TAB 12 - FA9201-09-R-0141 RFP 15 MAY 09.pdf

SOLICITATION, OFFER AND AWARD 1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 350)

RATING

DO-A7

PAGE OF PAGES

1 25

2. CONTRACT NO. 3. SOLICITATION NO. 4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

5. DATE ISSUED

15 MAY 2009

6. REQUISITION/PURCHASE NO.

FA9201-09-R-0141

7. ISSUED BY AAC/PKET CODE FA9201 8. ADDRESS OFFER TO (If other than Item 7)

DEPARTMENT OF THE AIR FORCE

AIR ARMAMENT CENTER (AAC)

205 W D AVE STE 427

EGLIN AFB, FL 32542

SHANNON K. PARADISE 850-882-0183

SHANNON.PARADISE@EGLIN.AF.MIL

NOTE: In sealed bid solicitations “offer” and “offeror” mean “bid” and “bidder”.

SOLICITATION

9.

10. FOR

INFORMATION

CALL:

A. NAME

See Block 7

B. TELEPHONE (Include area code)

(NO COLLECT CALLS)

See Block 7

C. E-MAIL ADDRESS

See Block 7

11. TABLE OF CONTENTS

() SEC. DESCRIPTION PAGE(S) () SEC DESCRIPTION PAGE(S)

PART I - THE SCHEDULE PART II - CONTRACT CLAUSES

A SOLICITATION/CONTRACT FORM 1 I CONTRACT CLAUSES 17

B SUPPLIES OR SERVICES AND PRICES/COSTS 2 PART III - LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACH.

C DESCRIPTION/SPECS./WORK STATEMENT 9 J LIST OF ATTACHMENTS 25

D PACKAGING AND MARKING 10 PART IV - REPRESENTATIONS AND INSTRUCTIONS

E INSPECTION AND ACCEPTANCE 11 K REPRESENTATIONS, CERTIFICATIONS, K - 1

F DELIVERIES OR PERFORMANCE 12 AND OTHER STATEMENTS OF OFFERORS

G CONTRACT ADMINISTRATION DATA 15 L INSTRS, CONDS, AND NOTICES TO OFFERORS L - 1

H SPECIAL CONTRACT REQUIREMENTS 16 M EVALUATION FACTORS FOR AWARD M - 1

OFFER (Must be fully completed by offeror) NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

12. In compliance with the above, the undersigned agrees, if this offer is accepted within ____ ____ calendar days (60 calendar days unless a different period is inserted by the offeror) from the date of receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

10 CALENDAR DAYS

20 CALENDAR DAYS

30 CALENDAR DAYS

CALENDAR DAYS

14. ACKNOWLEDGEMENTS OF AMENDMENTS

(The offeror acknowledges receipt of amend-

AMENDMENT NO. DATE AMENDMENT NO. DATE

ments to the SOLICITATION for offerors and related documents numbered and dated:

15A. NAME

AND

CODE FACILITY 16. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

ADDRESS

OF

OFFEROR

15B. TELEPHONE NO. (Include area code)

15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

17. SIGNATURE 18. OFFER DATE

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETI-

TION: 23. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

28. AWARD DATE

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 33 (REV. 9-97)

PREVIOUS EDITION IS UNUSABLE Prescribed by GSA ConWrite Version 6.10.8 FAR (48 CFR) 53.21(c) Created 14 May 2009 2:00 PM

PART I - THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

SECTION B FA9201-09-R-0141

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

Noun: TEST SITE (TS) A-3 TRANSMITTER SYSTEM 1 (YR 1) NSN: N - Not Applicable Descriptive Data:

All Subcontract Line Items Numbers (subCLINs) shall be provided, performed and delivered in accordance with the Advanced Command Destruct System (ACDS) Technical Requirements Document (TRD), Section J, Attachment 1. SubCLINS shall be delivered no earlier than delivery dates in Section F unless mutually agreed upon by the Government.

0001AA 1 __________

Lot __________

Noun: DEVELOP, BUILD, INTEGRATE & TEST TSA-3

TRANSMITTER SYSTEM 1

NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall acquire components and/or Sub-Systems, develop and build TSA-3 Transmitter System 1. Transmitter System 1 shall pass Sub-Systems Acceptance Testing. Legacy Command Destruct System (CDS) equipment interfacing with new transmitter shall be tested. TSA-3 Transmitter System 1 shall be integrated with legacy CDS. Modified CDS at TSA-3 shall pass Systems Acceptance Testing.

0001AB 1 __________

Lot __________

Noun: MAINTENANCE & OPERATIONAL TRAINING TSA-3

TRANSMITTER SYSTEM 1

NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall provide TSA-3 Transmitter System 1 Maintenance and Operational Training under this subCLIN.

SECTION B FA9201-09-R-0141

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

Noun: TSA-3 TRANSMITTER SYS, TSD-3 SYS 1 & 2, CONTROL

BOXES, MONITORS (YR 2)

NSN: N - Not Applicable Descriptive Data:

All CLINS and subCLINs shall be provided, performed and delivered in accordance with the Advanced Command Destruct System (ACDS) Technical Requirements Document (TRD), Section J, Attachment 1. SubCLINS shall be delivered no earlier than delivery dates in Section F unless mutually agreed upon by the Government.

0002AA 1 __________

Lot __________

Noun: TSA-3 TRANSMITTER SYSTEM 2 NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall acquire components and/or sub-Systems, develop and build Transmitter System 2 for TSA-3. Transmitter System 2 shall pass Sub-System Acceptance Testing.

Legacy Command Destruct System (CDS) equipment interfacing with new transmitter shall be tested. TSA-3 Transmitter System 2 shall be integrated with legacy CDS.

Modified CDS at TSA-3 shall pass System Acceptance Testing. Contractor shall provide Maintenance and Operational Training under this subCLIN.

