P169_Amend2_Issued_NECO.pdf

18RXXXX

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

RFP N62742-18-R-1319, WON 1572255, FY19 MCON PROJECT P-169, WATER TRANSMISSION LINE, WAIAWA, JBPHH, OAHU

Amendment No. 0002 is continued on page 2.

1. CONTRACT ID CODE PAGE OF PAGES

1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N6274218R1319

X 9B. DATED (SEE ITEM 11)

15-Oct-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

CODE

NAVFAC PACIFIC

CONSTR CONTRACTS BRANCH (CODE ACQ33)

258 MAKALAPA DR STE 100

JBPHH HI 96860-3134

N62742 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL: TEL:

30 Nov 2018

N6274218R1319 Amendment No. 0002

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

PRICE PROPOSAL SCHEDULE

Remove Page 3 of 4 and Page 4 of 4 (Amendment No. 0001) of the Price Proposal Schedule and replace with the attached revised Page 3 of 4 and Page 4 of 4 (Amendment No. 0002).

DOCUMENT 00 01 15, LIST OF DRAWINGS

1.2 CONTRACT DRAWINGS

On NAVFAC Dwg No. 19074963 (E-511)

Bridge Abutment Detail C-1 Notes. Add the following:

“4. Core drill the bridge wing walls for each conduit and fill the annular space between the conduits and the cored holes with epoxy grout.”

DOCUMENT 00700 NEGOTIATED CONTRACT CLAUSES

Remove Page 10 of 12 and Page 11 of 12 of Document 00700 and replace with the attached revised Page 10 of 12 and Page 11 of 12 (Amendment No. 0002).

DOCUMENT 00800 SPECIAL CONTRACT REQUIREMENTS

Paragraph 1.1 NOTICE CONCERNING LABOR RATES – in the first paragraph, delete “State of Hawaii General Wage Decision No. HI180001, Modification No. 13, Publication Date 10/26/2018” and replace with “State of Hawaii General Wage Decision No. HI180001, Modification No. 15, Publication Date 11/30/2018,” which is attached.

SECTION 01 11 00, SUMMARY OF WORK

1.1.1 Project Description

In the fourth sentence, delete “and right of entry from each entity.”

SECTION 01 30 00, ADMINISTRATIVE REQUIREMENTS

1.8 Preconstruction Meeting

In the first sentence, delete “requirements of Construction Right of Entry Agreements for individual landowners.”

SECTION 02 82 16.00 20, ENGINEERING CONTROL OF ASBESTOS CONTAINING MATERIALS

Para. 1.3.1 Description of Work

N6274218R1319

At the end of this paragraph, add “A Letter Report Asbestos and Lead Paint Survey dated June 2018 is provided at the end of this section.”

SECTION 02 83 13.00 20, LEAD IN CONSTRUCTION

Para. 1.3.1 Description of Work

At the end of this paragraph, add “A Final Letter Report Lead Paint Sampling dated April 2016 is provided at the end of this section.”

SOLICITATION, OFFER AND AWARD (SF 1442), CONTINUED

FOR

RFP NO. N62742-18-R-1319

FY19 MCON PROJECT P-169 WATER TRANSMISSION LINE, WAIAWA,

JOINT BASE PEARL HARBOR HICKAM, HAWAII

RFP N62742-18-R-1319

SF 1442 (Continued)

ITEM

NO. DESCRIPTION

QTY

UNIT OF

ISSUE

UNIT

PRICE

AMOUNT

0001AA

BASE ITEM: The basis for SLIN 0001AA is the price for the entire work for WON 1572255 complete and in accordance with the drawings and specifications (including restrained joints for Waterline “A” from Sta 4+21 to Sta 105+00 (10,079 lf)) but not including work defined in SLINs 0001AB through 0001AG.

Lump Sum

0001AB

The basis for SLIN 0001AB is all labor, material and equipment to remove and dispose of contaminated soil.

Cubic Yard

$_________/cy

0001AC

The basis for SLIN 0001AC is all labor, material and equipment to backfill and compact where contaminated soil was removed.

Cubic Yard

$_________/cy

0001AD

The basis for SLIN 0001AD is the price for all work to furnish, deliver, and install precast/prestressed concrete piles, complete in accordance with the drawings and specifications. See Section 31 62 13.20

PRECAST/PRESTRESSED CONCRETE

PILES.

Linear Foot

$_________/lf

0001AE

The basis for SLIN 0001AE is the price for pile load tests, complete in accordance with the drawings and specifications. See Section 31 62 13.20

PRECAST/PRESTRESSED CONCRETE

PILES.

Each

$_________/ea

0001AF

The basis for SLIN 0001AF is the price for all work to furnish, deliver, and install micropiles, complete in accordance with the drawings and specifications. See Section 31

63 33 DRILLED MICROPILES.

Linear Foot

$_________/lf

0001AG

The basis for SLIN 0001AG is the price for micropile load tests, complete in accordance with the drawings and specifications. See Section 31 63 33 DRILLED MICROPILES.

Each

$_________/ea

Total CLIN 0001 (SLINs 0001AA through 0001AG)

SOLICITATION, OFFER AND AWARD (SF 1442), CONTINUED

FOR

RFP NO. N62742-18-R-1319

FY19 MCON PROJECT P-169 WATER TRANSMISSION LINE, WAIAWA,

JOINT BASE PEARL HARBOR HICKAM, HAWAII

RFP N62742-18-R-1319

SF 1442 (Continued)

DEDUCTIVE ITEM NO. 1: The basis for CLIN 0002 is the difference in price to utilize push-on joints in lieu of restrained joints for Waterline “A” from Sta 4+21 to Sta 105+00 (10,079 lf) in accordance with the drawings and specifications but not including the work under any other CLIN or SLINs.

Lump Sum

NOTES:

1. See Document 00202 for the Price Evaluation.

2. A firm-fixed-price is required for all line items. The following NAVFAC Language applies:

ALL OR NONE OFFERS - Offers are solicited on an “all or none” basis and FAR 52.215-1, INSTRUCTIONS TO OFFERORS-COMPETITIVE ACQUISITION in Document 00100, is hereby modified. Failure to submit offers for all line items listed shall be cause for rejection of the offer.

3. The Offeror SHALL include a price for ALL CLINs.

4. Multiple awards will not be made.

5. It is the Government’s objective to award CLIN 0001, without utilizing CLIN 0002, within the Military Construction funds available. For purposes of evaluating CLIN 0002, the low offeror is the offeror that offers the lowest aggregate amount for CLIN 0001 minus the deductive item CLIN 0002.

