FA5685-11-R-0009 Repair Roof Bldg 282 Warehouse.doc

Section B - Supplies or Services and Prices

Repair Roof Bldg 282 Warehouse

FFP

SERVICES NON-PERSONAL: Provide all labor, equipment, materials, tools, parts, and transportation to and from job site to Repair Bldg 282 Warehouse Roof (Project No. LJYC 10-1018) in accordance with (IAW) attached Specifications an Drawings.

FOB: Destination

SIGNAL CODE: A

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

Section F - Deliveries or Performance

DELIVERY INFORMATION

AYTAC URUC

39CES/CECEP BLDG 444 UNIT 7065

APO AE 09824

676-3433

FOB: Destination F2G3C2

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

52.203-5 COVENANT AGAINST CONTINGENT FEES (APR 1984)

(a) The Contractor warrants that no person or agency has been employed or retained to solicit or obtain this contract upon an agreement or understanding for a contingent fee, except a bona fide employee or agency. For breach or violation of this warranty, the Government shall have the right to annul this contract without liability or, in its discretion, to deduct from the contract price or consideration, or otherwise recover, the full amount of the contingent fee.

(b) "Bona fide agency," as used in this clause, means an established commercial or selling agency, maintained by a contractor for the purpose of securing business, that neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds itself out as being able to obtain any Government contract or contracts through improper influence.

"Bona fide employee," as used in this clause, means a person, employed by a contractor and subject to the contractor's supervision and control as to time, place, and manner of performance, who neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds out as being able to obtain any Government contract or contracts through improper influence.

"Contingent fee," as used in this clause, means any commission, percentage, brokerage, or other fee that is contingent upon the success that a person or concern has in securing a Government contract.

"Improper influence," as used in this clause, means any influence that induces or tends to induce a Government employee or officer to give consideration or to act regarding a Government contract on any basis other than the merits of the matter.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 125 days after issuance of CNTP The time stated for completion shall include final cleanup of the premises.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $287.11for the first day and $176.96 each day thereafter until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (AUG 2003)

(a) Definitions. As used in this clause--

“Priority chemical means a chemical identified by the Interagency Environmental Leadership Workgroup or, alternatively, by an agency pursuant to section 503 of Executive Order 13148 of April 21, 2000, Greening the Government through Leadership in Environmental Management.”

“Toxic chemical means a chemical or chemical category listed in 40 CFR 372.65.”

(b) Executive Order 13148 requires Federal facilities to comply with the provisions of the Emergency Planning and Community Right-to-Know Act of 1986 (EPCRA) (42 U.S.C. 11001-11050) and the Pollution Prevention Act of 1990 (PPA) (42 U.S.C. 13101-13109).

(c) The Contractor shall provide all information needed by the Federal facility to comply with the following:

(1) The emergency planning reporting requirements of section 302 of EPCRA.

(2) The emergency notice requirements of section 304 of EPCRA.

(3) The list of Material Safety Data Sheets, required by section 311 of EPCRA.

(4) The emergency and hazardous chemical inventory forms of section 312 of EPCRA.

(5) The toxic chemical release inventory of section 313 of EPCRA, which includes the reduction and recycling information required by section 6607 of PPA.

(6) The toxic chemical, priority chemical, and hazardous substance release and use reduction goals of sections 502 and 503 of Executive Order 13148.

(End of clause)

52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JULY 2000)

(a) The Contractor shall submit one of the following payment protections:

Bank Guarantee Letter

(b) The amount of the payment protection shall be 100 percent of the contract price.

(c) The submission of the payment protection is required within 10 days of contract award.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.229-6 TAXES--FOREIGN FIXED-PRICE CONTRACTS (JUN 2003)

(a) To the extent that this contract provides for furnishing supplies or performing services outside the United States and its outlying areas, this clause applies in lieu of any Federal, State, and local taxes clause of the contract.

(b) Definitions. As used in this clause--

"Contract date," means the date set for bid opening or, if this is a negotiated contract or a modification, the effective date of this contract or modification.

Country concerned means any country, other than the United States and its outlying areas, in which expenditures under this contract are made.