SECTION B FA9201-09-R-0141

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0002AB 1 __________

Lot __________

Noun: TSD-3 TRANSMITTER SYSTEMS 1 & 2 NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall acquire components and/or Sub-Systems, develop and build Transmitter Systems 1 & 2 for TSD-3. Transmitter Systems 1 & 2 shall pass Sub-System Acceptance Testing. Legacy Command Destruct System (CDS) equipment interfacing with new transmitters shall be tested. TSA-3 Transmitter Systems 1 & 2 shall be integrated with legacy CDS. Modified CDS at TSD-3 shall pass System Acceptance Testing. Contractor shall provide Maintenance and Operational Training under this subCLIN.

0002AC 1 __________

Lot __________

Noun: CENTRAL CONTROL FACILITY (CCF) BOXES AND

CONTROL BOX INTERFACE

NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall develop and build Range Destruct Officer (RDO) and Project Officer (PO) CCF control Boxes. Contractor shall conduct and pass Sub-System Acceptance Testing. Legacy CDS equipment interfacing with new Control Boxes shall be tested.

Contractor shall interface/integrate and configure Boxes, Computers, Consoles, and Monitors. Modified CDS at CCF shall pass System Acceptance Testing. Contractor shall provide Maintenance and Operational Training under this subCLIN.

SECTION B FA9201-09-R-0141

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0002AD 1 __________

Lot __________

Noun: TSA-3, TSD-3, MOBILE TRANSMITTER SYSTEM (MTS)

MONITOR SYSTEMS

NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall acquire components and/or Sub-Systems and build monitor systems for TSA-3, TSD-3 and MTS. Monitors shall pass Sub-System Acceptance Testing. Legacy CDS equipment interface with new monitors shall be tested. Monitors shall be integrated with legacy CDS at TSA-3 and TSD-3. (Note: Integration of MTS monitor to take place in contract year 3). Modified CDS at TSA-3 and TSD-3 shall pass System Acceptance Testing. The contractor shall provide Maintenance and Operational Training under this subCLIN.

0002AE 1 __________

Lot __________

Noun: TSA-6 & TSD-3 FREQUENCY CONTROL & ANALYSIS (FCA)

MONITOR SYSTEMS

NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

The contractor shall acquire components and/or Sub-Systems, develop, and build FCA monitor systems for TSA-6 and TSD-3. Monitors shall pass Sub-System Acceptance Testing. Legacy FCA equipment interfacing with new monitors shall be tested. Contractor shall integrate FCA Monitors with legacy FCA equipment at TSA-6 and TSD-3. Modified FCA system at TSA-6 and TSD-3 shall pass System Acceptance Testing. The contractor shall provide Maintenance and Operational Training under this subCLIN.

SECTION B FA9201-09-R-0141

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

Noun: ANTENNAS FOR TSA-3, TSD-3, AND MTS; TRANSMITTER

FOR MTS (YR 3)

NSN: N - Not Applicable Descriptive Data:

All CLINS and subCLINs shall be provided, performed and delivered in accordance with the Advanced Command Destruct System (ACDS) Technical Requirements Document (TRD), Section J, Attachment 1. SubCLINS shall be delivered no earlier than delivery dates in Section F unless mutually agreed upon by the Government.

0003AA 1 __________

Lot __________

Noun: TSA-3,TSD-3 & MTS ANTENNAS NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall purchase and/or build antennas for TSA-3, TSD-3 and the MTS.

Antennas shall pass Sub-System Acceptance Testing. Legacy equipment interfacing with new antennas at TSA-3 and TSD-3 shall be tested. Contractor shall integrate Antennas at TSA-3 and TSD-3. The modified CDS system at TSA-3 and TSD-3 shall pass System Acceptance Testing. Contractor shall provide Maintenance and Operational Training under this subCLIN.

0003AB 1 __________

Lot __________

Noun: FCA ANTENNAS TSA-6, TSD-3 AND MOBILE FCA NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

The contractor shall purchase and/or build FCA antennas for TSA-6, TSD-3 and the Mobile FCA. Antennas shall pass Sub-System Acceptance Testing. Legacy FCA equipment interfacing with new antennas shall be tested. Contractor shall integrate FCA Antennas at TSA-6 and TSD-3 only. (Note: Mobile FCA antennas shall be delivered to the government). Modified FCA system at TSA-6 and TSD-3 shall pass System Acceptance Testing. Contractor shall provide Maintenance and Operational Training under this subCLIN.

SECTION B FA9201-09-R-0141

Qty Unit Price ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount

0003AC 1 __________

Lot __________

Noun: MOBILE TRANSMITTER SYSTEM (MTS) NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

Contractor shall acquire components and/or Sub-Systems (e.g. transmitter, monitors, etc.) of the MTS. Components/Sub-Systems shall pass acceptance test. Contractor shall test Legacy Command Destruct System (CDS) equipment that is to interface with components or Sub-Systems of the MTS. Contractor shall build the MTS. MTS shall pass acceptance testing. Contractor shall provide Maintenance and Operational Training under this subCLIN.

0004 1 __________ Lot __________

Noun: DATA NSN: N - Not Applicable DD1423 is Exhibit: A Contract type: J - FIRM FIXED PRICE Inspection: DESTINATION Acceptance: DESTINATION

FOB: DESTINATION

Descriptive Data:

The contractor shall deliver data in accordance with DDForm 1423-1, Exhibit A.

Data is Not Seperately Priced (NSP).

