N3220521R4008 Solicitation.pdf

CODE

(Hour)

PAGE(S)

until 05:00 PM local time 30 Sep 2021

X

A X B X C X D

EX

X

G F 32 - 44

45 - 51 H 52 - 61

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA FAR (48 CFR) 53.214(c)

1 61

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

N32205 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 0 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and

N/A - Received VIA DOD SAFE conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

3 - 11

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 15 - 17 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIONS AND INSTRUCTIONS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

18 - 30

PART II - CONTRACT CLAUSES

MILITARY SEALIFT COMMAND NORFOLK

471 EAST C STREET, BLDG SP-64 NAVAL STATION N

NORFOLK VA 23511

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.5. DATE ISSUED

17 Aug 2021

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

N3220521R4008

Section B - Supplies or Services and Prices

CLAUSES INCORPORATED BY REFERENCE

ShipRepair_B N104 Ship Repair Solicitation APR 2020

Section C - Descriptions and Specifications

CLAUSES INCORPORATED BY FULL TEXT

ACRONYM TABLE

ABIH American Board of Industrial Hygiene ABR Agreement for Boat Repair ABS American Bureau of Shipping ACO Administrative Contracting Officer AGR Additional Government Requirements AIHA American Industrial Hygiene Association ALT Alternate AMT Amount BLDG Building CCO Contract Change Order CD Compact Disc CDRL Contract Data Requirements List CD-ROM Compact Disc Read-Only Memory CFM Contractor Furnished Material CFP Contractor Furnished Property CFR Condition Found Report CHENG Chief Engineer CFR Code of Federal Regulations CIH Certified Industrial Hygienist CLIN Contract Line Item Number

CONUS

CPARS

Contiguous United States Contractor Performance Assessment Reporting System

DBIDS Defense Biometric Identification Systems DFARS Defense Federal Acquisition Regulation Supplement DOD Department of Defense DOD SAFE Department of Defense Secure Access File Exchange DON Department of the Navy EMAIL Electronic Mail ESRS Electronic Subcontract Report System FAPIIS Federal Awardee Performance and Integrity Information System FAR Federal Acquisition Regulation FBLR Fully-Burdened Labor Rate F/CC Fibers Per Cubic Centimeter FPCON Force Protection Condition FTR Federal Travel Regulations G&A General and Administrative GFI-TD Government Furnished Information – Technical Data GFM Government Furnished Material GFP Government Furnished Property GPE Governmentwide Point of Entry IAW In Accordance With ID Identification ISO International Organization for Standardization JTR Joint Travel Regulations KO Contracting Officer KWh Kilowatt Hour LLTM Long Lead Time Material LPTA Lowest Price Technically Acceptable

M&IE Meals and Incidental Expenses MSC Military Sealift Command MSCREP Military Sealift Command Representative MM Millimeter MSRA Master Ship Repair Agreement MTA Mid-Term Availability N/A Not Applicable NCACS Navy Commercial Access Control System NDA Non-Disclosure Agreement NO Number NSP Not Separately Priced ODC Other Direct Costs PAT Proficiency in Analytical Testing

PDF

PII

Portable Document Format Personally Identifiable Information

PM Program Manager PPE Principle Port Engineer PRIME Prime Contractor QA Quality Assurance QC Quality Control REV Revision RFC Request for Specification Clarification RFP Request for Proposal ROH/DD Regular Overhaul/Dry-Docking SECNAV Secretary of the Navy SF Standard Form SUB Subcontractor TPSN Time Phased Sequencing Network TWA Time-Weighted Average USC United States Code USCG United States Coast Guard USNS United States Naval Ship VR Voyage Repair WAWF Wide Area Workflow WI Work Item

SCOPE OF WORK

1. The contractor shall prepare for and accomplish the VR, overhaul, or alterations of the USNS KANAWHA (T- AO 196) as specified herein and IAW the WI package as provided in Attachment J-1 – WI Package (Specifications).

Unless otherwise specified, all work shall be performed at the contractor’s shipyard.

