FA4600-17-R-0008_HEMP_Solicitation.pdf

SEE ADDENDUM

(No Collect Calls)

FA460017R0008 05-Feb-2018

b. TELEPHONE NUMBER

(402) 294-4097

8. OFFER DUE DATE/LOCAL TIME

02:00 PM 08 Mar 2018

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

FA46009. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

ANGELA LEROY

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

55 CONTRACTING SQ

101 WASHINGTON SQ BLDG 40

OFFUTT AFB NE 68113-2107

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

FAX:

TEL: 402-232-6356

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$15,000,000

NAICS:

541330

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF74

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

FA460017R0008

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 12 Months B1000 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B1000

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

FOB: Destination

SIGNAL CODE: A

NET AMT

0002 1 Project Future Repairs and Upgrades to B1000

FFP

This CLIN is reserved for repairs and future HEMP HM/HS upgrades for B1000 at a maximum amount of $50,000 to accomodate repairs and future upgrades IAW

PWS Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this CLIN.

0003 12 Months B523 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B523

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

0004 12 Months B597 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B597

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

0005 12 Months B598 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B598

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

0006 1 Project Future Repair/Upgrades to B523/B597/B598

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for

B523/B597/B598 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this

CLIN.

1001 12 Months OPTION B1000 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B1000

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

1002 1 Project OPTION Future Repairs and Upgrades to B1000

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for B1000 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS

Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the

Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this CLIN.

1003 12 Months OPTION B523 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B523

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

1004 12 Months OPTION B597 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B597

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

1005 12 Months OPTION B598 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B598

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

1006 1 Project OPTION Future Repair/Upgrades to B523/B597/B598

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for

B523/B597/B598 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this

CLIN.

2001 12 Months OPTION B1000 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B1000

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

2002 1 Project OPTION Future Repairs and Upgrades to B1000

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for B1000 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS

Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the

Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this CLIN.

2003 12 Months OPTION B523 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B523

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

2004 12 Months OPTION B597 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B597

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

2005 12 Months OPTION B598 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B598

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

2006 1 Project OPTION Future Repair/Upgrades to B523/B597/B598

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for

B523/B597/B598 at a maximum amount of $50,000 to accomodate upgrades IAW

PWS Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this CLIN.

3001 12 Months OPTION B1000 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B1000

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

3002 1 Project OPTION Future Repairs and Upgrades to B1000

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for B1000 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS

Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the

Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this CLIN.

3003 12 Months OPTION B523 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B523

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

3004 12 Months OPTION B597 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B597

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

3005 12 Months OPTION B598 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B598

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

3006 1 Project OPTION Future Repair/Upgrades to B523/B597/B598

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for

B523/B597/B598 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this

CLIN.

4001 12 Months OPTION B1000 Monthly HM/HS Services

FFP

onthly preventative maintenance and service calls for HM/HS services for B1000

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

4002 1 Project OPTION Future Repairs and Upgrades to B1000

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for B1000 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS

Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the

Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this CLIN.

4003 12 Months OPTION B523 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B523

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

4004 12 Months OPTION B597 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B597

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

4005 12 Months OPTION B598 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B598

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

4006 1 Project OPTION Future Repair/Upgrades to B523/B597/B598

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for

B523/B597/B598 at a maximum amount of $50,000 to accomodate repairs and upgrades IAW PWS Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this

CLIN.

5001 6 Months OPTION B1000 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B1000

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

5002 1 Project OPTION Future Repairs and Upgrades to B1000

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for B1000 at a maximum amount of $25,000 to accomodate repairs and upgrades IAW PWS

Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the

Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this CLIN.

