FA8213-24-R-3018.pdf

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 1447 (REV. 8/2016)

PREVIOUS EDITION NOT USABLE Prescribed by GSA - FAR (48 CFR) 53.214(d)

23. ACCOUNTING AND APPROPRIATION DATA

SEE SCHEDULE

24. TOTAL AWARD AMOUNT (For Government Use Only)

TELEPHONE NUMBER

UNIQUE ENTITY

IDENTIFIER

CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

NO COLLECT CALLS

4. SOLICITATION NUMBER

FA8213-24-R-3018

6.SOLICITATION ISSUE DATE

8. THIS ACQUISITION IS UNRESTRICTED OR SET ASIDE: % FOR

SMALL BUSINESS WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOSB PROGRAM

HUBZONE SMALL

BUSINESS EDWOSB

SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS NAICS: 325920

8(A) SIZE STANDARD: 750

DATE SIGNED

28. UNITED STATES OF AMERICA (Signature of Contracting Officer)

26. AWARD OF CONTRACT: YOUR OFFER ON SOLICITATION NUMBER

SHOWN IN BLOCK 4 INCLUDING ANY ADDITIONS OR CHANGES WHICH

ARE SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

ROUTINE.

Subject to the terms and conditions stated herein, the Contractor agrees to hold its offered prices firm for 120 days.

EXPEDITED DELIVERY AND PARTIAL DELIVERIES AT NO ADDITIONAL COST TO THE GOVERNMENT ARE AUTHORIZED.

Sole source to: Chemring Energetic Devices; Cage Code: 93455

Either a complete and adequate data package is not available to be provided as a part of this solicitation, or special materials, facilities, tooling, or test equipment which may be required for performance are not available from the government. Offers from firms not previously identified as sources for this requirement will only be considered when it can be determined prior to award that the item or services being offered will meet the government's requirements.

Clause 52.23218 “Subject to Availability of Funds” is applicable.

Restricted to qualified sources. In order to be considered for award, the contractor shall be an approved source by the time of award. A qualification package is required for new sources. See clause 52.2091 and the attached source qualification statement for qualification requirements. Prospective contractors may submit an offer on supplies bearing different part numbers from those cited in the solicitation. Proposals will not be considered if a qualification package is not submitted with the proposal.

SEE LINE ITEM SCHEDULE

22.

AMOUNT

16. AUTHORITY FOR USING OTHER THAN 10 USC 2304 41 USC 253

FULL AND OPEN COMPETITION (c) (1 ) (c) ( )

DATE SIGNED

27. SIGNATURE OF OFFEROR/CONTRACTOR

20.

UNIT

21.

UNIT PRICE

19.

QUANTITY

13. CONTRACTOR OFFEROR CODE FACILITY CODE

11. IF OFFER IS ACCEPTED BY THE GOVERNMENT WITHIN * ___ CALENDAR DAYS (60 CALENDAR DAYS UNLESS OFFEROR

INSERTS A DIFFERENT PERIOD) FROM THE DATE SET FORTH IN BLOCK 9 ABOVE, THE CONTRACTOR AGREES TO HOLD

ITS OFFERED PRICES FIRM FOR THE ITEMS SOLICITED HEREIN AND TO ACCEPT ANY RESULTING CONTRACT SUBJECT TO

THE TERMS AND CONDITIONS STATED HEREIN. *120

RATING

DO: A6

3. AWARD/EFFECTIVE DATE

FA8213

2. CONTRACT NUMBER

X

17.

ITEM NUMBER

12. ADMINISTERED BY CODE

Total

SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK: 14 EFT:T

SCD:B

NAME AND TITLE OF SIGNER (Type or Print) NAME OF CONTRACTING OFFICER

5. SOLICITATION TYPE

SEALED BIDS NEGOTIATED

(IFB) (RFP)

15. PROMPT PAYMENT DISCOUNT

25. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN 1

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS SETFORTH OR OTHERWISE

IDENTIFIED ABOVE AND ON ANY CONTINUATION SHEETS SUBJECT

THE TERMS AND CONDITIONS SPECIFIED HEREIN.

10. ITEMS TO BE PURCHASED (Brief Description)

SUPPLIES SERVICES Explosives Manufacturing

9. (Agency Use) Solicitation: Offers will be received at the Issuing office until * on * . Late offers are subject to late proposal provisions incorporated herein. All offers are subject to such provisions, representations certifications and specifications as are attached or incorporated by reference.*

16APR2024 5:00PM

X

18.

SCHEDULE OF SUPPLIES/SERVICES

14. PAYMENT WILL BE MADE BY CODE

(SEE ESP CLAUSE 252.2327003.)

X

7. ISSUED BY CODE

DEPARTMENT OF THE AIR FORCE, DIRECTORATE OF CONTRACTING

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE UT 840565820

BUYER: Elizabeth Dykes/EBHK elizabeth.dykes@us.af.mil

X

1. THIS CONTRACT IS A RATED ORDER UNDER DPAS

(15 CFR 700)SOLICITATION/CONTRACT

BIDDER/OFFEROR TO COMPLETE BLOCKS 11, 13, 15, 21, 22, & 27.