2. In performing the WIs specified, the contractor shall be responsible for all of the following related work (in case of a discrepancy, the terms and conditions stated in the WIs take precedence over the following terms and conditions):

a. Providing the necessary management, procurement, production, testing, technical capability and resources, and quality assurance services.

b. Ensuring the timely procurement of CFM/CFP and the timely reporting, receipt, storage, installation, and accountability of GFM/GFP IAW FAR 52.245-1 and DFARS 252.211-7007, 252.245-7001, 252.245-7002, 252.245-7003, and 252.245-7004.

c. Using progress measurement systems to determine the physical progress of completed work for each of the elements in the scheduling plan, including material and manpower control, engineering, production, tests and trials

IAW the CDRL and the contractor's own Technical Proposal, and the WI package. The progressing system shall permit a direct comparison of the physical progress of completed work to the planned performance measurement baseline for each of the elements in the scheduling plan.

d. Using management procedures and systems to identify behind-schedule conditions and unfavorable schedule variances based on the TPSN submitted with the contractor’s proposal. The applied procedures and systems shall provide timely identification of scheduling problem areas to permit prompt management action to correct unsatisfactory conditions.

e. Developing a performance milestone schedule/critical path chart to measure scheduled performance.

Deviations from the milestone schedule/critical path chart dates in WI 0013 must be submitted to and approved by the KO. A performance milestone schedule and critical path chart shall be developed and submitted IAW the WI Package. The performance milestone schedule shall include and clearly identify primary and parallel critical paths.

The resource loaded performance milestone schedule shall include, at a minimum, those milestones identified in WI 0013.

f. Using approved quality control procedures as required by this contract and the WI package to ensure procured material and performed production work conforms to the required quality standards.

g. Ensuring the ship's equipment and systems remain configured to existing baselines with regard to procured material, production work, and software.

h. Applying stringent configuration control procedures to ensure that configuration baselines are maintained for procured material and production work.

i. Providing for staging and storing of material (both Government-furnished and contractor-furnished) and LLTM for use in the availabilities from the date of award.

j. Managing all subcontractors’ performance during the availability. Ensure subcontractor work is to the same quality and standards as expected from the prime contractor. Develop and maintain a subcontractor management plan. The plan shall ensure that all communication and control of subcontractors is maintained by the prime contractor.

k. Employing good judgment and sound engineering practice and principles, particularly when WIs do not describe all details of accomplishing the work. The contractor shall be expected to have, either organically or through subcontractors, access to competent engineers who have a history of working solutions in a maritime environment.

3. Contract work shall be performed by an eligible contractor as defined below.

a. The contractor shall be capable of performing the full scope of the requirement stated herein within its own facilities, utilizing its own shop(s) and work force, or be capable of subcontracting for these elements beyond its managerial, technical, or physical capability or capacity. The contractor shall assume full responsibility for the integrated scheduling, cost, and quality of subcontractor performance.

b. The contractor shall be a company recognized as engaged in ship repair work and possess an organization capable of the full scope of planning, engineering, quality control, shipboard/offship production and component/system testing and trials. The contractor shall provide industry certifications such as: MSRA, ABR, or ISO Certification that would further emphasize the contractor's ability to perform the work. To be determined responsible, the contractor shall submit acceptable evidence to demonstrate its ability to accomplish the work. This will include a conclusive demonstration of having the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them (including, as appropriate, such elements as production control procedures, property control systems, quality assurance measures, and safety programs applicable to materials to be produced or services to be performed by the prospective contractor and/or subcontractors) at the time of award. The contractor’s proposal shall provide a documented and positive demonstration of established organizational elements as set forth below. These characteristics will be evaluated to determine a firm's eligibility for contract award:

1) Administration/Management Control. Established organization geared toward ship repair at all levels of size, value, and complexity, and toward technology innovation and process improvement. Clear lines of authority.

Delegation of responsibility. Mid-level managerial positions in place. Competent and experienced employees with ship repair experience. Capability to develop and integrate planning, estimating, and scheduling functions. Defined managerial responsibilities for production, quality assurance, material procurement/control, and subcontractor control.

2) Financial Control. Segregation of accounting costs. Adequate accounting system. Favorable cash flow-ratios. Availability of a line of credit or other source of financial income to support the work effort. Prompt payment of subcontractors and suppliers.

3) Production Control. A production organization. On board (or ability to obtain) trade mix/skills to perform ship repair work. Control of production efforts. Integration of other key functions with production. Use of scheduling techniques. Methods of progressing. Training available to trades employees.

4) Production Technical Support. Engineering and design support capabilities (in-house or subcontracted) with sufficient capability to diagnose and evaluate technical problems and issues and to make competent technical recommendations to MSC when necessary and appropriate. The offeror shall be fully cognizant of ABS rules and USCG regulations and how they apply and impact this specification package.