SECTION B FA9201-09-R-0141

NOTICE: The following contract clauses pertinent to this section are hereby incorporated in full text:

OTHER CONTRACT CLAUSES IN FULL TEXT

B028 CONTRACT TYPE: FIRM FIXED PRICE (FEB 1997)

Total Price ____

Applicable to following Line Items: ALL

SECTION C - DESCRIPTION/SPECS./WORK STATEMENT

SECTION C FA9201-09-R-0141

NOTICE: The following contract clauses pertinent to this section are hereby incorporated in full text:

OTHER CONTRACT CLAUSES IN FULL TEXT

C001 WORK DESCRIPTION/SPECIFICATION (MAY 1997) (TAILORED)

Work called for by the contract line items specified in SECTION B shall be performed in accordance with the following:

CONTRACT LINE ITEM NUMBERS (CLINs) DESCRIPTION/SPECIFICATIONS ALL Advanced Command Destruct System (ACDS)

Technical Requirements Document (TRD), dated 1 April 2009, Section J, Attach 1, and ACDS System Safety Plan (SSP), dated March 2009, Section J, Attach 2

0004 Data delivery IAW Section J, Exhibit A, Contract Data Requirements List, dated 24 April 2009

SECTION D - PACKAGING AND MARKING

SECTION D FA9201-09-R-0141

NOTICE: The following contract clauses pertinent to this section are hereby incorporated by reference:

AIR FORCE MATERIEL COMMAND FEDERAL ACQUISITION REGULATION SUPPLEMENT

CONTRACT CLAUSES

5352.247-9008 CONTRACTOR COMMERCIAL PACKAGING (AFMC) (SEP 1998)

SECTION E - INSPECTION AND ACCEPTANCE

SECTION E FA9201-09-R-0141

I. NOTICE: The following contract clauses pertinent to this section are hereby incorporated by reference:

A. FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES

52.246-01 CONTRACTOR INSPECTION REQUIREMENTS (APR 1984)

52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996)

52.246-04 INSPECTION OF SERVICES -- FIXED-PRICE (AUG 1996)

B. DEFENSE FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT CLAUSES

252.246-7000 MATERIAL INSPECTION AND RECEIVING REPORT (MAR 2008)

II. NOTICE: The following contract clauses pertinent to this section are hereby incorporated in full text:

OTHER CONTRACT CLAUSES IN FULL TEXT

E005 INSPECTION AND ACCEPTANCE (MAR 1998) (TAILORED)

a. Line Items 0001 - 0003 shall be delivered F.O.B. Destination on a DD Form 250, Material Inspection and Receiving Report. Inspection and acceptance shall be performed at the destination.

b. Line Item 0004 - The data shall be delivered F.O.B. Destination to the office(s) specified in Block 14 of Exhibit A, DD Form 1423, and inspected and accepted at the destination.

E007 INSPECTION AND ACCEPTANCE AUTHORITY (APR 1998) (TAILORED)

Inspection and acceptance for all Contract and Exhibit Lines or Subline Items shall be accomplished by the Program Manager, 46 TW/TSTDL (MHU), 500 N. Florida Ave, Eglin AFB, 32542-5450, telephone:

(850)882-1962.

SECTION F - DELIVERIES OR PERFORMANCE

SECTION F FA9201-09-R-0141

SHIP MARK TRANS

ITEM SUPPLIES SCHEDULE DATA QTY TO FOR PRI DATE

0001AA 1 U 8 MARO

Noun: DEVELOP, BUILD, INTEGRATE & TEST TSA-3

TRANSMITTER SYSTEM 1

Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0001AB 1 U 10 MARO

Noun: MAINTENANCE & OPERATIONAL TRAINING TSA-3

TRANSMITTER SYSTEM 1

Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0002AA 1 U 14 MARO

Noun: TSA-3 TRANSMITTER SYSTEM 2 Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0002AB 1 U 16 MARO

Noun: TSD-3 TRANSMITTER SYSTEMS 1 & 2 Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0002AC 1 U 18 MARO

Noun: CENTRAL CONTROL FACILITY (CCF) BOXES AND

CONTROL BOX INTERFACE

Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0002AD 1 U 20 MARO

Noun: TSA-3, TSD-3, MOBILE TRANSMITTER SYSTEM

(MTS) MONITOR SYSTEMS

Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

SECTION F FA9201-09-R-0141

SHIP MARK TRANS

ITEM SUPPLIES SCHEDULE DATA QTY TO FOR PRI DATE

0002AE 1 U 23 MARO

Noun: TSA-6 & TSD-3 FREQUENCY CONTROL & ANALYSIS

(FCA) MONITOR SYSTEMS

Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0003AA 1 U 26 MARO

Noun: TSA-3,TSD-3 & MTS ANTENNAS Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0003AB 1 U 28 MARO

Noun: FCA ANTENNAS TSA-6, TSD-3 AND MOBILE FCA Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0003AC 1 U 35 MARO

Noun: MOBILE TRANSMITTER SYSTEM (MTS) Descriptive Data:

SEE F007 SHIPMENT ADDRESS AT SECTION F.

0004 1 U ASREQ

Noun: DATA Descriptive Data:

The contractor shall deliver data in accordance with DDForm 1423-1, Exhibit A.

I. NOTICE: The following contract clauses pertinent to this section are hereby incorporated by reference:

FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES

52.242-15 STOP-WORK ORDER (AUG 1989)

52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

52.247-34 F.O.B. DESTINATION (NOV 1991)

II. NOTICE: The following contract clauses pertinent to this section are hereby incorporated in full text:

SECTION F FA9201-09-R-0141

OTHER CONTRACT CLAUSES IN FULL TEXT

F002 PERIOD OF PERFORMANCE (FEB 1997)

Period of performance under this contract shall be 36 months.

F003 CONTRACT DELIVERIES (FEB 1997)

The following terms, if used within this contract in conjunction with contract delivery requirements (including data deliveries), are hereby defined as follows:

(a) "MAC" and "MARO" mean "months after the effective date for award of the contractual action (as shown in block 3, Section A, SF 26)".

(b) "WARO" means "weeks after the effective date for award of the contractual action".

(c) "DARO" means "days after the effective date for award of the contractual action".

(d) "ASREQ" means "as required". Detailed delivery requirements are then specified elsewhere in Section F.

