RFP_N40027-19-R-1002.pdf

CODE

(Hour)

PAGE(S)

until local time

X

A

X B

X C X D

EX

X

G

F 61 - 79

80 - 91

X H 92 - 94 chris.oconnor1@navy .mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

DO-A3 1 94

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

N40027 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

CHRIS O'CONNOR (904) 270-5126 X 3360

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

1 - 2

3 - 12

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

13 - 25

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

28 - 29 X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 30 - 35 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 36 - 43 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

44 - 59

PART II - CO NTRACT CLAUSES

COMMANDER SOUTHEAST REGIONAL MAINTENANCE

CTR P.O. BOX 280057, MAYPORT NAVAL STATION

JACKSONVILLE FL 32228-0057

(904) 270-5126 EXT 3259

(904) 270-5056FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.

N4002719DECK2019

5. DATE ISSUED

01 Feb 2019

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

N4002719R1002

Section A - Solicitation/Contract Form

MINIMUM / MAXIMUM

CONTRACT MINIMUM/MAXIMUM QUANTITY AND CONTRACT VALUE

The minimum quantity and contract value for all orders issued against this contract shall not be less than the minimum quantity and contract value stated in the following table. The maximum quantity and contract value for all orders issued against this contract shall not exceed the maximum quantity and contract value stated in the following table.

MINIMUM MINIMUM MAXIMUM MAXIMUM

QUANTITY AMOUNT QUANTITY AMOUNT

N/A $1,800.00 N/A $12,000,000.00

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

CLIN

Number

UNDEFINED Each

Interior Decks - Base Year

FFP

Interior Decks - Base Year Reference Exhibit A for Base Year Effort.

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

PURCHASE REQUEST NUMBER: N4002719DECK2019

PSC CD: J998

MAX

NET AMT

UNIT UNIT PRICE MAX AMOUNT

CLIN

OPTION Interior Decks - Option YR 1

Interior Decks -Option YR 1 Reference Exhibit B for Option Year ONE effort.

unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

PSC CD: J998

UNIT UNIT PRICE MAX AMOUNT

CLIN

OPTION Interior Decks - Option YR 2

Interior Decks -Option YR 2 Reference Exhibit C for Option Year 2 effort.

unique identification or a DoD recognized unique identification equivalent.

UNIT UNIT PRICE MAX AMOUNT

CLIN

OPTION Interior Decks - Option YR 3

Interior Decks -Option YR 3 Reference Exhibit D for Option Year 3 effort.

unique identification or a DoD recognized unique identification equivalent.

UNIT UNIT PRICE MAX AMOUNT

CLIN

OPTION Interior Decks - Option YR 4

Interior Decks -Option YR 4 Reference Exhibit E for Option Year 4 effort.

unique identification or a DoD recognized unique identification equivalent.

UNIT UNIT PRICE MAX AMOUNT

CLIN

UNDEFINED

DATA for CLINs 0001, 0002 - 0005

FFP

Contract Data Requirements List (CDRL) DD Form 1423, Exhibits A and B.

Price to be included in CLINS 0001 - 0005. Data for CLINs 0002-0005 if exercised.

CLAUSES INCORPORATED BY FULL TEXT

HQ B-2-0004 EXPEDITING CONTRACT CLOSEOUT (NAVSEA) (DEC 1995)

(a) As part of the negotiated fixed price or total estimated amount of this contact, both the Government and the

Contractor have agreed to waive any entitlement that otherwise might accrue to either party in any residual dollar amount of $500 or less at the time of final contract closeout. The term “residual dollar amount” shall include all money that would otherwise be owed to either party at the end of the contract, except that, amounts connected in any way with taxation, allegations of fraud and/or antitrust violations shall be excluded. For purposes of determining residual dollar amounts, offsets of money owed by one party against money that would otherwise be paid by that party may be considered to the extent permitted by law.

(b) This agreement to waive entitlement to residual dollar amounts has been considered by both parties. It is agreed that the administrative costs for either party associated with collecting such small dollar amounts could exceed the amount to be recovered.

NOTE B - Option item to which the option clause in SECTION I-2 applies and which is to be supplied only if and to the extent said option is exercised.

STATEMENT OF WORK

The contractor shall furnish the necessary management, material support services, labor, supplies and equipment in order to provide INTERIOR DECKING in accordance with SSP: SERM-DECK-19-0004, Attachment J-1 on all vessels (homeported, visiting ships, and barges) located in the Jacksonville homeport area within 30 days of contract award.

Delivery order may consist of multiple line items. The contractor may be required to respond to more than one requirement (simultaneous delivery orders for more than one Navy vessel/barge).

The contractor shall prepare for and accomplish interior decking on various naval vessels as specified herein and in accordance with standard items as listed in specification item index, for the following work item specifications:

077-11-001 634-11-001 634-11-002 634-11-003 634-11-004 634-11-005

634-11-006

The following Category ONE FY 20 Standard items are applicable for this solicitation.