"Tax" and "taxes," include fees and charges for doing business that are levied by the government of the country concerned or by its political subdivisions.

"All applicable taxes and duties," means all taxes and duties, in effect on the contract date, that the taxing authority is imposing and collecting on the transactions or property covered by this contract, pursuant to written ruling or regulation in effect on the contract date.

"After-imposed tax," means any new or increased tax or duty, or tax that was exempted or excluded on the contract date but whose exemption was later revoked or reduced during the contract period, other than excepted tax, on the transactions or property covered by this contract that the Contractor is required to pay or bear as the result of legislative, judicial, or administrative action taking effect after the contract date.

"After-relieved tax," means any amount of tax or duty, other than an excepted tax, that would otherwise have been payable on the transactions or property covered by this contract, but which the Contractor is not required to pay or bear, or for which the Contractor obtains a refund, as the result of legislative, judicial, or administrative action taking effect after the contract date.

"Excepted tax," means social security or other employment taxes, net income and franchise taxes, excess profits taxes, capital stock taxes, transportation taxes, unemployment compensation taxes, and property taxes. "Excepted tax" does not include gross income taxes levied on or measured by sales or receipts from sales, property taxes assessed on completed supplies covered by this contract, or any tax assessed on the Contractor's possession of, interest in, or use of property, title to which is in the U.S. Government.

(c) Unless otherwise provided in this contract, the contract price includes all applicable taxes and duties, except taxes and duties that the Government of the United States and the government of the country concerned have agreed shall not be applicable to expenditures in such country by or on behalf of the United States.

(d) The contract price shall be increased by the amount of any after-imposed tax or of any tax or duty specifically excluded from the contract price by a provision of this contract that the Contractor is required to pay or bear, including any interest or penalty, if the Contractor states in writing that the contract price does not include any contingency for such tax and if liability for such tax, interest, or penalty was not incurred through the Contractor's fault, negligence, or failure to follow instructions of the Contracting Officer or to comply with the provisions of paragraph (i) below.

(e) The contract price shall be decreased by the amount of any after-relieved tax, including any interest or penalty. The Government of the United States shall be entitled to interest received by the Contractor incident to a refund of taxes to the extent that such interest was earned after the Contractor was paid by the Government of the United States for such taxes. The Government of the United States shall be entitled to repayment of any penalty refunded to the Contractor to the extent that the penalty was paid by the Government.

(f) The contract price shall be decreased by the amount of any tax or duty, other than an excepted tax, that was included in the contract and that the Contractor is required to pay or bear, or does not obtain a refund of, through the Contractor's fault, negligence, or failure to follow instructions of the Contracting Officer or to comply with the provisions of paragraph (i) below.

(g) No adjustment shall be made in the contract price under this clause unless the amount of the adjustment exceeds $250.

(h) If the Contractor obtains a reduction in tax liability under the United States Internal Revenue Code (Title 26, U.S. Code) because of the payment of any tax or duty that either was included in the contract price or was the basis of an increase in the contract price, the amount of the reduction shall be paid or credited to the Government of the United States as the Contracting Officer directs.

(i) The Contractor shall take all reasonable action to obtain exemption from or refund of any taxes or duties, including interest or penalty, from which the United States Government, the Contractor, any subcontractor, or the transactions or property covered by this contract are exempt under the laws of the country concerned or its political subdivisions or which the governments of the United States and of the country concerned have agreed shall not be applicable to expenditures in such country by or on behalf of the United States.

(j) The Contractor shall promptly notify the Contracting Officer of all matters relating to taxes or duties that reasonably may be expected to result in either an increase or decrease in the contract price and shall take appropriate action as the Contracting Officer directs. The contract price shall be equitably adjusted to cover the costs of action taken by the Contractor at the direction of the Contracting Officer, including any interest, penalty, and reasonable attorneys' fees.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from 39 CONS/LGCA Unit 7090 127 APO AE 09824-0127.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for--

9 March 2011 at 1000

(c) Participants will meet at--

39 Contracting Sq (Blg 485)

(End of provision)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

(End of clause)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

252.225-7041 CORRESPONDENCE IN ENGLISH (JUNE 1997)

The Contractor shall ensure that all contract correspondence that is addressed to the United States Government is submitted in English or with an English translation.

