Solicitation Amendment - FA527023R00060002.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

Section A - Solicitation/Contract Form

Simplified Acquisition Base Engineering Requirements (SABER)

FA527023R00060002

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

(See each order)

Item Supplies/Service Estimated Quantity

Unit Unit Price Amount

(BASE) Simplified Acquisition Base Engineering Requirements (SABER) Contractor shall provide all labor, equipment, materials, transportation, supervision, administration, testing, etc., necessary to complete maintenance, repair, and minor construction services during standard / non-standard working time , working location in accordance with the SABER Specifications.

Product Service Code: Z2JZ Pricing Arrangement: Firm Fixed Price

1 Project

Option Line Item

(OPTION 1) Simplified Acquisition Base Engineering Requirements (SABER) Contractor shall provide all labor, equipment, materials, transportation, supervision, administration, testing, etc., necessary to complete maintenance, repair, and minor construction services during standard / non-standard working time , working location in accordance with the SABER Specifications.

Product Service Code: Z2JZ Pricing Arrangement: Firm Fixed Price

1 Project

Option Line Item

(OPTION 2) Simplified Acquisition Base Engineering Requirements (SABER) Contractor shall provide all labor, equipment, materials, transportation, supervision, administration, testing, etc., necessary to complete maintenance, repair, and minor construction services during standard / non-standard working time , working location in accordance with the SABER Specifications.

Product Service Code: Z2JZ Pricing Arrangement: Firm Fixed Price

1 Project

DFARS Clauses Incorporated by Full Text

252.229-7001 Tax Relief. Apr 2020

Basic. As prescribed in 229.402-70(a) and (a)(1), use the following clause:

TAX RELIEF-BASIC (APR 2020)

(a) Prices set forth in this contract are exclusive of all taxes and duties from which the United States Government is exempt by virtue of tax agreements between the United States Government and the Contractor's government. The following taxes or duties have been excluded from the contract price:

NAME OF TAX: ____(Offeror insert) RATE (PERCENTAGE): ____(Offeror insert)

(b) Invoices submitted in accordance with the terms and conditions of this contract shall be exclusive of all taxes or duties for which relief is available. The Contractor's invoice shall list separately the gross price, amount of tax deducted, and net price charged.

(c) When items manufactured to United States Government specifications are being acquired, the Contractor shall identify the materials or components intended to be imported in order to ensure that relief from import duties is obtained. If the Contractor intends to use imported products from inventories on hand, the price of which includes a factor for import duties, the Contractor shall ensure the United States Government's exemption from these taxes. The Contractor may obtain a refund of the import duties from its government or request the duty-free import of an amount of supplies or components corresponding to that used from inventory for this contract.

(End of clause)

Section C - Description/Specifications/Statement of Work

Requirements Simplified Acquisition Base Engineering Requirements (SABER), Indefinite-Delivery/Indefinite-Quantity (IDIQ) at Kadena Air Base, Japan

Section D - Packaging and Marking

Non-applicable

Section E - Inspection and Acceptance

Shall be specified in individual task orders

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. Aug 1996

Section F - Deliveries or Performance

Individual orders will define the period of performance and place of delivery.

"The Contractor shall complete performance within how many calendar days?" - Contractor shall reference delivery/performance of each individual order to find this information.

FAR References Applicable to this Section:

FAR 52.211-12 Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of ____________ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

FAR 52.211-13 Time Extensions (Sept 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause) Overall Contract Delivery Period

From date of lead time event to beginning of performance 30 Calendar Days Date of Notice to Proceed Receipt

From date of lead time event to completion of performance 365 Calendar Days Date of Notice to Proceed Receipt

Line Item Delivery Schedule Estimated Quantity

Address and POC

Delivery Schedule From date of lead time event to beginning of performance 12 Month Date of Award

1 Project Place of Performance DoDAAC: F2H2B9 CountryCode: USA

718 CES

AF BPN NO MILSBILLS PROCESSES,

UNIT 5261

APO, AP 96368-5261

UNITED STATES

Yoshihide Ikemiya Email: yoshihide.ikemiya.1.jp@us.af.mil

Period of Performance From 25 Sep 2023 To 24 Sep 2026

Telephone: 634-7258

Option Line Item

Delivery Schedule From date of lead time event to beginning of performance 12 Month CLIN Only - Date of Option Exercised

