Solicitation 09-R-0015 Skidrow.doc

Section B - Supplies or Services and Prices

Repair Airfield Pavement-Skid Row

FFP

Furnish all plant, labor, equipment, and materials necessary to accomplish Project MIN 09-0076, "Repair Airfield Pavement - Skid Row" at Minot AFB, North Dakota in accordance with specifications and drawings. Work is 100% General. Water and electricity required will be furnished by the government. The work is in a restricted area. There will possibly be security delays. Include in the NET AMT the cost for an estimated 20 crew hours of delays. The total statement of magnitude for this project is between $1,000,000 and $5,000,000. Performance Period for this project is 90 calendar days. Request a one-year warranty of construction. No Ozone Depleting Certification (ODC) required.

FOB: Destination

NSN: Z124-09-SKI-DROW

SIGNAL CODE: A

NET AMOUNT

PROPOSAL SCHEDULE for ITEM 0001:

All work as shown on the drawings and specified in the specifications.

Security delays to work – estimated delay time for all Contractor’s activity excluding those delays as described in Section 01000.

Minimum of one-hour increments.

Est. 20 crew hours x $___________ per crew hour _________________

Total Amount to include security delays

Note: The total amount ,to include security delays, is to be entered as Net Amount for Item 0001.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

Section F - Deliveries or Performance

DELIVERY INFORMATION

5 CONS

WALTER KULIG

211 MISSILE AVENUE

MINOT AFB ND 58705-5027

701-723-4184

FOB: Destination

FA4528

Section G - Contract Administration Data

WAWF

WIDE AREA WORK FLOW INFORMATION

Wide Area Work Flow DODAAC and Email Distribution Table

Questions concerning payment should be directed to the Defense Finance Accounting Services (DFAS) at (800) 390-5620 or (800) 337-0371. Please have your order number and invoice number ready when calling about payment status.

The accounts payable mailing address can be located in Block 18a of your order. You can easily access payment information using the DFAS web site at http://www.dfas.mil. Your purchase order/contract number or invoice will be required to inquire status of your payment. Go to DFAS on the web at: www/dfas.mil/money/vendor

Payments may be expedited electronically via Internet through the Wide Area Workflow (WAWF) system for more info go to https://wawf.eb.mil Note: Use of WAWF is mandatory. Use of WAWF will speed up your payment processing time and allow you to monitor your payment status online. There are no charges or fees to use WAWF. For more info contact us at 1-701-723-4184 or email 5conswawflgcb@minot.af.mil.

The following codes will be required to route your invoices and additional E-mails correctly through WAWF.

CAGE CODE:

ISSUE BY DODAAC: FA4528

ADMIN DODAAC: FA4528

INSPECT BY BPN: F3C3CN

SERVICE ACCEPTOR: F3C3CN

“SHIP TO” BPN:

PAY OFFICE DODAAC: F67100

E-MAIL POINT OF CONTACT LISTING:

SERVICE ACCEPTOR: 5ces.wawf@minot.af.mil

CONTRACT ADMINISTRATOR: 5conswawflgca2@minot.af.mil

CONTRACTING OFFICER: 5conswawflgca2@minot.af.mil ADDITIONAL CONTACTS: 5cpts.wawf@minot.af.mil walter.kulig@minot.af.mil

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

5352.232-9000 REMITTANCE ADDRESS (MAY 1996)

If the remittance address is different from the mailing address, enter the remittance address below. Failure to provide this information may impact payment.