F004 PROGRAM MILESTONES (DEC 2005) (TAILORED)

So that the Government can determine whether or not the Contractor is achieving satisfactory technical progress, certain milestones events during the performance of this contract (including Configuration Reviews and Audits) are established. These events are referred to as Program Milestones and are set forth below:

MILESTONE LOCATION COMPLETION DATE DURATION

(ACA-After Contract Award) (travel time not included)

Monthly Eglin/Contractor monthly- starting first month 2 hrs Telconference Facility ACA; No telecon QPR mos

Preliminary Systems Design Review (PSDR) Eglin AFB NLT 4 weeks ACA 2 days

Final Systems Design Review (FSDR) Vendor Facility NLT 10 weeks ACA 2 days

Quarterly Program Reviews (QPRs) Eglin AFB Every 3 months- first 1 day occurrence 3 months ACA

F007 SHIPMENT ADDRESS (SEP 1997) (TAILORED)

All deliverables under this contractor shall be shipped to the following address:

Deptartment of the Air Force

46TW/TSTDL (MHU)

500 N. Florida Ave.

Eglin AFB, 32542-5450

Mark For: Pat Scharmen (850)882-1962

SECTION G - CONTRACT ADMINISTRATION DATA

SECTION G FA9201-09-R-0141

NOTICE: The following contract clauses pertinent to this section are hereby incorporated in full text:

OTHER CONTRACT CLAUSES IN FULL TEXT

G014 IMPLEMENTATION OF PATENT RIGHTS CLAUSE (DEC 2007)

All documents and information required by the patent rights and/or patent reporting clauses set forth in Section I of this contract shall be submitted to the Administrative Contracting Officer and to AAC/JAQ, 501 West Van Matre Avenue, Suite 1, Eglin AFB FL 32542

The AAC/JAQ patent administrator can be reached at 850-882-5335 x 133.

This notice also constitutes a request (see FAR 52.227-11 or DFARS 252.227-7039(c), as applicable) for submission of a copy of the patent application, when filed, along with the patent application serial number, filing date, subsequent U.S. patent number and issue date, as received.

SECTION H - SPECIAL CONTRACT REQUIREMENTS

SECTION H FA9201-09-R-0141

NOTICE: The following contract clauses pertinent to this section are hereby incorporated in full text:

OTHER CONTRACT CLAUSES IN FULL TEXT

H025 INCORPORATION OF SECTION K (OCT 1998)

Section K of the solicitation is hereby incorporated by reference.

H029 IMPLEMENTATION OF DISCLOSURE OF INFORMATION (OCT 1997) (TAILORED)

In order to comply with DFARS 252.204-7000, Disclosure of Information, the following copies of the information to be released are required at least 45 days prior to the scheduled release date:

(a) One copy to: Office of Public Affairs, AAC/PA, 101 West D Avenue, Suite 110, Eglin AFB FL 32542-5498

(b) One copy to: Contracting Officer, AAC/PKET, 205 West D Ave, Suite 427, Eglin AFB FL 32542-6864

(c) One copy to: Program Manager, Pat Scharmen, 46 RANSS/TSRI c/o 46TW/TSRST; 308 West D. Avenue, Suite 203 Building 260, Eglin AFB FL 32542-5499

H063 CONTRACTOR IDENTIFICATION (FEB 2003)

(a) Contractor personnel and their subcontractors must identify themselves as Contractors or subcontractors during meetings, telephone conversations, in electronic messages, or correspondence related to this contract.

(b) Contractor-occupied facilities (on AFMC or other Government installations) such as offices, separate rooms, or cubicles must be clearly identified with Contractor supplied signs, name plates or other identification, showing that these are work areas for Contractor or subcontractor personnel.

PART II - CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

SECTION I FA9201-09-R-0141

Contract Clauses in this section are from the FAR, Defense FAR Sup, Air Force FAR Sup, and the Air Force Materiel Command FAR Sup, and are current through the following updates:

Database_Version: 6.10.8.2000; Issued: 4/22/2009; FAR: FAC 2005-32; DFAR: DCN20090115; DL.: DL 98- 021; Class Deviations: CD 2009-O0001; AFFAR: 2002 Edition; AFMCFAR: AFMCAC 07-03;

AFAC: AFAC 2009-0318; IPN: 98-009

I. NOTICE: The following contract clauses pertinent to this section are hereby incorporated by reference:

A. FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES

52.202-01 DEFINITIONS (JUL 2004)

52.203-03 GRATUITIES (APR 1984)

52.203-05 COVENANT AGAINST CONTINGENT FEES (APR 1984)

52.203-06 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (SEP 2006)

52.203-07 ANTI-KICKBACK PROCEDURES (JUL 1995)

52.203-08 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (JAN 1997)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS

(SEP 2007)

52.204-02 SECURITY REQUIREMENTS (AUG 1996)

52.204-04 PRINTED OR COPIED DOUBLE-SIDED ON RECYCLED PAPER (AUG 2000)

52.204-07 CENTRAL CONTRACTOR REGISTRATION (APR 2008)

52.204-09 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (SEP 2007)

52.211-05 MATERIAL REQUIREMENTS (AUG 2000)

52.215-02 AUDIT AND RECORDS -- NEGOTIATION (MAR 2009)

52.215-08 ORDER OF PRECEDENCE--UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-10 PRICE REDUCTION FOR DEFECTIVE COST OR PRICING DATA (OCT 1997)

52.215-12 SUBCONTRACTOR COST OR PRICING DATA (OCT 1997)

52.215-14 INTEGRITY OF UNIT PRICES (OCT 1997)

52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2004)

52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS

(PRB) OTHER THAN PENSIONS (JUL 2005)

52.215-21 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN

COST OR PRICING DATA--MODIFICATIONS (OCT 1997)

52.219-04 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS

CONCERNS (JUL 2005)

52.219-06 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (JUN 2003)

52.219-08 UTILIZATION OF SMALL BUSINESS CONCERNS (MAY 2004)

52.219-14 LIMITATIONS ON SUBCONTRACTING (DEC 1996)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2009)

52.222-01 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997)

52.222-20 WALSH-HEALEY PUBLIC CONTRACTS ACT (DEC 1996)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (FEB 1999)

52.222-26 EQUAL OPPORTUNITY (MAR 2007)

52.222-35 EQUAL OPPORTUNITY FOR SPECIAL DISABLED VETERANS, VETERANS OF THE

VIETNAM ERA, AND OTHER ELIGIBLE VETERANS (SEP 2006)