Period of Performance From 25 Sep 2026 To 24 Sep 2027

1 Project Service Performance Site DoDAAC: F2H2B9 CountryCode: USA

718 CES

AF BPN NO MILSBILLS PROCESSES,

UNIT 5261

APO, AP 96368-5261

UNITED STATES

Yoshihide Ikemiya Email: yoshihide.ikemiya.1.jp@us.af.mil Telephone: 634-7258

Option Line Item

Delivery Schedule From date of lead time event to beginning of performance 12 Month CLIN Only - Date of Option Exercised

Period of Performance From 25 Sep 2027 To 24 Sep 2028

1 Project Service Performance Site DoDAAC: F2H2B9 CountryCode: USA

718 CES

AF BPN NO MILSBILLS PROCESSES,

UNIT 5261

APO, AP 96368-5261

UNITED STATES

Yoshihide Ikemiya Email: yoshihide.ikemiya.1.jp@us.af.mil Telephone: 634-7258

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.242-17 Government Delay of Work. Apr 1984

Section G - Contract Administration Data

(a) Accounting and appropriation data will be cited on each individual task order(s) as awarded.

(b) SABER awardee is required to meet "OTHER CONTRACT REQUIREMENTS" in section H and any other requirements stated under this solicitation.

(c) Guaranteed Minimum Amount: Obligation of the guaranteed minimum amount stated within FAR 52.216-19 of this solicitation will be satisfied by issuing a task order for the guaranteed minimum amount or by issuing a firm requirement within the initial task order along with the award of the base IDIQ contract.

OCR 4- POST AWARD ADMINISTRATIVE INFORMATION

The contracting officer will provide to the contractor, a listing of the names of the Administrative Contracting Officer, Contract Administrator, and Construction Inspector (also referred to as the Contracting Officer's Representative (COR) or Technical Representative of the Contracting Officer (TRCO), their organizational codes and telephone numbers at the time of award or at the pre-construction conference. This provision in no way authorizes any person other than the contracting officer to commit the United States Government to changes in the terms or conditions of this contract. Reference Section I, DFARS 252.201-7000 entitled Contracting Officer's Representative (DEC 1991).

PAYING OFFICE: To be specified in a Task Order

For Directorate of Public Works (DPW), US Army

DoDAAC: HQ0671

DFAS JAPAN

GFEBS ARMY VENDOR PAY, UNIT 5220

APO AP 96328-5220

YOKOTA AB,

Japan

For 718 CES, Air Force

DoDAAC: F87700

ACCTG DISB STA NR 387700

DFAS DEAMS

27 ARKANSAS RD

LIMESTONE, ME 04751-6216

United States

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.201-7000 Contracting Officer's Representative. Dec 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018 252.232-7008 Assignment of Claims (Overseas). Jun 1997 252.236-7000 Modification Proposals--Price Breakdown. Dec 1991

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. Dec 2018

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC provided in individual task orders

Issue By DoDAAC FA5270

Admin DoDAAC FA5270

Inspect By DoDAAC provided in individual task orders

Service Approver (DoDAAC) provided in individual task orders

Service Acceptor (DoDAAC) FA5270

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

"Not applicable."

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Other Contract Requirements (OCR):

OCR 1- PRE-FINAL AND FINAL INSPECTION

In accordance with FAR 52.211-10 - Commencement, Prosecution, and Completion of Work (Apr 1984) the contractor is required to complete this project, ready for use, within the number of calendar days specified in the Task Order. To ensure adequate time to correct any deficiencies noted by the government during the final inspection, it is highly recommended that the contractor schedules such final inspection through the contract administrator at least seven (7) calendar days prior to the scheduled project completion date. The contractor is solely responsible for scheduling this inspection and is reminded that failure to complete the project ready for use in accordance with the contract terms and conditions may result in the assessment of liquidated damages as described in FAR 52.211-12 - Liquidated Damages-Construction (Sept 2000). Occasionally, minor discrepancies may be detected during the final inspection that may be considered "punchlist" items. If only minor "punchlist" items are found, another inspection may not be required. However, all punchlist items must be corrected by the contractor, and verified by the project inspector, prior to expiration of the contract period unless otherwise authorized in writing by the contracting officer. The determination as to what constitutes a minor discrepancy rests solely with the contracting officer and nothing in this paragraph shall be construed as a waiver of the government's rights under any clause in this contract, including the right to assess liquidated damages as may be appropriate for failure to complete the project in accordance with the terms and conditions contained therein.

