Airfield_paving_FA4659-17-R-0008.pdf

Repair Airf ield Pavements Basic Contract

Period of perfromance for this contract w ill be one (1) base year and four (4) option years. Winter exclusion shall be from 1 November through 15 April each year.

Type of Contract: Firm-Fixed Price, Requirements-Type. The quantities on the price schedule reflect the government's best estimate, but are not representaions of the quantities that w ill be required or ordered.

The Notice to Proceed for each task order w ill be issued at the time designated in each task order.

Contractors shall be registered in the System for Aw ard Mangagement (SAM) to be eligble to receive an aw ard under this solicitation.

This acqusitition is being set aside for 100% Total Small Business under NAICS code 237310, Highw ay, Street and Bridge Construction w ith a small business size standard of $36.5M.

Miinimum task order amount w ill be $25,000.00 and maximum task order amount w ill be $4,500,000.00 per clause 52.216-19, Ordering Limitations.

In accordance w ith DFAR 236.204(ii), Disclosure of Magnitude of Construction Projects, the magnitude of for this contract is betw een $25,000.000 and $100,000,000

DARRELL SCOTT HAAS 701-747-5285

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

06-Mar-2018

(RFP)

(IFB)

X

CALL:

Airf ield Paving & Repair

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________ calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________2 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________06 Apr 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

319 CONTRACTING FLIGHT

575 TUSKEGEE AIRMEN BLVD

GRAND FORKS AFB ND 58205 6436

FA4659

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

01:00 PM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

JFSD 201636

8. ADDRESS OFFER TO (If Other Than Item 7)

(701) 747-4215FAX:TEL: (701) 747-5287 TEL: FAX:

FA465917R0008 89

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA465917R0008

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES ESTIMATED

QUANTITY

UNIT UNIT PRICE ESTIMATED AMOUNT

0001 6 Each Mobilization

FFP

Mobilization- Line item includes all mobilization costs. Ref Specs Section 01000 paragraph 2.1 – 2.6 FOB: Destination

ESTIMATED

NET AMT

UNIT UNIT PRICE ESTIMATED AMOUNT

0002 30,000 Square Foot

Painting, Reflective- Type 1

FFP

Painting, Reflective- Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and layout using Type 1 Glass Beads. Ref Specs Sections: 32 17 23.00 20

UNIT UNIT PRICE ESTIMATED AMOUNT

0003 30,000 Square

Painting, Reflective - Type 3

Painting, Reflective - Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and layout using Type 3 Glass Beads. Ref Specs Sections: 32 17 23.00 20

UNIT UNIT PRICE ESTIMATED AMOUNT

0004 40,000 Square

Painting, Non-Reflective

Painting, Non-Reflective - Line item includes costs and work associated with non-reflective painting, to include but not limited to surface preparation, painting, masking and layout. Ref Specs Sections: 32 17 23.00 20

UNIT UNIT PRICE ESTIMATED AMOUNT

0005 10 Each Restricted Area Warning Pavement Marking

FFP

Restricted Area Warning Pavement Marking- Line item includes costs and work associated with restricted area warning pavement markings, to include but not limited to surface preparation, painting, masking and layout. Ref Specs Section 01000 paragraph 2.2

UNIT UNIT PRICE ESTIMATED AMOUNT

0006 20,000 Linear

Clean and Reseal Existing Joints

Clean and Reseal Existing Joints - Line item includes all costs associated with cleaning and resealing of concrete pavement, to include but not limited to the removal and disposal of old joint sealant and backer rod, sandblasting and cleaning of joint, placing new backer rod and joint sealant. All work shall be performed in manner consistent with UFC 3-270-04 Concrete Repair. Joint Sealant shall be Dow 890sl or approved alternative. Ref Specs Section: 32 01 19

UNIT UNIT PRICE ESTIMATED AMOUNT

0007 30,000 Linear

Route and Seal Random Cracks

Route and Seal Random Cracks - Line item includes all costs associated with routing and sealing random cracks, to include but not limited to routing or saw cutting, sandblasting, vacuuming, installation of backer rod and application of appropriate sealant for concrete or asphalt pavement. All work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall Repair and UFC 3-270-02 Asphalt Crack Repair. Concrete sealant shall be Dow 890sl or approved alternative. Asphalt sealant shall be Crafco Roadsaver 231 or approved alternative. Ref Specs Sections: 32 01 19 & 32 01 19.61

UNIT UNIT PRICE ESTIMATED AMOUNT

0008 2,000 Short Ton Bituminous Asphalt

FFP

Bituminous Asphalt - Line item includes all costs associated with the removal and replacement of asphalt pavement, to include but not limited to saw cutting pavement, loading and disposal of debris, re-compaction of disturbed sub-base, asphalt paving, tack coat, prime coat, and delivery of asphalt, compaction of asphalt and surveying/ grade control. All work shall be performed in a manner consistent with UFC 3-250-03 Standard Practice Manual for Flexible Pavements.

