N4008018Q1023.pdf

ROICC

DEIDRE PARKER

BLDG. 2004 BARNETT AVE

P.O. BOX 1855

QUANTICO VA 22134-0855

TEL: 703-784-5459 FAX:

ACQR5148610

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

N4008018Q1023 12-Apr-2018 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

PUBLIC WORKS DEPARTMENT

FEAD

P.O. BOX 1855

BLDG. 2004 BARNETT AVE.

QUANTICO VA 22134

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

14-May-2018(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

703-784-5459DEIDRE PARKER

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

N4008018Q1023

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Project Install Secure PDS & Camera Systems

FFP

The contractor shall provide all labor, equipment, materials and supervision in order to install secure PDS in B-1998 & Camera Systems in B-1998 & B-3025 at MCB Quantico, VA in accordance with attached scope of work. Contractors are required to submit invoices electronically at https://wawf.eb.mil.

FOB: Destination

PURCHASE REQUEST NUMBER: ACQR5148610

NET AMT

Section C - Descriptions and Specifications

SOW

SCOPE OF WORK

1. Background.

1.1. The purpose of this project is to restore existing cable infrastructure to Building 3070 in order to support a command personnel reorganization.

2. Construction General Conditions

2.1. All work to be completed at building 3070 located aboard MCB Quantico.

2.2. Contractor is responsible for all means, methods, supervision and coordination to produce a quality finished product. Time is of the essence, and this project shall be given due consideration and staffing. The contractor must provide all equipment, material, and labor necessary to complete scope of work, described herein.

2.3. The contractor shall identify the personnel responsible for the work. In compliance with Public Works Branch (PWB), Marine Corps and NAVFAC requirements.

2.4. Any discrepancy between the scope of work (SOW) and actual job conditions found during the project progress should be immediately reported to the KO & COR in writing.

2.5. In the case of inconsistencies, the contractor shall contact the COR, identify the inconsistency, and seek guidance. Contractor is responsible for providing any requests for information (RFI) in writing.

2.6. Contractor agrees to warrant work for a period of 365 calendar days (or twelve (12) months which-ever is longer) from the date of acceptance by the COR. Warranty will be furnished in writing and must accompany Contractor’s final invoice.

2.7. Materials. All materials required for the entire project shall meet industry standards, shall be new, free from all defects, of the best grade and quality, and entirely satisfactory for the purpose intended and shall be furnished in sufficient quantities to prevent delay.

2.8. The Contractor is advised that this installation does not currently possess personnel.

2.9. Work is to be completed by February 28, 2018.

2.10. The Contractor must be aware that Quantico MCB is a controlled access installation, and as a result requires photographic identification and the potential of vehicle inspection in order to gain entrance onto the installation. Detention, delay, and or other challenges presented to the contract as a result of this fact are the sole responsibility of the contractor.

2.11. The Contractor is to execute such work over whatever hours are required, inclusive of normal, weekend, overtime, alternate work time, as required to complete the work at no additional cost to the government within the prescribed period of performance. The contractor shall schedule and coordinate non-normal working hours work with the COR.

2.12. Work shall be carried out on consecutive days and completed within the aforementioned contract performance period.

2.13. The Contractor is to comply with local noise ordinances.

2.14. Contractor will have access to the site through the main gate.

2.15. Safety in accordance with the Contractor’s Safety Program. The Contractor will furnish three copies of their safety program to the KO & COR upon request (a copy of this plan will be held by the COR and the Quantico MCB Safety Office). The contractor shall be responsible for safety of employees, and Government employees within the work site premises during all operations in accordance with all Government safety requirements and guidance (EM-385-1-1) including the contractor providing and supervising the appropriate use of all personal protective equipment.

2.16. Any incident involving injury to Contractor’s employees or property damage must be immediately reported to the PWB Contracting Officer’s Representative (COR) and Quantico MCB Safety Office.