J

STANDARD FORM 1447 (REV. 8/2016) BACK

NO RESPONSE FOR REASONS CHECKED

TYPE OR PRINT NAME AND TITLE OF SIGNER

SIGNATURENAME AND ADDRESS OF FIRM (Include Zip Code)

WE DO NOT DESIRE TO BE RETAINED ON THE MAILING LIST FOR FUTURE PROCUREMENT OF THE TYPE OF

ITEMS INVOLVED

WE DO

OTHER (Specify)

UNABLE TO IDENTIFY THE ITEM(S)

CANNOT COMPLY WITH SPECIFICATIONS CANNOT MEET DELIVERY REQUIREMENT

DO NOT REGULARILY MANUFACTURE OR SELL THE TYPE OF ITEMS

INVOLVED

DATE AND LOCAL TIME 16 APR 2024 5:00 PM

SOLICITATION NUMBER FA821324R3018

FROM: AFFIX

STAMP

HERE

TO:

ATTN: Elizabeth Dykes/EBHK

DEPARTMENT OF THE AIR FORCE, DIRECTORATE OF CONTRACTING

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE UT 840565820

FA821324R3018

PART I THE SCHEDULE

SECTION B

SUPPLIES OR SERVICES AND PRICES/COSTS

DCMA and DFAS are required to withhold payment IAW DFAR 252.2277030 until CDRL A001, A005 & A006 have been delivered and/or approved by Hill AFB.

GAS/SMDC Initiator Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

72 EA

CLIN ACRN ACRN Total

0001 AA

NSN: 1377013758919 ES

GAS/SMDC INITIATOR

Propellant Actuated Initiator, Overall Length 3.242 inches min and 3.292 inches max, GasDetonation initiation method, used on egress sequencing system of B1 ACFT.

DODIC: MT60

Manufacturer Part Number 93455 6108100 Associated Document(s) Line Item(s)

FD20202450006 0002

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

GAS/SMDC Initiator

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 72 EA 31 MAR 2025

Proposed Delivery

B FV2037 72 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F010528207

TAC: FMZG

1.60 Sec Time Delay

Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

18 EA

CLIN ACRN ACRN Total

0002 AA

NSN: 1377013568732 ES

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection.

DODIC: MU17

Manufacturer Part Number 93455 6106600 Associated Document(s) Line Item(s)

FD20202450006 0003

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program

1.60 Sec Time Delay

IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 18 EA 31 MAR 2025

Proposed Delivery

B FV2037 18 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

3.20 Sec Time Delay

Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

18 EA

CLIN ACRN ACRN Total

0003 AA

NSN: 1377013568734 ES

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection.

DODIC: MU16

Manufacturer Part Number 93455 6106800 Associated Document(s) Line Item(s)

FD20202450006 0004

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

3.20 Sec Time Delay

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 18 EA 31 MAR 2025

Proposed Delivery

B FV2037 18 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

1.00 Sec Time Delay

Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

18 EA

CLIN ACRN ACRN Total

0004 AA

NSN: 1377013568731 ES

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection

DODIC: MU15

Manufacturer Part Number 93455 6106500 Associated Document(s) Line Item(s)

FD20202450006 0005

Priority: R ROUTINE.

1.00 Sec Time Delay

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 18 EA 31 MAR 2025

Proposed Delivery

B FV2037 18 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

0.70 Sec Time Delay

Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

9 EA

CLIN ACRN ACRN Total

0005 AA

NSN: 1377013568735 ES

0.70 Sec Time Delay

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection

DODIC: MU19

Manufacturer Part Number 93455 6106300 Associated Document(s) Line Item(s)

FD20202450006 0006

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 9 EA 31 MAR 2025

Proposed Delivery

B FV2037 9 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

0.50 Sec Time Delay

Item No.

0.50 Sec Time Delay

Firm Fixed Price Quantity U/I Unit Price Amount

36 EA

CLIN ACRN ACRN Total

0006 AA

NSN: 1377013565593 ES

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection

DODIC: MU80

Manufacturer Part Number 93455 6106200 Associated Document(s) Line Item(s)

FD20202450006 0007

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 36 EA 31 MAR 2025

Proposed Delivery

B FV2037 36 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

0.30 Sec Time Delay

Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

18 EA

CLIN ACRN ACRN Total

0007 AA

NSN: 1377013565592 ES

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection

DODIC: MU79

Manufacturer Part Number 93455 6106100 Associated Document(s) Line Item(s)

FD20202450006 0008

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 18 EA 31 MAR 2025

Proposed Delivery

B FV2037 18 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

2.40 Sec Time Delay

Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

18 EA

CLIN ACRN ACRN Total

0008 AA

NSN: 1377013568733 ES

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection

DODIC: MU18

Manufacturer Part Number 93455 6106700 Associated Document(s) Line Item(s)

FD20202450006 0009

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 18 EA 31 MAR 2025

Proposed Delivery

B FV2037 18 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

0.70 Sec Time Delay

Item No.