52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (JUN 1998)

52.222-37 EMPLOYMENT REPORTS ON SPECIAL DISABLED VETERANS, VETERANS OF THE

VIETNAM ERA, AND OTHER ELIGIBLE VETERANS (SEP 2006)

52.222-39 NOTIFICATION OF EMPLOYEE RIGHTS CONCERNING PAYMENT OF UNION DUES

OR FEES (DEC 2004)

SECTION I FA9201-09-R-0141

52.222-50 COMBATING TRAFFICKING IN PERSONS (FEB 2009)

52.223-05 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (AUG 2003)

52.223-06 DRUG-FREE WORKPLACE (MAY 2001)

52.223-14 TOXIC CHEMICAL RELEASE REPORTING (AUG 2003)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

52.227-01 AUTHORIZATION AND CONSENT (DEC 2007)

52.227-02 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT

INFRINGEMENT (DEC 2007)

52.227-11 PATENT RIGHTS -- OWNERSHIP BY THE CONTRACTOR (DEC 2007)

Para (j), Communications: 'See G014'

52.229-03 FEDERAL, STATE, AND LOCAL TAXES (APR 2003)

52.232-01 PAYMENTS (APR 1984)

52.232-08 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)

52.232-11 EXTRAS (APR 1984)

52.232-16 PROGRESS PAYMENTS (APR 2003)

52.232-23 ASSIGNMENT OF CLAIMS (JAN 1986)

52.232-25 PROMPT PAYMENT (OCT 2008)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER--CENTRAL CONTRACTOR

REGISTRATION (OCT 2003)

52.233-01 DISPUTES (JUL 2002)

52.233-03 PROTEST AFTER AWARD (AUG 1996)

52.233-04 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.237-11 ACCEPTING AND DISPENSING OF $1 COIN (SEP 2008)

52.242-03 PENALTIES FOR UNALLOWABLE COSTS (MAY 2001)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-01 CHANGES -- FIXED-PRICE (AUG 1987)

52.243-01 CHANGES -- FIXED-PRICE (AUG 1987) - ALTERNATE II (APR 1984)

52.243-07 NOTIFICATION OF CHANGES (APR 1984)

Para (b), Number of calendar days is (insert 30 for RDSS/C) '30 days' Para (d), Number of calendar days is (insert 30 for RDSS/C) '30 days'

52.244-06 SUBCONTRACTS FOR COMMERCIAL ITEMS (MAR 2009)

52.245-01 GOVERNMENT PROPERTY (JUN 2007)

52.245-09 USE AND CHARGES (JUN 2007)

52.246-24 LIMITATION OF LIABILITY -- HIGH-VALUE ITEMS (FEB 1997)

52.246-25 LIMITATION OF LIABILITY -- SERVICES (FEB 1997)

52.249-02 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (MAY

2004)

52.249-08 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (APR 1984)

52.253-01 COMPUTER GENERATED FORMS (JAN 1991)

B. DEFENSE FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT CLAUSES

252.203-7000 REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD OFFICIALS

(JAN 2009)

252.203-7001 PROHIBITION ON PERSONS CONVICTED OF FRAUD OR OTHER DEFENSE-

CONTRACT-RELATED FELONIES (DEC 2008)

252.203-7002 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (JAN

2009)

252.204-7000 DISCLOSURE OF INFORMATION (DEC 1991)

252.204-7003 CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR 1992)

252.204-7004 ALTERNATE A, CENTRAL CONTRACTOR REGISTRATION (SEP 2007)

252.205-7000 PROVISION OF INFORMATION TO COOPERATIVE AGREEMENT HOLDERS (DEC

1991)

252.209-7004 SUBCONTRACTING WITH FIRMS THAT ARE OWNED OR CONTROLLED BY THE

GOVERNMENT OF A TERRORIST COUNTRY (DEC 2006)

252.211-7003 ITEM IDENTIFICATION AND VALUATION (AUG 2008)

SECTION I FA9201-09-R-0141

Para (c)(1)(ii). Items with acquisition cost less than $5,000. 'n/a' Para (c)(1)(iii). Attachment Nr. 'n/a'

252.215-7000 PRICING ADJUSTMENTS (DEC 1991)

252.225-7002 QUALIFYING COUNTRY SOURCES AS SUBCONTRACTORS (APR 2003)

252.225-7012 PREFERENCE FOR CERTAIN DOMESTIC COMMODITIES (DEC 2008)

252.225-7016 RESTRICTION ON ACQUISITION OF BALL AND ROLLER BEARINGS (MAR 2006)

252.226-7001 UTILIZATION OF INDIAN ORGANIZATIONS, INDIAN-OWNED ECONOMIC

ENTERPRISES, AND NATIVE HAWAIIAN SMALL BUSINESS CONCERNS (SEP 2004)

252.227-7039 PATENTS--REPORTING OF SUBJECT INVENTIONS (APR 1990)

252.231-7000 SUPPLEMENTAL COST PRINCIPLES (DEC 1991)

252.232-7004 DOD PROGRESS PAYMENT RATES (OCT 2001)

252.232-7010 LEVIES ON CONTRACT PAYMENTS (DEC 2006)

252.235-7003 FREQUENCY AUTHORIZATION (DEC 1991)

252.235-7003 FREQUENCY AUTHORIZATION (DEC 1991) - ALTERNATE I (AUG 2008)

252.243-7001 PRICING OF CONTRACT MODIFICATIONS (DEC 1991)

252.243-7002 REQUESTS FOR EQUITABLE ADJUSTMENT (MAR 1998)

252.244-7000 SUBCONTRACTS FOR COMMERCIAL ITEMS AND COMMERCIAL COMPONENTS

(DOD CONTRACTS) (JAN 2009)

252.247-7023 TRANSPORTATION OF SUPPLIES BY SEA (MAY 2002)

C. AIR FORCE FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT CLAUSES

5352.223-9000 ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODS) (APR 2003) Para (c), List of Class I ODSs. 'None'