5) Material/Procurement Control. A material purchasing department with staff. Procedures for control of material (purchasing, monitoring, receipt, inspection, segregation, issuance, nonconformance, and disposal). An inventory system – ordering, tagging warehousing. CFM/GFM storage, control and protection. Existing environmentally-controlled warehouse space. Material handling equipment. Familiarity with the Navy logistics support system.

6) Subcontractor Control. Procedures for selecting, scheduling, managing, monitoring and controlling subcontractors.

7) Quality Control/Test and Trials. A quality control organization/department/staff. Quality assurance procedures/manual. Calibration and metrology system availability. Test memo writing capability. Nondestructive Testing capabilities. Welding procedures and welders’ qualifications. Ability to perform trend analysis. Quality control system shall be certified or equivalent to ISO 9001:2001 standards.

8) Safety/Security. Safety Organization/Manager or Engineer. Safety manual/procedures. Safety training.

First-aid capabilities or medical services. Fire protection/procedures. Physical yard security/security procedures.

9) Hazardous Material/Waste Control. Proper procedures and facilities to meet the legal requirements for removal, storage, and disposal of hazardous waste. Segregated storage. Documentation of licensed subcontractors responsible for control of hazardous waste removal, storage, and disposal. Appropriate state/federal agency-issued hazardous waste generator number. Disposal records which indicate type of material, date, and place of disposal.

10) Facilities. Although facility requirements may vary with the work authorized for a specific ship, the contractor must be a ship repair company that possesses or has available the following facilities:

o Pier, with services in place, accessible to the CLASS size ship for berthing o Structural Shop o Machine Shop o Pipe Shop o Electrical/Electronic Shop o Carpentry Shop o Rigging Equipment o Dry-dock – when required for docking of vessel in performance of the specification

11) Agreements. To be determined responsible, a prospective contractor must possess an MSRA, ABR or submit acceptable evidence in lieu of the aforementioned to effectively communicate and demonstrate its ability to obtain required resources.

c. The government reserves the right to perform a site survey(s) for verification of policies, procedures, capabilities and facilities prior to award.

4. Asbestos removal requirements.

a. During the performance of this contract the contractor and subcontractors may be required to perform work which involves the removal or disturbance of asbestos or asbestos-containing products. This requirement applies to each instance of asbestos removal or disturbance.

b. The contractor shall comply with the precautions required in 29 CFR 1910.1001, 29 CFR 1926.58 and 40 CFR Part 61 and all other applicable Federal, state, and local restrictions. The contractor shall forward a copy of all required notices, licenses and permits to the KO immediately upon issuance or receipt.

c. The latest change to the Federal, state, and local regulations in effect at the time of issuance of the contract shall govern. Compliance with these regulations is mandatory and is necessary to protect the employees of the contractor and Naval personnel from exposure to asbestos fibers in excess of the OSHA Action level airborne concentration (currently 0.1 f/cc of air).

d. During removal or disturbance, the contractor shall control airborne asbestos concentrations outside the removal boundary to less than 0.1 f/cc at all times.

e. After removal or disturbance is complete, the areas within the removal boundary shall not be released for re-occupancy until clearance air sampling demonstrates these spaces have concentrations of asbestos less than 0.1 f/cc.

f. In all respects, the performance of air sampling and analysis shall be performed IAW the OSHA Reference Method (Appendix A of 29 CFR 1910.1001), with the following additional specifications:

1) Aggressive clearance sampling shall be performed on 25 mm cassettes at 2.0 liters per minute for a minimum of four (4) hours.

2) In performing the clearance sampling, the pump shall be placed within the compartment where the removal or disturbance occurred. When this operation is conducted in a multilevel space, at least one pump shall be placed on each level.

3) Air sampling shall be performed by a person competent in sampling procedures and overseen by a CIH by the ABIH.

4) Laboratory analysis of samples shall be performed by a participant in the AIHA PAT Program rated proficient for asbestos and air.

g. Personal sampling shall be conducted using breathing zone air samples which are representative of the 8-hour TWA exposure of each individual. Samples shall be collected and analyzed using the OSHA Reference Method contained in either 29 CFR 1910.1001 (as amended) or 29 CFR 1926.58 (as amended).

h. The contractor agrees to indemnify MSC for any fines assessed by Federal, state, or local agencies, for the contractor's failure to properly follow applicable regulations.

i. The contractor shall insert this instruction in all subcontracts entered into under this contract.