5003 6 Months OPTION B523 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B523

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

5004 6 Months OPTION B597 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B597

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

5005 6 Months OPTION B598 Monthly HM/HS Services

FFP

Monthly preventative maintenance and service calls for HM/HS services for B598

(Reference PWS Paragraphs 2.6, 3.1 and 3.2)

5006 1 Project OPTION Future Repair/Upgrades to B523/B597/B598

FFP

This CLIN is reserved for future repairs and HEMP HM/HS upgrades for

B523/B597/B598 at a maximum amount of $25,000 to accomodate repairs and upgrades IAW PWS Paragraphs 3.3. Future repairs and upgrades will be funded upon approval by the Contracting Officer and the COR. The negotiated value of future repairs and upgrades will be transferred to the appropriate CLIN from this

CLIN.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

1001 Destination Government Destination Government

1002 Destination Government Destination Government

1003 Destination Government Destination Government

1004 Destination Government Destination Government

1005 Destination Government Destination Government

1006 Destination Government Destination Government

2001 Destination Government Destination Government

2002 Destination Government Destination Government

2003 Destination Government Destination Government

2004 Destination Government Destination Government

2005 Destination Government Destination Government

2006 Destination Government Destination Government

3001 Destination Government Destination Government

3002 Destination Government Destination Government

3003 Destination Government Destination Government

3004 Destination Government Destination Government

3005 Destination Government Destination Government

3006 Destination Government Destination Government

4001 Destination Government Destination Government

4002 Destination Government Destination Government

4003 Destination Government Destination Government

4004 Destination Government Destination Government

4005 Destination Government Destination Government

4006 Destination Government Destination Government

5001 Destination Government Destination Government

5002 Destination Government Destination Government

5003 Destination Government Destination Government

5004 Destination Government Destination Government

5005 Destination Government Destination Government

5006 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 01-AUG-2018 TO

31-JUL-2019

N/A 55 CES/CEOES

RYAN OLSON

106 PEACEKEEPER DR. SUITE 2N3

AREA:P-19

OFFUTT AFB NE 68113-4019

402-232-5279

F3H3G2

0002 POP 01-AUG-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 01-AUG-2018 TO

N/A F3HKB1 - 55CS

MICHAEL VOGEL

106 PEACEKEEPER DRIVE, BLDG. 301D,

AREA 18

OFFUTT AFB NE 68113-2040

402-294-4184

F3HKB1

0004 POP 01-AUG-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

0005 POP 01-AUG-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

0006 POP 01-AUG-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1001 POP 01-AUG-2019 TO

31-JUL-2020

N/A 55 CES/CEOES

RYAN OLSON

106 PEACEKEEPER DR. SUITE 2N3

AREA:P-19

OFFUTT AFB NE 68113-4019

402-232-5279

1002 POP 01-AUG-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

1003 POP 01-AUG-2019 TO

N/A F3HKB1 - 55CS

MICHAEL VOGEL

106 PEACEKEEPER DRIVE, BLDG. 301D,

AREA 18

OFFUTT AFB NE 68113-2040

402-294-4184

1004 POP 01-AUG-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

1005 POP 01-AUG-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

1006 POP 01-AUG-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2001 POP 01-AUG-2020 TO

31-JUL-2021

N/A 55 CES/CEOES

RYAN OLSON

106 PEACEKEEPER DR. SUITE 2N3

AREA:P-19

OFFUTT AFB NE 68113-4019

402-232-5279

2002 POP 01-AUG-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

2003 POP 01-AUG-2020 TO

N/A F3HKB1 - 55CS

MICHAEL VOGEL

106 PEACEKEEPER DRIVE, BLDG. 301D,

AREA 18

OFFUTT AFB NE 68113-2040

402-294-4184

2004 POP 01-AUG-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

2005 POP 01-AUG-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

2006 POP 01-AUG-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3001 POP 01-AUG-2021 TO

31-JUL-2022

N/A 55 CES/CEOES

RYAN OLSON

106 PEACEKEEPER DR. SUITE 2N3

AREA:P-19

OFFUTT AFB NE 68113-4019

402-232-5279

3002 POP 01-AUG-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

3003 POP 01-AUG-2021 TO

N/A F3HKB1 - 55CS

MICHAEL VOGEL

106 PEACEKEEPER DRIVE, BLDG. 301D,

AREA 18

OFFUTT AFB NE 68113-2040

402-294-4184

3004 POP 01-AUG-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

3005 POP 01-AUG-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

3006 POP 01-AUG-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4001 POP 01-AUG-2022 TO

31-JUL-2023

N/A 55 CES/CEOES

RYAN OLSON

106 PEACEKEEPER DR. SUITE 2N3

AREA:P-19

OFFUTT AFB NE 68113-4019

402-232-5279

4002 POP 01-AUG-2022 TO

N/A (SAME AS PREVIOUS LOCATION)