Firm Fixed Price Quantity U/I Unit Price Amount

27 EA

CLIN ACRN ACRN Total

0009 AA

NSN: 1377013568730 ES

A cylindrical device with mounting tabs and inlet and outlet ports for SMDC line connection

DODIC: MJ93

Manufacturer Part Number 93455 6106400 Associated Document(s) Line Item(s)

FD20202450006 0010

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Quality Assurance: Higher Level Contract Quality Requirements The Contractor shall comply with the standard(s) listed below. (if more than one, check the appropriate standard.)

Title Number Date Tailoring

ISO 9001:2015

Applicability: None ;

Buy American Act/Balance of Payments Program IUID Required: Yes Physical Item Markings:

Serial Number Required

Transportation From Continental United States CONUS (CONUS) Sources

TYPE / SHIP TO CODE F.O.B.

B FV2037 ORIGIN

Type / Ship To PACRN Mark For

B FV2037 B1 PDM

Type / Ship To Quantity (U/I) On or Before _ Req No / Pri

Required Delivery

B FV2037 27 EA 31 MAR 2025

0.70 Sec Time Delay

Proposed Delivery

B FV2037 27 EA

Physical Item Markings IAW CAD/PAD Item Marking Instructions version 1.6 dated 06 March 2023

SPI#: F011676621

TAC: FMZG

DATA

Item No.

Not Separately Priced Quantity U/I Unit Price

1 LO NSP

DATA

DATA IAW DD 14231 ATTACHED HERE TO EXHIBIT A

Priority: R ROUTINE.

Limitations of Liability: Other Than High Value Item

Inspection: Origin Acceptance: Origin Inspection/Acceptance Report: Receiving Report Required Exhibit: A Quality Assurance: Standard Inspection

CDRLs included in this CLIN include the following:

A001Ammunition Data Card (ADC)

A002Engineering Change Proposal (ECP)

A003Notice of Revision (NOR)

A004Request for Variance (RFV)

A005 Acceptance Test Plan

A006Test/Inspection Report

A007Failure Summary and Analysis Report

A008Obsolescence Alert Notice

A009Diminishing Manufacturing Sources and Material Shortages (DMSMS) Health Assessment Report

SHIP TO / PLACE OF PERFORMANCE

TYPE/CODE: B FV2037

72 ABW LGRSMK

7150 PATROL ROAD

TINKER AIR FORCE BASE OK 731455000

UNITED STATES

MARK FOR: (See Individual Line Item) REQUISITION NUMBER: (See Individual Line Item) REQUISITION PRIORITY: (See Individual Line Item)

AWARD NUMBER:

PART I THE SCHEDULE

SECTION C

DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

SPECIFICATIONS, STANDARDS AND DRAWINGS (MAY 1993)

(IAW FAR 11.201)

Specifications, standards or drawings (as applicable) are furnished/listed below or are listed in Section J herein. The contractor shall perform in accordance with those specifications and/or the attachments listed in Section J:

ITEM NR SPECIFICATIONS, STANDARDS AND/OR ATTACHMENTS

PART I THE SCHEDULE

SECTION E

INSPECTION AND ACCEPTANCE

52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)

(IAW FAR 46.302)

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

(IAW FAR 46.311, DFARS 246.202-4(1))

(a) The Contractor shall comply with the higherlevel quality standard(s) listed below. [If more than one standard is listed, the offeror shall indicate its selection by checking the appropriate block.]*

Title Number Date Tailoring *See Individual Line Item Schedule

52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)

(IAW FAR 46.316)

INSPECTION AND ACCEPTANCE (SEP 1999)

(IAW FAR 46.401(b), FAR 46.503)

Government Contract Quality Assurance Inspection and Acceptance will be at (Final):

[CONTRACTOR FILLIN]

Item No(s): See schedule for items with the following code(s) listed below :

Inspection Code and Address:

PART I THE SCHEDULE

SECTION F

DELIVERIES OR PERFORMANCE

52.211-8 TIME OF DELIVERY (JUN 1997)

(IAW FAR 11.404(a)(2))

DELIVERY FOR EACH ITEM IS ANNOTATED IN THE SCHEDULE (PART I SECTION B) UNDER EACH LINE ITEM.

52.211-8 TIME OF DELIVERY -- ALTERNATE I (APR 1984)

(IAW FAR 11.404(a)(2))

(b) the Government will make award by .