(End of clause)

252.229-7001 TAX RELIEF (JUN 1997)

(a) Prices set forth in this contract are exclusive of all taxes and duties from which the United States Government is exempt by virtue of tax agreements between the United States Government and the Contractor's government. The following taxes or duties have been excluded from the contract price:

VALUE ADDED TAX: NOT APPLICAPLE

(b) The Contractor's invoice shall list separately the gross price, amount of tax deducted, and net price charged.

(c) When items manufactured to United States Government specifications are being acquired, the Contractor shall identify the materials or components intended to be imported in order to ensure that relief from import duties is obtained. If the Contractor intends to use imported products from inventories on hand, the price of which includes a factor for import duties, the Contractor shall ensure the United States Government's exemption from these taxes. The Contractor may obtain a refund of the import duties from its government or request the duty-free import of an amount of supplies or components corresponding to that used from inventory for this contract.

(End of clause)

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (MAR 2008)

(a) Definitions. As used in this clause--

(1) Contract financing payment and invoice payment have the meanings given in section 32.001 of the Federal Acquisition Regulation.

(2) Electronic form means any automated system that transmits information electronically from the initiating system to all affected systems. Facsimile, e-mail, and scanned documents are not acceptable electronic forms for submission of payment requests. However, scanned documents are acceptable when they are part of a submission of a payment request made using Wide Area WorkFlow (WAWF) or another electronic form authorized by the Contracting Officer.

(3) Payment request means any request for contract financing payment or invoice payment submitted by the Contractor under this contract.

(b) Except as provided in paragraph (c) of this clause, the Contractor shall submit payment requests and receiving reports using WAWF, in one of the following electronic formats that WAWF accepts: Electronic Data Interchange, Secure File Transfer Protocol, or World Wide Web input. Information regarding WAWF is available on the Internet at https://wawf.eb.mil/.

(c) The Contractor may submit a payment request and receiving report using other than WAWF only when--

(1) The Contracting Officer authorizes use of another electronic form. With such an authorization, the Contractor and the Contracting Officer shall agree to a plan, which shall include a timeline, specifying when the Contractor will transfer to WAWF;

(2) DoD is unable to receive a payment request or provide acceptance in electronic form;

(3) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor. In such cases, the Contractor shall include a copy of the Contracting Officer's determination with each request for payment; or

(4) DoD makes payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoD-approved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System).

(d) The Contractor shall submit any non-electronic payment requests using the method or methods specified in Section G of the contract.

(e) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payments requests.

(End of clause)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Section J, Attachment 2: Drawings

(End of clause)

5352.201-9101 Ombudsman. OMBUDSMAN (APR 2010)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, concerned parties may contact the Center/MAJCOM ombudsmen:

Primary:

Ms Tara Petersen

HQ USAFE/A7K, UNIT 3050, Box 10, APO AE 09094-0110

HQ USAFE/A7K, Flugplatz Ramstein, 66877 Ramstein Germany

E-mail: tara.petersen@ramstein.af.mil

Tel: 0049-637-147-2209, Fax: (49)-6731-47-2025

Alternate:

Heidi Hoehn

HQ USAFE/A7K, UNIT 3050, Box 10, APO AE 09094-0110

HQ USAFE/A7K, Flugplatz Ramstein, 66877 Ramstein Germany

E-mail: heidi.hoehn@ramstein.af.mil

Tel: 0049-637-147-9330, Fax: (49)-6731-47-2025

Concerns, issues, disagreements, and recommendations that cannot be resolved at the MAJCOM/DRU level, may be brought by the concerned party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (703) 588-7004, facsimile number (703) 588-1067.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

(End of clause)

5352.242-9000 Contractor access to Air Force installations.

CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (JUN 2002)

(a) The contractor shall obtain base identification and vehicle passes for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, and valid vehicle insurance certificate to obtain a vehicle pass.