5. Post-award substitution of any major subcontractor should not be effected unless the proposed substitution is submitted to the KO and official approval is obtained. The post-award substitution or insertion of a second-tier subcontractor will be treated in the same manner as the substitution of a major subcontractor and requires specific approval by the KO.

6. Substitution of key personnel.

a. The contractor agrees to assign to this contract those persons identified as key personnel who are necessary to fulfill the requirements of this contract and whose resumes were submitted with the proposal. No substitution of key personnel shall be made except IAW these instructions.

b. All proposed substitutions must be submitted, in writing, at least seven (7) days in advance of the proposed substitutions to the KO and must provide the information required by paragraph “c” below.

c. All requests for substitution must provide a detailed explanation of the circumstances necessitating the proposed substitution, a resume for the proposed substitute, and any other information as requested by the KO. All proposed substitutes must have qualifications equal to or higher than the qualifications of the person to be replaced.

The KO or his authorized representative will evaluate such requests and promptly notify the contractor of the approval or disapproval thereof.

7. It is anticipated the ship will arrive at the contractor’s yard on or about 03 March 2022. All work shall be completed in no more than fifty (50) calendar days from the actual start date designated by the Government at the time of contract award.

8. The place of performance for this contract shall be the contractor’s facility.

Table 1: List of WIs:

SECTION 0000 GENERAL SERVICES AND REQUIREMENTS

0001 SCOPE GENERAL REQUIREMENTS AND DEFINITIONSx NSP 0002 TECHNICAL AND MANUFACTURERS REPRESENTATIVESx NSP

0003 APPROACH BERTH AND MOORING REQUIREMENTS REV

12Feb20

NSP

0004 TESTING AND QUALITY ASSURANCEx NSP

0005 ELECTRICAL SAFETY PROCEDURE REQUIREMENTS NSP

0006 HEAVY WEATHER PLAN NSP

0007 COLD WEATHER PLAN NSP

0010 FURNISH OFFICE FOR OVERHAUL MANAGEMENT TEAM (OMT)

REV 11May20 A

0011 GENERAL SERVICES FOR THE SHIP T-AO REV 02May20 A 0012 INFORMATION TECHNOLOGY SERVICES REV 1x A

0013 PROJECT PLANNING AND PRODUCTION STATUS MONITORING

REPORTS REV 25Feb20 A

0014 WEIGHT AND MOMENT REPORT REV 13Feb20 A 0015 ILS GFMx A 0016 FIRE PROTECTION AND SHIPS SAFETY PROGRAM docx A

0017 HANDLING SHIPS STORES A

0018 DELIVERY AND REDELIVERY OF THE VESSEL REV 13Feb20 A

0019 SHIPBOARD ACCESS AND SECURITY A

0020 GAS FREE CERTIFICATES A

0021 CLEAN AND GAS FREE TANKS VOIDS AND COFFERDAMS A

0022 MACHINERY SPACE TURN-OVER, DOCK TRIALS AND SEA

TRIALS REV 13Feb20 A

0023 HAZARDOUS WASTE DISPOSAL A

0024 PHYSICAL SECURITY AT PRIVATE CONTRACTOR FACILITY

REV 28Nov18

NSP

PHYSICAL SECURITY AT PRIVATE CONTRACTOR FACILITY

REV 28Nov18 Final Vessel Cleaning

B

B 0030 CONTINUATION OF SERVICES REV 04Jun20 B

0090 DAILY COVID-19 PREVENTION AND CONTROL SERVICES REV

M A

SECTION 0100 HULL AND STRUCTURAL

0101 NDT kingposts A

0102 KINGPOST REPAIR B

0103 Main Deck Sheet Metal Replacement A

0104 FANTAIL OVERHEAD PRESERVATION A

0107 STEEL REPLACEMENT B

0108 Miscellanous Steel Repairs A 0157 Cargo Potable Water Tank Preservation A

SECTION 0200 PROPULSION MACHINERY

0211 MAIN REDUCTION GEAR INSPECTION - CINCINNATI (1 YR) A

SECTION 0300 ELECTRICAL

0301 Motor Overhaul A 0302 NO 2 DFM Motor Cable Replacement A

0305 ANNUAL CARGO CONSOLE GROOM A

0308 OVERHAUL AND TEST CIRCUIT BREAKERS (10 YR) A

0310 UPS, BATTERIES - REPLACE (5 YR) A

SECTION 0400 COMMUNICATION AND NAVIGATION

0401 ECDIS and Radar Replacement- Trans-Alt 928 A 0403 UHF SATCOM & LOS Transceiver Groom A 0419 XLI Frequency Time Standard Testing and RF Cable Replace A