52.211-17 DELIVERY OF EXCESS QUANTITIES (SEP 1989)

(IAW FAR 11.703(b))

52.242-15 STOP-WORK ORDER (AUG 1989)

(IAW FAR 42.1305(b)(1))

52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

(IAW FAR 42.1305(c))

52.247-30 F.O.B. ORIGIN, CONTRACTOR'S FACILITY (FEB 2006)

(IAW FAR 47.303-2(c))

52.247-34 F.O.B. DESTINATION (NOV 1991)

(IAW FAR 47.303-6(c))

52.247-57 TRANSPORTATION TRANSIT PRIVILEGE CREDITS (APR 1984)

(IAW FAR 47.305-13(b)(4))

(d) The rate per CWT quoted will be used by the Government to evaluate the offered f.o.b. origin price unless a lower rate is applicable on the date of bid opening (or closing date specified for receipt of offers). To have the offer evaluated on this basis, the offeror must insert below the remaining transportation charges that the offeror agrees to pay, including any transit charges, subject to reimbursement by the Government, as explained in this clause, to destinations listed in the Schedule as follows:

RATE PER CWT IN CENTS ____________________

TO DESTINATION ____________________________

52.247-58 LOADING, BLOCKING, AND BRACING OF FREIGHT CAR SHIPMENTS (APR 1984)

(IAW FAR 47.305-15(a)(2))

52.247-59 F.O.B. ORIGIN-CARLOAD AND TRUCKLOAD SHIPMENTS (APR 1984)

(IAW FAR 47.305-16(a))

52.247-61 F.O.B. ORIGIN-MINIMUM SIZE OF SHIPMENTS (APR 1984)

(IAW FAR 47.305-16(c))

52.247-65 F.O.B. ORIGIN, PREPAID FREIGHT--SMALL PACKAGE SHIPMENTS (JAN 1991)

(IAW FAR 47.303-17(f))

F.O.B. ORIGIN (OCT 1993)

(IAW FAR 47.305(b))

Any supply item applicable to this document shall be delivered F.O.B. at:

F.O.B. Address

[CONTRACTOR FILLIN]

HAZARDOUS CLASSIFICATION (MAY 1998)

(IAW FAR 47.305-9(c))

For the purpose of identifying commodity description and freight classification of explosives and other dangerous supplies, the following applies.

Hazardous Classification Line Item 0001

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1988080416A DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0002

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050156 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0003

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050158 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0004

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050155 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0005

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050153 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0006

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050152 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0007

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050151 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0008

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050157 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification Line Item 0009

Hazardous Class Division 1.4 Storage Compatibility Group C

DOT Marking EX 1993050154 DOT Class 1.4 DOT Label Explosive 1.4

UN Serial No 0276 UN Proper Ship Name CARTRIDGES, POWER DEVICE

Freight Classification

PART I THE SCHEDULE

SECTION G

CONTRACT ADMINISTRATION DATA

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(IAW DFARS 232.7004(b), PGI 232.7004(b)(1), DFARS 212.301(f)(liii))

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

(Contracting Officer: Insert applicable document type(s).

Note: If a “Combo” document type is identified but not supportable by the Contractor’s business systems, an “Invoice” (standalone) and “Receiving Report” (standalone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable.”)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC Issue By DoDAAC Admin DoDAAC Inspect By DoDAAC Ship To Code Ship From Code Mark For Code Service Approver (DoDAAC) Service Acceptor (DoDAAC) Accept at Other DoDAAC LPO DoDAAC DCAA Auditor DoDAAC Other DoDAAC(s) (*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant backup documentation, as defined in DFARS Appendix F, (e.g.

timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

(Contracting Officer: Insert applicable email addresses or “Not applicable.”)

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) For technical WAWF help, contact the WAWF helpdesk at 8666185988.

ACCOUNTING AND APPROPRIATION DATA (AUG 1998)

Accounting and Appropriation Chargeable ACRN Funds Citation Amount Chargeable

Accounting and Appropriation Chargeable ACRN Funds Citation Amount Chargeable

AA 57 43011 . H8 4 LC HN 355102 4E27A1 63681 78070F 503000 F03000 $0.00

PSR: C60228 FSR: 078439

REFERENCE:

AA CIN: F2DCDE3317A1010000AA

PR: FD20202450006

ACRN TOTAL $ 0.00

PART II CONTRACT CLAUSES

SECTION I

CONTRACT CLAUSES

5352.201-9101 OMBUDSMAN (JUN 2023)

(IAW DAFFARS 5301.9103)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern.

The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employeeemployer actions, contests of OMB Circular A76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, Kayla V. Marshall at 801 777 6549 , FAX 000 000 0000 , email kayla.marshall@us.af.mil . Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/SMC ombudsman level, may be brought by the interested party for further consideration to the Department of the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 203301060, phone number (571) 2562395, facsimile number (571) 2562431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements.

Such inquiries shall be directed to the contracting officer.