D. AIR FORCE MATERIEL COMMAND FEDERAL ACQUISITION REGULATION SUPPLEMENT

CONTRACT CLAUSES

5352.215-9008 ENABLING CLAUSE BETWEEN PRIME CONTRACTORS AND SERVICE

CONTRACTORS (AFMC) (JUL 1997)

Para (a), Manpower Support Services Contractor's Name 'Jacobs Technology Inc., BTAS Inc., Colsa Corporation & InDyne Inc.' Para (a), Major Support Areas (Such as Technical Evaluation and Acquisition Management Support) 'Technical and Engineering Acquisition Support (TEAS, Jacobs Technology Inc.) and Technical and Acquisition Management Support (TAMS, BTAS Inc, and Colsa Corporation) and the Eglin Test and Training Complex Range Operations and Maintenance (ETTC Range O&M, InDyne, Inc.)' Para (b), Applicable Task Detail ':TEAS & TAMS tasks include assistance in preparing technical orders, manuals, statement of work, system specifications, contract data requirements lists, system engineering management plans, test and evaluation master plans, integrated logistic support plans, etc; review of development/product specifications, engineering drawings, technical reports, configuration audits; review of engineering drawings; and advisory participation in program management, technical interchange and group meetings. Tasks may entail appraising the technical performance of the contractor through meetings, exchanging data, presentation, reviewing hardware and software, witnessing and evaluating tests, analyzing plans for future work, evaluating efforts relative to contract technical objectives and providing an independent technical assessment for consideration of the Air Force Program Manager.

ETTC Range O&M Tasks involve support of improvement and modernization (I&M) efforts, including development of systems specifications, development of support requirements, system design, system fabrication, development of acceptance test requirements, and participation in acceptance tests. Tasks also involve providing recommendations on emerging technology and potential application to the Eglin Test and Training Complex and interface with other contractors by attending program reviews and

SECTION I FA9201-09-R-0141

technical interface meetings scheduled by the Government in support of I&M efforts.

Outsourced developmental items may become part of the GFP upon delivery. Tasks may also include support development of new systems as tasked by the Government' Para (c), Manpower Support Services Contractor's Name 'TEAS, TAMS & ETTC Range O&M' Para (c), Areas for Cooperation: 'responding to invitations from authorized personnel to attend meetings; providing access to technical information and research, development and planning data, test data and results, schedule and milestone data, financial data;

discussing technical matters related to the program; providing access to Contractor facilities utilized in the performance of the contract; participation in program reviews and acceptance tests; and allowing observation of technical activities by appropriate support personnel (TEAS,TAMS & ETTC Range O&M).'

5352.235-9003 APPLICATION FOR EQUIPMENT FREQUENCY AUTHORIZATION (AFMC) (OCT

2008)

5352.245-9004 BASE SUPPORT (AFMC) (JUL 1997)

Para (e), List Installations 'Eglin AFB. Access to locations/facilities, at a minimum, to include the Central Control Facility (CCF), Test Site A-3, Test Site A-6, and Test Site D-3 (main building and FCA building).' Para (f), List Support Items 'access to all required installation locations/facilities during normal business hours. At times however, access may be restricted due to mission operations. In the event that mission operations cause installation and test delays, afterhours access can and will be arranged. Contractor will be responsible for all material or equipment needed for performance of the contract.'

II. NOTICE: The following contract clauses pertinent to this section are hereby incorporated in full text:

A. FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES IN FULL TEXT

52.252-02 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://farsite.hill.af.mil/

52.252-06 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter

1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation Supplement (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

B. DEFENSE FAR SUPP CONTRACT CLAUSES IN FULL TEXT

252.225-7014 PREFERENCE FOR DOMESTIC SPECIALTY METALS (DEVIATION) (JUN 2005)

(a) Definitions. As used in this clause-

(1) "Produce" means the application of forces or processes to a specialty metal to create desired physical properties through quenching or tempering of steel plate, or gas atomization or sputtering of titanium.

SECTION I FA9201-09-R-0141

(2) "Specialty metals" means any of the following:

(i) Steel--

(A) With a maximum alloy content exceeding one or more of the following limits: manganese, 1.65 percent; silicon, 0.60 percent; or copper, 0.60 percent; or

(B) Containing more than 0.25 percent of any of the following elements:

aluminum, chromium, cobalt, molybdenum, nickel, niobium (columbium), titanium, tungsten, or vanadium;

(ii) Metal alloys consisting of

(A) Nickel or iron-nickel alloys that contain a total of alloying metals or other than nickel and iron in excess of 10 percent; or

(B) Cobalt alloys that contain a total of alloying metals other than cobalt and iron in excess of 10 percent;

(iii) Titanium and titanium alloys; or

(iv) Zirconium and zirconium alloys.

(b) Any specialty metal delivered under this contract shall be melted or produced in the United States or its outlying areas.

252.232-7007 LIMITATION OF GOVERNMENT'S OBLIGATION (MAY 2006) (TAILORED)

(a) Contract line items "ALL" are incrementally funded. For these items, the sum of (TBD at Contract Award) of the total price is presently available for payment and allotted to this contract. An allotment schedule is set forth in paragraph (j) of this clause.

(b) For item(s) identified in paragraph (a) of this clause, the Contractor agrees to perform up to the point at which the total amount payable by the Government, including reimbursement in the event of termination of those item(s) for the Government's convenience, approximates the total amount currently allotted to the contract. The Contractor is not authorized to continue work on those item(s) beyond that point. The Government will not be obligated in any event to reimburse the Contractor in excess of the amount allotted to the contract for those item(s) regardless of anything to the contrary in the clause entitled "Termination for Convenience of the Government." As used in this clause, the total amount payable by the Government in the event of termination of applicable contract line item(s) for convenience includes costs, profit, and estimated termination settlement costs for those item(s).

