frankin Microsoft Word - MC-COM-0015-26 SCADA.pdf

NOTICE OF RFP

The Township of Franklin, County of Somerset is soliciting proposals through the competitive contracting process in accordance with N.J.S.A. 40A:11-4.1, et seq.

Sealed RFP responses will be received by the Purchasing Agent on or by September 30, 2026 at 10:00 A.M. in the Purchasing Department, Municipal Building, 475 DeMott Lane, Somerset NJ 08873 at which time and place responses will be opened and read for:

SCADA Software and System Maintenance

CONTRACT # MC-COM-0015-26

RFPs shall be delivered in sealed envelopes and addressed to Jennifer Burns, Purchasing Agent, Purchasing Office at the Municipal Building, 475 DeMott Lane, Somerset, NJ 08873, clearly marked on the outside with the contract name and number, bearing the name and address of the bidder on the outside. Proposals may be submitted by certified mail or overnight delivery addressed to:

Purchasing Agent Municipal Building 475 DeMott Lane, Somerset, New Jersey, 08873

Specifications and instructions may be obtained on the Franklin Township website www.franklintwpnj.org. We are storing all responses electronically; therefore, submit all pages of the response on a CD or flash drive in addition to the printed copies.

* RFP Addenda will be issued on the website. Therefore, interested respondents should check the website from now through RFP opening. It is the sole responsibility of the respondent to be knowledgeable of all addenda related to this procurement.

Respondents shall comply with the requirements of P.L. 1975 C127 (N.J.A.C. 17:27et seq.)

Jennifer Burns, QPA Date Posted to Web: August 28, 2026

TOWNSHIP OF FRANKLIN, COUNTY OF SOMERSET

475 DeMott Lane, Somerset, NJ 08873-6704

MUNICIPAL BUILDING

Somerset, NJ 08873-6704

PURCHASING DEPARTMENT

Jennifer Burns

Purchasing Agent, QPA

PHONE: (732) 873-2500 ext. 6239 Email: Jennifer.Burns@franklinnj.gov

1. Introduction

This contract is to furnish and deliver software and system maintenance services for the Township of Franklin, County of Somerset SCADA system.

2. Administrative Conditions and Requirements

The following items express the conditions and requirements of this RFP. Together with the other RFP sections, they apply to the RFP process, the subsequent contract, and project production. Any proposed change, modification, or exception to these conditions and requirements may be the basis for Franklin Township County of Somerset, hereinafter referred to as owner, to determine the proposal as non-responsive to the RFP and will be a factor in the determination of an award of a contract. The contents of the proposal of the successful respondent, as accepted by the owner, will become part of any contract awarded as a result of this RFP.

2.1 Schedule

The dates established for respondent proposals, proposal review, contractor selection and project initiation are:

Release of RFP (published in Courier Newspaper and Township website August 28, 2026

Proposal Due Date September 30, 2026

Evaluation Completed October 2026

Governing Body Action October 2026

Contract Execution and Project Initiation October 2026

2.2 Proposal Submission Information

Submission Date and Time:

DATE, September 30, 2026 at 10:00 AM

One (1) Original five (5) copies and One (1) copy on CD or flash drive

The Township is storing all responses electronically; therefore submit all pages of the response on a CD and or flash drive in addition to the printed copies.

Submission Office:

Office of the Purchasing Agent Municipal Building 475 DeMott Lane Somerset, N.J. 08873

Clearly mark the submittal package with the title of this solicitation and the name of the responding firm, addressed to the Purchasing Agent. The original proposal shall be marked to distinguish it from the copies.

Only those responses received prior to or on the submission date will be considered. Responses delivered before the submission date and time specified above may be withdrawn upon written application of the respondent who shall be required to produce evidence showing that the individual is or represents the principal or principals involved in the proposal. After the submission date and time specified above, responses must remain firm for a period of sixty (60) days.

2.3 Using Department Information

Carl Hauck Public Works Manager Department of Public Works:

40 Churchill Avenue Somerset, NJ 08873 Voice: 732.249.7800 Ext 6383 Email: Carl.Hauck@franklinnj.gov

2.4 Township Representative for this Solicitation

Please direct all questions in writing to:

Jennifer Burns, QPA Purchasing Agent Voice: (732) 873-2500 ext. 6239 Fax: (732) 873-1059 Email: Jennifer.Burns@franklinnj.gov

2.5 Interpretations and Addenda

Respondents are expected to examine the RFP with care and observe all its requirements. All questions about the meaning or intent of this RFP, all interpretations and clarifications considered necessary by the owner’s representative in response to such comments and questions will be issued by Addenda posted to website and mailed or delivered to all parties recorded as having received the RFP package. Only comments and questions responded to by formal written Addenda will be binding. Oral interpretations, statements or clarifications are without legal effect.

2.6 Quantities of Estimate

Wherever the estimated quantities of work to be done are shown in any section of this RFP, including the Proposal Cost Form, they are given for use in comparing proposals. The owner especially reserves the right (except as herein otherwise specifically limited) to increase or diminish the quantities as may be deemed reasonably necessary or desirable by the owner to complete the work detailed by the contract. Such increase or diminution shall in no way violate this contract, nor shall any such increase or diminution give cause for claims or liability for damages.

2.7 Cost Liability and Additional Costs

The owner assumes no responsibility and liability for costs incurred by the Respondents prior to the issuance of an agreement. The liability of the owner shall be limited to the terms and conditions of the contract.

Respondents will assume responsibility for all costs not stated in their proposals. All unit rates either stated in the proposal or used as a basis for its pricing are required to be all-inclusive.

