules;

(v) the arrangements for the collection and recording, and any assessment, monitoring and review of safe work method statements at the workplace;

(vi) procedures and arrangements for the management of work health and safety generally, including:

A. details of the Contractor's work health and safety policy;

B.…