The work must be performed in a manner that will not damage existing pavements.

Any damage to existing pavements shall be repaired at contractor’s expense. A job mix formula shall be submitted for approval prior to commencement of work. Ref Specs Section: 32 12 15.13

UNIT UNIT PRICE ESTIMATED AMOUNT

0009 10,000 Square

Spalled Joint Repair, Partial Depth

Spalled Joint Repair, Partial Depth (Up to 5,000 SF) - Line item includes all cost associated with the repair of concrete spalls, to include but not limited to identification of spall limits, removal of spalled concrete, placement of new concrete, reestablishing proper joints at spall. The work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall Repair. Ref Specs Section: 32 01 29.62

UNIT UNIT PRICE ESTIMATED AMOUNT

0010 7,500 Cubic Yard

Random Slab Replacement

Random Slab Replacement (Removal and Replacement) - Line item includes all costs associated with the full slab replacement to include but not limited to saw cutting, removal of concrete, addition or re-compaction of disturbed base course, concrete, dowel bars, saw cutting joints resealing of new joints and surveying/grade control. The work shall be performed in a manner consistent with UFC 3-270-04 Concrete Repair. The work shall be performed in a manner which does not damage pavement to remain in place; any damage shall be repaired at contractor’s expense. Ref Specs ections: 32 11 16.16 & 32 13 11

UNIT UNIT PRICE ESTIMATED AMOUNT

0011 8 Lot Construction Limits Signs and Barricades

FFP

Construction Limits Signs and Barricades - Line item includes costs and work associated with construction limit sign and barricades, to include but not limited to all coordination, planning, preparation, materials, labor, and equipment required to implement and maintain the approved signage and barricades. Ref Specs Section:

01000 paragraph 7.3.5

UNIT UNIT PRICE ESTIMATED AMOUNT

0012 50 Quarter Hours

Security Delays

Security Delays - Line item includes costs and work associated with security delays, to include above normal or routine delay costs associated with employees, equipment or materials obtaining access to the work locations that are outside the contractor’s control. Security delays may be paid when the government-caused delays are in excess of 30 minutes. Ref Specs Section 01000 paragraph 16.2.1, 16.2.3 and 16.2.7

UNIT UNIT PRICE ESTIMATED AMOUNT

1001 6 Each OPTION Mobilization

FFP

Mobilization- Line item includes all mobilization costs. Ref Specs Section 01000

UNIT UNIT PRICE ESTIMATED AMOUNT

1002 30,000 Square

OPTION Painting, Reflective- Type 1

Painting, Reflective- Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

1003 30,000 Square

OPTION Painting, Reflective - Type 3

Painting, Reflective - Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

1004 40,000 Square

OPTION Painting, Non-Reflective

Painting, Non-Reflective - Line item includes costs and work associated with non-reflective painting, to include but not limited to surface preparation, painting, UNIT UNIT PRICE ESTIMATED AMOUNT

1005 10 Each OPTION Restricted Area Warning Pavement Marking

FFP

Restricted Area Warning Pavement Marking- Line item includes costs and work associated with restricted area warning pavement markings, to include but not limited to surface preparation, painting, masking and layout. Ref Specs Section

UNIT UNIT PRICE ESTIMATED AMOUNT

1006 20,000 Linear

OPTION Clean and Reseal Existing Joints

Clean and Reseal Existing Joints - Line item includes all costs associated with cleaning and resealing of concrete pavement, to include but not limited to the removal and disposal of old joint sealant and backer rod, sandblasting and cleaning of joint, placing new backer rod and joint sealant. All work shall be performed in manner consistent with UFC 3-270-04 Concrete Repair. Joint Sealant shall be Dow