OCR 2- DESIGNATION OF GOVERNMENT INSPECTOR

The Base Civil Engineer or his authorized representative is designated as the representative of the contracting officer for the purpose of technical surveillance of workmanship and inspection of materials for work being performed under this contract. This designation in no way authorizes anyone other than the contracting officer to commit the Government to changes in the terms of the contract.

OCR 3- ISSUANCE OF NOTICE TO PROCEED

The United States Government will issue Notice to Proceed within 30 calendar days after contract award. A Notice to Proceed will be issued with each individual Task Order. For work not related to task orders, the contractor may start work upon the award of the contract.

OCR 5- U.S. DOLLAR VERSUS YEN EQUIVALENT

For the duration of this solicitation the contractor shall use the FY22 exchange rate of USD $1.00 = JPY 127.7677 in determining the Yen equivalent to referenced US dollar amounts in this solicitation provisions/contract clauses and evaluation of the award. All referenced US dollar amounts in this solicitation provisions/contract clauses are modified to include "or Yen equivalent". Yen rate will be established per delivery order or task order.

OCR 6- REQUIRED INSURANCE (IN ADDITION TO THAT REQUIRED BY JAPANESE LAW)

a. The contractor shall procure and maintain during the entire period of his performance under this contract the following minimum insurance on each vehicle used by the contractor at the work site.

Type: Automobile Property Damage and Bodily Injuries

Amount: JPY 3,000,000 for automobile property damage JPY 30,000,000 for bodily injuries

b. Prior to the commencement of work hereunder, the contractor shall furnish to the contracting officer a certificate or written statement of the above required insurance. The policies evidencing required insurance shall contain an endorsement to the effect that cancellation or any material change in the policies adversely affecting the interests of the US Government in such insurance shall not be effective for such period as may be prescribed by the laws of the country of Japan in which this contract is to be performed and in no event less than thirty (30) days after written notice thereof to the contracting officer.

c. The contractor agrees to insert the substance of this clause, including this paragraph (c) in all subcontracts hereunder.

OCR 7- CONCILIATION

Except as otherwise provided in this contract, any disagreement arising under this contract which is not resolved by the parties to this contract may be submitted to the United States - Japan Joint Committee for Conciliation in accordance with Paragraph 10, Article XVIII, of the Status of Forces Agreement under Article VI of this Treaty of Mutual Cooperation and Security between Japan and the United States of America. Requests by the contractor for conciliation shall be made in accordance with the following procedures:

a. In the event the contractor desires conciliation after the decision of the contracting officer has been served upon him, he will first file his appeal from such findings of facts with the appropriate authority in accordance with the clause of this contract entitled "DISPUTES", and within the time limits described therein before filing request for conciliation with the Joint Committee and then request the appellate authority under the clause of this contract entitled "DISPUTES", to suspend its action on his appeal until such time as the Joint Committee has had an opportunity for effecting conciliation.

b. The request for conciliation will be submitted by the contractor through the nearest Defense Facilities Administration Bureau, to the Contract Conciliation Panel of the Joint Committee. Upon the filing of the request with the Joint Committee, the contractor will immediately notify the contracting officer in writing that the request for conciliation has been filed.

c. In the event the disagreement submitted to the Joint Committee under subparagraph (b) above has been resolved through conciliation, it will be the responsibility of the contractor to notify the appellate authority designated in the clause of this contract entitled "DISPUTES", of the settlement of the dispute and to withdraw his appeal.

d. In the event the contractor who has submitted a request for conciliation to the Joint Committee under subparagraph (b) above desires;

notwithstanding tendency of his request for conciliation, that action by the appropriate authority under the clause of this contract entitled "DISPUTES" be resumed on his appeal, it is his responsibility to so request the said authority in writing. The Joint Committee shall be immediately informed by the contractor of his action taken hereunder.

e. No request for conciliation can be submitted to the Joint Committee in the case of a dispute upon which the final decision of the appropriate authority under the clause of this contract entitled "DISPUTES" has been rendered. Pending the hearing of Conciliation Panel the contractor shall proceed diligently with the performance of the contract in accordance with the contracting officer's decision. The provisions of this clause shall not prejudice any right which the parties to the contract may have to file in a civil suit.