6. The proposed price for CLIN 0001 minus the deductive item CLIN 0002 (as applicable) will form the basis for the evaluation noted in Document 00202.

7. In the event there is a difference between a unit price and the extended total, the unit price will be held to be the intended offer and the extended total recomputed accordingly. If the offer provides a total but fails to enter a unit price, the total divided by the specified quantity will be held to be the intended unit price.

8. Payment for SLINs 0001AB through 0001AG shall be for actual quantities only. The unit prices will be used to adjust the contract price for any increase or decrease in the estimated quantities subject to the following clause:

a. FAR 52.211-18 Variation in Estimated Quantity (APR 1984)

If the quantity of a unit priced item in this contract is an estimated quantity and the actual quantity of the unit priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon an increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

End of Clause

FY19 MCON PROJECT P-169 WATER TRANSMISSION LINE WON 1572255

WAIAWA, JBPHH, OAHU

RFP N62742-18-R-1319

Amendment No. 0002

DOCUMENT 00700 (ADVERTISE)

1.92 FAR 52.232-40, PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (DEC 2013)

1.93 FAR 52.233-1, DISPUTES (MAY 2014) ALTERNATE I (DEC 1991)

1.94 FAR 52.233-3, PROTEST AFTER AWARD (AUG 1996)

1.95 FAR 52.233-4, APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

1.96 FAR 52.236-1, PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

1.97 FAR 52.236-2, DIFFERING SITE CONDITIONS (APR 1984)

1.98 FAR 52.236-3, SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

1.99 FAR 52.236-4, PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor’s information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by geotechnical borings.

(b) Weather conditions. Expected weather delays are indicated in Section 01 32 17.00 20.

(c) Bridge Load Rating and Posting: Page 2-1, Bridge Load Rating and Posting, and page 2-2, Load Rating and Posting Summary Sheet of the Bridge Inspection Report dated November 8, 2017

1.100 FAR 52.236-5, MATERIAL AND WORKMANSHIP (APR 1984)

1.101 FAR 52.236-6, SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

1.102 FAR 52.236-7, PERMITS AND RESPONSIBILITIES (NOV 1991)

1.103 FAR 52.236-8, OTHER CONTRACTS (APR 1984)

1.104 FAR 52.236-9, PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS (APR 1984)

1.105 FAR 52.236-10, OPERATIONS AND STORAGE AREAS (APR 1984)

1.106 FAR 52.236-11, USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

1.107 FAR 52.236-12, CLEANING UP (APR 1984)

1.108 FAR 52.236-13, ACCIDENT PREVENTION (NOV 1991) ALTERNATE I (NOV 1991)

1.109 FAR 52.236-15, SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

1.110 FAR 52.236-16, QUANTITY SURVEYS (APR 1984)

1.111 FAR 52.236-17, LAYOUT OF WORK (APR 1984)

1.112 FAR 52.236-21, SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

ALTERNATE I (APR 1984)

1.113 FAR 52.236-26, PRECONSTRUCTION CONFERENCE (FEB 1995)

1.114 FAR 52.242-5, PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (JAN 2017)

1.115 FAR 52.242-13, BANKRUPTCY (JUL 1995)

1.116 FAR 52.242-14, SUSPENSION OF WORK (APR 1984)

1.117 FAR 52.243-4, CHANGES (JUN 2007)

1.118 FAR 52.243-6, CHANGE ORDER ACCOUNTING (APR 1984)

1.119 FAR 52.244-6, SUBCONTRACTS FOR COMMERCIAL ITEMS (AUG 2018)

1.120 FAR 52.246-12, INSPECTION OF CONSTRUCTION (AUG 1996)

1.121 FAR 52.246-21, WARRANTY OF CONSTRUCTION (MAR 1994)

1.122 FAR 52.248-3, VALUE ENGINEERING -- CONSTRUCTION (OCT 2015)

1.123 FAR 52.249-2, TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED - PRICE)

(APR 2012) ALTERNATE I (SEP 1996)

1.124 FAR 52.249-10, DEFAULT (FIXED - PRICE CONSTRUCTION) (APR 1984)

1.125 FAR 52.252-4, ALTERATIONS IN CONTRACT (APR 1984)

Portions of this contract are altered as follows:

FAR 52.211-10, Commencement, Prosecution, and Completion of Work (APR 1984): Supplemental clarification of “notice to proceed”.

FY19 MCON PROJECT P-169 WATER TRANSMISSION LINE WON 1572255

WAIAWA, JBPHH, OAHU

RFP N62742-18-R-1319

Amendment No. 0002

DOCUMENT 00700 (ADVERTISE)

1.126 FAR 52.253-1, COMPUTER GENERATED FORMS (JAN 1991)

1.127 DFARS 252.203-7000, REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD

OFFICIALS (SEP 2011)

1.128 DFARS 252.203-7001, PROHIBITION ON PERSONS CONVICTED OF FRAUD OR OTHER

DEFENSE-CONTRACT-RELATED FELONIES (DEC 2008)

1.129 DFARS 252.203-7002, REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS

(SEP 2013)

1.130 DFARS 252.203-7003, AGENCY OFFICE OF THE INSPECTOR GENERAL (DEC 2012)

1.131 DFARS 252.203-7004, DISPLAY OF FRAUD HOTLINE POSTER(S) (OCT 2016)

1.132 DFARS 252.204-7000, DISCLOSURE OF INFORMATION (OCT 2016)

1.133 DFARS 252.204-7003, CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR 1992)

1.134 DFARS 252.204-7005, ORAL ATTESTATION OF SECURITY RESPONSIBILITIES (NOV 2001)

1.135 DFARS 252-204-7009, LIMITATIONS ON THE USE OR DISCLOSURE OF THIRD-PARTY

CONTRACTOR REPORTED CYBER INCIDENT INFORMATION (OCT 2016)

1.136 DFARS 252.204-7012, SAFEGUARDING COVERED DEFENSE INFORMATION AND CYBER

INCIDENT REPORTING (OCT 2016)

1.137 DFARS 252.204-7015, NOTICE OF AUTHORIZED DISCLOSURE OF INFORMATION FOR

LITIGATION SUPPORT (MAY 2016)

1.138 DFARS 252.205-7000, PROVISIONS OF INFORMATION TO COOPERATIVE AGREEMENT

HOLDERS (DEC 1991)