2.17. Safety Requirements and Reports.

2.17.1. During the performance of work under this contract, the Contractor shall strictly adhere to Environmental Protection Agency Regulations (EPA), Federal Occupational Safety and Health Regulations (OSHA), U.S. Army Corps of Engineers Safety and Health Handbook (EM-385-1-1), as well as all applicable state and local requirements.

2.18. Fire Protection.

The Contractor shall handle and store all combustible supplies, materials, waste and trash in a manner that prevents fire hazards to persons, facilities, and materials. Contractor must coordinate with the COR or KO to receive hot work permits from the Quantico MCB Fire Department. Must contact fire dispatch (703-784-2636) at least 72 hours in advance for the hot work permit.

2.18.1.

2.19. Environmental Protection.

2.19.1. The contractor shall comply with all applicable federal, state, and local laws, and with the regulations and standards. All environmental protection matters shall be coordinated with the KO. Inspection of any of the facilities operated by the Contractor may be accomplished by PWB Environmental Division and/or Safety personnel, or authorized officials on a no-notice basis at any time.

2.19.2. In event a regulatory agency assesses a monetary fine against the Government for violations caused by Contractor negligence, the Contractor shall reimburse the Government for the amount of that fine and other costs.

The Contractor shall also clean up any oil spills that result from the Contractor’s operations. The Contractor shall comply with the instructions from the Quantico MCB Industrial Hygienist with respect to avoidance of conditions which create a nuisance or which may be hazardous to the health of military of civilian personnel.

2.19.3. Air Program. Coatings must comply with VOC limits in 9 VAC 5-45, Article 5. Mastic texture coatings are limited to 300 grams VOC per liter of product. Primers, sealers, and undercoats are limited to 200 grams VOC per liter of product.

2.19.4. The contractor shall provide a list of all Hazardous Materials to be used on the Post and a MSDS shall be provided for each material listed.

2.20. Disposal.

2.20.1. Before completion of work each day, the Contractor shall secure all supplies, materials and equipment.

Contractor shall also remove all scrap, debris, etc. and dispose of off-post, unless otherwise directed elsewhere in this SOW and leave the job site in a clean, orderly and safe manner each day

2.20.2. Debris, rubbish, hazardous waste and unusable material resulting from the work under this contract shall be disposed of by the Contractor legally and in compliance with all regulations as may pertain at his expense off of Government property.

2.20.3. All recyclable materials; aluminum and metal cans, glass bottles and jars, plastic bottles, newspapers, cardboard, high grade paper, mixed paper, scrap metal, scrap lumber, pavement debris, and vegetation wastes shall be segregated, removed from the Post, and disposed of in accordance with Department of Defense recycling and solid waste management regulations.

2.20.4. Hazardous waste must be disposed of in accordance with the Resource Conservation and Recovery Act.

2.20.5. Hazardous Materials: Projects that are under contract: Materials that are contractor procured must be removed from base once job has been completed. You are not to leave it behind. A list of all Hazardous Materials USED for the project must be reported to NREA once job has been completed (list may be faxed to (703)784-4953.

SDS (MSDS) must be kept on hand at all times and produced when requested.

2.20.6. To ensure compliance with EO 13514 waste diversion guidance, the contractor shall use the Construction Waste Management Report form to report the disposal of all recyclable materials, debris, rubbish, hazardous waste and unusable material resulting from the work under this contract through the KO/COR to NREA Solid Waste Program Manager.

2.21. Permits: The Contractor shall, without additional expense to the Government, obtain all appointments, licenses, and permits required for the prosecution of the work. The Contractor shall comply with all applicable federal, state, and local laws. Evidence of such permits and licenses shall be provided to the KO before work commences.

2.22. Notwithstanding any other provisions of this scope of work (SOW), the Contractor shall comply with applicable rules, laws, regulations and policies, in effect at Quantico MCB, and all US laws.