OCR 8- PERFORMANCE BOND

A performance bond in the penal amount of one hundred percent (100%) for each task order of $150,000 or greater (or Yen equivalent) price shall be submitted within 15 calendar days after the delivery order is issued or prior to the receipt of the notice to proceed whichever comes first.

OCR 9- BASE DEFENSE ACT/WORKMAN'S COMPENSATION/WORK ON AN OVERSEAS INSTALLATION

This contract includes FAR 52.228-3, Workers' Compensation Insurance (Defense Base Act) (Jul 2014), and FAR 52.228-4, Worker's Compensation and War-Hazard Insurance Overseas (Apr 1984). FAR 52.228-3 applies only if the contractor has United States' citizen or national employees, regardless of whether they have SOFA status or a status of residence in Japan. FAR 52.228-4 applies if the contractor has non-United States' citizen or national employees. One or both clauses may apply to the contractor.

OCR 10- EXEMPTION FROM JAPANESE CUSTOMS DUTIES AND TAXES PURSUANT TO STATUS OF FORCES AGREEMENT

(a) Paragraph 2, Article XI of the Status of Forces Agreement between Japan and the United States, authorizes the United States entry into Japan free from Japanese customs duties and all other charges on materials, supplies, and equipment imported for the official use of the United States Armed Forces or for the exclusive use of such forces or ultimately to be incorporated into articles or facilities used by such forces.

(b) Paragraph 3, Article XII of said Status of Forces Agreement, authorizes the United States exemption from certain Japanese taxes for materials, supplies, equipment and services procured for official purpose in Japan by the United States Armed Forces or by authorized agencies of the United States Armed Forces. Currently, these taxes are: (1) Gasoline tax and local road tax on gasoline; (2) Diesel oil tax; (3) Liquefied petroleum tax, and

(4) Consumption tax.

(c) If you are the successful offeror, the contracting officer or his authorized representative will issue customs or tax exemption certificate in accordance with procedures agreed upon between the Government of Japan and the United States of America. Tax exemption certificates for either at the end of each month or upon termination of the contract. These can be applied against future purchases of motor fuel. They will be issued only to you as the prime contractor, so, if you employ a subcontractor or supplier who uses motor fuel, you must purchase the motor fuel to secure the exemption.

(d) List below the customs duties or taxes which have been excluded from your proposal as required by the taxes clause. Contractor must claim all customs and tax exemptions to which the US Government is entitled.

(1) Customs Duties Type of Commodity & Percentage of Tax

Amount of Duty or Tax Excluded in Yen

(2) Taxes

(a) Gasoline tax and local road tax on gasoline

(b) Diesel oil tax

(c) Liquefied petroleum tax

(d) Consumption tax

OCR 11- TAX EXEMPTION CERTIFICATE

The Contractor will submit requests for gasoline or diesel oil tax exemption certificates to the Contracting Officer. This request will show the actual amount of gasoline or diesel oil used exclusively for the performance of this contract, with documentary evidence and detailed item breakdown to certify the accurate consumption of gasoline or diesel oil, or other necessary information and data as may be required. The Contracting Officer will issue to the Contractor a Tax Exemption Certificate for the actual amount of gasoline or diesel oil used exclusively for the performance of this contract. The Contractor shall claim all tax and customs exemptions as listed in clause CONST-K-7250, entitled, "EXEMPTION FROM JAPANESE

CUSTOMS DUTIES AND TAXES PURSUANT TO STATUS OF FORCES AGREEMENT".