UNIT UNIT PRICE ESTIMATED AMOUNT

1007 30,000 Linear

OPTION Route and Seal Random Cracks

Route and Seal Random Cracks - Line item includes all costs associated with routing and sealing random cracks, to include but not limited to routing or saw cutting, sandblasting, vacuuming, installation of backer rod and application of appropriate sealant for concrete or asphalt pavement. All work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall Repair and UFC 3-270-02 Asphalt Crack Repair. Concrete sealant shall be Dow 890sl or approved alternative. Asphalt sealant shall be Crafco Roadsaver 231 or

UNIT UNIT PRICE ESTIMATED AMOUNT

1008 2,000 Short Ton OPTION Bituminous Asphalt

FFP

Bituminous Asphalt - Line item includes all costs associated with the removal and replacement of asphalt pavement, to include but not limited to saw cutting pavement, loading and disposal of debris, re-compaction of disturbed sub-base, asphalt paving, tack coat, prime coat, and delivery of asphalt, compaction of asphalt and surveying/ grade control. All work shall be performed in a manner consistent with UFC 3-250-03 Standard Practice Manual for Flexible Pavements.

The work must be performed in a manner that will not damage existing pavements.

Any damage to existing pavements shall be repaired at contractor’s expense. A job mix formula shall be submitted for approval prior to commencement of work. Ref

UNIT UNIT PRICE ESTIMATED AMOUNT

1009 10,000 Square

OPTION Spalled Joint Repair, Partial Depth

Spalled Joint Repair, Partial Depth (Up to 5,000 SF) - Line item includes all cost associated with the repair of concrete spalls, to include but not limited to identification of spall limits, removal of spalled concrete, placement of new concrete, reestablishing proper joints at spall. The work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall

UNIT UNIT PRICE ESTIMATED AMOUNT

1010 7,500 Cubic

OPTION Random Slab Replacement

Random Slab Replacement (Removal and Replacement) - Line item includes all costs associated with the full slab replacement to include but not limited to saw cutting, removal of concrete, addition or re-compaction of disturbed base course, concrete, dowel bars, saw cutting joints resealing of new joints and surveying/grade control. The work shall be performed in a manner consistent with UFC 3-270-04 Concrete Repair. The work shall be performed in a manner which does not damage pavement to remain in place; any damage shall be repaired at

UNIT UNIT PRICE ESTIMATED AMOUNT

1011 8 Lot OPTION Construction Limits Signs and Barricades

FFP

Construction Limits Signs and Barricades - Line item includes costs and work associated with construction limit sign and barricades, to include but not limited to all coordination, planning, preparation, materials, labor, and equipment required to implement and maintain the approved signage and barricades. Ref Specs Section:

UNIT UNIT PRICE ESTIMATED AMOUNT

1012 50 Quarter

OPTION Security Delays

Security Delays - Line item includes costs and work associated with security delays, to include above normal or routine delay costs associated with employees, equipment or materials obtaining access to the work locations that are outside the contractor’s control. Security delays may be paid when the government-caused delays are in excess of 30 minutes. Ref Specs Section 01000

UNIT UNIT PRICE ESTIMATED AMOUNT

2001 6 Each OPTION Mobilization

FFP

Mobilization- Line item includes all mobilization costs. Ref Specs Section 01000

UNIT UNIT PRICE ESTIMATED AMOUNT

2002 30,000 Square

Painting, Reflective- Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

2003 30,000 Square

Painting, Reflective - Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

2004 40,000 Square

Painting, Non-Reflective - Line item includes costs and work associated with non-reflective painting, to include but not limited to surface preparation, painting, UNIT UNIT PRICE ESTIMATED AMOUNT

2005 10 Each OPTION Restricted Area Warning Pavement Marking

FFP

Restricted Area Warning Pavement Marking- Line item includes costs and work associated with restricted area warning pavement markings, to include but not limited to surface preparation, painting, masking and layout. Ref Specs Section

UNIT UNIT PRICE ESTIMATED AMOUNT

2006 20,000 Linear

Clean and Reseal Existing Joints - Line item includes all costs associated with cleaning and resealing of concrete pavement, to include but not limited to the removal and disposal of old joint sealant and backer rod, sandblasting and cleaning of joint, placing new backer rod and joint sealant. All work shall be performed in manner consistent with UFC 3-270-04 Concrete Repair. Joint Sealant shall be Dow

UNIT UNIT PRICE ESTIMATED AMOUNT

2007 30,000 Linear

Route and Seal Random Cracks - Line item includes all costs associated with routing and sealing random cracks, to include but not limited to routing or saw cutting, sandblasting, vacuuming, installation of backer rod and application of appropriate sealant for concrete or asphalt pavement. All work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall Repair and UFC 3-270-02 Asphalt Crack Repair. Concrete sealant shall be Dow 890sl or approved alternative. Asphalt sealant shall be Crafco Roadsaver 231 or