4003 POP 01-AUG-2022 TO

N/A F3HKB1 - 55CS

MICHAEL VOGEL

106 PEACEKEEPER DRIVE, BLDG. 301D,

AREA 18

OFFUTT AFB NE 68113-2040

402-294-4184

4004 POP 01-AUG-2022 TO

N/A (SAME AS PREVIOUS LOCATION)

4005 POP 01-AUG-2022 TO

N/A (SAME AS PREVIOUS LOCATION)

4006 POP 01-AUG-2022 TO

N/A (SAME AS PREVIOUS LOCATION)

5001 POP 01-AUG-2023 TO

31-JAN-2024

N/A 55 CES/CEOES

RYAN OLSON

106 PEACEKEEPER DR. SUITE 2N3

AREA:P-19

OFFUTT AFB NE 68113-4019

402-232-5279

5002 POP 01-AUG-2023 TO

N/A (SAME AS PREVIOUS LOCATION)

5003 POP 01-AUG-2023 TO

N/A F3HKB1 - 55CS

MICHAEL VOGEL

106 PEACEKEEPER DRIVE, BLDG. 301D,

AREA 18

OFFUTT AFB NE 68113-2040

402-294-4184

5004 POP 01-AUG-2023 TO

N/A (SAME AS PREVIOUS LOCATION)

5005 POP 01-AUG-2023 TO

N/A (SAME AS PREVIOUS LOCATION)

5006 POP 01-AUG-2023 TO

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984

52.203-18 Prohibition on Contracting With Entities That Require Certain

Internal Confidentiality Agreements or Statements--

Representation

JAN 2017

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-13 System for Award Management Maintenance OCT 2016

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-17 Ownership or Control of Offeror JUL 2016

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-2 Prohibition on Contracting with Inverted Domestic

Corporations--Representation

NOV 2015

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.212-1 Instructions to Offerors--Commercial Items JAN 2017

52.212-2 Evaluation - Commercial Items OCT 2014

52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017

52.222-50 Combating Trafficking in Persons MAR 2015

52.223-6 Drug-Free Workplace MAY 2001

52.223-10 Waste Reduction Program MAY 2011

52.223-22 Public Disclosure of Greenhouse Gas Emissions and

Reduction Goals -- Representation.

DEC 2016

52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.232-11 Extras APR 1984

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.237-1 Site Visit APR 1984

52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation

APR 1984

52.237-3 Continuity Of Services JAN 1991

52.242-13 Bankruptcy JUL 1995

52.242-15 Stop-Work Order AUG 1989

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-0011 Contract-wide: Proration SEP 2009

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

OCT 2015

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items JUN 2013

252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012

252.245-7003 Contractor Property Management System Administration APR 2012

252.245-7004 Reporting, Reutilization, and Disposal SEP 2016

CLAUSES INCORPORATED BY FULL TEXT

52.204-20 Predecessor of Offeror (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics

Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA

Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

(End of provision)

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (JUN 2016)

(a) Definitions. As used in this clause--

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public Web sites) or simple transactional information, such as necessary to process payments.

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on

National Security Systems Instruction (CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices

(including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other

Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order

13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations

Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

https://www.acquisition.gov/

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision --

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means—

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) Concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance

Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a

State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

https://www.sam.gov/portal http://www.dol.gov/fairpayandsafeworkplaces

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment

Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment

Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the

FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of

``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

http://www.osha.gov/dcsp/osp/approved_state_plans.html

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act

(50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term

“successor” does not include new offices/divisions of the same company or a company that only changes its name.

The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

"Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

"Women-owned small business concern" means a small business concern--

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least

51 percent of its stock is owned by one or more women; or

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)”, means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the

United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal

Register advising the public of the termination of the injunction.

(b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted electronically on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-

3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ .

[Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any.) These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract will be performed in the United

States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a small business concern.

(2) Veteran-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, (…