OCR 12- JAPANESE ROAD LAWS

The Contractor shall comply with Japanese Road Laws while on U.S. military installations to specifically include:

Article 43, The Road Law (Japan) (prohibitive acts relative to roads). No person shall commit the following described acts:

Damaging the road, causing roads to be littered with debris, polluting the roads with debris or fall out from motor vehicles or otherwise defacing roads unreasonably or without due cause.

Article 43-2 (Measures to be taken to prevent cargo or things loaded on motor vehicles from falling out) The agency managing a road may, when there is reasonable cause for him to feel that items or cargo being carried in or on a motor vehicle may fall out and damage, pollute, or otherwise deface the road in such manner as to hinder or obstruct the traffic, order the operator of the vehicle in question to take steps or measures necessary to prevent occurrence of such hindrance by stopping operation of the vehicle, correcting the method of loading or traveling, or operation of the vehicle.

OCR 14- MAGNITUDE OF CONSTRUCTION PROJECTS

The estimated magnitude of this contract ceiling is set $49,500,000.

OCR 15 - CONTRACT PERFORMANCE IN JAPAN

This project will be performed in its entirety in the country of Japan. The successful offeror must be licensed and registered to perform work in the country of Japan.

FAR Clauses Incorporated by Full Text

52.236-1 Performance of Work by the Contractor. Apr 1984

As prescribed in 36.501(b), insert the following clause: [Complete the clause by inserting the appropriate percentage consistent with the complexity and magnitude of the work and customary or necessary specialty subcontracting (see 36.501(a)).]

Performance of Work by the Contractor (Apr 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 25 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

Section I - Contract Clauses

FAR CLAUSES INCORPORATED BY REFERENCE

252.239-7098 Prohibition Against Using Fiscal Year 2021 Funds to Maintain or Establish a Computer Network Unless Designed to Block Access to Certain Websites (DEVIATION 2021-O0003) (APR 2021)

252.225-7974 Prohibition on Contracting with Persons that have Business Operations with the Maduro Regime (DEVIATION 2020-O0005) (FEB 2020)

252.225-7976 Contractor Personnel Performing in Japan (DEVIATION 2018-O0019) (AUG 2018)

FAR PROVISIONS AND CLAUSES INCORPORATED BY FULL TEXT

252.211-7002 Availability for Examination of Specifications, Standards, Plans, Drawings, Data Item Descriptions, and Other Pertinent Documents

(DEC 1991)

The specifications, standards, plans, drawings, data item descriptions, and other pertinent documents cited in this solicitation are not available for distribution but may be examined at the following location:

(INSERT ADDRESS(ES))

(End of provision)

52.204-27 Prohibition on a ByteDance Covered Application (Jun 2023)

(a) Definitions. As used in this clause--

Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

Information technology, as defined in 40 U.S.C. 11101(6)--

(1) Means any equipment or interconnected system or subsystem of equipment, used in the automatic , storage, analysis, evaluation, acquisition manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive

, if the equipment is used by the directly or is used by a contractor under a contract with the that requires the agency executive agency executive agency use--

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L. 117-328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, "No TikTok on Government Devices" Implementation Guidance, collectively prohibit the presence or use of a on covered application executive agency

, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using ainformation technology covered on any owned or managed by the Government, or on any used or provided by the application information technology information technology

Contractor under this contract, including equipment provided by the Contractor's employees; however, this prohibition does not apply if the provides written notification to the Contractor that an exception has been granted in accordance with OMB Memorandum M-23-Contracting Officer

13.

(c) Subcontracts. The Contractor insert the substance of this clause, including this paragraph (c), in all subcontracts, including subcontracts for shall the of or . acquisition commercial products commercial services

(End of clause)

52.236-1 Performance of Work by the Contractor (APR 1984)

As prescribed in 36.501(b), insert the following clause: [Complete the clause by inserting the appropriate percentage consistent with the complexity and magnitude of the work and customary or necessary specialty subcontracting (see 36.501(a)).]