2.23. Contractor shall ensure they comply with any and all additional provisions as applicable to contractors working at Quantico MCB. The contractor is presumed to be fully aware and have full knowledge of any and all policies, procedures and requirements to work on this installation, and is to seek clarification on any specific provision that they are unclear about from the COR if this is not the case.

2.24. All Government design manual standards, the United Facilities Criteria (as posted on www.wbdg.org), the latest edition of the International Building Code (IBC) 2006, (inclusive of Section 1025, “Emergency Escape and Rescue”), and other applicable industry standards, or better, are to be complied with unless otherwise stated. The Authority Having Jurisdiction for the applicability of any and all code provisions is the Chief, Engineering Division, Quantico MCB PWB.

2.25. Unless otherwise indicated, the Government is represented by the CM. The CM for this contract is TBD.

2.26. Smoking will be prohibited anywhere on the Post so designated on Government property and at all times in such locations, smoking will be permitted in designated areas.

2.27. Site Restoration

2.28. Contractor will be allowed to use Government restrooms; however, the Contractor will ensure they are cleaned after use to the satisfaction of the PM.

2.29. The contractor is fully and totally responsible for the condition of the work and the work site en masse until the work is formally accepted by the government. As a consequence, the contractor may be required to execute rework until such time as formal acceptance of the work is made by the government.

2.30. Contractor shall repair any and all damaged items as a result of his efforts not included in this SOW, to their original condition or better.

2.30.1. On-going site cleanup and final site restoration is required in this contract.

2.30.2. The contractor will be held responsible to repair any damage to the structures, the site and/or property as part of this contract to the satisfaction of the Government.

2.30.3. Routine cleanup of the project will encompass all areas used by the contractor during construction.

2.31. The Contractor shall coordinate any oversized deliveries with the COR in order to allow access to the installation through the proper gate.

2.32. Contractor is required to visit the site prior to submission of a proposal. Contractor is responsible and will execute such measurements and calculations to determine the quantities required to execute the work described herein for bidding, construction estimating, and work execution. The Government will make no guarantee or other confirmation of the applicable quantities, the Contractor makes these determinations at their own risk.

2.33. POC’s for project:

2.33.1. MCCOG POC: Andrew Crofford

MCCOG, Comm Branch

(W) 703-432-8681 Andrew.Crofford@usmc.mil

2.33.2. SOW writer POC: NA

NA

(W) NA

2.33.3. NAVFAC POC if available

3. Government Provided Items:

4. Selective Demolition:

5. Architectural Work:

6. Civil Work:

7. Structural Work:

8. Mechanical Work:

9. Plumbing Work:

10. Electrical Work:

10.1. Install a 12 strand single mode fiber cable from MHV3 into Building 3070. Splicing within the manhole and termination within the closest are required.

10.2. Install a new network rack

10.3. Provide and install new network Cat5e patch panels and voice grade patch panels.

10.4. Existing wall jacks have 2 data / 2 voice ports. Any new/replaced wall jacks require the same capability.

10.5. If existing cable is unable to be restored, it is to be replaced with industry standard or better equivalent cabling.

10.6. Approximately 70 total workstation outlets are required within the space.

10.7. There are 6 existing office spaces (See 12.1 for details) that currently have 2 existing wall jack outlets.

Each office will require the installation of 2 additional wall jacks (2 data /2 voice). Empty flexible conduits and outlet boxes with pull strings exist in each office.