Additional charges, unless incurred for additional work performed by request of the owner as noted in 2.6, are not to be billed and will not be paid.

2.8 Statutory and Other Requirements

2.8.1 Compliance with Laws

Any contract entered into between the contractor and the owner must be in accordance with and subject to compliance by both parties with the New Jersey Local Public Contracts Law. The contractor must agree to comply with the non-discrimination provisions and all other laws and regulations applicable to the performance of services there under. The respondent shall sign and acknowledge such forms and certificates as may be required by this section.

2.8.2 Mandatory EEO/Affirmative Action Compliance

No firm shall be issued a contract unless it complies with the EEO/Affirmative Action requirements of P. L. 1975, C. 127 as identified in the documents attached hereto. The form shall be properly executed.

2.8.3 Additional Laws Against Discrimination

Discrimination on the basis of race, creed, color, national origin, nationality, ancestry, age, sex (including pregnancy), familial status, marital status, domestic partnership or civil union status, affectional or sexual orientation, gender identity or expression, atypical hereditary cellular or blood trait, genetic information, mental or physical disability, or perceived disability in contracting for the delivery of services is prohibited. Respondents are required to read the following laws and agree that the provisions of said laws are made part of, and incorporated into the contract. The contractor is obligated to comply with the laws (and any amendments thereto even if enacted after the date of this contract) and contractor agrees to hold the owner harmless for any claims of discrimination. Such laws include but may not be limited to:

Americans with Disabilities Act of 1990;

The Age Discrimination in Employment Act of 1967;

Title VII of the Civil Rights Act of 1964;

Genetic Information Nondiscrimination Act;

New Jersey Equal Pay Act;

New Jersey Civil Union Act.

2.8.4 Statement of Ownership Disclosure

No corporation or partnership shall be awarded any contract for the performance of any work or the furnishing of any goods, unless, with receipt of the proposal of said corporation or partnership, there is submitted to the Township a statement setting forth the names and addresses of all stockholders in the corporation or partnership who own ten (10) percent or greater interest therein. The Respondent shall complete and submit the form of statement that is included in this

RFP.

2.8.5 Non-Collusion Affidavit

The Non-Collusion Affidavit, which is part of this RFP, shall be properly executed and submitted with the RFP response.

2.8.6 N.J. BUSINESS REGISTRATION CERTIFICATE P.L. 2009, C.315

Reforms Business Registration Certificate Filing; permits filing prior to award of contracts if not filed with bid. Effective with bids received and contracts awarded after January 18, 2010, this law removes the requirement of the Local Public Contracts Law (N.J.S.A. 40A:11-23.2) that required a bid to be rejected if the respondent failed to include a BRC with their bid, even though it may have been the lowest responsible bid.

The law now allows the BRC to be filed any time prior to award of the contract and the bidder had to obtain the BRC prior to receipt of bids. This permits the BRC to be required with a bid, or submitted subsequently. If a BRC is required in a bid, but not submitted with the bid, it would be an immaterial defect; curable by being filed prior to award of the contract. A BRC is obtained from the New Jersey Division of Revenue. Information on obtaining a BRC is available on the internet at www.nj.gov/njbgs or by phone at (609) 292-1730.

2.8.7 “Pay to Play” – Notice of Disclosure Requirement – P.L. 2005, Chapter 271, Section 3 Reporting (N.J.S.A. 19:44A – 20.27)

(1) Any business entity that has received $50,000 or more in contracts from government entities in a calendar year is required to file an annual disclosure report with ELEC. The instructions and form are available on the ELEC website.

(2) Annual Disclosures require submission by March 30th of each year covering contracts and contributions for the prior calendar year.

(3) At a minimum, a list of all business entities that file an annual disclosure report will be listed on ELEC’s website at www.elec.state.nj.us.

(4) If you have any questions please contact ELEC at:

1-888-313-ELEC (3532) (toll free in NJ) or 609-292-8700

2.8.8 Assign, Sublet or Transfer Any Rights/Interests

Neither the owner nor the Contractor shall assign, sublet, or transfer any rights or interest in this Agreement without the prior written consent of the other party. Unless specifically stated to the contrary, in writing, prior to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under this Agreement. Nothing herein shall be construed to give any rights or benefits to anyone other than the owner and the Contractor.

2.8.9 Insurance and Indemnification

If it becomes necessary for the contractor, either as principal or by agent or employee, to enter upon the premises or property of the owner in order to construct, erect, inspect, make delivery or remove property hereunder, the contractor hereby covenants and agrees to take use, provide and make all proper, necessary and sufficient precautions, safeguards, and protection against the occurrence of happenings of any accident, injuries, damages, or hurt to person or property during the course of the work herein covered and be his/her sole responsibility.

The contractor further covenants and agrees to indemnify and save harmless the owner from the payment of all sums of money or any other consideration(s) by reason of any, or all, such accidents, injuries, damages, or hurt that may happen or occur upon or about such work and all fines, penalties and loss incurred for or by reason of the violation of any owner regulation, ordinance or the laws of the State, or the United States while said work is in progress.

The contractor shall maintain sufficient insurance to protect against all claims under Workers Compensation, General Liability and Automobile and shall be subject to approval for adequacy of protection and certificates of such insurance shall be provided.

A. Insurance Requirements:

Worker’s Compensation and Employer’s Liability Insurance This insurance shall be maintained in full force during the life of this contract by the contractor covering all employees engaged in performance of this contract pursuant to N.J.S.A. 34:15-12(a) and N.J.A.C. 12:235-1.6. Minimum Employer’s Liability $l,000,000.00.