UNIT UNIT PRICE ESTIMATED AMOUNT

2008 2,000 Short Ton OPTION Bituminous Asphalt

FFP

Bituminous Asphalt - Line item includes all costs associated with the removal and replacement of asphalt pavement, to include but not limited to saw cutting pavement, loading and disposal of debris, re-compaction of disturbed sub-base, asphalt paving, tack coat, prime coat, and delivery of asphalt, compaction of asphalt and surveying/ grade control. All work shall be performed in a manner consistent with UFC 3-250-03 Standard Practice Manual for Flexible Pavements.

The work must be performed in a manner that will not damage existing pavements.

Any damage to existing pavements shall be repaired at contractor’s expense. A job mix formula shall be submitted for approval prior to commencement of work. Ref

UNIT UNIT PRICE ESTIMATED AMOUNT

2009 10,000 Square

Spalled Joint Repair, Partial Depth (Up to 5,000 SF) - Line item includes all cost associated with the repair of concrete spalls, to include but not limited to identification of spall limits, removal of spalled concrete, placement of new concrete, reestablishing proper joints at spall. The work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall

UNIT UNIT PRICE ESTIMATED AMOUNT

2010 7,500 Cubic

Random Slab Replacement (Removal and Replacement) - Line item includes all costs associated with the full slab replacement to include but not limited to saw cutting, removal of concrete, addition or re-compaction of disturbed base course, concrete, dowel bars, saw cutting joints resealing of new joints and surveying/grade control. The work shall be performed in a manner consistent with UFC 3-270-04 Concrete Repair. The work shall be performed in a manner which does not damage pavement to remain in place; any damage shall be repaired at

UNIT UNIT PRICE ESTIMATED AMOUNT

2011 8 Lot OPTION Construction Limits Signs and Barricades

FFP

Construction Limits Signs and Barricades - Line item includes costs and work associated with construction limit sign and barricades, to include but not limited to all coordination, planning, preparation, materials, labor, and equipment required to implement and maintain the approved signage and barricades. Ref Specs Section:

UNIT UNIT PRICE ESTIMATED AMOUNT

2012 50 Quarter

Security Delays - Line item includes costs and work associated with security delays, to include above normal or routine delay costs associated with employees, equipment or materials obtaining access to the work locations that are outside the contractor’s control. Security delays may be paid when the government-caused delays are in excess of 30 minutes. Ref Specs Section 01000

UNIT UNIT PRICE ESTIMATED AMOUNT

3001 6 Each OPTION Mobilization

FFP

Mobilization- Line item includes all mobilization costs. Ref Specs Section 01000

UNIT UNIT PRICE ESTIMATED AMOUNT

3002 30,000 Square

Painting, Reflective- Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

3003 30,000 Square

Painting, Reflective - Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

3004 40,000 Square

Painting, Non-Reflective - Line item includes costs and work associated with non-reflective painting, to include but not limited to surface preparation, painting, UNIT UNIT PRICE ESTIMATED AMOUNT

3005 10 Each OPTION Restricted Area Warning Pavement Marking

FFP

Restricted Area Warning Pavement Marking- Line item includes costs and work associated with restricted area warning pavement markings, to include but not limited to surface preparation, painting, masking and layout. Ref Specs Section

UNIT UNIT PRICE ESTIMATED AMOUNT

3006 20,000 Linear

Clean and Reseal Existing Joints - Line item includes all costs associated with cleaning and resealing of concrete pavement, to include but not limited to the removal and disposal of old joint sealant and backer rod, sandblasting and cleaning of joint, placing new backer rod and joint sealant. All work shall be performed in manner consistent with UFC 3-270-04 Concrete Repair. Joint Sealant shall be Dow

UNIT UNIT PRICE ESTIMATED AMOUNT

3007 30,000 Linear

Route and Seal Random Cracks - Line item includes all costs associated with routing and sealing random cracks, to include but not limited to routing or saw cutting, sandblasting, vacuuming, installation of backer rod and application of appropriate sealant for concrete or asphalt pavement. All work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall Repair and UFC 3-270-02 Asphalt Crack Repair. Concrete sealant shall be Dow 890sl or approved alternative. Asphalt sealant shall be Crafco Roadsaver 231 or

UNIT UNIT PRICE ESTIMATED AMOUNT

3008 2,000 Short Ton OPTION Bituminous Asphalt

FFP

Bituminous Asphalt - Line item includes all costs associated with the removal and replacement of asphalt pavement, to include but not limited to saw cutting pavement, loading and disposal of debris, re-compaction of disturbed sub-base, asphalt paving, tack coat, prime coat, and delivery of asphalt, compaction of asphalt and surveying/ grade control. All work shall be performed in a manner consistent with UFC 3-250-03 Standard Practice Manual for Flexible Pavements.