(c) Our office will certify applications for gate passes for Turkish pass and ID. The Turkish Air Force will coordinate with contractors to attain the necessary documents and information to grant access to the installation. The U.S. government will not be held liable for any delays or breach of contract caused by refusal of the Turkish Air Force to grant a gate pass to a contractor. If a gate pass is not granted to a contractor allowing the delivery of goods, execution of warranty support, or performance of services please contact the contracting officer immediately. Below is a number to the Turkish Air Force Pass and ID for all gate pass issues: 322-316-4184 or 322-316-4186

(d) Performance of this contract is located on a Turkish Air Force installation, and all access to the installation is controlled and granted by the Turkish Air Force (TAF) Security Battalion.

(e) Prior to commencing work the Contractor shall furnish a complete list of all vehicles and personnel involved in the accomplishment of the contract work to the Turkish Air Force Pass and ID or designated representative to ensure access to the respective installations. The following information must be furnished on this list:

Vehicles: Make, model, year of manufacture, capacity, type, license number, and insurance policy number. Personnel: First and last name, date of birth, place of birth, passport or identification card number, place of residence and any such other information, as required, to satisfy individual air base or army security regulations governing access to granting of passes to the particular military establishment.

(f) All passes may be obtained from the Turkish Air Force Pass and ID or designated representative approximately 10 days after the aforementioned lists have been submitted. The contractor shall inform all assigned workers that they may be subject to search, at the discretion of the installation commander, when entering or leaving the installation.

(g) Installation passes will be returned immediately to the Issuing Officer when:

(1) Pass has expired.

(2) Pass holder is no longer employed by the Contractor.

(3) Contract is completed.

(4) Issuing Officer so directs.

(h) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(i) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel Security Program Management, as applicable.

(j) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(k) Failure to comply with these requirements may result in withholding of final payment.

(End of clause)

Section J - List of Documents, Exhibits and Other Attachments

SPECIFICATIONS/DRAWINGS

DOCUMENT TYPE

DESCRIPTION

PAGES

DATE

Attachment 1

Specifications

Feb 2011

Attachment 2

Drawings

Feb 2011

Attachment 3

AF Form 66 / INC 1106

Undated

Attachment 4

AF Form 3052 / INC 1101

Undated

Attachment 5

Incirlik Instructions

Attachment 6

WAWF Instructions

Attachment 7

Site Visit Reservation Form

Undated

Attachments 1, 4, 5, 6 and 7 will be posted on FBO. All attachments (1-7) shall be provided to each offeror on a CD-ROM at a time of the scheduled Pre-Proposal Conference/Site Visit. CD-ROM will also be made available for pick-up at the 39th Contracting Squadron Bldg 485, Incirlik AB to offerors prior to the proposal due date.

Section K - Representations, Certifications and Other Statements of Offerors

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2010)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is -------------- [insert NAICS code].

(2) The small business size standard is -------------- [insert size standard].

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the clause at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the clause at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

(__) Paragraph (d) applies.

(__) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in ORCA are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the clause at 52.204-7, Central Contractor Registration.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business).This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vi) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(vii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(viii) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(ix) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(x) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xi) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xiv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xv) 52.225-2, Buy American Act Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvi) 52.225-4, Buy American Act--Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternate I, and Alternate II) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $67,826, the provision with its Alternate II applies.

(xvii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xviii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xix) 52.225-25, Prohibition on Engaging in Sanctioned Activities Relating to Iran--Certification. This provision applies to all solicitations.

(xx) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to--

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(Contracting Officer check as appropriate.)

----(i) 52.219-19, Small Business Concern Representation for the Small Business Competitiveness Demonstration Program.

------(ii) 52.219-21, Small Business Size Representation for Targeted Industry Categories Under the Small Business Competitiveness Demonstration Program.

------(iii) 52.219-22, Small Disadvantaged Business Status.

------(A) Basic.

------(B) Alternate I.

------(iv) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

------(v) 52.222-48, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment Certification.

------(vi) 52.222-52 Exemption from Application of the Service Contract Act to Contracts for Certain Services--Certification.

------(vii) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

------(viii) 52.223-13, Certification of Toxic Chemical Release Reporting.

------(ix) 52.227-6, Royalty Information.

------ (A) Basic.

------ (B) Alternate I.