1.139 DFARS 252.209-7004, SUBCONTRACTING WITH FIRMS THAT ARE OWNED OR CONTROLLED

BY THE GOVERNMENT OF A COUNTRY THAT IS STATE SPONSOR OF TERRORISM (OCT 2015)

1.140 DFARS 252.211-7003, ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2016)

1.141 DFARS 252.219-7003, SMALL BUSINESS SUBCONTRACTING PLAN (DOD CONTRACTS)

(DEVIATION 2018-O0007) (DEC 2017)

1.142 DFARS 252.222-7006, RESTRICTIONS ON THE USE OF MANDATORY ARBITRATION

AGREEMENTS (DEC 2010)

1.143 DFARS 252.223-7001, HAZARD WARNING LABELS (DEC 1991)

1.144 DFARS 252.223-7004, DRUG-FREE WORK FORCE (SEP 1988)

1.145 DFARS 252.223-7006, PROHIBITION ON STORAGE, TREATMENT AND DISPOSAL OF TOXIC OR

HAZARDOUS MATERIALS – BASIC (SEP 2014)

1.146 DFARS 252.223-7008, PROHIBITION OF HEXAVALENT CHROMIUM (JUN 2013)

1.147 DFARS 252.225-7012, PREFERENCE FOR CERTAIN DOMESTIC COMMODITIES (DEC 2017)

1.148 DFARS 252.225-7048, EXPORT-CONTROLLED ITEMS (JUN 2013)

1.149 DFARS 252.227-7033, RIGHTS IN SHOP DRAWINGS (APR 1966)

1.150 DFARS 252.231-7000, SUPPLEMENTAL COST PRINCIPLES (DEC 1991)

1.151 DFARS 252.232-7003, ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING

REPORTS (JUN 2012)

1.152 DFARS 252.232-7006, WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

1.153 DFARS 252.232-7010, LEVIES ON CONTRACT PAYMENTS (DEC 2006)

1.154 DFARS 252.236-7000, MODIFICATION PROPOSALS -- PRICE BREAKDOWN (DEC 1991)

1.155 DFARS 252.236-7001, CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

1.156 DFARS 252.236-7013, REQUIREMENT FOR COMPETITION OPPORTUNITY FOR AMERICAN

STEEL PRODUCERS, FABRICATORS, AND MANUFACTURERS (JUN 2013)

1.157 DFARS 252.243-7001, PRICING OF CONTRACT MODIFICATIONS (DEC 1991)

1.158 DFARS 252.243-7002, REQUESTS FOR EQUITABLE ADJUSTMENT (DEC 2012)

1.159 DFARS 252.244-7000, SUBCONTRACTS FOR COMMERCIAL ITEMS (JUN 2013)

1.160 DFARS 252.246-7003, NOTIFICATION OF POTENTIAL SAFETY ISSUES (JUN 2013)

1.161 DFARS 252.246-7004, SAFETY OF FACILITIES, INFRASTRUCTURE, AND EQUIPMENT FOR

MILITARY OPERATIONS (OCT 2010)

1.162 DFARS 252.247-7023, TRANSPORTATION OF SUPPLIES BY SEA – BASIC (APR 2014)

1.163 DFARS 252.247-7024, NOTIFICATION OF TRANSPORTATION OF SUPPLIES BY SEA (MAR 2000)

1.164 DFARS 252.251-7000, ORDERING FROM GOVERNMENT SUPPLY SOURCES (AUG 2012)

1.165 NFAS 5252.209-9300, ORGANIZATIONAL CONFLICTS OF INTEREST (JUN 1994)

General Decision Number: HI180001 11/30/2018 HI1

Superseded General Decision Number: HI20170001

State: Hawaii

Construction Types: Building, Heavy (Heavy and Dredging), Highway and Residential

Counties: Hawaii Statewide.

BUILDING CONSTRUCTION PROJECTS; RESIDENTIAL CONSTRUCTION

PROJECTS (consisting of single family homes and apartments up to and including 4 stories); HEAVY AND HIGHWAY CONSTRUCTION

PROJECTS AND DREDGING

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.35 for calendar year 2018 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.35 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2018. The EO minimum wage rate will be adjusted annually.

Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/05/2018 1 01/26/2018 2 02/23/2018 3 03/09/2018 4 04/27/2018 5 07/06/2018 6 07/20/2018 7 08/03/2018 8 08/24/2018 9 08/31/2018 10 09/07/2018 11 09/28/2018 12 10/05/2018 13 10/26/2018 14 11/02/2018 15 11/30/2018

ASBE0132-001 08/31/2015

Rates Fringes

Asbestos Workers/Insulator

11/30/2018https://www.wdol.gov/wdol/scafiles/davisbacon/HI1.dvb?v=15

Includes application of all insulating materials, protective coverings, coatings and finishes to all types of mechanical systems. Also the application of firestopping material for wall openings and penetrations in walls, floors, ceilings and curtain walls...............$ 39.65 23.50

BOIL0627-005 01/01/2013

Rates Fringes

BOILERMAKER......................$ 35.20 27.35

BRHI0001-001 09/04/2017

Rates Fringes

BRICKLAYER

Bricklayers and Stonemasons.$ 39.76 28.12 Pointers, Caulkers and Weatherproofers.............$ 40.01 28.12

BRHI0001-002 09/04/2017

Rates Fringes

Tile, Marble & Terrazzo Worker Terrazzo Base Grinders......$ 39.14 28.12 Terrazzo Floor Grinders and Tenders.................$ 37.59 28.12 Tile, Marble and Terrazzo Workers.....................$ 40.95 28.12

CARP0745-001 09/03/2018

Rates Fringes

Carpenters:

Carpenters; Hardwood Floor Layers; Patent Scaffold Erectors (14 ft. and over); Piledrivers;

Pneumatic Nailers; Wood Shinglers and Transit and/or Layout Man...........$ 49.45 21.75 Millwrights and Machine Erectors....................$ 49.70 21.75 Power Saw Operators (2 h.p. and over)..............$ 49.60 21.75

CARP0745-002 09/03/2018

Rates Fringes

Drywall and Acoustical Workers and Lathers..............$ 49.70 21.75

ELEC1186-001 08/26/2018

Rates Fringes

Electricians:

Cable Splicers..............$ 54.78 29.20 Electricians................$ 49.80 27.85 Telecommunication worker....$ 28.44 11.94

ELEC1186-002 08/26/2018

Rates Fringes

Line Construction:

Cable Splicers..............$ 54.78 29.20 Groundmen/Truck Drivers.....$ 37.35 24.48 Heavy Equipment Operators...$ 44.82 26.49 Linemen.....................$ 49.80 27.85 Telecommunication worker....$ 28.44 11.94

ELEV0126-001 01/01/2018

Rates Fringes

ELEVATOR MECHANIC................$ 57.36 32.65

a. VACATION: Employer contributes 8% of basic hourly rate for 5 years service and 6% of basic hourly rate for 6 months to 5 years service as vacation pay credit.

b. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence Day, Labor Day, Veterans' Day, Thanksgiving Day, the Friday after Thanksgiving Day and Christmas Day.