0453 ANNUAL GYRO SERVICE A

0454 ANNUAL VDR RECERTIFICATION A

0455 ANNUAL RADIO COMMUNCATION EQUIPMENT

RECERTIFICATION

A

SECTION 0500 AUXILIARY MACHINERY

0501 Pump Overhaul- 22 A 0503 CFW Pump Overhaul A

0504 NO 3 SSDG ENGINE SERVICE - BERGEN (10K HRS) (SCSI) A

0506 Replace AFFF Weather Deck Piping Zone 2 A

0507 ANNUAL OCM SERVICE CALIBRATION A

0508 MISC PIPING REPLACE B

0509 INCINERATOR MAINTENANCE AND REPAIR A

0511 SSDG ENGINE TURBOCHARGER MAINTENANCE -BERGEN

HRS) (SCSI)

(8K A

0512 SSDG ENGINE AIR CHARGE COOLER SERVICE -

BERGEN (15K

HRS)

A

0551 OVERHAUL CFW PLATE COOLERS (3 YR) A

0558 PERSONNEL ELEVATOR ANNUAL INSPECTION (1 YR) A

0561 GAUGE CALIBRATION (1 YR) A

0562 SCBA ANNUAL INSPECTION (1 YR) A

0563 SCBA Air Compressor Inspection (1 YR) A

0565 FIXED GAS FIREFIGHTING SYSTEM INSPECTION & TEST (1 YR) A

0567 FIXED FOAM FIREFIGHTING SYSTEM INSPECION AND TEST (1

YR)

A

0569 FIRE AND SMOKE DETECTION AND ALARM SYSTEM (1

YR)(SCSI)

A

0570 PORTABLE FIRE EXTINGUISHER SERVICE (1 YR) A

0571 FIRE AND SMOKE DAMPER SERVICE (1 YR) A

0572 DEEP FAT FRYER AND RANGE HOOD FIRE EXTINGUISHING

SYSTEM (1 YR)

A

0573 FIRE HOSES (1 YR) A

SECTION 0600 HABITABILITY OUTFITTING AND FURNISHINGS

0601 SHOWER STALL BULKHEAD PANEL RENEWALS A

0602 Head Deck Covering Replacement A

0603 GALLEY EQUIPMENT SERVICE (1 YR) A

0604 Port Rescue Boat Davit Winch Replacement A 0606 EDG Halon Piping Renewal A 0607 Vacuum Sewage System Cleaning A 0608 MSD Tank Re-Coat A 0613 HALON Bottle Rebuild A

0513A AUXILIARY BOILER SERVICE - CLAYTON (1 YR) A

0651 ANNUAL LIFEBOAT AND DAVIT INSPECTIONS (ABS) (1YR) A

0653 ANNUAL RESCUE BOAT AND DAVIT INSPECTION (ABS) (1 YR) A

0656 ANNUAL LIFERAFT CERTIFICATION (1 YR) A

0660 Deck Tile Replacement A 0661 Carpet Replacement A

0662 DEEP FAT FRYER INSPECTION (1 YR) A

SECTION 0800 HVAC

0801 Air Handler Refurbishment A

0851 ANNUAL GALLEY VENTILATION AND GAYLORD HOOD

CLEANING (1 YR)

A

0852 ANNUAL LAUNDRY VENT CLEANING (1 YR) A

SECTION 1000 UNDERWAY REPLENISHMENT EQUIPMENT

1001 Station 3 and 4 Crossover pipe replacement A

1002 KANAWHA SADDLE WINCH MOTOR REPAIRS A

1003 Kanawha spanwire, highline winch electric motor refurbishment A 1004 KANAWHA Saddle Winch foundation Refurbishment A 1006 RAM tensioner preservation, bearing seals Replacement and drain lines refurbishment A