The work must be performed in a manner that will not damage existing pavements.

Any damage to existing pavements shall be repaired at contractor’s expense. A job mix formula shall be submitted for approval prior to commencement of work. Ref

UNIT UNIT PRICE ESTIMATED AMOUNT

3009 10,000 Square

Spalled Joint Repair, Partial Depth (Up to 5,000 SF) - Line item includes all cost associated with the repair of concrete spalls, to include but not limited to identification of spall limits, removal of spalled concrete, placement of new concrete, reestablishing proper joints at spall. The work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall

UNIT UNIT PRICE ESTIMATED AMOUNT

3010 7,500 Cubic

Random Slab Replacement (Removal and Replacement) - Line item includes all costs associated with the full slab replacement to include but not limited to saw cutting, removal of concrete, addition or re-compaction of disturbed base course, concrete, dowel bars, saw cutting joints resealing of new joints and surveying/grade control. The work shall be performed in a manner consistent with UFC 3-270-04 Concrete Repair. The work shall be performed in a manner which does not damage pavement to remain in place; any damage shall be repaired at

UNIT UNIT PRICE ESTIMATED AMOUNT

3011 8 Lot OPTION Construction Limits Signs and Barricades

FFP

Construction Limits Signs and Barricades - Line item includes costs and work associated with construction limit sign and barricades, to include but not limited to all coordination, planning, preparation, materials, labor, and equipment required to implement and maintain the approved signage and barricades. Ref Specs Section:

UNIT UNIT PRICE ESTIMATED AMOUNT

3012 50 Quarter

Security Delays - Line item includes costs and work associated with security delays, to include above normal or routine delay costs associated with employees, equipment or materials obtaining access to the work locations that are outside the contractor’s control. Security delays may be paid when the government-caused delays are in excess of 30 minutes. Ref Specs Section 01000

UNIT UNIT PRICE ESTIMATED AMOUNT

4001 6 Each OPTION Mobilization

FFP

Mobilization- Line item includes all mobilization costs. Ref Specs Section 01000

UNIT UNIT PRICE ESTIMATED AMOUNT

4002 30,000 Square

Painting, Reflective- Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

4003 30,000 Square

Painting, Reflective - Line item includes costs and work associated with reflective painting, to include but not limited to surface preparation, painting, masking and

UNIT UNIT PRICE ESTIMATED AMOUNT

4004 40,000 Square

Painting, Non-Reflective - Line item includes costs and work associated with non-reflective painting, to include but not limited to surface preparation, painting, UNIT UNIT PRICE ESTIMATED AMOUNT

4005 10 Each OPTION Restricted Area Warning Pavement Marking

FFP

Restricted Area Warning Pavement Marking- Line item includes costs and work associated with restricted area warning pavement markings, to include but not limited to surface preparation, painting, masking and layout. Ref Specs Section

UNIT UNIT PRICE ESTIMATED AMOUNT

4006 20,000 Linear

Clean and Reseal Existing Joints - Line item includes all costs associated with cleaning and resealing of concrete pavement, to include but not limited to the removal and disposal of old joint sealant and backer rod, sandblasting and cleaning of joint, placing new backer rod and joint sealant. All work shall be performed in manner consistent with UFC 3-270-04 Concrete Repair. Joint Sealant shall be Dow

UNIT UNIT PRICE ESTIMATED AMOUNT

4007 30,000 Linear

Route and Seal Random Cracks - Line item includes all costs associated with routing and sealing random cracks, to include but not limited to routing or saw cutting, sandblasting, vacuuming, installation of backer rod and application of appropriate sealant for concrete or asphalt pavement. All work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall Repair and UFC 3-270-02 Asphalt Crack Repair. Concrete sealant shall be Dow 890sl or approved alternative. Asphalt sealant shall be Crafco Roadsaver 231 or

UNIT UNIT PRICE ESTIMATED AMOUNT

4008 2,000 Short Ton OPTION Bituminous Asphalt

FFP

Bituminous Asphalt - Line item includes all costs associated with the removal and replacement of asphalt pavement, to include but not limited to saw cutting pavement, loading and disposal of debris, re-compaction of disturbed sub-base, asphalt paving, tack coat, prime coat, and delivery of asphalt, compaction of asphalt and surveying/ grade control. All work shall be performed in a manner consistent with UFC 3-250-03 Standard Practice Manual for Flexible Pavements.