ENGI0003-002 09/03/2018

Rates Fringes

Diver (Aqua Lung) (Scuba)) Diver (Aqua Lung) (Scuba) (over a depth of 30 feet)...$ 66.00 31.26 Diver (Aqua Lung) (Scuba) (up to a depth of 30 feet)..$ 56.63 31.26 Stand-by Diver (Aqua Lung) (Scuba)....................$ 47.25 31.26 Diver (Other than Aqua Lung) Diver (Other than Aqua Lung).......................$ 66.00 31.26 Diver Tender (Other than Aqua Lung)..................$ 44.22 31.26 Stand-by Diver (Other than Aqua Lung)..................$ 47.25 31.26 Helicopter Work Airborne Hoist Operator for Helicopter..............$ 45.80 31.26 Co-Pilot of Helicopter......$ 45.98 31.26

Pilot of Helicopter.........$ 46.11 31.26 Power equipment operator -tunnel work

GROUP 1....................$ 42.24 31.26

GROUP 2....................$ 42.35 31.26

GROUP 3....................$ 42.52 31.26

GROUP 4....................$ 42.79 31.26

GROUP 5....................$ 43.10 31.26

GROUP 6....................$ 43.75 31.26

GROUP 7....................$ 44.07 31.26

GROUP 8....................$ 44.18 31.26

GROUP 9....................$ 44.29 31.26

GROUP 9A...................$ 44.52 31.26

GROUP 10....................$ 44.58 31.26

GROUP 10A...................$ 44.73 31.26

GROUP 11....................$ 44.88 31.26

GROUP 12....................$ 45.24 31.26

GROUP 12A...................$ 45.60 31.26

Power equipment operators:

GROUP 1....................$ 41.94 31.26

GROUP 2....................$ 42.05 31.26

GROUP 3....................$ 42.22 31.26

GROUP 4....................$ 42.49 31.26

GROUP 5....................$ 42.80 31.26

GROUP 6....................$ 43.45 31.26

GROUP 7....................$ 43.77 31.26

GROUP 8....................$ 43.88 31.26

GROUP 9....................$ 43.99 31.26

GROUP 9A...................$ 44.22 31.26

GROUP 10....................$ 44.28 31.26

GROUP 10A...................$ 44.43 31.26

GROUP 11....................$ 44.58 31.26

GROUP 12....................$ 44.94 31.26

GROUP 12A...................$ 45.30 31.26

GROUP 13....................$ 42.22 31.26

GROUP 13A...................$ 42.49 31.26

GROUP 13B...................$ 42.80 31.26

GROUP 13C...................$ 43.45 31.26

GROUP 13D...................$ 43.77 31.26

GROUP 13E...................$ 43.88 31.26

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Fork Lift (up to and including 10 tons); Partsman (heavy duty repair shop parts room when needed).

GROUP 2: Conveyor Operator (Handling building material);

Hydraulic Monitor; Mixer Box Operator (Concrete Plant).

GROUP 3: Brakeman; Deckhand; Fireman; Oiler;

Oiler/Gradechecker; Signalman; Switchman; Highline Cableway Signalman; Bargeman; Bunkerman; Concrete Curing Machine (self-propelled, automatically applied unit on streets, highways, airports and canals); Leveeman; Roller (5 tons and under); Tugger Hoist.

GROUP 4: Boom Truck or dual purpose "A" Frame Truck (5 tons or less); Concrete Placing Boom (Building Construction);

Dinky Operator; Elevator Operator; Hoist and/or Winch (one drum); Straddle Truck (Ross Carrier, Hyster and similar).

GROUP 5: Asphalt Plant Fireman; Compressors, Pumps, Generators and Welding Machines ("Bank" of 9 or more, individually or collectively); Concrete Pumps or Pumpcrete Guns; Lubrication and Service Engineer (Grease Rack);

Screedman.

GROUP 6: Boom Truck or Dual Purpose "A"Frame Truck (over 5 tons); Combination Loader/Backhoe (up to and including 3/4

cu. yd.); Concrete Batch Plants (wet or dry); Concrete Cutter, Groover and/or Grinder (self-propelled unit on streets, highways, airports, and canals); Conveyor or Concrete Pump (Truck or Equipment Mounted); Drilling Machinery (not to apply to waterliners, wagon drills or jack hammers); Fork Lift (over 10 tons); Loader (up to and including 3 and 1/2 cu. yds); Lull High Lift (under 40 feet); Lubrication and Service Engineer (Mobile); Maginnis Internal Full Slab Vibrator (on airports, highways, canals and warehouses); Man or Material Hoist; Mechanical Concrete Finisher (Large Clary, Johnson Bidwell, Bridge Deck and similar); Mobile Truck Crane Driver; Portable Shotblast Concrete Cleaning Machine; Portable Boring Machine (under streets, highways, etc.); Portable Crusher; Power Jumbo Operator (setting slip forms, etc., in tunnels); Rollers (over 5 tons); Self-propelled Compactor (single engine);

Self-propelled Pavement Breaker; Skidsteer Loader with attachments; Slip Form Pumps (Power driven by hydraulic, electric, air, gas, etc., lifting device for concrete forms); Small Rubber Tired Tractors; Trencher (up to and including 6 feet); Underbridge Personnel Aerial Platform (50 feet of platform or less).