1007 LEAD ANGLE COMPENSATOR REPAIRS A

1010 Winch Booths Deck Renewal A 1012 UNREP Station No1 Steel Repairs A 1014 UNREP Station No3 Steel Repairs A

Section D - Packaging and Marking

WOOD PACKAGING MATERIAL (WPM) - ADDITIONAL DELIVERY INSTRUCTIONS

In accordance with the requirements of International Standards for Phytosanitary Measures (ISPM) 15, the following commercial heat treatment process has been approved by the American Lumber Standards Committee (ALSC) and is required for all Wood Packaging Material (WPM). WPM is defined as wood pallets, skids, load boards, pallet collars, wooden boxes, reels, dunnage, crates, frames, and cleats. Packaging materials exempt from the requirements are materials that have undergone a manufacturing process such as corrugated fiberboard, plywood, particleboard, veneer and oriented strand board. All WPM shall be constructed from Heat Treated (HT to 56 degrees Centigrade for 30 minutes) lumber and certified by an accredited agency recognized by the ALSC in accordance with Wood Packaging Material Policy and Wood Packaging Material Enforcement Regulations (see URL: http://www.alsc.org). All materials must include certification markings in accordance with ALSC standards and be placed in an unobstructed area that will be readily visible to inspectors. Pallet markings shall be applied to the stringer or block on diagonally opposite sides and ends of the pallet and be contrasting and clearly visible. All dunnage used in configuring and/or securing the load shall also comply with ISPM 15 and be marked with an ALSC approved "DUNNAGE" stamp. Failure to comply with the requirements of this restriction may result in refusal, destruction, or treatment of materials at the point of entry.

(end of instructions)

Section E - Inspection and Acceptance

252.217-7005 Inspection and Manner of Doing Work JUL 2009 252.217-7006 Title DEC 1991 252.217-7013 Guarantees DEC 1991

Section F - Delivery and Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.247-55 F.O.B. Point For Delivery Of Government-Furnished

Property

JUN 2003

Section G - Contract Administration data

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232- 7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer. Invoice and Receiving Report (Combo)

The following information, at a minimum, must be attached into WAWF and submitted with every invoice showing certification with the Onsite Management Team prior to submission:

MSC ACO

MSC PPE Shipyard Representative

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer. NOT APPLICABLE

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC N50082

Issue By DoDAAC ____

Admin DoDAAC** ____

Inspect By DoDAAC ____

Ship To Code N62387

CLIN

Contract Price Through Mod P0000x

Complete

Contract Completed

Less Retainage

Less Prev Payments

Amount due this Invoice ($)

Total Invoiced to Date ($)

0003 Option

0004 Option

0005 Option

0006 Option

0007 Option

0008 Option

0009 Option

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) N62387

Service Acceptor (DoDAAC) N62387

Accept at Other DoDAAC ____

LPO DoDAAC N62387

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

MSCHQ_WAWF@NAVY.MIL

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

MSC SPECIFIC

WAWF

MSC SPECIFIC WAWF AUG 2012

Section I - Contract Clauses

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

JUN 2020

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-1 Approval of Contract DEC 1989 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information Systems

JUN 2016

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

JUN 2020

52.209-7 Information Regarding Responsibility Matters OCT 2018 52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research JUN 2020 52.211-5 Material Requirements AUG 2000 52.215-2 Audit and Records--Negotiation JUN 2020 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011 52.215-12 (Dev) Subcontractor Certified Cost or Pricing Data (Deviation 2018-

O0015)

JUN 2020

52.215-14 Integrity of Unit Prices JUN 2020 52.215-17 Waiver of Facilities Capital Cost of Money OCT 1997 52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

JUN 2020

52.215-21 Alt IV Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data -- Modifications (JUN 2020) - Alternate IV

OCT 2010

52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION 2020-O0008).

OCT 2020

52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-9 Small Business Subcontracting Plan JUN 2020 52.219-9 Alt II Small Business Subcontracting Plan (JUN 2020) Alternate II NOV 2016 52.219-14 (Dev) Limitations on Subcontracting (DEVIATION 2020-O0008) MAR 2020 52.219-16 Liquidated Damages-Subcontracting Plan JAN 1999 52.219-28 Post-Award Small Business Program Rerepresentation NOV 2020 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-19 (Dev) Child Labor - Cooperation with Authorities and Remedies

(DEVIATION 2020-O0019)

JUL 2020

52.222-20 Contracts for Materials, Supplies, Articles, and Equipment JUN 2020 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-25 Affirmative Action Compliance APR 1984 52.222-26 Equal Opportunity SEP 2016 52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons OCT 2020 52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021 52.223-6 Drug-Free Workplace MAY 2001 52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration

Equipment and Air Conditioners.