The work must be performed in a manner that will not damage existing pavements.

Any damage to existing pavements shall be repaired at contractor’s expense. A job mix formula shall be submitted for approval prior to commencement of work. Ref

UNIT UNIT PRICE ESTIMATED AMOUNT

4009 10,000 Square

Spalled Joint Repair, Partial Depth (Up to 5,000 SF) - Line item includes all cost associated with the repair of concrete spalls, to include but not limited to identification of spall limits, removal of spalled concrete, placement of new concrete, reestablishing proper joints at spall. The work shall be performed in a manner consistent with UFC 3-270-03 Concrete Crack and Partial Depth Spall

UNIT UNIT PRICE ESTIMATED AMOUNT

4010 7,500 Cubic

Random Slab Replacement (Removal and Replacement) - Line item includes all costs associated with the full slab replacement to include but not limited to saw cutting, removal of concrete, addition or re-compaction of disturbed base course, concrete, dowel bars, saw cutting joints resealing of new joints and surveying/grade control. The work shall be performed in a manner consistent with UFC 3-270-04 Concrete Repair. The work shall be performed in a manner which does not damage pavement to remain in place; any damage shall be repaired at

UNIT UNIT PRICE ESTIMATED AMOUNT

4011 8 Lot OPTION Construction Limits Signs and Barricades

FFP

Construction Limits Signs and Barricades - Line item includes costs and work associated with construction limit sign and barricades, to include but not limited to all coordination, planning, preparation, materials, labor, and equipment required to implement and maintain the approved signage and barricades. Ref Specs Section:

UNIT UNIT PRICE ESTIMATED AMOUNT

4012 50 Quarter

Security Delays - Line item includes costs and work associated with security delays, to include above normal or routine delay costs associated with employees, equipment or materials obtaining access to the work locations that are outside the contractor’s control. Security delays may be paid when the government-caused delays are in excess of 30 minutes. Ref Specs Section 01000

DELIVERY/TASK ORDER MINIMUM/MAXIMUM QUANTITY AND ORDER VALUE

The minimum quantity and order value for each Delivery/Task Order issued shall not be less than the minimum quantity and order value stated in the following table. The maximum quantity and order value for each Delivery/Task Order issued shall not exceed the maximum quantity and order value stated in the following table.

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

AMOUNT

$25,000.00 $4,500,000.00

CLIN DELIVERY/TASK ORDER MINIMUM/MAXIMUM QUANTITY AND CLIN ORDER VALUE

The minimum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not be less than the minimum quantity and order value stated in the following table. The maximum quantity and order value for the given Delivery/Task Order issued for this CLIN shall not exceed the maximum quantity and order value stated in the following table.

CLIN

MINIMUM

QUANTITY

MINIMUM

AMOUNT

MAXIMUM

QUANTITY

MAXIMUM

AMOUNT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 Destination Government Destination Government 0007 Destination Government Destination Government 0008 Destination Government Destination Government 0009 Destination Government Destination Government 0010 Destination Government Destination Government 0011 Destination Government Destination Government 0012 Destination Government Destination Government 1001 Destination Government Destination Government 1002 Destination Government Destination Government 1003 Destination Government Destination Government 1004 Destination Government Destination Government 1005 Destination Government Destination Government 1006 Destination Government Destination Government 1007 Destination Government Destination Government 1008 Destination Government Destination Government 1009 Destination Government Destination Government 1010 Destination Government Destination Government 1011 Destination Government Destination Government 1012 Destination Government Destination Government 2001 Destination Government Destination Government 2002 Destination Government Destination Government 2003 Destination Government Destination Government 2004 Destination Government Destination Government 2005 Destination Government Destination Government 2006 Destination Government Destination Government 2007 Destination Government Destination Government 2008 Destination Government Destination Government 2009 Destination Government Destination Government 2010 Destination Government Destination Government 2011 Destination Government Destination Government 2012 Destination Government Destination Government 3001 Destination Government Destination Government 3002 Destination Government Destination Government 3003 Destination Government Destination Government 3004 Destination Government Destination Government 3005 Destination Government Destination Government 3006 Destination Government Destination Government 3007 Destination Government Destination Government 3008 Destination Government Destination Government