GROUP 7: Crusher Plant Engineer, Dozer (D-4, Case 450, John Deere 450, and similar); Dual Drum Mixer, Extend Lift;

Hoist and/or Winch (2 drums); Loader (over 3 and 1/2 cu.

yds. up to and including 6 yards.); Mechanical Finisher or Spreader Machine (asphalt), (Barber Greene and similar) (Screedman required); Mine or Shaft Hoist; Mobile Concrete Mixer (over 5 tons); Pipe Bending Machine (pipelines only);

Pipe Cleaning Machine (tractor propelled and supported);

Pipe Wrapping Machine (tractor propelled and supported);

Roller Operator (Asphalt); Self-Propelled Elevating Grade Plane; Slusher Operator; Tractor (with boom) (D-6, or similar); Trencher (over 6 feet and less than 200 h.p.);

Water Tanker (pulled by Euclids, T-Pulls, DW-10, 20 or 21, or similar); Winchman (Stern Winch on Dredge).

GROUP 8: Asphalt Plant Operator; Barge Mate (Seagoing);

Cast-in-Place Pipe Laying Machine; Concrete Batch Plant (multiple units); Conveyor Operator (tunnel); Deckmate;

Dozer (D-6 and similar); Finishing Machine Operator (airports and highways); Gradesetter; Kolman Loader (and similar); Mucking Machine (Crawler-type); Mucking Machine (Conveyor-type); No-Joint Pipe Laying Machine; Portable Crushing and Screening Plant; Power Blade Operator (under 12); Saurman Type Dragline (up to and including 5 yds.);

Stationary Pipe Wrapping, Cleaning and Bending Machine;

Surface Heater and Planer Operator, Tractor (D-6 and similar); Tri-Batch Paver; Tunnel Badger; Tunnel Mole and/or Boring Machine Operator Underbridge Personnel Aerial

Platform (over 50 feet of platform).

GROUP 9: Combination Mixer and Compressor (gunite); Do-Mor Loaderand Adams Elegrader; Dozer (D-7 or equal); Wheel and/or Ladder Trencher (over 6 feet and 200 to 749 h.p.).

GROUP 9A: Dozer (D-8 and similar); Gradesetter (when required by the Contractor to work from drawings, plans or specifications without the direct supervision of a foreman or superintendent); Push Cat; Scrapers (up to and including 20 cu. yds); Self-propelled Compactor with Dozer;

Self-Propelled, Rubber-Tired Earthmoving Equipment (up to and including 20 cu. yds) (621 Band and similar); Sheep's Foot; Tractor (D-8 and similar); Tractors with boom (larger than D-6, and similar).

GROUP 10: Chicago Boom; Cold Planers; Heavy Duty Repairman or Welder; Hoist and/or Winch (3 drums); Hydraulic Skooper (Koehring and similar); Loader (over 6 cu. yds. up to and including 12 cu. yds.); Saurman type Dragline (over 5 cu.

yds.); Self-propelled, rubber-tired Earthmoving Equipment (over 20 cu. yds. up to and including 31 cu. yds.) (637D and similar); Soil Stabilizer (P & H or equal); Sub-Grader (Gurries or other automatic type); Tractors (D-9 or equivalent, all attachments); Tractor (Tandem Scraper);

Watch Engineer.

GROUP 10A: Boat Operator; Cable-operated Crawler Crane (up to and including 25 tons); Cable-operated Power Shovel, Clamshell, Dragline and Backhoe (up to and including 1 cu.

yd.); Dozer D9-L; Dozer (D-10, HD41 and similar) (all attachments); Gradall (up to and including 1 cu. yd.);

Hydraulic Backhoe (over 3/4 cu. yds. up to and including 2

cu. yds.); Mobile Truck Crane Operator (up to and including 25 tons) (Mobile Truck Crane Driver Required);

Self-propelled Boom Type Lifting Device (Center Mount) (up to and including 25 tons) (Grove, Drott, P&H, Pettibone and similar; Trencher (over 6 feet and 750 h.p. or more); Watch Engineer (steam or electric).

GROUP 11: Automatic Slip Form Paver (concrete or asphalt);

Band Wagon (in conjunction with Wheel Excavator);

Cable-operated Crawler Cranes (over 25 tons but less than 50 tons); Cable-operated Power Shovel, Clamshell, Dragline and Backhoe (over 1 cu. yd. up to 7 cu. yds.); Gradall (over 1 cu. yds. up to 7 cu. yds.); DW-10, 20, etc.

(Tandem); Earthmoving Machines (multiple propulsion power units and 2 or more Scrapers) (up to and including 35 cu.

yds.," struck" m.r.c.); Highline Cableway; Hydraulic Backhoe (over 2 cu. yds. up to and including 4 cu. yds.);

Leverman; Lift Slab Machine; Loader (over 12 cu. yds);

Master Boat Operator; Mobile Truck Crane Operator (over 25 tons but less than 50 tons); (Mobile Truck Crane Driver required); Pre-stress Wire Wrapping Machine; Self-propelled Boom-type Lifting Device (Center Mount) (over 25 tons m.r.c); Self-propelled Compactor (with multiple-propulsion power units); Single Engine Rubber Tired Earthmoving Machine (with Tandem Scraper); Tandem Cats; Trencher (pulling attached shield).

GROUP 12: Clamshell or Dipper Operator; Derricks; Drill Rigs;

Multi-Propulsion Earthmoving Machines (2 or more Scrapers) (over 35 cu. yds "struck"m.r.c.); Operators (Derricks, Piledrivers and Cranes); Power Shovels and Draglines (7 cu.

yds. m.r.c. and over); Self-propelled rubber-tired Earthmoving equipment (over 31 cu. yds.) (657B and similar); Wheel Excavator (up to and including 750 cu. yds.

per hour); Wheel Excavator (over 750 cu. yds. per hour).

GROUP 12A: Dozer (D-11 or similar or larger); Hydraulic Excavators (over 4 cu. yds.); Lifting cranes (50 tons and over); Pioneering Dozer/Backhoe (initial clearing and excavation for the purpose of providing access for other equipment where the terrain worked involves 1-to-1 slopes that are 50 feet in height or depth, the scope of this work does not include normal clearing and grubbing on usual hilly terrain nor the excavation work once the access is provided); Power Blade Operator (Cat 12 or equivalent or over); Straddle Lifts (over 50 tons); Tower Crane, Mobile;

Traveling Truss Cranes; Universal, Liebher, Linden, and similar types of Tower Cranes (in the erection, dismantling, and moving of equipment there shall be an additional Operating Engineer or Heavy Duty Repairman);

Yo-Yo Cat or Dozer.

GROUP 13: Truck Driver (Utility, Flatbed, etc.)

GROUP 13A: Dump Truck, 8 cu.yds. and under (water level);

Water Truck (up to and including 2,000 gallons).

