Solicitation Amendment FA665626B00030002 SF 30 (2).pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

J

2. AMENDMENT/MODIFICATION NUMBER

3. EFFECTIVE DATE

24 Jun 2026

4. REQUISITION/PURCHASE

REQUISITION NUMBER

5. PROJECT NUMBER (if applicable)

ZQEL 22-0006

6. ISSUED BY CODE FA6656

FA6656 910 AW LGC YNGSTN WRN ARPT

3976 KING GRAVES RD, ADMINISTRATIVE ONLY NO REQUISITIONS

VIENNA, OH 44473-0910

UNITED STATES

PATRICK NALLEY, Email: patrick.nalley@us.af.mil Telephone: 330-609-1046 Joseph Perry, Email: joseph.perry.14@us.af.mil Telephone: 3306091212

7. ADMINISTERED BY (if other than Item 6)

CODE

SCD: PAS:

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code)

CODE: FACILITY CODE:

9A. AMENDMENT OF SOLICITATION NUMBER

FA665626B0003

9B. DATED (SEE ITEM 11)

08 Jun 2026

10A. MODIFICATION OF CONTRACT/ORDER

NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; 1 or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required) See Section G - Contract Administration Data

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK

ONE

A.THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.)

SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

See Schedule

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Computer generated. Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA-FAR (48 CFR) 53.243

Created On:

24 Jun 2026, 09:53 AM Eastern Daylight Time

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Adding the Clauses Block 14 (Description of Amendment/Modification):

52.211-12 Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $350.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.228-1 Bid Guarantee (Sept 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $____, whichever is less.

Section A - Solicitation/Contract Form

The following modifications were made:

Information From To Solicitation Number FA665626B00030001 FA665626B00030002

Section I - Contract Clauses

Additional Regulation or Supplemental Clauses Incorporated by Full Text

The following Clause(s) were added:

FAR Clauses Incorporated by Full Text 52.211-12 Liquidated Damages-Construction. (Sep 2000)

LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.____

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

Section L - Instructions, Conditions, & Notices to Offerors or Quoters

Additional Regulation or Supplemental Clauses Incorporated by Full Text

The following Clause(s) were added:

FAR Clauses Incorporated by Full Text 52.228-1 Bid Guarantee. (Sep 1996)

FA665626B00030002

BID GUARANTEE (SEPT 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, bid bond supported by good and sufficient surety or sureties acceptable to the e.g., Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be percent of the bid price or $ , whichever is less.20 ____

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of clause)

FA665626B00030002