Commercial General Liability Insurance This insurance shall be on an “occurrence” basis, including products and completed operations, property damage, bodily injury and personal & advertising injury with limits no less than $1,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location or the general aggregate limit shall be twice the required occurrence limit. The Township of Franklin, its officers, officials, employees, and volunteers are to be covered as additional insureds on the commercial general liability policy with respect to liability arising out of work or operations performed by or on behalf of the Consultant including materials, parts, or equipment furnished in connection with such work or operations

Automobile Liability Insurance This insurance covering contractor for claims arising from owned, hired and non-owned vehicles with limits of not less than $1,000,000.00 any one person and $1,000,000.00 any one accident for bodily injury and $1,000,000.00 each accident for property damage, shall be maintained in force during the life of this contract by the contractor.

B. Certificates of the Required Insurance

Certificates shall be submitted along with the contract as evidence covering the above insurances in the amounts set forth above. Such coverage shall be with acceptable insurance companies operating on an admitted basis in the State of New Jersey.

Self-insured contractors shall submit an affidavit attesting to their self-insured coverage and shall name the owner as an additional insured.

Franklin Township will not accept Mutual Limitation of Liability terms.

C. Indemnification Successful respondent shall indemnify and hold harmless the owner from all claims, suits or actions and damages or costs of every name and description to which the owner may be subjected or put by reason of injury to the person or property of another, or the property of the owner, resulting from negligent acts or omissions on the part of the respondent, the respondent’s agents, servants or subcontractors in the delivery of goods and services, or in the performance of the work under the contract.

Professional Liability, (Errors & Omissions) Insurance Policy

Insurance appropriates to the Consultant’s profession, with limit no less than $1,000,000 per occurrence or claim, $1,000,000 aggregate.

2.8.10 HIPAA (If Applicable)

Both parties agree to comply with all requirements of the Federal Health Insurance Portability and Accountability Act of 1996 (“HIPAA”) as maybe amended from time to time, and the corresponding HIPAA regulations for the confidentiality and security of medical information.

The Contractor shall:

Not use or disclose protected health information other than as permitted or required by law Use appropriate safeguards to protect the confidentiality of the information Report any use or disclosure not permitted

The contractor, by execution of the contract, shall thereby indemnify and hold the Township harmless from any and all liabilities, claims, actions, costs and penalties which may be incurred as the result of the failure of the contractor to comply with the requirements of the Health Insurance Portability and Accountability Act (HIPAA) or any other statute or case law protecting the privacy of persons using its services.

2.8.11 Proof of Licensure

Proof of licensure for providing Professional Services in the State of New Jersey, for either the firm or the person responsible for the work, shall be provided as required.

2.8.12 Disclosure of Investment Activities in Iran

P.L. 2012, c.25 prohibits State and local public contracts with persons or entities engaging in certain investment activities in energy or finance sectors of Iran.

2.9 Public Emergency

In the event of a Public Emergency declared at the Local, State or Federal Level, if the Township opts to extend terms and conditions of this RFP, the contractor agrees to extend the terms and conditions of this RFP, whether existing, expiring or expired no longer than six months, for goods and/or services for the duration of the emergency. In the event the original contractor cannot meet this requirement, the Township may solicit the goods and/or services from any respondent on this contract.

2.10 Multiple Proposals Not Accepted

More than one proposal from an individual, a firm or partnership, a corporation or association under the same or different names shall not be considered.

2.11 Use of Sub-consultants

Respondent may find it advantageous to include sub-consultants in their proposal. Such an arrangement is acceptable provided that the relationship between firms is clearly defined and the method of maintaining proper project management and oversight is described within the proposal. The use of sub-consultants is left to the discretion of respondent, provided that the criteria of adequate capability in all areas of the scope of work is met. Any sub-consultants must be identified in the same manner as the primary consultant.

2.12 Failure to Enter Contract

Should the respondent, to whom the contract is awarded, fail to enter into a contract within ten

(10) days, Sundays and holidays excepted, the owner may then, at its option, accept the proposal of another respondent.

2.13 Commencement of Work

The contractor agrees to commence work after the date of award by the owner and upon notice from the using department.

2.14 Termination of Contract

If, through any cause, the contractor shall fail to fulfill in a timely and proper manner obligations under the Contract or if the contractor violates any requirements of the Contract, the owner shall thereupon have the right to terminate the Contract by giving written notice to the contractor of such termination at least thirty (30) days prior to the proposed effective date of the termination.

Such termination shall relieve the owner of any obligation for the balances to the contractor of any sum or sums set forth in the Contract.

The contractor agrees to indemnify and hold the owner harmless from any liability to subcontractors/suppliers concerning payment for work performed or goods supplied arising out of the lawful termination of the Contract by the owner under this provision. In case of default by the contractor, the owner may procure the articles or services from other sources and hold the contractor responsible for any excess cost occasioned thereby.

2.15 Non-Allocation of Funding Termination

Each fiscal year payment obligation of the Owner is conditioned upon the availability of Owner funds appropriated or allocated for the payment of such an obligation. If funds are not allocated and available for the continuance of any services performed by the Contractor hereunder, whether in whole or in part, the Owner at the end of any particular fiscal year may terminate such services. The Owner will notify the Contractor in writing immediately of any services that will be affected by a shortage of appropriated funds. This provision shall not be construed so as to permit the Owner to terminate this Agreement during the term, or any service hereunder, merely in order to acquire identical services from a third party contractor.