52.202-1 DEFINITIONS (JUN 2020)

(IAW FAR 2.201)

52.203-3 GRATUITIES (APR 1984)

(IAW FAR 3.202)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

(IAW FAR 3.404)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

(IAW FAR 3.503-2)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

(IAW FAR 3.502-3)

52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR

IMPROPER ACTIVITY (MAY 2014)

(IAW FAR 3.104-9(a))

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

(IAW FAR 3.104-9(b))

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS

(JUN 2020)

(IAW FAR 3.808(b))

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY

AGREEMENTS OR STATEMENTS (JAN 2017)

(IAW FAR 3.909-3 (b))

252.203-7000 REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD OFFICIALS

(SEP 2011)

(IAW DFARS 203.171-4(a), DFARS 212.301(f)(ii))

252.203-7001 PROHIBITION ON PERSONS CONVICTED OF FRAUD OR OTHER

DEFENSE-CONTRACT-RELATED FELONIES (JAN 2023)

(IAW DFARS 203.570-3)

252.203-7002 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS

(DEC 2022)

(IAW DFARS 203.970)

52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON RECYCLED PAPER (MAY 2011)

(IAW FAR 4.303)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (JUN 2020)

(IAW FAR 4.1403(a))

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

(IAW FAR 4.1105(b))

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

(IAW FAR 4.1804(c), FAR 12.301(d))

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS

(DEC 2014)

(IAW FAR 4.1202(b))

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS

(NOV 2021)

(IAW FAR 4.1903)

52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED

ENTITIES (NOV 2021)

(IAW FAR 4.2004)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

(IAW 4.2105(b))

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

(IAW FAR 4.2203)

252.204-7002 PAYMENT FOR SUBLINE ITEMS NOT SEPARATELY PRICED (APR 2020)

(IAW DFARS 204.7109(a))

252.204-7003 CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR 1992)

(IAW DFARS 204.404-70(b))

252.204-7009 LIMITATIONS ON THE USE OR DISCLOSURE OF THIRD-PARTY CONTRACTOR

REPORTED CYBER INCIDENT INFORMATION (JAN 2023)

(IAW DFARS 204.7304(b))

252.204-7012 SAFEGUARDING COVERED DEFENSE INFORMATION AND CYBER INCIDENT

REPORTING (JAN 2023)

(IAW DFARS 204.7304(c))

252.204-7015 NOTICE OF AUTHORIZED DISCLOSURE OF INFORMATION FOR LITIGATION

SUPPORT (JAN 2023)

(IAW DFARS 204.7403(b), DFARS 212.301(f)(i)(F))

252.204-7018 PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE

TELECOMMUNICATIONS EQUIPMENT OR SERVICES (JAN 2023)

(IAW DFARS 204.2105(c))

252.204-7020 NIST SP 800-171 DOD ASSESSMENT REQUIREMENTS (JAN 2023)

(IAW DFARS 204.7304(e))

252.204-7022 EXPEDITING CONTRACT CLOSEOUT (MAY 2021)

(IAW DFARS 204.804-70)

52.209-1 QUALIFICATION REQUIREMENTS (FEB 1995)

(IAW FAR 9.206-2)

(b)

Item No Agency Name/Address

0001 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0002 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0003 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0004 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0005 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0006 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0007 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0008 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

0009 DEPARTMENT OF THE AIR FORCE

AFLCMC EBHK

6072 FIR AVENUE BLDG 1233

HILL AIR FORCE BASE, UT 840565820

(c) If an offeror, manufacturer, source, product or service covered by a qualification requirement has already met the standards specified, the relevant information noted below should be provided.

Offeror's Name _____________________________

Manufacturer's Name ________________________

Source's Name _____________________________

Item Name _________________________________

Service Identification _________________________

Test Number _______________________________ (to the extent known)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT

(NOV 2021)

(IAW FAR 9.409)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(NOV 2015)

(IAW FAR 9.108-5(b))

252.209-7004 SUBCONTRACTING WITH FIRMS THAT ARE OWNED OR CONTROLLED BY THE

GOVERNMENT OF A COUNTRY THAT IS A STATE SPONSOR OF TERRORISM

(MAY 2019)

(IAW DFARS 209.409)

252.209-7009 ORGANIZATIONAL CONFLICT OF INTEREST--MAJOR DEFENSE ACQUISITION

PROGRAM (MAY 2019)

(IAW DFARS 209.571-8(b))

252.209-7010 CRITICAL SAFETY ITEMS (AUG 2011)

(IAW DFARS 209.270-5)

(b) Identification of critical safety items. One or more of the items being procured under this contract is an aviation or ship critical safety item. The following items have been designated aviation critical safety items or ship critical safety items by the designated design control activity:

Line Item Description

0001 NSN: 1377013758919ES

0002 NSN: 1377013568732ES

0003 NSN: 1377013568734ES

0004 NSN: 1377013568731ES

0005 NSN: 1377013568735ES

0006 NSN: 1377013565593ES

0007 NSN: 1377013565592ES

0008 NSN: 1377013568733ES

0009 NSN: 1377013568730ES

52.211-5 MATERIAL REQUIREMENTS (AUG 2000)

(IAW FAR 11.304)

52.211-15 DEFENSE PRIORITY AND ALLOCATION REQUIREMENTS (APR 2008)

(IAW FAR 11.604(b))

This is a rated order certified for national defense, emergency preparedness, and energy program use, and the Contractor shall follow all the requirements of the Defense Priorities and Allocations System regulation (15 CFR 700).