GROUP 13B: Water Truck (over 2,000 gallons); Tandem Dump Truck, over 8 cu. yds. (water level).

GROUP 13C: Truck Driver (Semi-trailer. Rock Cans, Semi-Dump or Roll-Offs).

GROUP 13D: Truck Driver (Slip-In or Pup).

GROUP 13E: End Dumps, Unlicensed (Euclid, Mack, Caterpillar or similar); Tractor Trailer (Hauling Equipment); Tandem Trucks hooked up to Trailer (Hauling Equipment)

BOOMS AND/OR LEADS (HOURLY PREMIUMS):

The Operator of a crane (under 50 tons) with a boom of 80 feet or more (including jib), or of a crane (under 50 tons) with leads of 100 feet or more, shall receive a per hour premium for each hour worked on said crane (under 50 tons) in accordance with the following schedule:

Booms of 80 feet up to but not including 130 feet or Leads of 100 feet up to but not including 130 feet 0.50 Booms and/or Leads of 130 feet up to but not including 180 feet 0.75 Booms and/or Leads of 180 feet up to and including 250 feet 1.15 Booms and/or Leads over 250 feet 1.50

The Operator of a crane (50 tons and over) with a boom of 180 feet or more (including jib) shall receive a per hour premium for each hour worked on said crane (50 tons and over) in accordance with the following schedule:

Booms of 180 feet up to and including 250 feet 1.25 Booms over 250 feet 1.75

ENGI0003-004 09/04/2017

Rates Fringes

Dredging: (Boat Operators) Boat Deckhand...............$ 41.22 30.93 Boat Operator...............$ 43.43 30.93 Master Boat Operator........$ 43.58 30.93 Dredging: (Clamshell or Dipper Dredging)

GROUP 1.....................$ 43.94 30.93

GROUP 2.....................$ 43.28 30.93

GROUP 3.....................$ 42.88 30.93

GROUP 4.....................$ 41.22 30.93

Dredging: (Derricks)

GROUP 1.....................$ 43.94 30.93

GROUP 2.....................$ 43.28 30.93

GROUP 3.....................$ 42.88 30.93

GROUP 4.....................$ 41.22 30.93

Dredging: (Hydraulic Suction Dredges)

GROUP 1.....................$ 43.58 30.93

GROUP 2.....................$ 43.43 30.93

GROUP 3.....................$ 43.28 30.93

GROUP 4.....................$ 43.22 30.93

GROUP 5.....................$ 37.88 26.76

Group 5.....................$ 42.88 30.93

GROUP 6.....................$ 37.77 26.76

Group 6.....................$ 42.77 30.93

GROUP 7.....................$ 36.22 26.76

Group 7.....................$ 41.22 30.93

CLAMSHELL OR DIPPER DREDGING CLASSIFICATIONS

GROUP 1: Clamshell or Dipper Operator.

GROUP 2: Mechanic or Welder; Watch Engineer.

GROUP 3: Barge Mate; Deckmate.

GROUP 4: Bargeman; Deckhand; Fireman; Oiler.

HYDRAULIC SUCTION DREDGING CLASSIFICATIONS

GROUP 1: Leverman.

GROUP 2: Watch Engineer (steam or electric).

GROUP 3: Mechanic or Welder.

GROUP 4: Dozer Operator.

GROUP 5: Deckmate.

GROUP 6: Winchman (Stern Winch on Dredge) GROUP 7: Deckhand (can operate anchor scow under direction of Deckmate); Fireman; Leveeman; Oiler.

DERRICK CLASSIFICATIONS

GROUP 1: Operators (Derricks, Piledrivers and Cranes).

GROUP 2: Saurman Type Dragline (over 5 cubic yards).

GROUP 3: Deckmate; Saurman Type Dragline (up to and including 5 yards).

GROUP 4: Deckhand, Fireman, Oiler.

ENGI0003-044 09/03/2018

Rates Fringes

Power Equipment Operators

(PAVING)

Asphalt Concrete Material Transfer....................$ 42.92 32.08 Asphalt Plant Operator......$ 43.35 32.08 Asphalt Raker...............$ 41.96 32.08 Asphalt Spreader Operator...$ 43.44 32.08 Cold Planer.................$ 43.75 32.08 Combination Loader/Backhoe (over 3/4 cu.yd.)...........$ 41.96 32.08 Combination Loader/Backhoe (up to 3/4 cu.yd.)..........$ 40.98 32.08 Concrete Saws and/or Grinder (self-propelled unit on streets, highways, airports and canals)........$ 42.92 32.08 Grader......................$ 43.75 32.08 Laborer, Hand Roller........$ 41.46 32.08 Loader (2 1/2 cu. yds. and under)......................$ 42.92 32.08 Loader (over 2 1/2 cu.

yds. to and including 5

cu. yds.)...................$ 43.24 32.08 Roller Operator (five tons and under)..................$ 41.69 32.08 Roller Operator (over five tons).......................$ 43.12 32.08 Screed Person...............$ 42.92 32.08 Soil Stabilizer.............$ 43.75 32.08

IRON0625-001 09/01/2018

Rates Fringes

Ironworkers:.....................$ 40.25 35.79

a. Employees will be paid $.50 per hour more while working in tunnels and coffer dams; $1.00 per hour more when required to work under or are covered with water (submerged) and when they are required to work on the summit of Mauna Kea, Mauna Loa or Haleakala.

LABO0368-001 09/03/2018

Rates Fringes

Laborers:

Driller.....................$ 38.40 20.26 Final Clean Up..............$ 28.80 16.12 Gunite/Shotcrete Operator and High Scaler.............$ 37.90 20.26 Laborer I...................$ 37.40 20.26 Laborer II..................$ 34.80 20.26 Mason Tender/Hod Carrier....$ 37.90 20.26 Powderman...................$ 38.40 20.26 Window Washer (bosun chair).$ 36.90 20.26

LABORERS CLASSIFICATIONS

Laborer I: Air Blasting run by electric or pneumatic compressor; Asphalt Laborer, Ironer, Raker, Luteman, and Handroller, and all types of Asphalt Spreader Boxes;

Asphalt Shoveler; Assembly and Installation of Multiplates, Liner Plates, Rings, Mesh, Mats; Batching Plant (portable and temporary); Boring Machine Operator (under streets and sidewalks); Buggymobile; Burning and Welding; Chainsaw, Faller, Logloader, and Bucker; Compactors (Jackson Jumping Jack and similar); Concrete Bucket Dumpman; Concrete Chipping; Concrete Chuteman/Hoseman (pouring concrete) (the handling of the chute from ready-mix trucks for such jobs as walls, slabs, decks, floors, foundations, footings, curbs, gutters, and sidewalks); Concrete Core Cutter (Walls, Floors, and Ceiling); Concrete Grinding or Sanding;

