N40085/N4008518R731818-R-7318_-0001_Amend_NFAS_FAR_Sched.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICAITON NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicble)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICIATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a)By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPIRATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc. ) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION ( Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

J 1 2

0001 Aug 22, 2018

NAVFAC MID ATLANTIC PWD NEW LONDON

BOX 26, BLDG 135

NAVAL SUBMARINE BASE NEW LONDON GROTON CT

06349-5026

See Item #6

N40085-18-R-7318

Aug 2, 2018

N40085-18-R-7318: ATFP Off-Installation Facility Physical Security Improvements for at Naval Submarine Base New London, Groton CT

Revised Bid Schedule is attached.

The solicitation due date remains the same 4 September 2018 at 2:00 PM (EST).

the following clauses to this solicitation are replaced.

Michael A. Giangregorio

N40085-18-R-7318

14. a. NFAS 5252.228-9305 Notice of Bonding Requirements is replaced with

FAR 52.228-15, Performance and Payment Bonds – Construction.

And NFAS language:

NOTICE OF BONDING REQUIREMENTS

Within ___10__ days after receipt of award, the bidder/offeror to whom the award is made shall furnish the bonds required by FAR Clause FAR 52.228-15.

Bidders/offerors are hereby notified that the contract time for purposes of fixing the completion date, default, and liquidated damages will be as stated in FAR Clause 52.211-10

Commencement, Prosecution, and Completion of Work, regardless of when performance and payment bonds or deposits in lieu of surety are executed.

(End of NAVFAC language)

b. 5252.236-9307 DRAWINGS PREPARED BY AN ARCHITECT-ENGINEER (JUN

1994) is replaced with the following requirement per NFAS 36.609-102 NAVFAC:

DRAWINGS PREPARED BY AN ARCHITECT-ENGINEER

The engineer or architect signing the drawings must be registered in the country of record for the architect-engineer firm or the country of the proposed construction -- as a Professional Engineer

(P.E.) or Registered Architect (R.A.). In addition, the drawings shall be signed by a responsible person of corporate status in the architect-engineer firm and stamped with his/her registration seal when the seal is authorized by the country where the project is to be constructed.

(End of NAVFAC language)

c. 5252.236-9309 KEY PERSONNEL (JUN 1994) is replaced with the following NFAS requirement: NFAS 36.609-102 NAVFAC;

KEY PERSONNEL

The Architect-Engineer (A-E) shall employ the following professional personnel to perform the services required under this contract. Prior to starting work, the A-E will forward to the Contracting Officer a resume for the individual(s) assigned to each discipline to be utilized.

No substitution will be made without the advance written approval of the Contracting Officer, after he has reviewed the proposed replacement's experience and qualifications record submitted by the architect-engineer firm with explanation of the necessity for the change. No increase in salary rates will be allowed when personnel substitution is authorized.

DISCIPLINE NAME JOB TITLE

(End of NAVFAC language)

d. NFAS 5252.236-9312 DESIGN-BUILD CONTRACT- ORDER OF PRECENDENCE

(AUGUST 2006) is deleted from the solicitation.

e. NFAS 5252.236-9304, UTILITIES FOR CONSTRUCTION AND TESTING (JUNE

1994) is replaced with: NFAS; 36.5-100 NAVFAC;

UTILITIES FOR CONSTRUCTION AND TESTING

The Contractor shall be responsible for obtaining, either from available Government sources or local utility companies, all utilities required for construction and testing. The

Contractor shall provide these utilities at his expense, paid for at the current utility rate delivered to the job site. The Contractor shall provide and maintain all temporary utility connections and distribution lines, and all meters required to measure the amount of each utility used.

(End of NAVFAC language)

Does Contractor provide all of his own utilities? Yes

f. NFAS 5252.214-9301, NOTICE TO BIDDERS (JUN 1994) is replaced with FAR

52.214-12, Preparation of Bids.

g. FAR Clause 52.211-12, Liquidated Damages—Construction is changed as follows:

Liquidated damages: $600.00 per calendar day for base and 1st Option (see breakdown table below) if awarded together.

CLIN Item LDs Duration/Days Notes:

1 Base Price-NL $450.00 380

2 Option Item No. 1 - NP $200.00 380 Days from Option Award

Total (If awarded together) $600.00 380

Duration if Base and Option are awarded together

h. There is an updated bid schedule attached to this amendment. An explanation of the schedule is as follows:

The intent is for the contractor to provide a price to perform site surveys to complete the checklist and document existing conditions at all of the listed facilities as one lump sum in

0001AA.

The contractor should provide a unit price for 1 square foot of window film in CLIN

0001AF. The total price for CLIN 001AF should be the square foot price times 3000 square foot. We will modify the contract based on an approved/negotiated area of film after government review of the survey results. However, the contract should expect the final amount to be at least the 1000 square foot minimum area listed in the description.

For the remaining CLINs, the contractor should provide a unit price for 1 of each of the items. The total price for each CLIN should be the unit price times the number of units listed for that item. We will modify the contract based on an approved/negotiated numbers of each item to be installed after government review of the survey results. However, the contract should expect the final amount to be at least the minimum number of items for each description listed.

Example 1, CLIN001AB requests a unit price for 1 door. The number of units is 1. The total price for CLIN 0001AB will be the price of 1 door, but we may not award any door installations because the minimum number in the description is 0.

Example 2, CLIN001AD1 requests a unit price for 1 doorbell. The number of units is 5.

The total price for CLIN 0001AD1 will be the price of 5 doorbells, but may only award 1 doorbell installations because the minimum number in the description is 1.

The successful contractor will be awarded a contract to start the site surveys listed in

CLIN 0001AA. There will be a planned MOD to the contract to award negotiated quantities on the remaining CLINs. The funding document will have funds to cover award of the sum of the

"Total Price for CLIN" spreadsheet column for all CLINs.

I. There will be no tax exemption forms for this solicitation issued.

j. POC for this amendment is Mike Giangregorio. Michael.giangregorio@navy.mil.

k. Rhode Island Wages have been updated: RI180001 08032018 RI1 Amend 01 mailto:Michael.giangregorio@navy.mil