252.211-7003 ITEM UNIQUE IDENTIFICATION AND VALUATION (JAN 2023)

(IAW DFARS 211.274-6(a)(1), DFARS 212.301(f)(xii))

(a) Definitions. As used in this clause—

“DoD recognized unique identification equivalent” means a unique identification method that is in commercial use and has been recognized by DoD. All DoD recognized unique identification equivalents are listed at https://www.acq.osd.mil/asda/dpc/ce/ds/uniqueid.html.

“Unique item identifier type” means a designator to indicate which method of uniquely identifying a part has been used. The current list of accepted unique item identifier types is maintained at https://www.acq.osd.mil/asda/dpc/ce/ds/uniqueid.html.

(c) Unique item identifier.

(1) The Contractor shall provide a unique item identifier for the following:

(i) Delivered items for which the Government’s unit acquisition cost is $5,000 or more, except for the following line items:

Contract Line, Subline, or Exhibit Line Item Number

Item Description

See Schedule as Applicable

(ii) Items for which the Government’s unit acquisition cost is less than $5,000 that are identified in the Schedule or the following table:

Contract Line, Subline, or Exhibit Line Item Number

Item Description

*Items less than $5000, which require UID, will be specifically identified in the schedule.

See Schedule as Applicable

(iii) Subassemblies, components, and parts embedded within delivered items, items with warranty requirements, DoD serially managed reparables and DoD serially managed nonreparables as specified in Attachment Number _____( or See Schedule as Applicable).

(iv) Any item of special tooling or special test equipment as defined in FAR 2.101 that have been designated for preservation and storage for a Major Defense Acquisition Program as specified in Attachment Number _____( or See Schedule as Applicable).

(v) Any item not included in paragraphs (c)(1)(i), (ii), (iii), or (iv) of this clause for which the contractor creates and marks a unique item identifier for traceability.

(f) The Contractor shall submit the information required by paragraphs (d) and (e) of this clause as follows:

(1) End items shall be reported using the receiving report capability in Wide Area WorkFlow (WAWF) in accordance with the clause at 252.2327003. If WAWF is not required by this contract, and the contractor is not using WAWF, follow the procedures at http://dodprocurementtoolbox.com/site/uidregistry/ .

(2) Embedded items shall be reported by one of the following methods—

(i) Use of the embedded items capability in WAWF;

(ii) Direct data submission to the IUID Registry following the procedures and formats at http://dodprocurementtoolbox.com/site/uidregistry/; or

(iii) Via WAWF as a deliverable attachment for exhibit line item number ______, Unique Item Identifier Report for Embedded Items, Contract Data Requirements List, DD Form 1423.

52.215-2 AUDIT AND RECORDS--NEGOTIATION (JUN 2020)

(IAW FAR 15.209(b)(1))

52.215-8 ORDER OF PRECEDENCE--UNIFORM CONTRACT FORMAT (OCT 1997)

(IAW FAR 15.209(h))

52.215-14 INTEGRITY OF UNIT PRICES (NOV 2021)

(IAW FAR 15.408(f)(1))

52.215-14 INTEGRITY OF UNIT PRICES -- ALTERNATE I (OCT 1997)

(IAW FAR 15.408(f)(2))

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (DEVIATION 2023-O0002)

(DEC 2022)

(IAW Deviation 2023-O0002, Revision 1)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (OCT 2022)

(IAW FAR 19.309(c))

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code ________ assigned to contract number _______________.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a womenowned small business concern.

(4) Womenowned small business (WOSB) joint venture eligible under the WOSB Program. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture: _______.]

(5) Economically disadvantaged womenowned small business (EDWOSB) joint venture. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) and through (c). [The Contractor shall enter the name and unique entity identifier of each party to the joint venture: _______.]

(6) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a veteranowned small business concern.

(7) [Complete only if the Contractor represented itself as a veteranowned small business concern in paragraph (h)(6) of this clause.] The Contractor represents that it [ ] is, [ ] is not a servicedisabled veteranowned small business concern.

(8) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that—

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture.

[The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: _________________________________________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[Contractor to sign and date and insert authorized signer’s name and title.]

52.222-19 CHILD LABOR--COOPERATION WITH AUTHORITIES AND REMEDIES (DEC 2022)

(IAW FAR 22.1505(b))

52.222-20 CONTRACTS FOR MATERIALS, ARTICLES, AND EQUIPMENT (JUN 2020)

(IAW FAR 22.610)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

(IAW FAR 22.810(a)(1))

52.222-26 EQUAL OPPORTUNITY (SEP 2016)

(IAW FAR 22.810(e))

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

(IAW FAR 22.1310(a)(1), DFARS 222.1310(a)(1))

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)

(IAW FAR 22.1408(a))

52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUN 2020)

(IAW FAR 22.1310(b))

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR

RELATIONS ACT (DEC 2010)

(IAW FAR 22.1605)

52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

(IAW FAR 22.1705(a)(1))

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA

(FEB 2021)

(IAW FAR 23.303(a))

(b) The offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract.