(c) Notwithstanding the dates specified in the allotment schedule in paragraph (j) of this clause, the Contractor will notify the Contracting Officer in writing at least ninety days prior to the date when, in the Contractor's best judgment, the work will reach the point at which the total amount payable by the Government, including any cost for termination for convenience, will approximate 85 percent of the total amount then allotted to the contract for performance of the applicable item(s). The notification will state

(1) the estimated date when that point will be reached and (2) an estimate of additional funding, if any, needed to continue performance of applicable line items up to the next scheduled date for allotment of funds identified in paragraph (j) of this clause, or to a mutually agreed upon substitute date. The notification will also advise the Contracting Officer of the estimated amount of additional funds that will be required for the timely performance of the item(s) funded pursuant to this clause, for a subsequent period as may be specified in the allotment schedule in paragraph (j) of this clause or otherwise agreed to by the parties. If after such notification additional funds are not allotted by the date identified in the Contractor's notification, or by an agreed substitute date, the Contracting Officer will terminate any item(s) for which additional funds have not been allotted, pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

SECTION I FA9201-09-R-0141

(d) When additional funds are allotted for continued performance of the contract line item(s) identified in paragraph (a) of this clause, the parties will agree as to the period of contract performance which will be covered by the funds. The provisions of paragraphs (b) through (d) of this clause will apply in like manner to the additional allotted funds and agreed substitute date, and the contract will be modified accordingly.

(e) If, solely by reason of failure of the Government to allot additional funds, by the dates indicated below, in amounts sufficient for timely performance of the contract line item(s) identified in paragraph (a) of this clause, the Contractor incurs additional costs or is delayed in the performance of the work under this contract and if additional funds are allotted, an equitable adjustment will be made in the price or prices (including appropriate target, billing, and ceiling prices where applicable) of the item(s), or in the time of delivery, or both. Failure to agree to any such equitable adjustment hereunder will be a dispute concerning a question of fact within the meaning of the clause entitled "Disputes."

(f) The Government may at any time prior to termination allot additional funds for the performance of the contract line item(s) identified in paragraph (a) of this clause.

(g) The termination provisions of this clause do not limit the rights of the Government under the clause entitled "Default." The provisions of this clause are limited to the work and allotment of funds for the contract line item(s) set forth in paragraph (a) of this clause. This clause no longer applies once the contract is fully funded except with regard to the rights or obligations of the parties concerning equitable adjustments negotiated under paragraphs (d) or (e) of this clause.

(h) Nothing in this clause affects the rights of the Government to terminate this contract pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

(i) Nothing in this clause shall be construed as authorization of voluntary services whose acceptance is otherwise prohibited under 31 U.S.C. 1342.

(j) The parties contemplate that the Government will allot funds to this contract in accordance with the following schedule:

On execution of contract: Schedule TBD at Contract Award

C. AIR FORCE FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT CLAUSES IN FULL TEXT

5352.201-9101 OMBUDSMAN (AUG 2005) (TAILORED)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, concerned parties may contact the Center/MAJCOM ombudsmen, Col Arnold W. Bunch, AAC/CV at 101 West D Ave, Suite 116, Eglin AFB FL 32542-5495, telephone: (850)882-5422. Concerns, issues, disagreements, and recommendations

SECTION I FA9201-09-R-0141

that cannot be resolved at the MAJCOM/DRU level, may be brought by the concerned party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (703) 588-7004, facsimile number (703) 588-1067.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (AUG 2007)

(TAILORED)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver's license.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with applicable facility access procedures.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Failure to comply with these requirements may result in withholding of final payment.

D. AIR FORCE MATERIEL COMMAND FEDERAL ACQUISITION REGULATION SUPPLEMENT CONTRACT

CLAUSES IN FULL TEXT

5352.245-9000 GOVERNMENT- FURNISHED PROPERTY (GFP) (AFMC) (OCT 2008) (TAILORED)

Pursuant to the Government Property clause herein, the Government shall furnish the item(s) of property listed below as Government-Furnished Property (GFP) to the Contractor, f.o.b. DESTINATION (insert origin or destination as appropriate), for use in performance of this contract. Upon completion of the contract, the Contractor shall obtain disposition instructions from the Government Property Administrator of the activity having responsibility for administration of the contract.

Item # Noun and part # Quantity Delivery Date

1 Redundant CCF infrastructure items 1 N/A

(fiber and media converters)

SECTION I FA9201-09-R-0141

2 L-3 EFTS-602 TDU encryption devices 26 Upon Request

3 Redundant Ethernet network to connect 1 N/A ACDS Sites (com infrastructure)

4 PA1000 High Powered Amplifiers (HPAs) 10 Upon Request (Manufactured by WV Communications)

5 Communications antennas for Mobile

a. Motorola G425 1 Upon Request

b. MaxRad MWV1365S 1

c. Shakespeare Galaxy 5225-XP 1

PART III - LIST OF DOCUMENTS, EXHIBITS & ATTACHMENTS

SECTION J - LIST OF ATTACHMENTS

SECTION J FA9201-09-R-0141

DOCUMENT PGS DATE TITLE

EXHIBIT A 16 24 APR 2009 CONTRACT REQUIREMENTS DATA LIST, DD

1423-1

ATTACHMENT 1 37 30 APR 2009 ACDS TECHNICAL REQUIREMENTS DOCUMENT

ATTACHMENT 2 16 01 MAR 2009 ACDS SYSTEM SAFETY PLAN (SSP)

ATTACHMENT 3 4 DRAFT DD254 CONTRACT SECURITY

SPECIFICATION CLASSIFICATION

FA9201-09-R-0141, Attach 1

Advanced Command Destruct System (ACDS)

Technical Requirements Document (TRD)