------(x) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the Online Representations and Certifications Application (ORCA) website at http://orca.bpn.gov. After reviewing the ORCA database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below (offeror to insert changes, identifyingchange by clause number, title, date). These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on ORCA.

(End of Provision)

Section L - Instructions, Conditions and Notices to Bidders

INSTRUCTIONS TO OFFERORS

L-01.

PROPOSAL PREPARATION INSTRUCTIONS

A. To assure timely and equitable evaluation of proposals, offerors must follow the instructions contained herein. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements, in addition to those identified as evaluation factors or subfactors. Failure to meet a requirement may result in an offer being ineligible for award. Offerors must clearly identify any exception to the solicitation terms and conditions and provide complete accompanying rationale. The response shall consist of two separate parts; Part I - Price Proposal, and Part II - Technical Proposal.

B. The Contracting Officer (CO) has determined there is a high probability of adequate price competition in this acquisition. Upon examination of the initial offers, the CO will review this determination and if, in the CO’s opinion, adequate price competition exists, no additional cost information will be requested and certification under FAR 15.406-2 will not be required. However, if at any time during this competition the CO determines that adequate price competition no longer exists; offerors may be required to submit information to the extent necessary for the CO to determine the reasonableness and affordability of the price.

C. Specific Instructions:

1. PART I – PRICE PROPOSAL - Submit original and one (1) copy

(a) Complete blocks 14, 15, 17, 18, 19 and 20 of the SF 1442.

(b) Insert proposed unit and extended prices in Section B for each Contract Line Item Number (CLIN).

(c) Complete the necessary fill-ins and certifications in Sections F through K. Section K shall be returned in its entirety. For Sections F through J, the offeror shall submit only those pages that require a fill-in.

(d) Each offeror shall be responsible for estimating and conforming the individual quantities required by Technical Specifications & Drawings. These quantities shall be included on the INC Form 1101(old Form 3052, Cost Breakdown), and will be used during the evaluation of offeror and negotiations, if required. The INC 1101 SHALL NOT be a part of the resultant contract (see Section J, Attachment 4).

(e) Acknowledgement of all amendments to the solicitation in accordance with the instructions on the SF 30 (amendment form)

2. PART II – TECHNICAL PROPOSAL .

1. Quality Control: Contractor shall provide information that effectively represents their quality control program and methodology. The offeror’s quality control plan and methodology shall meet or exceed commercial standards routinely used by the construction industry for same or similar projects. Any innovative procedures or methods shall be explained in detail. This information shall provide the Government with no doubt of the offeror’s contract management and process improvement abilities.

2. Technical Capabilities: The offeror shall provide information that effectively represents their technical expertise and project management capabilities. All techniques and resources shall meet or exceed commercial standards routinely used by the construction industry for same or similar projects. Any innovative procedures or methods shall be explained in detail. As a minimum, offerors shall include:

A narrative to demonstrate a sound approach and methodology for accomplishing work requirements identified in the solicitation with the appropriate skills, equipment, and materials, in the appropriate quantities, and at the appropriate time to meet the Government’s desired outcomes. Each offeror shall also submit their proposed work plan for the major elements of the project as listed below. The narrative and materials submittal shall provide the Government with no doubt of the offeror’s abilities to manage all resources required to perform the requirements outlined in this solicitation. The offeror’s proposed material listing shall be incorporated into any resultant contract. (Max. 5 Pages)

1. Trapezoidal metal sandwich roof systems and skylight applications.

2. A list of all necessary testing, adjusting, and methodology.

3. Documentation, the list of key personnel and accompanying resumes will be evaluated for completeness to determine if all key personnel identified have the technical and educational background, relevant job experience and qualifications to perform the work requirements of this project. Documentation (resume, references), indicating that the site architect/civil engineer assigned to this project has a minimum of five years of experience. This engineer must be able to speak English and will be required to be present at the job site at all times when work is in progress.