Concrete: Hooking on, signaling, dumping of concrete for treme work over water on caissons, pilings, abutments, etc.; Concrete: Mixing, handling, conveying, pouring, vibrating, otherwise placing of concrete or aggregates or by any other process; Concrete: Operation of motorized wheelbarrows or buggies or machines of similar character, whether run by gas, diesel, or electric power; Concrete Placement Machine Operator: operation of Somero Hammerhead, Copperheads, or similar machines; Concrete Pump Machine (laying, coupling, uncoupling of all connections and cleaning of equipment); Concrete and/or Asphalt Saw (Walking or Handtype) (cutting walls or flatwork) (scoring old or new concrete and/or asphalt) (cutting for expansion joints) (streets and ways for laying of pipe, cable or conduit for all purposes); Concrete Shovelers/Laborers (Wet or Dry); Concrete Screeding for Rough Strike-Off: Rodding or striking-off, by hand or mechanical means prior to finishing; Concrete Vibrator Operator; Coring Holes: Walls, footings, piers or other obstructions for passage of pipes or conduits for any purpose and the pouring of concrete to secure the hole; Cribbers, Shorer, Lagging, Sheeting, and Trench Jacking and Bracing, Hand-Guided Lagging Hammer Whaling Bracing; Curbing (Concrete and Asphalt); Curing of Concrete (impervious membrane and form oiler) mortar and other materials by any mode or method; Cut Granite Curb Setter (setting, leveling and grouting of all precast concrete or stone curbs); Cutting and Burning Torch (demolition); Dri Pak-It Machine; Environmental Abatement:

removal of asbestos, lead, and bio hazardous materials (EPA and/or OSHA certified); Falling, bucking, yarding, loading or burning of all trees or timber on construction site;

Forklift (9 ft. and under); Gas, Pneumatic, and Electric tools; Grating and Grill work for drains or other purposes;

Green Cutter of concrete or aggregate in any form, by hand, mechanical means, grindstone or air and/or water; Grout:

Spreading for any purpose; Guinea Chaser (Grade Checker) for general utility trenches, sitework, and excavation;

Headerboard Man (Asphalt or Concrete); Heat Welder of Plastic (Laborers' AGC certified workers) (when work involves waterproofing for waterponds, artificial lakes and reservoir) heat welding for sewer pipes and fusion of HDPE pipes; Heavy Highway Laborer (Rigging, signaling, handling, and installation of pre-cast catch basins, manholes, curbs and gutters); High Pressure Nozzleman - Hydraulic Monitor (over 100# pressure); Jackhammer Operator; Jacking of slip forms: All semi and unskilled work connected therewithin;

Laying of all multi-cell conduit or multi-purpose pipe;

Magnesite and Mastic Workers (Wet or Dry)(including mixer operator);Mortar Man; Mortar Mixer (Block, Brick, Masonry, and Plastering); Nozzleman (Sandblasting and/or Water Blasting): handling, placing and operation of nozzle;

Operation, Manual or Hydraulic jacking of shields and the use of such other mechanical equipment as may be necessary;

Pavement Breakers; Paving, curbing and surfacing of streets, ways, courts, under and overpasses, bridges, approaches, slope walls, and all other labor connected therewith; Pilecutters; Pipe Accessment in place, bolting and lining up of sectional metal or other pipe including corrugated pipe; Pipelayer performing all services in the laying and installation of pipe from the point of receiving pipe in the ditch until completion of operation, including any and all forms of tubular material, whether pipe, HDPE, metallic or non-metallic, conduit, and any other stationary-type of tubular device used for conveying of any substance or element, whether water, sewage, solid, gas, air, or other product whatsoever and without regard to the nature of material from which tubular material is fabricated; No-joint pipe and stripping of same, Pipewrapper, Caulker, Bander, Kettlemen, and men applying asphalt, Laykold, treating Creosote and similar-type materials (6-inch) pipe and over); Piping: resurfacing and paving of all ditches in preparation for laying of all pipes; Pipe laying of lateral sewer pipe from main or side sewer to buildings or structure (except Contactor may direct work be done under proper supervision); Pipe laying, leveling and marking of the joint used for main or side sewers and storm sewers; Laying of all clay, terra cotta, ironstone, vitrified concrete, HDPE or other pipe for drainage; Placing and setting of water mains, gas mains and all pipe including removal of skids; Plaster Mortar Mixer/Pump; Pneumatic Impact Wrench; Portable Sawmill Operation: Choker setters, off bearers, and lumber handlers connected with clearing; Posthole Digger (Hand Held, Gas, Air and Electric); Powderman's Tender; Power Broom Sweepers (Small); Preparation and Compaction of roadbeds for railroad track laying, highway construction, and the preparation of trenches, footings, etc., for cross-country transmission by pipelines, electrical transmission or underground lines or cables (by mechanical means); Raising of structure by manual or hydraulic jacks or other methods and resetting of structure in new locations, including all concrete work; Ramming or compaction; Rigging in connection with Laborers' work (except demolition), Signaling (including the use of walkie talkie) Choke Setting, tag line usage; Tagging and Signaling of building materials into high rise units; Riprap, Stonepaver, and Rock Slinger (includes placement of stacked concrete, wet or dry and loading, unloading, signaling, slinging and setting of other similar materials); Rotary Scarifier (including multiple head concrete chipping Scarifier); Salamander Heater, Drying of plaster, concrete mortar or other aggregate; Scaffold Erector Leadman; Scaffolds: (Swing and hanging) including maintenance thereof; Scaler; Septic Tank/Cesspool and Drain Fields Digger and Installer;

Shredder/Chipper (tree branches, brush, etc.); Stripping and Setting Forms; Stripping of Forms: Other than panel forms which are to be re-used in their original form, and stripping of forms on all flat arch work; Tampers (Barko, Wacker, and similar type); Tank Scaler and Cleaners;

Tarman; Tree Climbers and Trimmers; Trencher (includes hand-held, Davis T-66 and similar type); Trucks (flatbed up to and including 2 1/2 tons when used in connection with on-site Laborers'work; Trucks (Refuse and Garbage Disposal) (from job site to dump); Vibra-Screed (Bull Float in connection with Laborers' work); Well Points, Installation of or any other dewatering system.