3009 Destination Government Destination Government 3010 Destination Government Destination Government 3011 Destination Government Destination Government 3012 Destination Government Destination Government 4001 Destination Government Destination Government 4002 Destination Government Destination Government 4003 Destination Government Destination Government 4004 Destination Government Destination Government 4005 Destination Government Destination Government 4006 Destination Government Destination Government 4007 Destination Government Destination Government 4008 Destination Government Destination Government 4009 Destination Government Destination Government 4010 Destination Government Destination Government 4011 Destination Government Destination Government 4012 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 1 yr. ADC 6 319 CES/CEC - F2A3E1

MIKE MOATS

575 TUSKEGEE AIRMEN BLVD, BLDG

410, RM 155A

GRAND FORKS AFB ND 58205-6219

7017474592

F2A3E1

0002 1 yr. ADC 30,000 (SAME AS PREVIOUS LOCATION)

0003 1 yr. ADC 30,000 (SAME AS PREVIOUS LOCATION)

0004 1 yr. ADC 40,000 (SAME AS PREVIOUS LOCATION)

0005 1 yr. ADC 10 (SAME AS PREVIOUS LOCATION)

0006 1 yr. ADC 20,000 (SAME AS PREVIOUS LOCATION)

0007 1 yr. ADC 30,000 (SAME AS PREVIOUS LOCATION)

0008 1 yr. ADC 2,000 (SAME AS PREVIOUS LOCATION)

0009 1 yr. ADC 10,000 (SAME AS PREVIOUS LOCATION)

0010 1 yr. ADC 7,500 (SAME AS PREVIOUS LOCATION)

0011 1 yr. ADC 8 (SAME AS PREVIOUS LOCATION)

0012 1 yr. ADC 50 (SAME AS PREVIOUS LOCATION)

1001 2 yrs. ADC 6 (SAME AS PREVIOUS LOCATION)

1002 2 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

1003 2 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

1004 2 yrs. ADC 40,000 (SAME AS PREVIOUS LOCATION)

1005 2 yrs. ADC 10 (SAME AS PREVIOUS LOCATION)

1006 2 yrs. ADC 20,000 (SAME AS PREVIOUS LOCATION)

1007 2 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

1008 2 yrs. ADC 2,000 (SAME AS PREVIOUS LOCATION)

1009 2 yrs. ADC 10,000 (SAME AS PREVIOUS LOCATION)

1010 2 yrs. ADC 7,500 (SAME AS PREVIOUS LOCATION)

1011 2 yrs. ADC 8 (SAME AS PREVIOUS LOCATION)

1012 2 yrs. ADC 50 (SAME AS PREVIOUS LOCATION)

2001 3 yrs. ADC 6 (SAME AS PREVIOUS LOCATION)

2002 3 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

2003 3 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

2004 3 yrs. ADC 40,000 (SAME AS PREVIOUS LOCATION)

2005 3 yrs. ADC 10 (SAME AS PREVIOUS LOCATION)

2006 3 yrs. ADC 20,000 (SAME AS PREVIOUS LOCATION)

2007 3 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

2008 3 yrs. ADC 2,000 (SAME AS PREVIOUS LOCATION)

2009 3 yrs. ADC 10,000 (SAME AS PREVIOUS LOCATION)

2010 3 yrs. ADC 7,500 (SAME AS PREVIOUS LOCATION)

2011 3 yrs. ADC 8 (SAME AS PREVIOUS LOCATION)

2012 3 yrs. ADC 50 (SAME AS PREVIOUS LOCATION)

3001 4 yrs. ADC 6 (SAME AS PREVIOUS LOCATION)

3002 4 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

3003 4 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

3004 4 yrs. ADC 40,000 (SAME AS PREVIOUS LOCATION)

3005 4 yrs. ADC 10 (SAME AS PREVIOUS LOCATION)

3006 4 yrs. ADC 20,000 (SAME AS PREVIOUS LOCATION)

3007 4 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

3008 4 yrs. ADC 2,000 (SAME AS PREVIOUS LOCATION)

3009 4 yrs. ADC 10,000 (SAME AS PREVIOUS LOCATION)