Points of Contact:

Contract Administrator:

Mr Walter Kulig

Phone: (701) 723-4184

Fax: (701) 723-4179

Email: walter.kulig@minot.af.mil Contracting Officer:

Mr David Schwaiger

Phone: (701) 723-3829

Fax: (701) 723-4179

Email: david.schwaiger@minot.af.mil Section H - Special Contract Requirements

SPECIAL CONTRACT REQUIREMENTS

REQUIRED INSURANCE

IAW FAR 28.306(b)

Reference FAR clause entitled “Insurance ...” the contractor shall, at its own expense, procure and thereafter maintain the following kinds of insurance with respect to performance under the contract.

a. Workmen’s Compensation and Employers Liability Insurance as required by law except that if this contract is to be performed in a state which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such state will be satisfactory. The required Workmen’s Compensation insurance shall extend to cover employer’s liability for accidental bodily injury or death and for occupational disease with a minimum liability limit of $100,000.

b. General Liability Insurance. Bodily injury liability insurance, in the minimum limits of $500,000 per occurrence, shall be required on the comprehensive form of the policy.

c. Automobile Liability Insurance. This insurance shall be required on the comprehensive form of the policy and shall provide bodily injury liability and property damage liability covering the operation of all automobiles used in connection with the performance of the contract. At least the minimum limits of $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage shall be required.

PROHIBITION ON HIRING ILLEGAL ALIENS

In accordance with the Air Combat Command Supplement to Air Force Instruction 31-101, it is prohibited to hire illegal aliens for work on this contract. Illegal aliens will not be permitted access to Minot AFB, ND. Violation of this policy will result in corrective action.

EMPLOYEES RESTRICTIONS

The Government reserves the right, under this contract to restrict the employment of any employee, or prospective contractor employee, who is identified as a potential threat to the health, safety, or general well being of operations mission of the installation and its population. Contractor Management and employees must conduct themselves in a professional manner at all times, in the performance of their assigned duties and responsibilities.

TRAFFIC REGULATIONS

Contractor will abide by all traffic regulations outlined in the Air Force Regulation 31-206, for Minot AFB, as supplemented. Copies of these regulations and supplements are available for review at Base Pass and Registration, 15 Missile Avenue or Base Security Police Office, 330 Tanker Trail. Changes will be furnished to the contractor prior to enforcement.

BASE PASSES

The contractor will be required to comply with all security and safety clearances that are enforced at Minot AFB. All contractor's personnel requiring access to Minot AFB, ND will be required to obtain base vehicle passes. Details for obtaining vehicle passes will be provided at the pre-performance conference.

MANDATORY SEATBELT REQUIREMENT

The use of seatbelts by all vehicle operators and passengers is mandatory on Minot AFB, ND, to include the operation of vehicles on Minot AFB Missile Sites. The first offense carries a mandatory 30-day suspension of base driving priveledges. For a second offense, the individual’s driving priveledges will be terminated by the 5th Mission Support Group Commander.

CELL PHONE USAGE

The use of cellular telephones while driving on Minot AFB is prohibited unless using a hands free device.

COMPLIANCE WITH APPLICABLE FEDERAL, STATE AND LOCAL REQUIREMENTS

In performing work under this contract, the Contractor shall comply with all applicable federal, state, and local statutes, ordinances, laws and regulations.

SCHEDULE OF MATERIAL SUBMITTALS (IAW AFFARS 5336.9001)

AF Form 66, Schedule of Material Submittals, may be used by the contracting officer, civil engineer, and contractor to help material submittal requirements. The form is initially prepared by the civil engineer and submitted to the contracting officer with the purchase request. The contracting officer will include the form in the solicitation as an attachment. Upon award, the contracting officer, or designee, will provide copies to the contractor and the civil engineer at the pre-performance conference. AF Form 66 may also be used to track the submission of periodic usage data for estimated quantity line items when the contract contains estimated quantity line items.

VEHICLE REGISTRATION

All contractors shall provide the following vehicle informatiton: Vehicle make, model, color, tag #, and state the vehicle is registered in. Individuals will be allowed to register one (1) vehicle onto the installation. If they will be utilizing a different vehicle other than the one they have registered they will have to receive a 24hr pass for the day. This also includes motorcycles.

PAYMENTS FOR MATERIALS DELIVERED TO WORK SITE

The government will not pay for materials delivered to the work site. Payment for progress is the normal method of payment on contracts.

LIQUIDATED DAMAGES

Reference Section I 52.211-12.

PAYMENT AND PERFORMANCE BONDS

(a) Performance Bonds (Standard Form 25). The penal amount of performance bonds shall equal 100 percent of the contract price.