10.8. Existing wall jacks and face plates are Hubbell. All new and replaced face plate will be Hubbell.

10.9. Provide and install 4 Tellabs 24-Port rack mounted ONT’s.

10.10. Provide and install 25 pair male to male cables for connection from ONT’s to voice grade panels.

11. Construction/Product Submittals:

11.1. Project Schedule

11.2. Project Schedule of Values

11.3. Project Superintendent

12. Miscellaneous Drawings

12.1. Drawing A:

End of Scope of Work

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 120 dys. ADC 1 ROICC

DEIDRE PARKER

BLDG. 2004 BARNETT AVE

P.O. BOX 1855

QUANTICO VA 22134-0855

703-784-5459 FOB: Destination

N40080

Section G - Contract Administration Data

GENERAL REQUIREMENTS

GENERAL REQUIREMENTS

PROJECT NAME: Install Secure PDS into B-1998 and Camera Systems into B-1998 & B-3025

NAICS: 238210

A. Solicitation is 100% Small Business.

B. All work shall be performed in accordance with the attached Statements of Work, dated 11/4/2017.

C. The magnitude of this project is between $50,000 and $100,000.

D. Proposals must be received not later than COB 5/16/2018.

E. Proposal must be valid for 60 days.

F. Point of Contact (POC) is as follows:

Deidre Parker, Contract Specialist 703-784-5459, deidre.parker@navy.mil Contracting Officer Lisa Coyle at 703-784-1196, lisa.t.coyle1@navy.mil

G. A Site visit will be held Thursday 4/19/2018 at 9:00 AM EST at B-2004 and proceed to B-1998 then B- 3025.

H: RFIs are to be submitted via email to Deidre Parker at deidre.parker@navy.mil by COB 4/25/2018.

I. Notice to Offeror(s): The Government reserves the right to cancel this solicitation, either before or after the closing date for receipt of proposals; the Gov. has no obligation to reimburse an offeror for any quotation costs.

J. Criteria for award selection will be as follows: 1) Lowest Price; 2) Past Performance;

3) Contractor attendance at scheduled site visit; 4) Contractor has requisite NAICS code in SAMS

K. THE SITE VISIT IS MANDATORY TO BE CONSIDERED FOR AWARD.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under and Federal Law

FEB 2016

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law

FEB 2016

52.211-10 Commencement, Prosecution, and Completion of Work APR 1984 52.211-10 Commencement, Prosecution, and Completion of Work APR 1984 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-14 Limitations On Subcontracting JAN 2017 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-16 Approval of Wage Rates MAY 2014 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-27 Affirmative Action Compliance Requirements for Construction

APR 2015

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-3 Protest After Award AUG 1996

52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-13 Accident Prevention NOV 1991 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.236-27 Site Visit (Construction) FEB 1995 52.237-1 Site Visit APR 1984 52.242-14 Suspension of Work APR 1984 52.243-1 Changes--Fixed Price AUG 1987 52.243-5 Changes and Changed Conditions APR 1984 52.243-6 Change Order Accounting APR 1984 52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.204-7006 Billing Instructions OCT 2005 252.219-7011 Notification to Delay Performance JUN 1998 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.228-7004 Bonds Or Other Security DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (NOV 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238210.

(2) The small business size standard is $15,000,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225- 5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

X (i) 52.204-17, Ownership or Control of Offeror.

X (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JAN 2017).

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(iii) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(iv) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(v) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(vi) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(vii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (JAN 2017).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States). (For purposes of this clause, ``United States'' includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S.

Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)(A) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O 13627) (Applies to all solicitations and contracts).

(B) Alternate I (MAR 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (Executive Order 13658) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (MAY 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR[supreg] Program or Federal Energy Management Program (FEMP) will be--

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (June, 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent;

or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American--Supplies (MAY 2014) (41 U.S.C. chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition--

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (JUL 2013) (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) database as its source of EFT information.)

(xx) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information.)

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. App. 1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).)

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (June, 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000).

(iii) 52.211-17, Delivery of Excess Quantities (SEP 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

FAR:https://www.acquisition.gov/browsefar

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights--

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination.

The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(End of clause)

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order N40080-18-P-1023

(1) Document type. The Contractor shall use the following document type(s).