2.16 Force Majeure

Neither party shall be responsible for any resulting loss or obligation to fulfill duties as specified in any of the terms or provisions of this Agreement if the fulfillment of any term or provision of this Agreement is delayed or prevented by any revolutions, insurrections, riots, wars, acts of enemies, national emergencies, strikes, floods, fires, acts of God, or by any cause not within the control of the party whose performance is interfered with which by the exercise of reasonable diligence such party is unable to prevent. Additionally, if the fulfillment of any of the terms and provisions of this Agreement is delayed or prevented by any court order, or action or injunction or other such agreement, this Agreement shall become voidable by the owner by notice to each party.

2.16 The owner and the Contractor each bind themselves and their successors, executors, administrators, heirs and assigns and legal representatives of the other party respecting all covenants and agreements and obligations of this contract.

2.17 The terms of this Agreement shall be construed and interpreted, and all respective rights and duties of the parties shall be governed by the laws of the State of New Jersey.

2.18 Challenge of Specifications

Any respondent who wishes to challenge a specification shall file such challenge in writing with the Purchasing Agent no less than three (3) business days prior to the opening of the RFP's.

Challenges filed after that time shall be considered void and having no impact on the owner or the award of contract.

2.19 Payment

Invoices shall specify, in detail, the period for which payment is claimed, the services performed during the prescribed period, the amount claimed and correlation between the services claimed and the Proposal Cost Form.

Payment will be made on presentation of owner’s voucher duly signed and executed.

The owner may withhold all or partial payments on account of subsequently discovered evidence including but not limited to the following:

1 Deliverables not complying with the project specification;

2 Claims filed or responsible evidence indicating probability of filing claims;

3 A reasonable doubt that the Contract can be completed for the balance then unpaid.

When the above grounds are removed, payment shall be made for amounts withheld because of them.

2.20 Non-payment of Penalties and Interest on Overdue Bills

Public funds may be used to pay only for goods delivered or services rendered. Franklin Township, Somerset County will not pay penalties and/or interest on overdue bills. No employee is authorized to sign a letter of credit or any other document that represents a legal commitment on the part of the Township to pay additional fees.

2.21 Ownership of Material

The owner shall retain all of its rights and interest in any and all documents and property both hard copy and digital furnished by the owner to the contractor for the purpose of assisting the contractor in the performance of this contract. All such items shall be returned immediately to the owner at the expiration or termination of the contract or completion of any related services, pursuant thereto, whichever comes first. None of the documents and/or property shall, without the written consent of the owner, be disclosed to others or used by the contractor or permitted by the contractor to be used by their parties at any time except in the performance of the resulting contract.

Ownership of all data, materials and documentation originated and prepared for the owner pursuant to this contract shall belong exclusively to the owner. All data, reports, computerized information, programs and materials related to this project shall be delivered to and become the property of the owner upon completion of the project. The contractor shall not have the right to use, sell, or disclose the total of the interim or final work products, or make available to third parties, without the prior written consent of the owner. All information supplied to the owner may be required to be supplied on CD-ROM media compatible with the owner’s computer operating system, windows based, Microsoft Office Suite 2007 or greater.

2.22 Source of Specifications/RFP Packages

Official Municipal Request for Proposal (RFP) packages for routine goods and services are available from www.franklintwpnj.org at no cost to the prospective respondents. All addenda are posted on this site. Potential respondents are cautioned that they are responding at their own risk if a third party supplied the specifications that may or may not be complete. The owner is not responsible for third party supplied RFP documents.

2.23 Multi-Brand Manufacturer’s

Specifications for a contract item may include a specific manufacturer's brand and model number or equivalent. The product brand or brands referenced in the specifications shall be restricted to one brand produced or manufactured by a multi-brand commercial products manufacturer.

2.24 Consultant Affiliation

Consultants are prohibited from specifying a product line in which such consultant has an affiliation. As such, there shall be no affiliation between the consultant and product manufacturers referenced in the specifications, nor shall the consultant endorse those companies or manufacturers referenced in the specifications.

2.25 Source of Specifications/RFP Packages

Official Township Request for Proposal (RFP) packages for routine goods and services are available from http://www.franklintwpnj.org/ at no cost to the prospective respondents. All addenda are posted on this site. Potential respondents are cautioned that they are responding at their own risk if a third party supplied the specifications that may or may not be complete. The Township is not responsible for third party supplied RFP documents.

2.26 Altering Official Document

Respondents shall not write in any margins or alter the official content of Franklin Township RFP document.

2.27 Government entities are not private business/consumer clients;

therefore, separate company agreements are not honored. Terms of the specifications/bid package prevail unless otherwise noted by the vendor as exceptions.

2.28 W-9

Successful respondent shall complete W-9 Form and submit to Purchasing prior to contract award. The form is available at the following link: http://www.irs.gov/pub/irs-pdf/fw9.pdf

2.29 Conflict of Interest

Successful respondents are required to be free of any conflict of interest. As the Township is a public entity, please note that the Township is precluded by the Rules of Professional Conduct from waiving conflicts of interest. See RPC 1.7(a)(2) and RPC 1.7(b)(2). If your firm is awarded a contract, you have an ongoing obligation during the term of your designation to disclose any and all actual or potential conflicts and to not accept matters adverse to the Township.

2.30 No Endorsement

Award of professional services contract does not constitute an endorsement by the Township of Franklin, County of Somerset. A firm awarded a professional services contract shall not promote or advertise its designation without first obtaining the Township’s permission.

2.31 future use

2.32 Open Public Records Act

Respondents are hereby advised that their responses may be subject to dissemination under the Open Public Records Act (“OPRA”) or the common law right of access.

3. SCOPE OF WORK (SOW)

1.0 GENERAL REQUIREMENTS

1.1 The Scope of work may generally will consist of the emergency trouble shooting and repair, testing, calibration, review of improvement plans (pump stations, tanks, and interconnects) as related to the SCADA system, installation of software and software upgrades, PLC programing and troubleshooting, and display/communication modifications for the SCADA system.