Identification No. MATERIAL (If none, Insert None)

NSN: 1377013758919ES LI 0001 CARTRIDGE, IMPULSE

NSN: 1377013568732ES LI 0002 INITIATOR, PROPELLANT ACTUATED

NSN: 1377013568734ES LI 0003 INITIATOR, PROPELLANT ACTUATED

NSN: 1377013568731ES LI 0004 INITIATOR, PROPELLANT ACTUATED

NSN: 1377013568735ES LI 0005 INITIATOR, PROPELLANT ACTUATED

NSN: 1377013565593ES LI 0006 INITIATOR, PROPELLANT ACTUATED

NSN: 1377013565592ES LI 0007 INITIATOR, PROPELLANT ACTUATED

NSN: 1377013568733ES LI 0008 INITIATOR, PROPELLANT ACTUATED

NSN: 1377013568730ES LI 0009 INITIATOR, PROPELLANT ACTUATED

LI 0010 None

52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

(IAW FAR 23.505)

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE

DRIVING (JUN 2020)

(IAW FAR 23.1105)

252.223-7001 HAZARD WARNING LABELS (DEC 1991)

(IAW DFARS 223.303)

(c) The Offeror shall list which hazardous material listed in the Hazardous Material Identification and Material Safety Data clause of this contract will be labeled in accordance with one of the Acts in paragraphs (b)(1) through (5) of this clause instead of the Hazard Communication Standard. Any hazardous material not listed will be interpreted to mean that a label is required in accordance with the Hazard Communication Standard.

ACT MATERIAL (If None, Insert “None.”)

LI 0001 CARTRIDGE, IMPULSE

LI 0002 INITIATOR, PROPELLANT ACTUATED

LI 0003 INITIATOR, PROPELLANT ACTUATED

LI 0004 INITIATOR, PROPELLANT ACTUATED

LI 0005 INITIATOR, PROPELLANT ACTUATED

LI 0006 INITIATOR, PROPELLANT ACTUATED

LI 0007 INITIATOR, PROPELLANT ACTUATED

LI 0008 INITIATOR, PROPELLANT ACTUATED

LI 0009 INITIATOR, PROPELLANT ACTUATED

LI 0010 None

252.223-7002 SAFETY PRECAUTIONS FOR AMMUNITION AND EXPLOSIVES (MAY 1994)

(IAW DFARS 223.370-5)

252.223-7003 CHANGE IN PLACE OF PERFORMANCE--AMMUNITION AND EXPLOSIVES

(DEC 1991)

(IAW DFARS 223.370-5)

252.223-7008 PROHIBITION OF HEXAVALENT CHROMIUM (JAN 2023)

(IAW DFARS 223.7306, DFARS 212.301(f)(xxi))

52.224-3 PRIVACY TRAINING (JAN 2017)

(IAW FAR 24.302(a))

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

(IAW FAR 25.1103(a))

252.225-7001 BUY AMERICAN AND BALANCE OF PAYMENTS PROGRAM--BASIC (JAN 2023)

(IAW DFARS 225.1101(2)(i) and (2)(ii))

252.225-7002 QUALIFYING COUNTRY SOURCES AS SUBCONTRACTORS (MAR 2022)

(IAW DFARS 225.1101(3))

252.225-7007 PROHIBITION ON ACQUISITION OF UNITED STATES MUNITIONS LIST ITEMS FROM

COMMUNIST CHINESE MILITARY COMPANIES (DEC 2018)

(IAW DFARS 225.1103(4))

252.225-7008 RESTRICTION ON ACQUISITION OF SPECIALTY METALS (MAR 2013)

(IAW DFARS 225.7003-5(a)(1), DFARS 212.301(f)(xxiv))

252.225-7009 RESTRICTION ON ACQUISITION OF CERTAIN ARTICLES CONTAINING SPECIALTY

METALS (JAN 2023)

(IAW DFARS 225.7003-5(a)(2), DFARS 212.301(f)(xxv))

252.225-7012 PREFERENCE FOR CERTAIN DOMESTIC COMMODITIES (APR 2022)

(IAW DFARS 225.7002-3(a))

252.225-7013 DUTY-FREE ENTRY (DEC 2022)

(IAW DFARS 225.1101(4))

252.225-7048 EXPORT-CONTROLLED ITEMS (JUN 2013)

(IAW DFARS 225.7901-4)

252.225-7052 RESTRICTION ON THE ACQUISITION OF CERTAIN MAGNETS, TANTALUM, AND

TUNGSTEN (JAN 2023)

(IAW DFARS 225.7018-5)

252.225-7061 RESTRICTION ON THE ACQUISITION OF PERSONAL PROTECTIVE EQUIPMENT

AND CERTAIN OTHER ITEMS FROM NON-ALLIED FOREIGN NATIONS (JAN 2023)

(IAW DFARS 225.7023-4)