Performance of Work by the Contractor (Apr 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least twenty-five percent (25%) of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

TAX RELIEF-BASIC (APR 2020)

(a) Prices set forth in this contract are exclusive of all taxes and duties from which the United States Government is exempt by virtue of tax agreements between the United States Government and the Contractor's government. The following taxes or duties have been excluded from the contract price:

NAME OF TAX: ____(Offeror insert) RATE (PERCENTAGE): ____(Offeror insert)

(b) Invoices submitted in accordance with the terms and conditions of this contract shall be exclusive of all taxes or duties for which relief is available. The Contractor's invoice shall list separately the gross price, amount of tax deducted, and net price charged.

(c) When items manufactured to United States Government specifications are being acquired, the Contractor shall identify the materials or components intended to be imported in order to ensure that relief from import duties is obtained. If the Contractor intends to use imported products from inventories on hand, the price of which includes a factor for import duties, the Contractor shall ensure the United States Government's exemption from these taxes. The Contractor may obtain a refund of the import duties from its government or request the duty-free import of an amount of supplies or components corresponding to that used from inventory for this contract.

(End of clause)

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.202-1 Definitions. Jun 2020 52.203-3 Gratuities. Apr 1984 52.203-5 Covenant Against Contingent Fees. May 2014 52.203-6 Restrictions on Subcontractor Sales to the Government. Jun 2020 52.203-7 Anti-Kickback Procedures. Jun 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. May 2014 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. May 2014 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. Jun 2020 52.203-13 Contractor Code of Business Ethics and Conduct. Nov 2021

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights.

Jun 2020

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper. May 2011 52.204-9 Personal Identity Verification of Contractor Personnel. Jan 2011 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. Jun 2020 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

Nov 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment.

Nov 2021

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. Oct 2018 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.210-1 Market Research. Nov 2021 52.215-8 Order of Precedence-Uniform Contract Format. Oct 1997 52.222-21 Prohibition of Segregated Facilities. Apr 2015 52.222-26 Equal Opportunity. Sep 2016 52.222-27 Affirmative Action Compliance Requirements for Construction. Apr 2015 52.222-50 Combating Trafficking in Persons. Nov 2021 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. Jun 2020 52.225-13 Restrictions on Certain Foreign Purchases. Feb 2021 52.225-14 Inconsistency between English Version and Translation of Contract. Feb 2000 52.228-2 Additional Bond Security. Oct 1997 52.228-11 Individual Surety-Pledge of Assets. Feb 2021 52.228-14 Irrevocable Letter of Credit. Nov 2014 52.229-6 Taxes-Foreign Fixed-Price Contracts. Feb 2013 52.229-12 Tax on Certain Foreign Procurements. Feb 2021 52.232-17 Interest. May 2014 52.232-29 Terms for Financing of Purchases of Commercial Items. Feb 2002 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. Oct 2018

52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Nov 2021 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.233-4 Applicable Law for Breach of Contract Claim. Oct 2004 52.236-2 Differing Site Conditions. Apr 1984 52.236-3 Site Investigation and Conditions Affecting the Work. Apr 1984 52.236-5 Material and Workmanship. Apr 1984 52.236-6 Superintendence by the Contractor. Apr 1984 52.236-7 Permits and Responsibilities. Nov 1991 52.236-8 Other Contracts. Apr 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

Apr 1984

52.236-10 Operations and Storage Areas. Apr 1984 52.236-11 Use and Possession Prior to Completion. Apr 1984 52.236-12 Cleaning Up. Apr 1984 52.236-13 Accident Prevention. Nov 1991 52.236-15 Schedules for Construction Contracts. Apr 1984 52.236-21 Specifications and Drawings for Construction. Feb 1997 52.242-13 Bankruptcy. Jul 1995 52.242-14 Suspension of Work. Apr 1984 52.243-4 Changes. Jun 2007 52.244-6 Subcontracts for Commercial Items. Jul 2021 52.249-2 Termination for Convenience of the Government (Fixed-Price). Apr 2012 52.249-2 Alternate I Termination for Convenience of the Government (Fixed-Price). - (Alternate I) Sep 1996 52.249-10 Default (Fixed-Price Construction). Apr 1984

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies.