1.2 Also included is updating system architecture schematics, wiring diagrams, maintaining logic documentation, building and replacing any PLC racks and modules, and making upgrade recommendations.

1.3 The system includes operator stations, virtual machines running SCADA software, and, communication hardware and software

1.4 Monitoring of condition of their communication networks and reporting of issues as requested.

1.5 Included in services is installation, repairing, and replacing of instrumentation and other portions of the SCADA system.

2.0 QUALIFICATIONS

2.1 The Contractor shall have completed Work of similar or greater complexity on at least three (3) previous projects within the last five (5) years.

3.0 DETAILS OF SYSTEM

3.1 Communication, HMI, database, and alarming applications:

3.1.1 GE MDS Orbit radio platform

3.1.2 Rockwell Plant Pax

3.1.3 FactoryTalk View SE

3.1.4 FactoryTalk View ME

3.1.5 FactoryTalk Studio

3.1.6 FactoryTalk Historian SE

3.1.7 FactoryTalk Alarm & Events Server

3.1.8 WIN 911 alarm notification

3.1.9 Virtual Private Networks (VPN) for SCADA systems web servers

3.1.10 Operator Station - 1

3.1.11 Operator Station - 2

3.1.12 SCADA Virtual Servers

3.2 Locations:

3.2.1 Berry Street Pump Station PLC & OIT

3.2.1.1 Maintain Flowmeter IO

3.2.1.2 Maintain Water Quality Chlorine Residual IO

3.2.1.3 Maintain Motor control IO

3.2.1.4 Maintain UPS Power

3.2.1.5 Maintain Instrumentation

3.2.1.6 Maintain Radios

3.2.1.7 Maintain interface enclosure containing the following:

3.2.1.7.1 120V surge suppression and signal surge suppression

3.2.1.7.2 12Vac Transformer and 24Vdc power supply

3.2.1.7.3 Input and output interpose relays

3.2.1.7.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.1.7.5 Maintain wiring for power and signals.

3.2.1.7.6 Maintain wiring, programming, and interface with

equipment.

3.2.2 Cortelyous Pump Station PLC & OIT

3.2.2.1 Maintain Flowmeter IO

3.2.2.2 Maintain Water Quality Chlorine Residual IO

3.2.2.3 Maintain Motor control IO

3.2.2.4 Maintain UPS Power

3.2.2.5 Maintain Instrumentation

3.2.2.6 Maintain Radios

3.2.2.7 Maintain Vliet Tank Tank Level IO

3.2.2.8 Maintain interface enclosure containing the following:

3.2.2.8.1 120V surge suppression and signal surge suppression

3.2.2.8.2 12Vac Transformer and 24Vdc power supply

3.2.2.8.3 Input and output interpose relays

3.2.2.8.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.2.8.5 Maintain wiring for power and signals.

3.2.2.8.6 Maintain wiring, programming, and interface with

equipment.

3.2.3 Society Hill Pump Station PLC & OIT

3.2.3.1 Maintain Flowmeter IO

3.2.3.2 Maintain Water Quality Chlorine Residual IO

3.2.3.3 Maintain Motor control IO

3.2.3.4 Maintain UPS Power

3.2.3.5 Maintain Instrumentation

3.2.3.6 Maintain Radios

3.2.3.7 Maintain interface enclosure containing the following:

3.2.3.7.1 120V surge suppression and signal surge suppression

3.2.3.7.2 12Vac Transformer and 24Vdc power supply

3.2.3.7.3 Input and output interpose relays

3.2.3.7.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.3.7.5 Maintain wiring for power and signals.

3.2.3.7.6 Maintain wiring, programming, and interface with

equipment.

3.2.4 Rocky Hill (RT 518) Pump Station PLC & OIT

3.2.4.1 Maintain Flowmeter IO

3.2.4.2 Maintain Water Quality Chlorine Residual IO

3.2.4.3 Maintain Motor control IO

3.2.4.4 Maintain UPS Power

3.2.4.5 Maintain Instrumentation

3.2.4.6 Maintain Radios

3.2.4.7 Maintain interface enclosure containing the following:

3.2.4.7.1 120V surge suppression and signal surge suppression

3.2.4.7.2 12Vac Transformer and 24Vdc power supply

3.2.4.7.3 Input and output interpose relays

3.2.4.7.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.4.7.5 Maintain wiring for power and signals.

3.2.4.7.6 Maintain wiring, programming, and interface with

equipment.

3.2.5 Bunker Hill Pump Station PLC & OIT

3.2.5.1 Maintain Flowmeter IO

3.2.5.2 Maintain Water Quality Chlorine Residual IO

3.2.5.3 Maintain Motor control IO

3.2.5.4 Maintain UPS Power

3.2.5.5 Maintain Instrumentation

3.2.5.6 Maintain Radios

3.2.5.7 Maintain South End Tank Tank Level IO

3.2.5.8 Maintain interface enclosure containing the following:

3.2.5.8.1 120V surge suppression and signal surge suppression

3.2.5.8.2 12Vac Transformer and 24Vdc power supply

3.2.5.8.3 Input and output interpose relays

3.2.5.8.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.5.8.5 Maintain wiring for power and signals.

3.2.5.8.6 Maintain wiring, programming, and interface with

equipment.