3. A progress schedule for all major construction elements of this project based upon the offeror’s proposed performance period. All milestones and any phasing shall be annotated with proposed actual dates in two formats: a line graph (e.g AFF 3064, or equal), and as a Gantt chart (e.g. MS Project, or equal). The offeror’s proposed performance period shall not exceed the performance period outlined in SF 1442, block 11. Offeror shall explain what he will do to minimize the period of performance (e.g. increase crew size and/or number of crews, etc.)

4. Provide safety plan and safety equipment list. (Maximum 10 pages)

5. Proposed material list using the PPL, to the maximum extent possible.

Offeror’s shall comply with submitting the following with the below:

a. Quality Control Plan

b. Narrative and Materials

c. Project Schedule

d. Key Personnel 1 Original + 2 Electronic Copies

1 Original + 2 Electronic Copies 1 Original + 2 Electronic Copies

1 Original + 2 Electronic Copies

L-02.

GENERAL INFORMATION

A. Contractors should be aware that this is a Turkish Installation and that all access to this installation is granted by the Turkish Air Force (TuAF). Therefore SOME DELAYS SHOULD BE ANTICIPATED WHEN HAND CARRYING PROPOSALS. Offeror should allow sufficient time to arrive and submit the proposals to Contracting Office PRIOR to the set closing time. Late proposals will be processed in accordance with the provisions “Late Submission, Modifications, and Withdrawals of Proposals”. If a gate access is not granted please contact the CO immediately. The contractors are responsible for coordinating and processing gate pass requests in a timely manner. The USG shall not be held accountable. Furthermore, contractors must consider that although the duty day is Monday through Friday from 07:30 to 16:30, contractors may not get to the job site at 07:30 due to TuAF gate entrance procedures. Also, contractors need to exit the base by 16:30. This may require contractors to stop work, prepare to leave the base, and clean up prior to 16:30. Contractors are encouraged to take this into consideration when proposing a delivery or performance time. The USG shall not be responsible for delays due to in processing or out-processing the base.

B. YOUR COMPANY MUST BE CENTRAL CONTRACTOR REGISTRATION (CCR) REGISTERED IN ORDER TO BE CONSIDERED FOR AWARDS.

THE WEBSITE FOR CCR REGISTRATION: http://www.ccr.gov/

YOU NEED TO HAVE DUNS AND NCAGE CODE (NATO CAGE CODE) TO BE REGISTERED ON CCR.

NATO CAGE CODE: ________________________________

If you do not have a NATO Cage Code, you must contact:

http://www.msb.mil.tr/prgs/tekhizweb/TEKMURACAT/NCAGE/default.asp or MLLI SAVUNMA BAKANLIGI

TEK.HIZ.D. BSK.LIGI

(TURK MILLI KODLANDIRMA BUROSU)

06100 Bakanliklar, ANKARA

Telephone NCAGE ASSIGNMENT: 0312-4106184

YOUR COMPANY’S “DUNS” NUMBER: ___________________________

If you do not have a DUNS number, you must contact “DUNS and BRADSTREET”, at the numbers below to have one assigned, before your quotation will be considered:

U.S.A. OFFICE:

ISTANBUL OFFICE (Ms. Demet Kulik):

Phone: 001 610-882-7741

Phone: 0-212-327-2238 ext 122

FAX: 001 610-882-7140

FAX: 0-212-327-2243

WEBSITE: http://www.dbis/customer/custlist.htm or http://www.finar.com.tr C. Proposal Characteristics:

(1) All text must be legible and easily read. All text shall be typed single-spaced. Margins (1-inch) shall be clean and clear. Each volume shall be contained within a separate 3 or 2-ring binder (no heat or spiral bound volumes). Project Schedule shall be developed and submitted in Microsoft Project format or equivalent sufficiently sized for clear readability.

(2) All proposals shall contain the requirements stated herein and the volume number and name, address, and telephone number of the prime on the cover shall identify every volume. Each volume shall also contain a Table of Contents, List of Tables, List of Figures, List of Appendices, and List of Acronyms and at the bottom left side of each page the volume number shall be included. The list of acronyms should include all acronyms appearing in the volume. The offeror's name, address, signature, and telephone number shall appear on any document to be evaluated.

(3) Proposal clarity, organization (as requested in this solicitation) and cross-referencing are mandatory. No material shall be incorporated by reference.