(b) Payment Bonds (Standard Form 25-A). The penal amount of payment bonds shall equal 100 percent of the contract price.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (SEP 2007)

(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24, and Federal Information Processing Standards Publication (FIPS PUB) Number 201.

(b) The Contractor shall insert this clause in all subcontracts when the subcontractor is required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than ninty (90) calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $349.01 for the first day and $321.01 for each calendar day thereafter of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JUNE 2007)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the exercise date specified in the contract for any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure they reflect current status. The Contractor shall notify the contracting office by e-mail, or otherwise in writing, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237310- assigned to contract number TBD.

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

52.225-9 BUY AMERICAN ACT—CONSTRUCTION MATERIALS (JAN 2005)

(a) Definitions. As used in this clause--

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States; or

(2) A construction material manufactured in the United States, if the cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. (1) This clause implements the Buy American Act (41 U.S.C. 10a-10d) by providing a preference for domestic construction material. The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to the construction material or components listed by the Government as follows: None

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction material description Unit of measure Quantity Price (dollars) \1\

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least thirty (30) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Walter Kulig Address: 211 Missile Avenues, Minot AFB ND, 58705 Telephone: (701) 723-4184

(c) A pre-proposal conference will be conducted at 9:30 A.M Local Time on 24 March 2009 in Bldg 165, 5th Contracting Squadron, Minot AFB, ND for the purpose of reviewing the work site and submitting questions regarding this solicitation. For those interested parties that do not have base passes, you must arrive at the Visitors Center (located at the main gate) no later than 30 minutes prior to the start of the site visit. This will allow time to obtain a temporary pass from the Visitors Center and to have vehicles searched before entering the installation. Each individual must hand-carry and submit to the Visitors Center his or her driver’s license, vehicle registration, and current proof of insurance to receive a temporary base pass.

(d) Submit the names of all attendees exactly as they appear on driver’s license, and social security number, not to exceed (4) personnel to point of contact 5 CONS/LGCAC Attn: Walter Kulig, 211 Missile Avenue, Minot AFB ND, 58705 or fax to (701) 723-4179 prior to 10:00 A.M. on 20 March 2009. This information must be provided in advance in order to ensure access to the military base/conference site and adequate seating for the conference.

(End of provision)

CLAUSES INCORPORATED BY FULL TEXT

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address:

http:/farsite.hill.af.mil

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation (48 CFRChapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Title

File Drawing No.

Specifications

Repair Airfield Pavement-Skid Row

MIN 09-0076

Sheets 1-9 of 9

244 Pages (End of clause)

252.236-7005 AIRFIELD SAFETY PRECAUTIONS. (DEC 1991)

(a) Definitions. As used in this clause --

(1) "Landing areas means" --

(i) The primary surfaces, comprising the surface of the runway, runway shoulders, and lateral safety zones. The length of each primary surface is the same as the runway length. The width of each primary surface is 2,000 feet (1,000 feet on each side of the runway centerline);

(ii) The "clear zone" beyond the ends of each runway, i.e., the extension of the primary surface for a distance of 1,000 feet beyond each end of each runway;

(iii) All taxiways, plus the lateral clearance zones along each side for the length of the taxiways (the outer edge of each lateral clearance zone is laterally 250 feet from the far or opposite edge of the taxiway, e.g., a 75-foot-wide taxiway would have a combined width of taxiway and lateral clearance zones of 425 feet); and

(iv) All aircraft parking aprons, plus the area 125 feet in width extending beyond each edge all around the aprons.

(2) "Safety precaution" areas means those portions of approach-departure clearance zones and transitional zones where placement of objects incident to contract performance might result in vertical projections at or above the approach-departure clearance, or the transitional surface.

(i) "The approach-departure clearance surface" is an extension of the primary surface and the clear zone at each end of each runway, for a distance of 50,000 feet, first along an inclined (glide angle) and then along a horizontal plane, both flaring symmetrically about the runway centerline extended.