252.225-7972 PROHIBITION ON THE PROCUREMENT OF FOREIGN-MADE UNMANNED AIRCRAFT

SYSTEMS (DEVIATION 2020-O0015) (MAY 2020)

(IAW Deviation 2020-O0015)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

(IAW FAR 27.201-2(a)(1))

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT

INFRINGEMENT (JUN 2020)

(IAW FAR 27.201-2(b))

252.227-7030 TECHNICAL DATA--WITHHOLDING OF PAYMENT (MAR 2000)

(IAW DFARS 227.7103-6(e)(2), DFARS 227.7104(e)(4))

(a) the Contracting Officer may until such data is accepted by the Government, withhold payment to the Contractor of ten percent (10%) of the total contract price or amount

52.229-4 FEDERAL, STATE, AND LOCAL TAXES (STATE AND LOCAL ADJUSTMENTS)

(FEB 2013)

(IAW FAR 29.401-3(b))

52.229-12 TAX ON CERTAIN FOREIGN PROCUREMENTS (FEB 2021)

(IAW 29.402-3(b))

252.229-7014 FULL EXEMPTION FROM TWO-PERCENT EXCISE TAX ON CERTAIN FOREIGN

PROCUREMENTS. (OCT 2022)

(IAW DFARS 229-402(k))

52.232-1 PAYMENTS (APR 1984)

(IAW FAR 32.111(a)(1))

52.232-8 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)

(IAW FAR 32.111(b)(1))

52.232-11 EXTRAS (APR 1984)

(IAW FAR 32.111(c)(2))

52.232-17 INTEREST (MAY 2014)

(IAW FAR 32.611(a), FAR 32.611(b))

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

(IAW FAR 32.706-1(a))

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

(IAW FAR 32.806(a)(1))

52.232-25 PROMPT PAYMENT (JAN 2017)

(IAW FAR 32.908(c))

(a) Invoice payments—

(5) Computing penalty amount. The Government will compute the interest penalty in accordance with the Office of Management and Budget prompt payment regulations at 5 CFR part 1315.

(i) For the sole purpose of computing an interest penalty that might be due the Contractor, Government acceptance is deemed to occur constructively on the 7th day (unless otherwise specified in this contract) after the Contractor delivers the supplies or performs the services in accordance with the terms and conditions of the contract, unless there is a disagreement over quantity, quality, or Contractor compliance with a contract provision. If actual acceptance occurs within the constructive acceptance period, the Government will base the determination of an interest penalty on the actual date of acceptance. The constructive acceptance requirement does not, however, compel Government officials to accept supplies or services, perform contract administration functions, or make payment prior to fulfilling their responsibilities.

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER--SYSTEM FOR AWARD

MANAGEMENT (OCT 2018)

(IAW FAR 32.1110(a)(1))

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

(IAW FAR 32.706-3)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS

SUBCONTRACTORS (MAR 2023)

(IAW FAR 32.009-2)

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS

(DEC 2018)

(IAW DFARS 232.7004(a))

(a) Definitions. As used in this clause—

(1) “Contract financing payment” and “invoice payment” have the meanings given in section 32.001 of the Federal Acquisition Regulation.

(2) “Electronic form” means any automated system that transmits information electronically from the initiating system to all affected systems. Facsimile, email, and scanned documents are not acceptable electronic forms for submission of payment requests. However, scanned documents are acceptable when they are part of a submission of a payment request made using Wide Area WorkFlow (WAWF) or another electronic form authorized by the Contracting Officer.

(3) “Payment request” means any request for contract financing payment or invoice payment submitted by the Contractor under this contract.

(b) Except as provided in paragraph (c) of this clause, the Contractor shall submit payment requests and receiving reports using WAWF, in one of the following electronic formats that WAWF accepts: Electronic Data Interchange, Secure File Transfer Protocol, or World Wide Web input. Information regarding WAWF is available on the Internet at https://wawf.eb.mil/ .

(c) The Contractor may submit a payment request and receiving report using other than WAWF only when—

(1) The Contracting Officer authorizes use of another electronic form. With such an authorization, the Contractor and the Contracting Officer shall agree to a plan, which shall include a timeline, specifying when the Contractor will transfer to WAWF;

(2) DoD is unable to receive a payment request or provide acceptance in electronic form;

(3) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor. In such cases, the Contractor shall include a copy of the Contracting Officer’s determination with each request for payment; or

(4) DoD makes a payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoDapproved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System).

(d) The Contractor shall submit any nonelectronic payment requests using the method or methods specified in Section G of the contract.

(e) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payment requests.

252.232-7010 LEVIES ON CONTRACT PAYMENTS (DEC 2006)

(IAW DFARS 232.7102)

52.233-1 DISPUTES (MAY 2014)

(IAW FAR 33.215)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

(IAW FAR 33.106(b))

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

(IAW FAR 33.215(b))

52.242-13 BANKRUPTCY (JUL 1995)

(IAW FAR 42.903)

52.243-1…