3010 4 yrs. ADC 7,500 (SAME AS PREVIOUS LOCATION)

3011 4 yrs. ADC 8 (SAME AS PREVIOUS LOCATION)

3012 4 yrs. ADC 50 (SAME AS PREVIOUS LOCATION)

4001 5 yrs. ADC 6 (SAME AS PREVIOUS LOCATION)

4002 5 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

4003 5 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

4004 5 yrs. ADC 40,000 (SAME AS PREVIOUS LOCATION)

4005 5 yrs. ADC 10 (SAME AS PREVIOUS LOCATION)

4006 5 yrs. ADC 20,000 (SAME AS PREVIOUS LOCATION)

4007 5 yrs. ADC 30,000 (SAME AS PREVIOUS LOCATION)

4008 5 yrs. ADC 2,000 (SAME AS PREVIOUS LOCATION)

4009 5 yrs. ADC 10,000 (SAME AS PREVIOUS LOCATION)

4010 5 yrs. ADC 7,500 (SAME AS PREVIOUS LOCATION)

4011 5 yrs. ADC 8 (SAME AS PREVIOUS LOCATION)

4012 5 yrs. ADC 50 (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.247-34 F.O.B. Destination NOV 1991

Section G - Contract Administration Data

ADMINISTRATIVE MATTERS

G-1 ADMINISTRATIVE MATTERS

The address and telephone number for the Acquisitions Flight:

319th Contracting Flight 295 Steen Blvd, Bld 242 Grand Forks, ND 58205 (701)747-5252

G-2 CONTRACTOR'S INFORMATION

To Be Completed by the Contractor:

Name and Title:__________________________________________________________ Doing Business As:________________________________________________________ Responsible Office: ______________________________________________________ Address: _______________________________________________________________ Telephone Number:_______________________________________________________ Email: __________________________________________________________________ Cage Code: ______________________________________________________________ DUNS Number: ___________________________________________________________ Tax Identification Number: ____________________________________________________

G-3 AUTHORIZED INDIVIDUALS

To be completed by the Contractor:

The below individuals are authorized to negotiate or discuss this proposal:

Name of Primary: _________________________ Title/Position:____________________________ Address: ________________________________ Telephone: ______________________________ Alternate Phone: __________________________ Email: ___________________________________

Name of alternate: ________________________ Title/Position:____________________________ Address: ________________________________ Telephone: ______________________________ Alternate Phone: __________________________ Email: ___________________________________

CLAUSES INCORPORATED BY FULL TEXT

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

CONSTRUCTION PROGRESS INVOICE

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

F2A3CC

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F87700 Issue By DoDAAC FA4659 Admin DoDAAC FA4659 Inspect By DoDAAC F2A3CC Ship To Code F2A3CC Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) N/A Service Acceptor (DoDAAC) F2A3CC Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

Darrell.Haas.2@us.af.mil Ellen.Reed@us.af.mil Jeffrey.Fuqua@us.af.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Voice: 1-888-3327411 Email: DFAS.INDIANAPOLIS-IN.JFL.MBX.AMPO-INQUIRIES@MAIL.MIL Fax: 317-257-0123

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause) mailto:Darrell.Haas.2@us.af.mil mailto:Ellen.Reed@us.af.mil mailto:Jeffrey.Fuqua@us.af.mil mailto:DFAS.INDIANAPOLIS-IN.JFL.MBX.AMPO-INQUIRIES@MAIL.MIL

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-2 Certificate Of Independent Price Determination APR 1985 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreeements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-2 Prohibition on Contracting with Inverted Domestic Corporations--Representation

NOV 2015

52.209-5 Certification Regarding Responsibility Matters OCT 2015 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-7 Information Regarding Responsibility Matters JUL 2013 52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research APR 2011 52.211-10 Commencement, Prosecution, and Completion of Work APR 1984 52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.215-2 Audit and Records--Negotiation OCT 2010 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.217-5 Evaluation Of Options JUL 1990 52.219-1 Small Business Program Representations OCT 2014 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting JAN 2017

52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-30 Construction Wage Rate Requirements--Price Adjustment (None or Separately Specified Method)

MAY 2014

52.222-34 Project Labor Agreement MAY 2010 52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-4 Recovered Material Certification MAY 2008 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.229-3 Federal, State And Local Taxes FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-16 Progress Payments APR 2012 52.232-17 Interest MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-25 Prompt Payment JAN 2017 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.