N55236-15-R-0034_ACB-1_CRAFTS_AMENDMENT_0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

REF: ACB-1 CRAFTS CMAV

SEE CONTINUATION PAGES

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 10-Jul-2015

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N55236-15-R-0034

X 9B. DATED (SEE ITEM 11)

02-Jul-2015

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

09-Jul-2015

CODE

SOUTHWEST REGIONAL MAINTENANCE CENTER

CODE 410 3755 BRINSER STREET, STE 1

SAN DIEGO CA 92136

N55236 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N55236-15-R-0034

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0002 CONTINUED

REQUEST FOR SPECIFICATION/CLARIFICATION:

QUESTION # 0001 – WORK ITEM 110-00-003: References 2.2 thru 2.7 not provided on reference disk. Please provide.

ANSWER # 0001 – Contact Staff Sergeant Daniel Calleja, for a copy of disc #2 containing references 2.2 thru 2.7, via email: daniel.calleja@navy.mil QUESTION # 0002 - Will craft be on the pier or in the water? Please list where craft will be.

ANSWER # 0002 - 80CM0306, 80CM0310, 80IM0303, 88WT0304, 88CFPM0606, 80BM0616, will be hauled from water and blocked by ACB-1. All other craft to remain waterborne.

QUESTION # 0003 – WORK ITEM 077-11-001, PARA NO. 3.5. Please verify the hazardous waste to be produced as it appears to be unrealistically high: 500 Tons of Spent Abrasive Material ANSWER # 0003 – Work Item 077-11-001 Para No. 3.5, change from “500 Tons” to “40 Tons” of Spent Abrasive Blast Material.

SECTION F - DELIVERIES OR PERFORMANCE

The following have been added by full text:

HQ F-2-0006 MILESTONES (NAVSEA) (SEP 1990)

Milestone Event Date

Launch PM16, BM16, and WT4 8 DEC 2015

Ship’s Force to Remove Craft from IEM Status 9-12 DEC 2015

Commence Equipment Testing 14-17 DEC 2015

End of Contract 18 DEC 2015

(a) The Contractor shall successfully accomplish the major milestones on, or prior to, the dates listed above.

(b) If any milestone event is not accomplished by the date listed, and the failure to accomplish any such milestone event does not arise from a cause beyond the control and without fault or negligence of the Contractor, such failure may be deemed to constitute a failure to perform this contract in accordance with its terms within the meaning of subparagraph (a)(1)(ii) of the clause of this contract entitled "DEFAULT (FIXED-PRICE SUPPLY AND SERVICE)" (FAR 52.249-8) or "DEFAULT (FIXED-PRICE RESEARCH AND DEVELOPMENT)" (FAR 52.249-9), as applicable.

The following have been modified:

RMC F-1-0002 PLACE OF PERFORMANCE (RMC)

(a)Work on the Vessel under this contract shall be performed at: Naval Amphibious Base Coronado or Contractor’s Facility (West Coast)

(b) Drydocking shall be accomplished at: N/A

(c) All other work shall be accomplished at: Naval Amphibious Base Coronado or Contractor’s Facility (West Coast)

RMC-F-1-0003 DELIVERY / REDELIVERY SCHEDULE (RMC)

The Government agrees to deliver the Vessel to the Contractor at: Naval Amphibious Base Coronado no later than the following "Commencement Date". The Contractor agrees to redeliver the Vessel to the Government at:

Naval Amphibious Base Coronado on the following “Completion Date".

CLIN VESSEL COMMENCEMENT DATE COMPLETION DATE

0001 ACB-1 CRAFTS 01 SEP 2015 18 DEC 2015

0002 ACB-1 CRAFTS As Specified in Over and Above Work Orders

CRAFT DELIVERY SCHEDULE:

80IM0303: 01 SEP 2015 05 OCT 2015

80IM0621, 80CM0304,

80CM0308, 80RM0302 02 OCT 2015 30 OCT 2015

80CM0306, 80CM0310 07 OCT 2015 06 NOV 2015

88WT0304, 88CFPM0616,

80BM0616 12 OCT 2015 18 DEC 2015

Dates specified above represent the availability dates of the Craft.

SECTION L - INSTRUCTIONS, CONDITIONS AND NOTICES TO BIDDERS

The following have been modified:

RMC L-2-0007 INSPECTION OF VESSELS

(a) The vessel(s) will be available for inspection as follows:

Place: Naval Amphibious Base Coronado, California 92155

Date/Time: 9-10 July, 2015/0800 to 1600

(b) Arrangements for inspection may be made by communicating with:

Keith Goard (619) 520-9467 or Tom Lyons (619) 437-5756

(c) Offeror's representatives inspecting vessel(s) will be subject to security, safety, and other applicable regulations established by the activity at which the vessel(s) is/are located and the Commanding Officer of the vessel(s).

(End of Summary of Changes)