(A) The inclined plane (glide angle) begins in the clear zone 200 feet past the end of the runway (and primary surface) at the same elevation as the end of the runway. It continues upward at a slope of 50:1 (1 foot vertically for each 50 feet horizontally) to an elevation of 500 feet above the established airfield elevation. At that point the plane becomes horizontal, continuing at that same uniform elevation to a point 50,000 feet longitudinally from the beginning of the inclined plane (glide angle) and ending there.

(B) The width of the surface at the beginning of the inclined plane (glide angle) is the same as the width of the clear zone. It then flares uniformly, reaching the maximum width of 16,000 feet at the end.

(ii) The "approach-departure clearance zone" is the ground area under the approach-departure clearance surface.

(iii) The "transitional surface" is a sideways extension of all primary surfaces, clear zones, and approach-departure clearance surfaces along inclined planes.

(A) The inclined plane in each case begins at the edge of the surface.

(B) The slope of the incline plane is 7:1 (1 foot vertically for each 7 feet horizontally). It continues to the point of intersection with the --

(1) Inner horizontal surface (which is the horizontal plane 150 feet above the established airfield elevation); or

(2) Outer horizontal surface (which is the horizontal plane 500 feet above the established airfield elevation), whichever is applicable.

(iv) The "transitional zone" is the ground area under the transitional surface. (It adjoins the primary surface, clear zone, and approach-departure clearance zone.)

(b) General. (1) The Contractor shall comply with the requirements of this clause while --

(i) Operating all ground equipment (mobile or stationary);

(ii) Placing all materials; and

(iii) Performing all work, upon and around all airfields.

(2) The requirements of this clause are in addition to any other safety requirements of this contract.

(c) The Contractor shall -

(1) Report to the Contracting Officer before initiating any work;

(2) Notify the Contracting Officer of proposed changes to locations and operations;

(3) Not permit either its equipment or personnel to use any runway for purposes other than aircraft operation without permission of the Contracting Officer, unless the runway is -

(i) Closed by order of the Contracting Officer; and

(ii) Marked as provided in paragraph (d)(2) of this clause;

(4) Keep all paved surfaces, such as runways, taxiways, and hardstands, clean at all times and, specifically, free from small stones which might damage aircraft propellers or jet aircraft;

(5) Operate mobile equipment according to the safety provisions of this clause, while actually performing work on the airfield. At all other times, the Contractor shall remove all mobile equipment to locations -

(i) Approved by the Contracting Officer;

(ii) At a distance of at least 750 feet from the runway centerline, plus any additional distance; and

(iii) Necessary to ensure compliance with the other provisions of this clause; and

(6) Not open a trench unless material is on hand and ready for placing in the trench. As soon as practicable after material has been placed and work approved, the Contractor shall backfill and compact trenches as required by the contract. Meanwhile, all hazardous conditions shall be marked and lighted in accordance with the other provisions of this clause.

(d) Landing areas. The Contractor shall -

(1) Place nothing upon the landing areas without the authorization of the Contracting Officer;

(2) Outline those landing areas hazardous to aircraft, using (unless otherwise authorized by the Contracting Officer) red flags by day, and electric, battery-operated low-intensity red flasher lights by night;

(3) Obtain, at an airfield where flying is controlled, additional permission from the control tower operator every time before entering any landing area, unless the landing area is marked as hazardous in accordance with paragraph (d)(2) of this clause;

(4) Identify all vehicles it operates in landing areas by means of a flag on a staff attached to, and flying above, the vehicle. The flag shall be three feet square, and consist of a checkered pattern of international orange and white squares of 1 foot on each side (except that the flag may vary up to ten percent from each of these dimensions);

(5) Mark all other equipment and materials in the landing areas, using the same marking devices as in paragraph (d)(2) of this clause; and

(6) Perform work so as to leave that portion of the landing area which is available to aircraft free from hazards, holes, piles of material, and projecting shoulders that might damage an airplane tire.