009-01, 009-03, 009-04, 009-06, 009-07, 009-10, 009-24, 009-40, 009-69, 009-74, 009-93, 009-111, and

009-120

The following NAVSEA FY 20 Local Standard items are applicable for this solicitation.

099-01SE, 099-51SE, 099-58SE, 099-60SE, and 099-74SE

The following Category TWO FY 20 Standard items are applicable for this solicitation without further reference.

009-26 and 009-32

C.2 ORGANIZATION AND PERSONNEL

The contractor shall have an organization with the experience and ability to apply management techniques, methods and procedures required to complete the requirements of this solicitation. The contractor shall employ trained and technically qualified personnel to perform delivery orders for the duration of this contract. The contractor, upon request by the SUPERVISOR, shall substantiate the qualifications of any individual performing work under this contract.

C.3 GENERAL REQUIREMENTS

1) Official contractor vehicles will be permitted to make deliveries to the work site/vessel, as defined in the

RCP, only. No waterfront parking will be provided.

2) Simultaneous performance of multiple delivery orders for different ships/barges may be anticipated and required. Conversely, periods of weeks or months may lapse without orders, depending on the needs of the

Government.

3) The Contractor shall provide a quality management system meeting ISO 9000 series standards.

4) The Contractor shall manage subcontractors, including selecting, scheduling, managing, monitoring and controlling of subcontractors.

5) The Contractor shall manage all Safety/Security, including safety training, required first aid/medical services, fire protection/procedures, and physical yard security.

6) The Contractor shall control Hazardous Material/Waste. Satisfy all legal requirements and local &

NAVSTA Mayport requirements for removal, storage, and disposal of hazardous waste. This includes providing segregated storage of Hazardous Material, and obtaining all required State/Federal agency issued hazardous waste generator numbers and disposal documentation.

7) The contractor shall not commence any work unless it can be completed within the scheduled performance period.

8) The contractor shall coordinate space access/availability with the ship’s force point of contact (SFPOC) as designated in the DO, within 48 hours of scheduled start.

9) The contractor’s representative shall be required to attend progress and scheduling meetings, which may be held on a daily and/or weekly basis. The representative must be authorized to make management decisions, which in good faith, commit the contractor.

10) The Contractor is responsible for providing an experienced Safety Inspector/Fire Marshal who will accomplish daily inspections of the Contractor’s entire work area on the ship, together with the Contracting

Office’s Safety Representative. This Inspector or Fire Marshal shall not be one of the Contractor’s supervisors or superintendents normally assigned to the ship.

11) The Government is not obligated, nor is the Government limited to the quantities listed in the ELINs. The quantities listed are for estimating purposes only.

12) The contractor shall provide immediate verbal notification to the SUPERVISOR, followed in writing within 24 hours of verbal notification, any deterioration or damage caused or uncovered during surface preparation and/or installation.

13) The contractor shall maintain all documentation generated by this contract IAW FAR 4.7.

C5. PERDIEM/TRAVEL

No per diem or travel costs will be paid under this contract.

C6. DATA REQUIREMENTS

The data to be furnished hereunder shall be prepared in accordance with the Contract Data Requirements List, DD

Form 1423, Exhibit(s) A & B, attached hereto and are not separately priced.

C.7 DELAY/DISRUPTION

The Contractor shall coordinate the DO work effort with the Maintenance Team on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less in duration. Minor delays and/or disruptions are considered normal rather than unusual occurrences during the performance of requirements ordered under this contract.

If, during DO performance, delays greater than a minor delay indicated above are encountered, the Contractor shall immediately (verbally) notify the Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, and action taken to minimize impact.

C.8 SUBMISSION OF HAZARDOUS WASTE MANIFEST

Submission of the completed and signed Hazardous Waste Manifest forms, as required by the applicable Hazardous

Waste Handling and Disposal Work Item, shall be submitted directly to Southeast Regional Maintenance Center via the Navy Maintenance Database (NMD). The completed forms must be submitted and accepted by SERMC no later than 1400 local time, 30 days after the period of performance is completed (C+30).

C.9 GOVERNMENT FURNISHED MATERIAL

(a) Government Furnished Material (GFM) cited in the solicitation will be picked up at Warehouse

Building 191, unless other location(s) is/are specified in the contract. The successful offeror is to telephone the

Warehouse at (904) 270-5700 to coordinate the pickup of Government Furnished Material.

(b) Government property permanently removed from a vessel that requires a Property Administrator's disposition instructions, shall be properly prepared for shipment and be delivered as directed by the Property

Administrator. The distance between contractor's plant and location to be designated is estimated to be less than 75 miles (one way).

(c) GFM will be listed in paragraph 5 of the Work Item(s).

C.10 USE OF BLACK OXIDE COATED THREADED FASTENERS (BOCTFs)

Due to safety concerns, use of BOCTFs is not authorized when installing or replacing threaded fasteners in the accomplishment of any work required by any Work Item in this contract

C.11 CITIZENSHIP REQUIREMENTS

The contractor shall comply with the Department of Defense Industrial Security Manual (DoD 5220.22), and any revisions to that manual as of the Bid Opening Date prescribed, for verification of all U. S. Citizens.

Prospective offerors shall refer all questions pertaining to the above to the Southeast Regional Maintenance Center

(SERMC) Security Manager, phillip.actkins@navy.mil and carbon copy (cc) the contracting officer.

C.12 THREAT CONDITIONS

While the current Threat Condition is set at Bravo, Threat Condition Charlie shall be assumed when submitting a proposal for this solicitation. Any costs associated with delays, disruptions, or security precautions associated with

Threat Condition Charlie shall be included in your proposal. Contractors will not receive additional compensation for delays, disruptions, or security precautions associated with Threat Condition Charlie. Contractors are to expect delays upon gaining access to Naval Station Mayport and the vessel.

C.13 REQUIRED STANDARD OF WORKMANSHIP

Unless otherwise specifically provided in this contract, the quality of all services rendered hereunder shall conform to the highest standards in the relevant profession, trade, or field of endeavor. All services shall be rendered by or supervised directly by individuals fully qualified in the relevant profession, trade, or field, and holding any licenses required by law.

C.14 DOCUMENTS ACCEPTABLE FOR PROOF OF U.S. CITIZENSHIP

a. A certified birth certificate indicating the individual was born in the United States of America.

b. A U.S. Passport.

c. A certificate of naturalization if the individual claims citizenship by naturalization.

d. Report of Birth Abroad of a Citizen of the United States of America (Form FS-240), a Certification of

Birth (Form FS-545 or DS-1350), or a Certificate of Citizenship of Parents.

e. If primary evidence of U.S. Citizenship is not obtainable, then the best available secondary evidence, showing that the individual was born in the U.S., is required. Such evidence may include a combination of at least two of the following: a baptismal certificate; a hospital birth record; evidence of persons having personal knowledge of the facts of birth; or other documentary evidence, such as U.S. military records, early census, school or family

Bible records, insurance papers, or newspaper files. The secondary evidence must be adequate to support a “good faith” determination that the individual is in fact a U.S. citizen. Secondary evidence submitted as proof of birth in the U.S. shall be original or certified documents. Non-certified copies are not acceptable.

C.15 BERTHING OF VESSELS

Vessels in the Mayport Naval Station basin may be berthed next to a pier, or may be berthed out board of another vessel.

C.16 QUALITY ASSURANCE PROGRAM

The Contractor shall provide and maintain a quality assurance program acceptable to the Government, and shall perform or have performed the inspections and tests pursuant to that program to substantiate that the material and workmanship provided pursuant to the job order conform to the drawings, specifications, job orders, and contract requirements listed herein. The Contractor's quality assurance program shall be in accordance with that set forth in

Standard Item 009-04. In addition to its rights under DFARS Clause 252.217-7005, the Government shall have the right to deem work or material furnished by the Contractor to be incomplete and not in accordance with the requirements of the job order by reason of the Contractor's failure to comply with the requirements of its quality assurance program and, as such, the Contractor shall not be entitled to progress payments for said work and material.

C.17 UTILIZATION OF NMD

The successful offeror shall utilize the Navy Maintenance Database (NMD) program to perform administrative functions with the Government. The contractor must have access to NMD no later than five days after contract award.

Each individual needing access to NMD will require a PKI certificate. For additional information concerning NMD, please contact the Southeast Regional Maintenance Center ERP Business Office Help Desk at:

SERMC_MYPT_ERP_HELPDESK@navy.mil

C.18 SENSITIVE WEAPONS TECHNOLOGIES INFORMATION

mailto:SERMC_MYPT_ERP_HELPDESK@navy.mil

All technical data provided to the Contractor by the Government will be protected from public disclosure in accordance with the markings contained thereon. All other information relating to items to be delivered or services to be performed under this contract may not be disclosed by any means without prior approval of the authorized representative of the Contracting Officer. Dissemination or public disclosure includes, but is not limited to, permitting access to such information by foreign nationals or by any other person or entity; publication of technical or scientific papers; advertising; or any other proposed release. The Contractor shall provide adequate physical protection to such information so as to preclude access by any person or entity not authorized such access by the Government.

C.19 PLANS, DRAWINGS AND OTHER REFERENCE DATA

(a) Drawings, plans and test memos will be available through the following website:

https://nsedr.nnsy.navy.mil/webjedmics/index.jsp and https://mercury.tdmis.navy.mil/

The above website requires registration and approval prior to having full access to reference material. If not previously registered, the contractor will not have enough time to complete the requirements of registration. The offeror is required to retrieve the necessary documents from the following location during normal business hours:

Southeast Regional Maintenance Center (SERMC)

Bldg. 1488, Tech Library

Mayport Naval Station FL 32228-0057

Email: SERMC_MYPT_Code_400_PCO@navy.mil and kathy.dugan@navy.mil

(b) NAVSHIPS Technical Manual, NAVSHIP NOTES, MIL-Standards, MIL SPEC, NAVSHIP Instructions, Electronics Field Change Bulletins, Electronic Information Bulletins, Navy Medical Manuals, General

Specifications for Ships for the U.S. Navy (NAVSEA 5990-AA-SPN-010/GEN-SPEC), Design Service Allocation

Manual (NAVSHIPS 0900-060-0210), and NAVSEA S9300-AW-EDG-010/EPISM (Electric Plant Installation-

Standard Methods) are available for inspection by offerors at the above address.

C.20 GOVERNMENT FURNISHED FACILITIES AND EQUIPMENT

(a) In accordance with the provisions of Section I, DFARS Clause 252.217-7010 entitled "Performance" and

"Place of Performance", this is the only provision in this contract for the Government to provide to the Contractor any facilities, equipment, or services. The Government will provide for use in connection with and under the terms of this contract the following:

(b) (1) Access to the vessel at: Naval Station Mayport

(2) Pier space, within the vicinity of the vessel, for location of Contractor equipment.

(c) The Contractor shall furnish all other necessary material, labor, services, equipment (i.e. air compressors, crane services), accessories, facilities, and such other things and services as are necessary for accomplishing the work specified in the contract subject to the rights reserved by the Government under Section I, FAR Clause 52.245-

2 entitled "Government Property".

C.21 USE OF OZONE DEPLETING SUBSTANCES

(a) In accordance with Section 326 of Pub. L. 102-484, the Department of Defense is prohibited from awarding any contract which includes a DoD-directed specification or standard that requires the use of a Class I ozone-depleting substance (ODS) or that can be met only through the use of such a substance unless such use has been approved by a senior acquisition official (SA)). The SAO approval is based on a technical certification that no suitable substitute for the ODS is currently available.

https://nsedr.nnsy.navy.mil/webjedmics/index.jsp https://mercury.tdmis.navy.mil/ mailto:SERMC_MYPT_Code_400_PCO@navy.mil mailto:kathy.dugan@navy.mil

(b) To comply with this statute, the Navy has screened the specifications and standards associated with this solicitation. To the extent that ODS requirements were revealed by this review they are identified below.

Class I ODS Identified Specification/Standard

(c) If offerors possess knowledge about any other Class I ODS required directly or indirectly by the specification or standards, the Navy would appreciate such information in your response to this solicitation.

Offerors are under no obligation to comply with this request and no compensation can be provided for doing so.

Section C - Descriptions and Specifications

HQ C-1-0001 DATA REQUIREMENTS (NAVSEA) (SEP 1992)

CLIN Item 0006 - The data to be furnished hereunder shall be prepared in accordance with the Contract Data

Requirements List, DD Form 1423, Exhibit(s) A0001-0018 and B0001-0002, attached hereto.

HQ C-2-0002 ACCESS TO PROPRIETARY DATA OR COMPUTER SOFTWARE (NAVSEA) (JUN 1994)

(a) Performance under this contract may require that the Contractor have access to technical data, computer software, or other sensitive data of another party who asserts that such data or software is proprietary. If access to such data or software is required or to be provided, the Contractor shall enter into a written agreement with such party prior to gaining access to such data or software. The agreement shall address, at a minimum, (1) access to, and use of, the proprietary data or software exclusively for the purposes of performance of the work required by this contract, and (2) safeguards to protect such data or software from unauthorized use or disclosure for so long as the data or software remains proprietary. In addition, the agreement shall not impose any limitation upon the

Government or its employees with respect to such data or software. A copy of the executed agreement shall be provided to the Contracting Officer. The Government may unilaterally modify the contract to list those third parties with which the Contractor has agreement(s).

(b) The Contractor agrees to: (1) indoctrinate its personnel who will have access to the data or software as to the restrictions under which access is granted; (2) not disclose the data or software to another party or other Contractor personnel except as authorized by the Contracting Officer; (3) not engage in any other action, venture, or employment wherein this information will be used, other than under this contract, in any manner inconsistent with the spirit and intent of this requirement; (4) not disclose the data or software to any other party, including, but not limited to, joint venturer, affiliate, successor, or assign of the Contractor; and (5) reproduce the restrictive stamp, marking, or legend on each use of the data or software whether in whole or in part.

(c) The restrictions on use and disclosure of the data and software described above also apply to such information received from the Government through any means to which the Contractor has access in the performance of this contract that contains proprietary or other restrictive markings.

(d) The Contractor agrees that it will promptly notify the Contracting Officer of any attempt by an individual, company, or Government representative not directly involved in the effort to be performed under this contract to gain access to such proprietary information. Such notification shall include the name and organization of the individual, company, or Government representative seeking access to such information.

(e) The Contractor shall include this requirement in subcontracts of any tier which involve access to information covered by paragraph (a), substituting "subcontractor" for "Contractor" where appropriate.

(f) Compliance with this requirement is a material requirement of this contract.

HQ C-2-0003 ACCESS TO THE NAVY SUPPLY SYSTEM (NAVSEA) (MAR 2011)

(a) In compliance with the comparability requirement of 10 U.S.C. 7314, Public and Private Shipyards will be provided equal access to the Naval Supply System. Use by private yards is permissive, not mandatory.

(b) Pursuant to the clause of this contract entitled "GOVERNMENT SUPPLY SOURCES" (FAR 52.251-1) the

Contracting Officer hereby authorizes the Contractor to place orders with the Navy Supply System for materials and equipment or other supplies necessary to perform the required work. The Naval Supply System shall process such orders in the same manner as it would for any other Navy supply user, and the Contractor shall make payment on account of materials and equipment and other supplies ordered and/or received in accordance with the normal requirements of the Naval Supply Systems Command, but in no event shall payment in full be any later than 30 days after receipt by the Contractor of each order. The Contractor shall pay the Naval Supply System any costs for materials, equipments, or other supplies obtained including any surcharges normally charged to any other Naval

Supply System user.

(c) This job order has been priced on the basis that, except as specifically provided elsewhere in this contract with regards to Government furnished property, the Contractor shall provide all necessary materials, equipment and supplies for performance of this contract. If the Contractor uses the Naval Supply System, it has elected to use the system for its own convenience to meet its contractual obligations to perform the work under this contract. The

Naval Supply System is considered to be an alternate source or vendor of contractor furnished material; therefore materials, equipments, or other supplies ordered and/or obtained from the Naval Supply System are specifically not considered to be Government furnished material, but are considered to be contractor furnished material. The

Government makes no representation as to the availability of materials, equipments, or other supplies for the performance of the work required under this contract, nor shall unavailability, late delivery, delivery of non-conforming supplies, higher costs of the Naval Supply System (if any), or any failure of the Naval Supply System to meet the expectations or requirements of the Contractor constitute excusable delay or grounds for equitable or any other adjustment to the contract or relief from the requirement to perform in accordance with the terms of the

HQ C-2-0004 ACCESS TO THE VESSEL(S) (NAVSEA) (SEP 2016)

Officers, employees and associates of other prime Contractors with the Government and their subcontractors, shall, as authorized by the Supervisor, have, at all reasonable times, admission to the plant, access to the vessel(s) where and as required, and be permitted, within the plant and on the vessel(s) required, to perform and fulfill their respective obligations to the Government. The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Supervisor to be given admission to the plant and access to the vessel(s) for office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of the respective responsibilities involved, and reasonable to their performance.

HQ C-2-0005 ACCESS TO THE VESSELS BY NON-U.S. CITIZENS (NAVSEA) (SEP 2016)

(a) No person not known to be a U.S. citizen shall be eligible for access to naval vessels, work sites and adjacent areas when said vessels are under construction, conversion, overhaul, or repair, except upon a finding by

COMNAVSEA or his designated representative that such access should be permitted in the best interest of the

United States. The Contractor shall establish procedures to comply with this requirement and NAVSEAINST

5510.3 series in effect on the date of this contract or agreement.

(b) If the Contractor desires to employ non-U.S. citizens in the performance of work under this contract or agreement that requires access as specified in paragraph (a) of this requirement, approval must be obtained prior to access for each contract or agreement where such access is required. To request such approval for non-U.S. citizens of friendly countries, the Contractor shall submit to the cognizant Contract Administration Office (CAO), an Access

Control Plan (ACP) which shall contain as a minimum, the following information:

(1) Badge or Pass oriented identification, access, and movement control system for non-U.S. citizen employees with the badge or pass to be worn or displayed on outer garments at all times while on the Contractor's facilities and when performing work aboard ship.

(i) Badges must be of such design and appearance that permits easy recognition to facilitate quick and positive identification.

(ii) Access authorization and limitations for the bearer must be clearly established and in accordance with applicable security regulations and instructions.

(iii) A control system, which provides rigid accountability procedures for handling lost, damaged, forgotten or no longer required badges, must be established.

(iv) A badge or pass check must be performed at all points of entry to the Contractor's facilities or by a site supervisor for work performed on vessels outside the Contractor's plant.

(2) Contractor's plan for ascertaining citizenship and for screening employees for security risk.

(3) Data reflecting the number, nationality, and positions held by non-U.S. citizen employees, including procedures to update data as non-U.S. citizen employee data changes, and pass to cognizant CAO.

(4) Contractor's plan for ensuring subcontractor compliance with the provisions of the Contractor's ACP.

(5) These conditions and controls are intended to serve as guidelines representing the minimum requirements of an acceptable ACP. They are not meant to restrict the Contractor in any way from imposing additional controls necessary to tailor these requirements to a specific facility.

(c) To request approval for non-U.S. citizens of hostile and/or communist-controlled countries (listed in Department of Defense Industrial Security Manual, DOD 5220.22-M or available from cognizant CAO), Contractor shall include in the ACP the following employee data: name, place of birth, citizenship (if different from place of birth), date of entry to U.S., extenuating circumstances (if any) concerning immigration to U.S., number of years employed by

Contractor, position, and stated intent concerning U.S. citizenship. COMNAVSEA or his designated representative will make individual determinations for desirability of access for the above group. Approval of ACP's for access of non-U.S. citizens of friendly countries will not be delayed for approval of non-U.S. citizens of hostile communist-controlled countries. Until approval is received, Contractor must deny access to vessels for employees who are non-

U.S. citizens of hostile and/or communist-controlled countries.

(d) The Contractor shall fully comply with approved ACPs. Noncompliance by the Contractor or subcontractor serves to cancel any authorization previously granted, in which case the Contractor shall be precluded from the continued use of non-U.S. citizens on this contract or agreement until such time as the compliance with an approved

ACP is demonstrated and upon a determination by the CAO that the Government's interests are protected. Further, the Government reserves the right to cancel previously granted authority when such cancellation is determined to be in the Government's best interest. Use of non-U.S. citizens, without an approved ACP or when a previous authorization has been canceled, will be considered a violation of security regulations. Upon confirmation by the

CAO of such violation, this contract, agreement or any job order issued under this agreement may be terminated or default in accordance with the clause entitled "DEFAULT (FIXED-PRICE SUPPLY AND SERVICE)" (FAR

52.249-8), "DEFAULT (FIXED-PRICE RESEARCH AND DEVELOPMENT)" (FAR 52.249-9) or

"TERMINATION (COST REIMBURSEMENT)" (FAR 52.249-6), as applicable.

(e) Prime Contractors have full responsibility for the proper administration of the approved ACP for all work performed under this contract or agreement, regardless of the location of the vessel, and must ensure compliance by all subcontractors, technical representatives and other persons granted access to U.S. Navy vessels, adjacent areas, and work sites.

(f) In the event the Contractor does not intend to employ non-U.S. citizens in the performance of the work under this contract, but has non-U.S. citizen employees, such employees must be precluded from access to the vessel and its work site and those shops where work on the vessel's equipment is being performed. The ACP must spell out how non-U.S. citizens are excluded from access to contract work areas.

(g) The same restriction as in paragraph (f) above applies to other non-U.S. citizens who have access to the

Contractor's facilities (e.g., for accomplishing facility improvements, from foreign crewed vessels within its facility, etc.) except that, with respect to access to the vessel and worksite, the restrictions shall not apply to uniformed U.S.

Navy personnel who are non-U.S. citizens and who are either assigned to the ship or require access to the ship to perform their duties.

HQ C-2-0006 ADDITIONAL PROVISIONS RELATING TO GOVERNMENT PROPERTY (NAVSEA) (SEP 2009)

(a) For purposes of paragraph (h) of the clause entitled "GOVERNMENT PROPERTY" (FAR 52.245-1) in addition to those items of property defined in that clause as Government Property, the following shall also be included within the definition of Government Property:

(1) the vessel;

(2) the equipment on the vessel;

(3) movable stores;

(4) cargo; and

(5) other material on the vessel

(b) For purposes of paragraph (b) of the clause entitled "GOVERNMENT PROPERTY", notwithstanding any other requirement of this contract, the following shall not be considered Government Property:

(1) the vessel;

(2) the equipment on the vessel;

(3) movable stores; and

(4) other material on the vessel

HQ C-2-0007 APPROVAL BY THE GOVERNMENT (AT) (NAVSEA) (JAN 1983)

Approval by the Government as required under this contract and applicable specifications shall not relieve the

Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

HQ C-2-0014 CONTRACTOR'S PROPOSAL

(a) Performance of this contract by the Contractor shall be conducted and performed in accordance with detailed obligations to which the Contractor committed itself in its proposal *_________dated: *__________in response to

SERMC Solicitation No. N40027-19-R-1002.

(b) The Contractor's proposal is incorporated by reference and hereby made subject to the provisions of the "ORDER

OF PRECEDENCE" (FAR 52.215-8) clause of this contract. Under the "ORDER OF PRECEDENCE" clause, the

Contractor's proposal referenced herein is hereby designated as item (f) of the clause, following "the specification" in the order of precedence.

*To be filled at time of award.

HQ C-2-0016 DEPARTMENT OF LABOR SAFETY AND HEALTH STANDARDS FOR SHIP REPAIR (NAVSEA)

(APR 2015)

Attention of the Contractor is directed to the Occupational Safety and Health Act of 1970 (29 USC 651-678), and to the Safety and Health Regulations for Ship Repairing (29 CFR 1915), promulgated under Public Law 85-742, amending Section 41 of the Longshoremen's and Harbor Workers' Compensation Act (33 USC 941), and adopted by the Department of Labor as occupational safety or health standards under Section 6(a) of the Occupational Safety and Health Act of 1970 (See 29 CFR 1910.15). These regulations apply to all ship repair and related work, as defined in the regulations performed under this contract on the navigable waters of the United States including any dry dock and marine railway. Nothing contained in this contract shall be construed as relieving the Contractor from any obligations, which it may have for compliance with the aforesaid regulations.

HQ C-2-0018 DISPOSAL OF SCRAP (NAVSEA) (JAN 2008)

(a) All Government scrap resulting from accomplishment of any job order is the property of the Contractor to be disposed as it sees fit. Scrap is defined as property that has no reasonable prospect of being sold except for the recovery value of its basic material content. The determination as to which materials are scrap and which materials are salvage, will be made, or concurred in, by the duly appointed Property Administrator for the cognizant SUPSHIP or RMC Office.

(b) As consideration for retaining the Government's scrap, the Contractor's price for the performance of the work required herein shall be a net price reflecting the value of the Government scrap.

(c) This requirement is not intended to conflict in any way with the clauses of this contract entitled

"PERFORMANCE" (DFARS 252.217-7010) or "GOVERNMENT PROPERTY" (FAR 52.245-1) under the Master

Contract in effect at the time of job order award, nor does it relieve the Contractor of any other requirement under such clauses.

HQ C-2-0023 EXCLUSION OF MERCURY (NAVSEA) (MAY 1998)

Mercury or mercury containing compounds shall not be intentionally added or come in direct contact with hardware or supplies furnished under this contract.

HQ C-2-0024 EXTENSION OF COMMERCIAL WARRANTY (NAVSEA) (NOV 1996)

The Contractor shall extend to the Government the full coverage of any standard commercial warranty normally offered in a similar commercial sale, provided that such warranty is available at no additional cost to the

Government. The Contractor shall provide a copy of the standard commercial warranty with the item. The standard commercial warranty period shall begin upon the final acceptance of the applicable material or software.

Acceptance of the standard commercial warranty does not waive the Government’s rights under the “Inspection” clause, no does it limit the Government’s rights with regard to other terms and conditions of the contract. In the event of a conflict, the terms and conditions of the contract shall take precedence over the standard commercial warranty.

HQ C-2-0028 GOVERNMENT SURPLUS PROPERTY (NAVSEA) (SEP 1990)

No former Government surplus property or residual inventory resulting from terminated Government contracts shall be furnished under this contract unless (i) such property is identified in the Special Contract Requirements or (ii) is approved in writing by the Contracting Officer. Notwithstanding any such identification in the Special Contract

Requirements or approval by the Contracting Officer, the Contractor agrees all items or components described in this requirement shall comply in all respects with the specifications contained herein.

HQ C-2-0029 HEAVY WEATHER PLAN (NAVSEA) (JUN 1999)

In order to ensure that Naval vessels and material are protected during gales, storms, hurricanes and destructive weather, the Contractor is required to have a written Heavy Weather Plan (HWP) which assigns responsibilities and prescribes actions to be taken on the approach of and during heavy weather conditions as delineated in Local

Standard Item (LSI) 099-58SE. In accordance with LSI 099-58SE, the Contractor shall furnish to Southeast

Regional Maintenance Center (SERMC), U.S. Navy, a copy of such HWP, and shall make such changes in the plan as SERMC considers necessary and reasonable to protect and care for vessels and machinery and equipment to be installed therein.

In the event SERMC directs the Contractor to implement the HWP pursuant to LSI 099-58SE, the Contractor may submit to the Contracting Officer a request for reimbursement for costs resulting from such actions together with any documentation that the Contracting Officer may reasonably require. The Government shall reimburse the

Contractor for all reasonable, allowable and allocable costs resulting from the Contractor's implementation of the

HWP based on such Government direction.

(End of Clause)

HQ C-2-0030 INFORMATION AND DATA FURNISHED BY THE GOVERNMENT (FIXED-PRICE) (NAVSEA)

(SEP 2009)

(a) Contract Specifications. The Government will furnish, if not included as an attachment to the contract, any unique contract specifications set forth in Section C.

(b) Contract Drawings and Data. The Government will furnish contract drawings, design agent drawings, ship construction drawings, and/or other design or alteration data cited or referenced in Section C or in the contract specification as mandatory for use or for contract performance.

(c) Government Furnished Information (GFI). GFI is defined as that information essential for the installation, test, operation, and interface support of all Government Furnished Material enumerated on NAVSEA Form 4205/19 or

Schedule A, as applicable, attached to the contract. The Government shall furnish only the GFI identified on the

NAVSEA Form 4340/2 or Schedule C, as applicable, attached to the contract. The GFI furnished to the contractor need not be in any particular format. Further, the Government reserves the right to revise the listing of GFI on the

NAVSEA Form 4340/2 or Schedule C, as applicable, as follows:

(1) The Contracting Officer may at any time by written order:

(i) delete, supersede, or revise, in whole or in part, data listed or specifically referenced in NAVSEA

Form 4340/2 or Schedule C, as applicable; or

(ii) add items of data or information to NAVSEA Form 4340/2 or Schedule C, as applicable; or

(iii) establish or revise due dates for items of data or information in NAVSEA Form 4340/2 or Schedule

C, as applicable.

(2) If any action taken by the Contracting Officer pursuant to subparagraph (1) immediately above causes an increase or decrease in the costs of, or the time required for, performance of any part of the work under this contract, the contractor may be entitled to an equitable adjustment in the contract price and delivery schedule in accordance with the procedures provided for in the clause of this contract entitled "CHANGES--FIXED-PRICE"

(FAR 52.243-1).

(d) Except for the Government information and data specified by paragraphs (a), (b), and (c) above, the

Government will not be obligated to furnish the Contractor any specification, standard, drawing, technical documentation, or other publication, notwithstanding anything to the contrary in the contract specifications, the GFI listed on the NAVSEA Form 4340/2 or Schedule C, as applicable, the clause of this contract entitled

"GOVERNMENT PROPERTY" (FAR 52.245-1) or "GOVERNMENT PROPERTY INSTALLATION

OPERATION SERVICES " (FAR 52.245-2), as applicable, or any other term or condition of this contract.

(e) Referenced Documentation. The Government will not be obligated to furnish Government specifications and standards, including Navy standard and type drawings and other technical documentation, which are referenced directly or indirectly in the contract specifications set forth in Section C and which are applicable to this contract as specifications. Such referenced documentation may be obtained:

(1) From the ASSIST database via the internet at https://assist.dla.mil/ or

(2) By submitting a request to the

Department of Defense Single Stock Point (DoDSSP)

Building 4, Section D

700 Robbins Avenue

Philadelphia, Pennsylvania 19111-5094

Telephone (215) 697-6396

Facsimile (215) 697-9398.

Commercial specifications and standards, which may be referenced in the contract specification or any sub-tier specification or standard, are not available from Government sources and should be obtained from the publishers.

HQ C-2-0034 MINIMUM INSURANCE REQUIREMENTS (NAVSEA) (SEP 1990)

In accordance with the clause of this contract entitled "INSURANCE--WORK ON A GOVERNMENT

INSTALLATION" (FAR 52.228-5), the Contractor shall procure and maintain insurance, of at least the kinds and minimum amounts set forth below:

(a) Workers' Compensation and Employer's Liability coverage shall be at least $100,000, except as provided in

FAR 28.307-2(a).

(b) Bodily injury liability insurance coverage shall be written on the comprehensive form of policy of at least

$500,000 per occurrence.

(c) Automobile Liability policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

HQ C-2-0040 PLANT PROTECTION (NAVSEA) (SEP 2016)

https://assist.dla.mil/

(a) In accordance with NAVSEA STANDARD ITEM (SI) 009-72, (FY20) the Contractor shall develop, maintain, and implement, as necessary, a Plant Protection Plan (FY20) which prescribes the actions and procedures and assigns responsibilities for actions to be taken to provide adequate protection of the ship(s) and the materials and equipment to be installed therein. A copy of SI 009-72 can be obtained from the purchasing office representative listed in Section G of the contract or via the internet by going to http://www.navsea.navy.mil/Home/RMC/CNRMC/OurPrograms/SSRAC/NSI/ and selecting the NAVSEA Standard Items (NSI) tab then select the applicable FY standard item link and then select SI

009-72.

(b) The Contractor shall establish and maintain, for its plant and the work in process under this contract, physical security boundaries and other security measures to provide safeguards against hazards, including unauthorized entry, malicious mischief, theft, espionage, sabotage, and terrorism to U.S. Naval Vessels and their crews, in accordance with SI 009-72 and Attachment A thereto. The Contractor shall also provide reasonable safeguards against vandalism and fire.

(c) The Contractor shall meet the requirements of Force Protection Condition NORMAL (as defined in SI 009-72) at all times. In addition and in accordance with SI 009-72, the Contractor shall meet the requirements of increased levels of Force Protection as may be required or approved by the Contracting Officer, or when notified by the

Supervisor, for the protection of its plant and the work in process under this contract against any threats including terrorism, espionage, sabotage, and enemy action.

(d) At the Supervisor’s discretion, the Contractor and the Supervisor shall negotiate a cost rate agreement applicable to each level of increased Force Protection above the NORMAL level. In addition to material costs, the labor cost rates shall be negotiated using the contractor’s and the Supervisor’s accepted common business practices. The labor and material costs to the Contractor for all safeguards so required or approved shall, to the extent allowable and allocable to this contract, be reimbursed to the Contractor in the same manner as if the Contractor has furnished such safeguards pursuant to a change order issued under the clause of this contract entitled "CHANGES--FIXED PRICE"

(FAR 52.243-1) or "CHANGES--COST-REIMBURSEMENT" (FAR 52.243-2), as applicable. Such costs shall not include any allowance on account of overhead expense, except shop overhead charges incident to the construction or installation of such devices or equipment.

(e) Upon payment, in accordance with the Payments provision of this contract, by the Government of the cost to the

Contractor for any device or equipment required or approved under paragraph (c) above, title thereto shall vest in the

Government, and the Contractor shall comply with the instructions of the Contracting Officer respecting the identification and disposition thereof. No part or item of any such devices or equipment shall be or become a fixture by reason of affixation to any realty not owned by the Government.

(f) The plant protection plan and rate agreements required by this requirement shall be completed and implemented, within sixty (60) days of contract award for new construction and prior to ship arrival for conversion, repair or overhaul.

HQ C-2-0047 REMOVALS (NAVSEA) (SEP 1990)

The Contracting Officer may, by…