3.2.6 Landing Lane Pump Station PLC & OIT

3.2.6.1 Maintain Flowmeter IO

3.2.6.2 Maintain Water Quality Chlorine Residual IO

3.2.6.3 Maintain Motor control IO

3.2.6.4 Maintain UPS Power

3.2.6.5 Maintain Instrumentation

3.2.6.6 Maintain Radios

3.2.6.7 Maintain South End Tank Tank Level IO

3.2.6.8 Maintain interface enclosure containing the following:

3.2.6.8.1 120V surge suppression and signal surge suppression

3.2.6.8.2 12Vac Transformer and 24Vdc power supply

3.2.6.8.3 Input and output interpose relays

3.2.6.8.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.6.8.5 Maintain wiring for power and signals.

3.2.6.8.6 Maintain wiring, programming, and interface with

equipment.

3.2.7 Amwell Road Interconnect PLC

3.2.7.1 Maintain Flowmeter IO

3.2.7.2 Maintain Chart Recorders IO

3.2.7.3 Maintain UPS Power

3.2.7.4 Maintain Radios

3.2.7.5 Maintain interface enclosure containing the following:

3.2.7.5.1 120V surge suppression and signal surge suppression

3.2.7.5.2 12Vac Transformer and 24Vdc power supply

3.2.7.5.3 Input and output interpose relays

3.2.7.5.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.7.5.5 Maintain wiring for power and signals.

3.2.7.5.6 Maintain wiring, programming, and interface with

equipment.

3.2.8 Canal Road Interconnect PLC

3.2.8.1 Maintain Flowmeter IO

3.2.8.2 Maintain Chart Recorders IO

3.2.8.3 Maintain UPS Power

3.2.8.4 Maintain Radios

3.2.8.5 Maintain interface enclosure containing the following:

3.2.8.5.1 120V surge suppression and signal surge suppression

3.2.8.5.2 12Vac Transformer and 24Vdc power supply

3.2.8.5.3 Input and output interpose relays

3.2.8.5.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.8.5.5 Maintain wiring for power and signals.

3.2.8.5.6 Maintain wiring, programming, and interface with

equipment.

3.2.9 Mettlers Road Interconnect PLC

3.2.9.1 Maintain Flowmeter IO

3.2.9.2 Maintain Chart Recorders IO

3.2.9.3 Maintain UPS Power

3.2.9.4 Maintain Radios

3.2.9.5 Maintain interface enclosure containing the following:

3.2.9.5.1 120V surge suppression and signal surge suppression

3.2.9.5.2 12Vac Transformer and 24Vdc power supply

3.2.9.5.3 Input and output interpose relays

3.2.9.5.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.9.5.5 Maintain wiring for power and signals.

3.2.9.5.6 Maintain wiring, programming, and interface with

equipment.

3.2.10 Randolph Road Interconnect PLC

3.2.10.1 Maintain Flowmeter IO

3.2.10.2 Maintain Chart Recorders IO

3.2.10.3 Maintain UPS Power

3.2.10.4 Maintain Radios

3.2.10.5 Maintain interface enclosure containing the following:

3.2.10.5.1 120V surge suppression and signal surge suppression

3.2.10.5.2 12Vac Transformer and 24Vdc power supply

3.2.10.5.3 Input and output interpose relays

3.2.10.5.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.10.5.5 Maintain wiring for power and signals.

3.2.10.5.6 Maintain wiring, programming, and interface with

equipment.

3.2.11 School House Road Interconnect PLC

3.2.11.1 Maintain Flowmeter IO

3.2.11.2 Maintain Chart Recorders IO

3.2.11.3 Maintain UPS Power

3.2.11.4 Maintain Radios

3.2.11.5 Maintain interface enclosure containing the following:

3.2.11.5.1 120V surge suppression and signal surge suppression

3.2.11.5.2 12Vac Transformer and 24Vdc power supply

3.2.11.5.3 Input and output interpose relays

3.2.11.5.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.11.5.5 Maintain wiring for power and signals.

3.2.11.5.6 Maintain wiring, programming, and interface with

equipment.

3.2.12 Weston Road Interconnect PLC

3.2.12.1 Maintain Flowmeter IO

3.2.12.2 Maintain Chart Recorders IO

3.2.12.3 Maintain UPS Power

3.2.12.4 Maintain Radios

3.2.12.5 Maintain interface enclosure containing the following:

3.2.12.5.1 120V surge suppression and signal surge suppression

3.2.12.5.2 12Vac Transformer and 24Vdc power supply

3.2.12.5.3 Input and output interpose relays

3.2.12.5.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.12.5.5 Maintain wiring for power and signals.

3.2.12.5.6 Maintain wiring, programming, and interface with

equipment.

3.2.13 South End Tank PLC & OIT

3.2.13.1 Maintain South End Tank Tank Level transmitter IO

3.2.13.2 Maintain UPS Power

3.2.13.3 Maintain Radios

3.2.13.4 Maintain interface enclosure containing the following:

3.2.13.4.1 120V surge suppression and signal surge suppression

3.2.13.4.2 12Vac Transformer and 24Vdc power supply

3.2.13.4.3 Input and output interpose relays

3.2.13.4.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.13.4.5 Maintain wiring for power and signals.

3.2.13.4.6 Maintain wiring, programming, and interface with

equipment.

3.2.14 Vliet Road Tank PLC & OIT

3.2.14.1 Maintain Vliet Tank Tank Level transmitter IO

3.2.14.2 Maintain UPS Power

3.2.14.3 Maintain Radios

3.2.14.4 Maintain interface enclosure containing the following:

3.2.14.4.1 120V surge suppression and signal surge suppression

3.2.14.4.2 12Vac Transformer and 24Vdc power supply

3.2.14.4.3 Input and output interpose relays

3.2.14.4.4 Fuse blocks, terminal blocks, dinrail, Panduit

3.2.14.4.5 Maintain wiring for power and signals.

3.2.14.4.6 Maintain wiring, programming, and interface with

equipment.