Navy Construction/Facilities Management Invoice

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

Inspection- N44199 Acceptance- N44199

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC N68732 Issue By DoDAAC N44199 Admin DoDAAC N44199 Inspect By DoDAAC N44199 Ship To Code N/A Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) N/A Service Acceptor (DoDAAC) N/A Accept at Other DoDAAC N/A LPO DoDAAC N44199

DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A Accept By N44199

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

Quanticoinvoice@navy.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

deidre.parker@navy.mil

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

5252.201-9300 Contracting Officer Authority (JUN 1994)

CONTRACTING OFFICER AUTHORITY (JUN 1994)

In no event shall any understanding or agreement between the Contractor and any Government employee other than the Contracting Officer on any contract, modification, change order, letter or verbal direction to the Contractor be effective or binding upon the Government. All such actions must be formalized by a proper contractual document executed by an appointed Contracting Officer. The Contractor is hereby put on notice that in the event a Government employee other than the Contracting Officer directs a change in the work to be performed or increases the scope of work to be performed, it is the Contrator’s responsibility to make inquiry of the Contracting Officer before making the deviation. Payments will not be made without being authorized by an appointed Contracting Officer with the legal authority to bind the Government.

(END OF CLAUSE)

5252.236-9303 Accident Prevention

ACCIDENT PREVENTION (NOV 1998)

(a) The Contractor will maintain an accurate record of, and will report to the Contracting Officer in the manner and on the forms prescribed by the Contracting Officer, all accidents resulting in death, traumatic injury, occupation disease, and damage to property, materials, supplies and equipment incident to work performed under this contract.

(b) Compliance with the provisions of this article by subcontractors will be the responsibility of the Contractor.

(c) Prior to commencement of the work, the Contractor may be required to:

(1) submit in writing his proposals for effectuating provision for accident prevention;

(2) meet in conference with representatives of the Contracting Officer to discuss and develop mutual understanding relative to administration of the overall safety program. (End of Clause).

5252.236-9304 Utilities For Construction and Testing.

UTILITIES FOR CONSTRUCTION AND TESTING (JUN 1994)

The Contractor shall be responsible for obtaining, either from available Government sources or local utility companies, all utilities required for construction and testing. The Contractor shall provide these utilities at his expense, paid for at the current utility rate delivered to the job site. The Contractor shall provide and maintain all temporary utility connections and distribution lines, and all meters required to measure the amount of each utility used. (End of clause)

5252.236-9305 Availability of Utilities.

AVAILABILITY OF UTILITIES (JUN 1994)

When available, the Government will furnish reasonable amounts of the following utilities for the work to be performed under this contract at no cost to the Contractor. Information concerning the location of existing outlets may be secured from the OIC. The Contractor shall provide and maintain, at his expense, the necessary service lines from existing Government outlets to the site of work.

Electric - Water - Compressed Air

Contractor Furnished Utilities. In the event that the Government is unable to provide the required types of utilities, the Contractor shall, at his expense, arrange for the required utilities.

Contractor Energy Conservation. The Contractor shall be directly responsible for instructing employees in utilities conservation practices. The Contractor shall be responsible for operating under conditions which preclude the waste of utilities, which shall include:

a. Lights shall be used only in areas where and at the time when work is actually being performed.

b. Mechanical equipment controls for heating, ventilation and air conditioning systems will not be adjusted by the workers.

c. Water faucets or valves shall be turned off after the required usage has been accomplished.

Telephone Lines. Telephone lines for the sole use of the contractor will not be available. Government telephones shall not be used for personal reasons.

Contractor Availability. The contractor shall maintain a telephone at which he or his representative may be reached 24 hours daily. The telephone shall be listed in the contractor's name. If the contractor does not have a local telephone, he shall maintain a toll free emergency telephone (or accept collect calls from authorized Government personnel) at which he or his representative may be reached at night, weekends and holidays. It is mandatory that the contractor or his representative be available to a toll-free telephone 24 hours per day, seven days per week, including holidays. He shall notify the OIC in writing of the mailing address and telephone number within three days after award of this contract and immediately thereafter in the event of change. (End of clause)

Section J - List of Documents,…