JUN 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.223-20 Aerosols JUN 2016 52.223-21 Foams JUN 2016 52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.226-1 Utilization Of Indian Organizations And Indian-Owned

Economic Enterprises

JUN 2000

52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-3 Patent Indemnity APR 1984 52.229-3 Federal, State And Local Taxes FEB 2013 52.229-12 Tax on Certain Foreign Procurements FEB 2021 52.232-1 Payments APR 1984 52.232-8 Discounts For Prompt Payment FEB 2002 52.232-9 Limitation On Withholding Of Payments APR 1984 52.232-11 Extras APR 1984 52.232-17 Interest MAY 2014 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-25 Prompt Payment JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.242-2 Production Progress Reports APR 1991 52.242-5 Payments to Small Business Subcontractors JAN 2017 52.242-13 Bankruptcy JUL 1995 52.242-17 Government Delay Of Work APR 1984 52.243-1 Changes--Fixed Price AUG 1987 52.244-2 Subcontracts JUN 2020 52.244-6 Subcontracts for Commercial Items JUL 2021 52.245-1 Government Property JAN 2017 52.245-9 Use And Charges APR 2012 52.247-63 Preference For U.S. Flag Air Carriers JUN 2003 52.248-1 Value Engineering JUN 2020 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-8 Default (Fixed-Price Supply & Service) APR 1984 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General AUG 2019 252.203-7004 Display of Hotline Posters AUG 2019 252.204-7000 Disclosure Of Information OCT 2016 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.204-7020 NIST SP 800-171 DoD Assessment Requirements NOV 2020 252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.211-7007 Reporting of Government-Furnished Property AUG 2012 252.217-7003 Changes DEC 1991 252.217-7004 Job Orders and Compensation MAY 2006 252.217-7007 Payments DEC 1991 252.217-7008 Bonds DEC 1991 252.217-7009 Default DEC 1991 252.217-7010 Performance JUL 2009 252.217-7011 Access to Vessel DEC 1991 252.217-7012 Liability and Insurance AUG 2003 252.217-7014 Discharge of Liens DEC 1991 252.217-7015 Safety and Health DEC 1991 252.217-7016 Plant Protection DEC 1991 252.217-7028 Over And Above Work DEC 1991 252.219-7003 Small Business Subcontracting Plan (DOD Contracts) DEC 2019 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010 252.223-7002 Safety Precautions For Ammunition And Explosives MAY 1994 252.223-7004 Drug Free Work Force SEP 1988 252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2017

252.225-7008 Restriction on Acquisition of Specialty Metals MAR 2013 252.225-7009 Restriction on Acquisition of Certain Articles Containing

Specialty Metals

DEC 2019

252.225-7013 (Dev) Duty-Free Entry (DEVIATION 2020-O0019) JUL 2020 252.225-7015 Restriction on Acquisition of Hand Or Measuring Tools JUN 2005 252.225-7016 Restriction On Acquisition Of Ball and Roller Bearings JUN 2011 252.225-7038 Restriction on Acquisition of Air Circuit Breakers DEC 2018 252.225-7048 Export-Controlled Items JUN 2013 252.225-7052 Restriction on the Acquisition of Certain Magnets, Tantalum, and Tungsten.

OCT 2020

252.225-7972 (Dev) Prohibition on the Procurement of Foreign-Made Unmanned Aircraft Systems (DEVIATION 2020-O0015)

MAY 2020

252.226-7001 Utilization of Indian Organizations and Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns

APR 2019

252.227-7013 Rights in Technical Data--Noncommercial Items FEB 2014 252.227-7015 Technical Data--Commercial Items FEB 2014 252.227-7016 Rights in Bid or Proposal Information JAN 2011 252.227-7017 Identification and Assertion of Use, Release, or Disclosure

Restrictions

JAN 2011

252.227-7025 Limitations on the Use or Disclosure of Government- Furnished Information Marked with Restrictive Legends

MAY 2013

252.227-7027 Deferred Ordering Of Technical Data Or Computer Software APR 1988 252.227-7030 Technical Data--Withholding Of Payment MAR 2000 252.227-7037 Validation of Restrictive Markings on Technical Data SEP 2016 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.232-7017 Accelerating Payments to Small Business Subcontractors--