3.2.15 Radio Repeater Site

3.2.15.1 Maintain UPS Power

3.2.15.2 Maintain Radios

3.2.15.3 Maintain Instrumentation

3.2.16 Trap Rock Pump Station PLC & OIT (FUTURE)

3.2.17 Kingston Interconnect PLC (FUTURE)

4.0 AUTHORITY OF PROCUREMENT

4.1 This competitive contract is being conducted as per the authority of

N.J.S.A. 40A:11-4.1 et. Seq.,

5.0 BASIS OF AWARD

5.1 As per the authority provided in the Competitive Contract process, the bases of award will be to the vendor who is the most advantageous to the Township of Franklin based upon Price and Other Factors. These factors per statute and rules are the demonstrated basis of:

5.1.1 Cost

5.1.2 Technical Ability

5.1.3 Managerial Ability

6.0 TERM AND PROPOSAL

6.1 The Township will be seeking a five (5) year contract with the successful vendor.

6.2 Respondents are to provide for cost consideration:

6.2.1 Proposed hourly rate fee schedule for contract

6.2.2 Any other outside costs in addition to maintenance, software upgrades and service outside of the scope of this procurement.

Experience & Qualifications Questionnaire

This questionnaire must be filled out and submitted as a part of the Proposal.

Failure to complete this form or to provide any of the requested information will be grounds for the rejection of the bid proposal. If additional space is required, the respondent shall add additional sheets, which identify the question being answered.

Number of years in business under present name & address:

If less than 5 years, list previous names and address:

Within the last 5 years has the business or any officer/partner failed to complete a contract awarded to them: _______ . If yes, provide the details in on a separate page.

Have any liens and lawsuits been filed against the company in the past 5 years: __________

If yes, please provide details:

List similar services you are now providing for which you have signed contract, but not yet started work:

List all major subcontractors to be used to complete the service and the area of their responsibility:

Please provide at least 3 references below:

Name: Phone:

Address:

Equipment/Service Provided:

Contract Amount:

Name: Phone:

Address:

Equipment/Service Provided:

Contract Amount:

Name: Phone:

Address:

Equipment/Service Provided:

Contract Amount:

Name: Phone:

Address:

Equipment/Service Provided:

Contract Amount:

4. Proposal Requirements

4.1 Qualification Statement

A statement is to be provided by the respondent who will serve as the primary contractor. The statement shall set forth brief details of the firm's principal activities, the number of personnel in the firm and the firm's location. Please provide a list of (3) three clients for whom similar services have been provided. Include the following in your response:

1. Name of government agency

2. Contact person’s name, position, and current telephone number

3. Dates, cost and scope of service

4. Status and comments

Qualification Statements and Proposals will be reviewed and evaluated by staff from Franklin Township.

Fee Schedule

Consultants shall submit a fee schedule with their proposal for the services to meet the requirements of this contract.

5. Evaluation, Review and Selection Process

5.1 Proposals to Remain Subject to Acceptance

RFP responses shall remain open for a period of sixty (60) calendar days from the stated submittal date. The owner will either award the Contract within the applicable time period or reject all proposals.

The owner may extend the decision to award or reject all proposals beyond the sixty (60) calendar days when the proposals of any respondents who consent thereto may, at the request of the owner, be held for consideration for such longer period as may be agreed.

5.2 Rejection of Proposals

The owner reserves the right to reject any or all proposals, or to reject any proposals if the evidence submitted by, or investigation of such respondent fails to satisfy the owner that such respondent is properly qualified to carry out the obligations of the RFP and to complete the work contemplated therein. The owner reserves the right to waive any minor informality in the RFP.

5.3 Evaluation Process

An evaluation team will review all proposals to determine if they satisfy the Proposal Requirements, determine if a proposal should be rejected and evaluate the proposals based upon the Evaluation Criteria. The highest-ranking respondent will then be recommended to the governing body for award of contract, based on price and other factors.

5.4 Evaluation Criteria

The criterion considered in the evaluation of each proposal follows. The arrangement of the criteria is not meant to imply order of importance in the selection process. All criteria will be used to select the successful respondent. The respondent may be requested to clarify elements of the proposal.

5.4.1 Understanding of the Requested Work

The proposals will be evaluated for general compliance with instructions and requests issued in the RFP. Non-compliance with significant instructions shall be grounds for disqualification of proposals.

5.4.2 Knowledge and Technical Competence

This includes the ability of the respondent to perform all of the tasks and fulfill adequately the stated requirements.

5.4.2.a. Management, Experience and Personnel Qualifications

Expertise of the firm shall be demonstrated by past contract successes providing government or other agencies with similar services. The respondent will be evaluated on knowledge, experience, prior collaboration and successful completion of projects/services similar to that requested in this RFP. In additional to relevant experience, respondents shall provide personnel qualifications in the Proposal.

5.4.3 Ability to Complete the Services in a Timely Manner

This is based on the estimated duration of the tasks and the respondent’s ability to accomplish these tasks as stated.

5.4.4 Cost

Price shall be based on schedules of fees submitted with the proposal. Any services not included as part of any resulting contract scope of services must be approved and authorized by the owner before such work is initiated. The owner shall pay for such approved services, at the rate or cost agreed upon between the owner and contractor, and provided the respondent has provided a schedule of fees for additional services with this RFP.

5.5 Payment

a. Successful respondent must provide an itemized invoice and signed Purchase Order/Voucher.