(e) Safety precaution areas. The Contractor shall -

(1) Place nothing upon the safety precaution areas without authorization of the Contracting Officer;

(2) Mark all equipment and materials in safety precaution areas, using (unless otherwise authorized by the Contracting Officer) red flags by day, and electric, battery-operated, low-intensity red flasher lights by night; and

(3) Provide all objects placed in safety precaution areas with a red light or red lantern at night, if the objects project above the approach-departure clearance surface or above the transitional surface.

5352.201-9101 OMBUDSMAN (AUG 2005)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMBC A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, concerned parties may contact the Center/MAJCOM ombudsmen, Lorraine Cotton, HQ ACC/A7K, Langley AFB VA 23665; commercial phone (757) 764-5372, fax (757) 764-4400; email: lorraine.cotton@langley.af.mil . Concerns, issues, disagreements, and recommendations that cannot be resolved at the MAJCOM/DRU level, may be brought by the concerned party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (703) 588-7004, facsimile number (703) 588-1067.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (MAY 1996)

(a) The contractor shall obtain base identification and vehicle passes for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, valid vehicle insurance certificate to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-209, the Air Force Resource Protection Program, and AFI 31-501, Personnel Security Program Management, as applicable.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Prior to submitting an invoice for final payment, the prime contractor shall obtain a clearance certification from the issuing office which states all base identification passes have been turned in, accounted for, or transferred to a follow-on contract. This certification shall be submitted to the contracting officer prior to submission of the final invoice for payment.

(g) Failure to comply with these requirements may result in withholding of final payment.

Section J - List of Documents, Exhibits and Other Attachments

SECTION J

DOCUMENT TYPE

DISCRIPTION

PAGES

DATE

Attachment 1

Specifications

January 2009 Attachment 2

Drawings

March 2007

Attachment 3

Wage Determination ND20080002

21 November 2008

Attachment 4

Technical Acceptance Criteria

N/A

Attachment 5

Responsibility Questionaire

N/A Section K - Representations, Certifications and Other Statements of Offerors

CLAUSES INCORPORATED BY REFERENCE

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2006)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237310.

(2) The small business size standard is $33,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the clause at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (c) of this provision applies.

(2) If the clause at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronically, the offeror may choose to use paragraph (b) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

(X ) Paragraph (c) applies.

(__) Paragraph (c) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) The offeror has completed the annual representations and certifications electronically via the Online Representations and Certifications Application (ORCA) website at http://orca.bpn.gov. After reviewing the ORCA database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on ORCA.

(End of Provision)

252.247-7022 REPRESENTATION OF EXTENT OF TRANSPORTATION BY SEA (AUG 1992)

(a) The Offeror shall indicate by checking the appropriate blank in paragraph (b) of this provision whether transportation of supplies by sea is anticipated under the resultant contract. The term supplies is defined in the Transportation of Supplies by Sea clause of this solicitation.

(b) Representation. The Offeror represents that it:

____ (1) Does anticipate that supplies will be transported by sea in the performance of any contract or subcontract resulting from this solicitation.

____ (2) Does not anticipate that supplies will be transported by sea in the performance of any contract or subcontract resulting from this solicitation.

(c) Any contract resulting from this solicitation will include the Transportation of Supplies by Sea clause. If the Offeror represents that it will not use ocean transportation, the resulting contract will also include the Defense FAR Supplement clause at 252.247-7024, Notification of Transportation of Supplies by Sea.

(End of provision)

Section L - Instructions, Conditions and Notices to Bidders

INSTRUCTIONS

Offerors must complete and return the following with each offer:

1. Standard Form 1442, “Offer” and Section B, “Offer Schedule”

2. Section K, Representations, Certifications, and Other Statements of Offerors or complete ORCA per clause 52.204-8 and Representation of extent of Transportation by Sea (Aug 1992).

3. Attachment 4 - Technical Acceptance Criteria

4. Attachment 5 - Responsibility Questionnaire

5. Large Businesses only are required to submit a Small Business Subcontracting Plan IAW FAR 19.704.

CLAUSES INCORPORATED BY REFERENCE

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects.