AMENDMENT 0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES 1 2

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

0002 12/31/2025 7477134

6. ISSUED BY Code N40085 7. ADMINISTERED BY (If other than item 6.) Code

FEAD CHERRY POINT

PSC BOX 8006

CHERRY POINT, NC 28533

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) 9A. AMENDMENT OF SOLICITATION Project Number 7477134 P990 Abandoned Piping Demo

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning 1 copy of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14. ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATION CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103 (b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER: (specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return original to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

AMENDMENT MUST BE ACKNOWLEDGED WITH YOUR PROPOSAL

Project Number 7477134 P990 Abandoned Piping Demo, MCAS Cherry Point, NC

The date and the hour for the receipt of proposals remains 7 January 2026 no later than 2:00 pm (EST).

See continuation pages.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR (Same as Item 8) 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV.1-83) 0224-3(10-90)

PREVIOUS EDITION UNUSABLE Prescribed by GSA

16C. DATE SIGNED

Block 14. DESCRIPTION OF AMENDMENT (cont.)

A. The purpose of this amendment is to respond to the following RFIs:

1. Please review $800.00 liquidated damages for delay, this appears higher than normal.

Response: Liquidated damages cost is consistent for the work and duration of the project.

2. Please add an addition 60 days for performance of the work.

Response: The contract duration will remain 45 days after contract award.

3. The specification specifically states that the SSHO cannot serve as the superintendent. There are no restrictions within the QC or Superintendent Specification requirements. Please confirm that this project requires the SSHO and Superintendent to be separate personnel.

Response: Refer to revised Specification Section 01 35 26.

4. The SSHO qualification requirement is unclear. The specification specifically states that the alternate SSHO can be a level one, two, or three SSHO however it does not provide the same clear and specific requirements for the primary SSHO. The specification noting that the alternate must be qualified compared to the primary SSHO leads to the understanding that a level one, two, or three Primary SSHO can perform the project. Please provide clarity on what level Primary SSHO is required.

Response: Refer to revised Specification Section 01 35 26.

5. What is the scope we will be required to complete for the revegetation of disturbed work area? Seed or Sod?

Response: Refer to revised Specification Section 31 00 00.

6. Due to the holiday period prior to this project’s bid date, we are experiencing limited subcontractor participation for this opportunity. To ensure a competitive and comprehensive proposal, we kindly request an extension of the bid due date.

Response: At this time, the proposal submission date remains 7 January 2026 by 2:00 PM

EST.

B. All other contract terms and conditions remain unchanged.

7477134 RFI Response.pdf