The Voucher will be certified correct by the Department Head who receives the material or service. Payment will only be made following the approval of by the Township Council. The Township Council meets and approves warrants on the second and fourth Tuesday of each month, except July, August and December, when they meet only on the 2nd Tuesday of the month. Payment vouchers and invoices must reach the Department for review no later than three weeks before the Township Council meeting in order for payment to be on the agenda for approval.

b. Acceptance of the final payment by the successful respondent shall be considered as a release in full of all claims against the Township of Franklin, Somerset County.

c. The Township of Franklin will not pay penalties, interest or late fees. No employee is authorized to sign a letter or credit of any other document that represents a legal commitment on the part of the Township to pay additional fees.

5.6 Notice of Award

The successful respondent will be notified of the award of contract upon a favorable decision by the governing body. The Purchasing Agent may then send a Purchase Order/Voucher to the contractor.

5.7 Term of Contract:

Five years

TOWNSHIP OF FRANKLIN, COUNTY OF SOMERSET

EXCEPTIONS

(IF NONE SO STATE)

USE ADDITIONAL SHEET IF NECESSARY

FRANKLIN TOWNSHIP, COUNTY OF SOMERSET

RFP DOCUMENT CHECKLIST

Required With

Response

Read, Signed & Submitted Respondent’s

Initial

A. FAILURE TO SUBMIT ANY OF THESE ITEMS IS MANDATORY CAUSE FOR

REJECTION OF RFP

Ownership Disclosure Certification Non-Collusion Affidavit Acknowledgement of Receipt of Addenda (To be Completed if Addenda are Issued) Required Evidence EEO/Affirmative Action Regulations Certificate or Questionnaire

Qualification Statement Proposal Cost page/Fee Schedule

Key Personnel Information

B. MANDATORY ITEM(S), REQUIRED NO LATER THAN TIME PERIOD INDICATED

New Jersey Business Registration Certificate – Prior to award of contract CD or flash drive with PDF of RFP along with Printed Copies Three (3) references for similar projects Copy of Certificate of insurance Name Owner as Additionally Insured

Disclosure of Activities in Iran (must submit prior to award of contract)

C. READ ONLY

Americans With Disability Act of 1990 Language

This checklist is provided for respondent’s use in assuring compliance with required documentation; however, it does not necessarily include all specifications requirements and does not relieve the respondent of the need to read and comply with the specifications.

Name of Respondent: Date:

By Authorized Representative:

Signature:

Print Name & Title:

PROPOSAL COST FORM/SIGNATURE PAGE

SCADA Software and System Maintenance

CONTRACT # MC-COM-0015-21

TO THE FRANKLIN TOWNSHIP COUNCIL:

The undersigned declares that he/she has read the Notice, Instructions, Affidavits and Scope of Services attached, that he/she has determined the conditions affecting the proposal and agrees, if this proposal is accepted, to furnish and deliver services per fee schedule submitted with the proposal.

Fee schedule submitted with proposal

(Corporate)

The undersigned is a (Partnership) under the laws of the State of _______________________________ having its (Individual) principal office at

Company Federal I.D. # or last 4 digits Social Security #

Address

Signature of Authorized Agent Type or Print Name

Telephone Number Date

Fax Number Email Address

STATEMENT OF OWNERSHIP DISCLOSURE

N.J.S.A. 52:25-24.2 (P.L. 1977, c.33, as amended by P.L. 2016, c.43)

This statement shall be completed, certified to, and included with all bid and proposal submissions.

Failure to submit the required information is cause for automatic rejection of the bid or proposal.

Name of Organization:_________________________________________________________________

Organization Address:_________________________________________________________________

Part I Check the box that represents the type of business organization:

Sole Proprietorship (skip Parts II and III, execute certification in Part IV) Non-Profit Corporation (skip Parts II and III, execute certification in Part IV) For-Profit Corporation (any type) Limited Liability Company (LLC) Partnership Limited Partnership Limited Liability Partnership (LLP) Other (be specific): ______________________________________________

Part II

The list below contains the names and addresses of all stockholders in the corporation who own 10 percent or more of its stock, of any class, or of all individual partners in the partnership who own a 10 percent or greater interest therein, or of all members in the limited liability company who own a 10 percent or greater interest therein, as the case may be. (COMPLETE

THE LIST BELOW IN THIS SECTION)

OR

No one stockholder in the corporation owns 10 percent or more of its stock, of any class, or no individual partner in the partnership owns a 10 percent or greater interest therein, or no member in the limited liability company owns a 10 percent or greater interest therein, as the case may be. (SKIP TO PART IV)

(Please attach additional sheets if more space is needed):

Name of Individual or Business Entity Address (for Individuals) or Business Address

Part III DISCLOSURE OF 10% OR GREATER OWNERSHIP IN THE STOCKHOLDERS, PARTNERS OR LLC MEMBERS LISTED IN PART II

If a bidder has a direct or indirect parent entity which is publicly traded, and any person holds a 10 percent or greater beneficial interest in the publicly traded parent entity as of the last annual federal Security and Exchange Commission (SEC) or foreign equivalent filing, ownership disclosure can be met by providing links to the website(s) containing the last annual filing(s) with the federal Securities and Exchange Commission (or foreign equivalent) that contain the name and address of each person holding a 10% or greater beneficial interest in the publicly traded parent entity, along with the relevant page numbers of the filing(s) that contain the information on each such person. Attach additional sheets if more space is needed.

Website (URL) containing the last annual SEC (or foreign equivalent) filing Page #’s

Please list the names and addresses of each stockholder, partner or member owning a 10 percent or greater interest in any corresponding corporation, partnership and/or limited liability company (LLC) listed in Part II other than for any publicly traded parent entities referenced above.