Laborer II: Asphalt Plant Laborer; Boring Machine Tender;

Bridge Laborer; Burning of all debris (crates, boxes, packaging waste materials); Chainman, Rodmen, and Grade Markers; Cleaning, clearing, grading and/or removal for streets, highways, roadways, aprons, runways, sidewalks, parking areas, airports, approaches, and other similar installations; Cleaning or reconditioning of streets, ways, sewers and waterlines, all maintenance work and work of an unskilled and semi-skilled nature; Concrete Bucket Tender (Groundman) hooking and unhooking of bucket; Concrete Forms; moving, cleaning, oiling and carrying to the next point of erection of all forms; Concrete Products Plant Laborers; Conveyor Tender (conveying of building materials); Crushed Stone Yards and Gravel and Sand Pit Laborers and all other similar plants; Demolition, Wrecking and Salvage Laborers: Wrecking and dismantling of buildings and all structures, with use of cutting or wrecking tools, breaking away, cleaning and removal of all fixtures, All hooking, unhooking, signaling of materials for salvage or scrap removed by crane or derrick; Digging under streets, roadways, aprons or other paved surfaces; Driller's Tender;

Chuck Tender, Outside Nipper; Dry-packing of concrete (plugging and filling of she-bolt holes); Fence and/or Guardrail Erector: Dismantling and/or re-installation of all fence; Finegrader; Firewatcher; Flagman (Coning, preparing, stablishing and removing portable roadway barricade devices); Signal Men on all construction work defined herein, including Traffic Control Signal Men at construction site; General Excavation; Backfilling, Grading and all other labor connected therewith; Digging of trenches, ditches and manholes and the leveling, grading and other preparation prior to laying pipe or conduit for any purpose; Excavations and foundations for buildings, piers, foundations and holes, and all other construction.

Preparation of street ways and bridges; General Laborer:

Cleaning and Clearing of all debris and surplus material.

Clean-up of right-of-way. Clearing and slashing of brush or trees by hand or mechanical cutting. General Clean up:

sweeping, cleaning, wash-down, wiping of construction facility and equipment (other than "Light Clean up (Janitorial) Laborer. Garbage and Debris Handlers and Cleaners. Appliance Handling (job site) (after delivery unlading in storage area); Ground and Soil Treatment Work (Pest Control); Gunite/Shotcrete Operator Tender; Junk Yard Laborers (same as Salvage Yard); Laser Beam "Target Man" in connection with Laborers' work; Layout Person for Plastic (when work involves waterproofing for waterponds, artificial lakes and reservoirs); Limbers, Brush Loaders, and Pilers; Loading, Unloading, carrying, distributing and handling of all rods and material for use in reinforcing concrete construction (except when a derrick or outrigger operated by other than hand power is used); Loading, unloading, sorting, stockpiling, handling and distribution of water mains, gas mains and all pipes; Loading and unloading of all materials, fixtures, furnishings and appliances from point of delivery to stockpile to point of installation; hooking and signaling from truck, conveyance or stockpile; Material Yard Laborers; Pipelayer Tender;

Pipewrapper, Caulker, Bander, Kettlemen, and men applying asphalt, Laykold, Creosote, and similar-type materials (pipe under 6 inches); Plasterer Laborer; Preparation, construction and maintenance of roadbeds and sub-grade for all paving, including excavation, dumping, and spreading of sub-grade material; Prestressed or precast concrete slabs, walls, or sections: all loading, unloading, stockpiling, hooking on of such slabs, walls or sections; Quarry Laborers; Railroad, Streetcar, and Rail Transit Maintenance and Repair; Roustabout; Rubbish Trucks in connection with Building Construction Projects (excluding clearing, grubbing, and excavating); Salvage Yard: All work connected with cutting, cleaning, storing, stockpiling or handling of materials, all cleanup, removal of debris, burning, back-filling and landscaping of the site; Sandblasting Tender (Pot Tender): Hoses and pots or markers; Scaffolds:

Erection, planking and removal of all scaffolds used for support for lathers, plasters, brick layers, masons, and other construction trades crafts; Scaffolds: (Specially designed by carpenters) laborers shall tend said carpenter on erection and dismantling thereof, preparation for foundation or mudsills, maintenance; Scraping of floors;

Screeds: Handling of all screeds to be reused; handling, dismantling and conveyance of screeds; Setting, leveling and securing or bracing of metal or other road forms and expansion joints; Sheeting Piling/trench shoring (handling and placing of skip sheet or wood plank trench shoring);

Ship Scalers; Shipwright Tender; Sign Erector (subdivision traffic, regulatory, and street-name signs); Sloper; Slurry Seal Crews (Mixer Operator, Applicator, Squeegee Man, Shuttle Man, Top Man); Snapping of wall ties and removal of tie rods; Soil Test operations of semi and unskilled labor such as filling sand bags; Striper (Asphalt, Concrete or other Paved Surfaces); Tool Room Attendant (Job Site);

Traffic Delineating Device Applicator; Underpinning, lagging, bracing, propping and shoring, loading, signaling, right-of-way clearance along the route of movement, The clearance of new site, excavation of foundation when moving a house or structure from old site to new site; Utilities employees; Water Man; Waterscape/Hardscape Laborers; Wire Mesh Pulling (all concrete pouring operations); Wrecking, stripping, dismantling and handling concrete forms an false work.

LABO0368-002 09/03/2018

Rates Fringes

Landscape & Irrigation Laborers

GROUP 1.....................$ 25.50 12.68

GROUP 2.....................$ 26.40 12.68

GROUP 3.....................$ 21.10 12.68

LABORERS CLASSIFICATIONS

GROUP 1: Installation of non-potable permanent or temporary irrigation water systems performed for the purposes of Landscaping and Irrigation architectural horticultural work; the installation of drinking fountains and permanent or temporary irrigation systems using potable water for Landscaping and Irrigation architectural horticultural purposes only. This work includes (a) the installation of all heads, risers, valves, valve boxes, vacuum breakers (pressure and non-pressure), low voltage electrical lines and, provided such work involves electrical wiring that will carry 24 volts or less, the installation of sensors, master control panels, display boards, junction boxes, conductors, including all other components for controllers,

(b) and metallic (copper, brass, galvanized, or similar) pipe, as well as PVC or other plastic pipe including all work incidental thereto,…