Prohibition on Fees and Consideration

APR 2020

252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JAN 2021 252.244-7001 Contractor Purchasing System Administration MAY 2014 252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property JAN 2021 252.245-7003 Contractor Property Management System Administration APR 2012 252.245-7004 Reporting, Reutilization, and Disposal DEC 2017 252.246-7003 Notification of Potential Safety Issues JUN 2013 252.246-7008 Sources of Electronic Parts MAY 2018 252.247-7023 Transportation of Supplies by Sea FEB 2019

52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of not to exceed 122,615.00 per calendar day of delay. Total Liquidated Damages shall not exceed 50% of the contract value.

(b) If the Government terminates this contract in whole or in part under the Default--Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default--Fixed-Price Supply and Service clause in this contract.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within the performance period. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS

CONCERNS (DEVIATION 2020-O0008) (MAR 2020)

(a) Definitions. As used in this clause— “HUBZone small business concern” means a small business concern, certified by the Small Business Administration (SBA), that appears on the List of Qualified HUBZone Small Business Concerns maintained by the SBA (13 CFR 126.103).

“Similarly situated entity” means a first-tier subcontractor, including an independent contractor, that—

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(b) Evaluation preference.

(1) Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except—

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(2) The factor of 10 percent shall be applied on a line item basis or to any group of items on which award may be made. Other evaluation factors described in the solicitation shall be applied before application of the factor.

(3) When the two highest rated offerors are a HUBZone small business concern and a large business, and the evaluated offer of the HUBZone small business concern is equal to the evaluated offer of the large business after considering the price evaluation preference, award will be made to the HUBZone small business concern.

(c) Waiver of evaluation preference. A HUBZone small business concern may elect to waive the evaluation preference, in which case the factor will be added to its offer for evaluation purposes. The agreements in paragraphs

(e) and (f) of this clause do not apply if the Offeror has waived the evaluation preference.

__ Offeror elects to waive the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, a HUBZone small business concern agrees that, in the case of a contract assigned a NAICS code for—

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract. Other direct costs are excluded to the extent they are not the principal purpose of the contract and cannot be obtained from small business concerns;

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count toward the prime contractor’s 75 percent subcontract amount that cannot be exceeded.

(f) A HUBZone joint venture agrees that the aggregate of the HUBZone small business concerns to the joint venture, not each concern separately, will perform the applicable requirements specified in paragraph (e) of this clause.

(g) Nonmanufacturer.

(1) Unless SBA has waived the requirements of paragraphs (g)(1)(i) through (iii) of this clause in accordance with 13 CFR 121.1204, a HUBZone small business concern that provides an end item it did not manufacture, process, or produce, shall—

(i) Provide an end item that a small business has manufactured, processed, or produced in the United States or its outlying areas;

(ii) Be primarily engaged in the retail or wholesale trade and normally sell the type of item being supplied; and

(iii) Take ownership or possession of the item(s) with its personnel, equipment, or facilities in a manner consistent with industry practice; for example, providing storage, transportation, or delivery.

(2) For contracts or orders for multiple end items, at least 50 percent of the total value of the contract or order shall be manufactured, processed, or produced in the United States or its outlying areas by small business concerns.

(3) Paragraphs (g)(1) through (2) of this clause do not apply—

(i) To construction or service contracts; or

(ii) When the Offeror waives the evaluation preference.

(h) Notice. The HUBZone small business Offeror acknowledges that a prospective HUBZone awardee must be a HUBZone small business concern at the time of award of this contract. The HUBZone offeror shall provide the Contracting Officer a copy of the notice required by 13 CFR 126.501 if material changes occur before contract award that could affect its HUBZone eligibility. If the apparently successful HUBZone Offeror is not a HUBZone small business concern at the time of award of this contract, the Contracting Officer will proceed to award to the next otherwise successful HUBZone small business concern or other offeror.

52.229-12 TAX ON CERTAIN FOREIGN PROCUREMENTS (FEB 2021)

(a) Definitions. As used in this clause--

Foreign person means any person other than a United States person.

United States person, as defined in 26 U.S.C. 7701(a)(30), means--

(1) A citizen or resident of the United States;

(2) A domestic partnership;

(3) A domestic corporation;

(4)…