Rev 0.0

46th RANGE GROUP

April 30, 2009

Table of Contents

1. Introduction

1.1. Purpose of TRD

1.2. Scope of TRD

1.3. References

2. Descriptions

2.1. System

2.2. Order of procurement

2.3. Installation

2.4. Training

3. System Level Requirements

3.1. Flight Termination System (FTS) Formats

3.2. Component Redundancy

3.3. System Timing

3.4. System Safety Plan (SSP)

3.4.1. Personnel Safety

3.4.2. Range Safety

3.4.3. Software

3.5. Multiple Mission Support

3.6. Fail Over

3.7. Frequency

3.8. RF Authorization

3.9. Indicators

3.10. Computer hard drives

3.11. ACDS command and destruct control locations

3.11.1. Single mission operation

3.11.2. Dual mission operation

3.12. Equipment Racks

3.13. Equipment Slides

3.14. Acceptance Tests

4. Subsystem Level/Functional Requirements

4.1. RDO Control Boxes

4.1.1. Quantity

4.1.2. Ease of Operation

4.1.3. Switches

4.1.4. Common Switch Command Assignments

4.1.5. Types of RDO Control Boxes

4.1.5.1. Main RDO Control Box

4.1.5.1.1. System Fault Indicator

4.1.5.1.2. Discrete Tone Indicators

4.1.5.1.3. On/Off Switch

4.1.5.1.4. Project Enable Switch

4.1.5.1.5. Transmitter Controls

4.1.5.1.6. Test Vehicle Controls

4.1.5.1.6.1. IRIG Standard Tone Mode

4.1.5.1.6.2. EFTS Mode

4.1.5.2. Auxiliary RDO Control Box

4.1.5.2.1. Carrier On Indicator

4.1.5.2.2. Discrete Tone Indicators

4.1.5.2.3. On/Off Switch

4.1.5.2.4. Project Enable Switch

4.1.5.2.5. Test Vehicle Controls

4.1.6. RDO Control Box Labels

4.2. Project Officer Control Box

4.2.1. Quantity

4.2.2. Ease of Operation

4.2.3. Features

4.2.4. Indicators

4.2.4.1. RDO Disabled

4.2.4.2. Max Tones

4.2.5. IRIG Standard Tone Mode

4.2.6. EFTS Mode

4.3. Remote Maintenance

4.4. Command/Message Configuration

4.4.1. Mission Parameters and Settings

4.4.2. IRIG Standard Tone Operation

4.4.3. EFTS Operation

4.4.4. Command Prioritization

4.4.5. Push Configuration to remote Equipment

4.5. Encryption

4.5.1. IRIG Encryption

4.5.2. EFTS Encryption

4.6. ACDS Communications Network

4.7. UHF Transmitters

4.7.1. Transmitter System

4.7.2. Transmitter System Selection

4.7.4. Output Power

4.7.5. EFTS Message Verification

4.7.6. Maintenance after Fail Over

4.7.7. Locations

4.7.8. Antenna Selection

4.8. Antennas

4.8.1. Polarization

4.8.2. Types

4.8.3. Quantities

4.8.4. Omni Antenna

4.8.5. Directional Antenna

4.8.6. Pedestal

4.8.6.1. Corrosion Mitigation

4.8.6.2. Rotation Notification

4.8.6.3. Slew Rates

4.8.6.4. Pointing Accuracy

4.8.6.5. Positioning Control

4.8.6.5.1. Manual Control

4.8.6.5.2. GUI Control

4.8.6.5.3. Range Slaving

4.8.7. High Power Transmission Lines

4.9. Monitoring Equipment

4.9.1. ACDS Operations Center in the CCF

4.9.2. Transmitter Sites

4.9.3. FCA Sites

4.10. Mobile Transmitter System (MTS)

4.10.1. Generator

4.10.2. Trailer

4.10.3. Shelter

4.10.3.1. Power

4.10.3.2. Interior

4.10.3.3. Exterior

4.10.3.4. ACDS Equipment

4.10.3.5. Eglin Equipment

5. Miscellaneous

5.1. Tools

5.2. Test Equipment

5.3. Documentation

5.3.1. Reports and Presentations

5.3.2. Manuals

5.3.3. Drawings and Schematics

5.3.4. PC Software

5.3.5 Spares List…………………………………………………………………………..26

APPENDIX A ACRONYMS………………………………………………………………. 28

APPENDIX B Notional Main RDO Control Box…………………………………………….31 APPENDIIX C Notional Auxiliary RDO Control Box APPENDIX D Notional Omni Antenna………………………………………………….33

APPENDIX E Notional MTS Trailer………………………………………………………34

1. Introduction

1.1. Purpose of TRD.

The purpose of this TRD is to define functionality and specification requirements for the purchase of the ACDS that will operate on the Eglin Test and Training Complex (ETTC). The ACDS will replace the existing Command Destruct System (CDS) and must provide the Eglin Range Safety Office with the capability to command and/or destruct test vehicles by broadcasting the required Radio Frequency (RF) signal from one of three transmitter locations.

1.2. Scope of TRD.

This TRD establishes technical requirements used for the evaluation of vendor’s proposals for implementing the ACDS at Eglin Test and Training Center. The ACDS, its subsystems and/or components, shall comply with the requirements of this TRD, including requirements covering equipment operation, non-operation and storage.

1.3. References.

The documents listed in this section, hereunder, form a part of this TRD to the extent invoked by specific reference in other paragraphs of this TRD. In the event of conflict between the documents referenced below and the contents of this TRD, the content of this TRD shall supersede.

Classification Standard Title Date/Rev Controlling Organization

Military IRIG 208-06 IRIG Standards for UHF Command Systems

2006 Range Commander’s Council Telecommunications and Timing Group POC: Pat Scharmen

(850) 882-1962

Military IRIG 200-04 IRIG Serial Time Code Formats

September

Range Commander’s Council Telecommunications and Timing Group

Military EFTS Command Link IRD

Enhanced Flight Termination System

(EFTS)

Command Link

Interface Requirements Document (IRD)

September

EFTS CTEIP Program Office POC: Pat Scharmen (850)-882-1962

Military ACDS SSP ACDS System Safety Plan

(SSP)

March 2009 Rev 1

Eglin AFB Range Safety Office POC: Ron Cofer

(850) 882-7347

Military DD Form

Application for Equipment Frequency Allocation

United States Military…