Dec 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Sep 2013 252.203-7003 Agency Office of the Inspector General. Aug 2019 252.204-7003 Control of Government Personnel Work Product. Apr 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. Dec 2019 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. May 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2021

252.205-7000 Provision of Information to Cooperative Agreement Holders. Dec 1991

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

May 2019

252.222-7002 Compliance with Local Labor Laws (Overseas). Jun 1997 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements. Dec 2010 252.223-7008 Prohibition of Hexavalent Chromium. Jun 2013 252.225-7041 Correspondence in English. Jun 1997 252.225-7043 Antiterrorism/Force Protection for Defense Contractors Outside the United States. Jun 2015 252.225-7048 Export-Controlled Items. Jun 2013

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns.

Apr 2019

252.232-7010 Levies on Contract Payments. Dec 2006

252.232-7017 Accelerating Payments to Small Business Subcontractors-Prohibition on Fees and Consideration.

Apr 2020

252.233-7001 Choice of Law (Overseas). Jun 1997 252.236-7005 Airfield Safety Precautions. Dec 1991 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.243-7002 Requests for Equitable Adjustment. Dec 2012 252.244-7000 Subcontracts for Commercial Items. Jan 2021 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military Operations. Oct 2010

FAR Clauses Incorporated by Full Text

52.211-10 Commencement, Prosecution, and Completion of Work. Apr 1984

As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 30 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the completion date in the task order. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 Liquidated Damages-Construction. Sep 2000

As prescribed in 11.503(b), insert the following clause in solicitations and contracts:

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of "to be determined within each task order" for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

As prescribed in 11.503(b), insert the following clause in solicitations and contracts: Liquidated Damages- Construction (Sept 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of "to be determined within each task order" for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause)

52.216-18 Ordering. Aug 2020

As prescribed in 16.506(a), insert the following clause:

Ordering (Aug 2020)

(a) Any supplies and services to be furnished under this contract shall be ordered by issuance of delivery orders or task orders by the individuals or activities designated in the Schedule. Such orders may be issued from 1 Oct 2023 through 30 Sep 2028.

(b) All delivery orders or task orders are subject to the terms and conditions of this contract. In the event of conflict between a delivery order or task order and this contract, the contract shall control.

(c) A delivery order or task order is considered "issued" when-

(1) If sent by mail (includes transmittal by U.S. mail or private delivery service), the Government deposits the order in the mail;

(2) If sent by fax, the Government transmits the order to the Contractor's fax number; or

(3) If sent electronically, the Government either-

(i) Posts a copy of the delivery order or task order to a Government document access system, and notice is sent to the Contractor; or

(ii) Distributes the delivery order or task order via email to the Contractor's email address.

(d) Orders may be issued by methods other than those enumerated in this clause only if authorized in the contract.

(End of clause)

52.216-19 Order Limitations. Oct 1995

As prescribed in 16.506(b), insert a clause substantially the same as follows:

Order Limitations (Oct 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than $ 2,000 or JPY equivalent amount, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor-

(1) Any order for a single item in excess of $1,000,000 or JPY equivalent amount;

(2) Any order for a combination of items in excess of $1,000,000 or JPY equivalent amount ; or

(3) A series of orders from the same ordering office within 7 days that together call for quantities exceeding the limitation in paragraph (b)(1) or (2) of this section.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) of this section.

(d) Notwithstanding paragraphs (b) and (c) of this section, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 5 days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons. Upon receiving this notice, the Government may acquire the supplies or services from another source.

(End of clause)

52.216-22 Indefinite Quantity. Oct 1995

As prescribed in 16.506(e), insert the following clause:

Indefinite Quantity (Oct 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum." The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum."

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after the task order completion date.

(End of clause)

52.217-9 Option to Extend the Term of the Contract. Mar 2000

As prescribed in 17.208(g), insert a clause substantially the same as the following:

Option to Extend the Term of the Contract (Mar 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 30 days before the contract expires; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 days before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 60 months. .

(End of clause)

52.232-5 Payments under Fixed-Price Construction Contracts. May 2014

As prescribed in , insert the following clause:32.111(a)(5)

Payments under Fixed-Price Construction Contracts (May 2014)

. The Government shall pay the Contractor the contract price as provided in this contract.(a) Payment of price

. The Government shall make progress payments monthly as the work proceeds, or at more frequent intervals as…