Atch_1_-_Specifications _Bldg_169.pdf

SPECIFICATIONS

REPAIRS TO BASE

OPS/CMD POST,

BLDG 169

AT

JOINT BASE CHARLESTON

AIR BASE, SOUTH CAROLINA

PROJECT No.: DKFX 14-1042 AND DKFX 14-1042D

SUBMITTAL DATE: 27 MAY, 2016

ARCHITECTURE / PLANNING / INTERIOR DESIGN

493 King Street, Suite 100 Charleston, South Carolina 29403

Telephone: 843.577.6377 / Fax: 843.722.1768 Internet: www.glickboehmarchitecture.com

GBA Project No.: 1508

Project Design Team

Architect: Glick/Boehm & Associates, Inc.

493 King Street, Suite 100 Charleston, South Carolina 29403 (843)577.6377

Mechanical / Plumbing / DWG Consulting Engineers, Inc.

Electrical Consultant/ 1009 Anna Knapp Blvd., Suite 202 Fire Protection: Mt. Pleasant, South Carolina 29464 (843)849.1141

DKFX 14-1042 Repairs to Base Ops/Cmd Post, Bldg. 169

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 31 26 INFORMATION AVAILABLE TO PROPOSERS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 JBCGS SUMMARY OF WORK

01 14 00 JBCGS WORK RESTRICTIONS

01 22 00.00 10 UNIT PRICE PAYMENT

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 16.00 20 JBCGS PROJECT SCHEDULE AND PROGRESS DOCUMENTATION

01 33 00 JBCGS SUBMITTAL PROCEDURES

01 35 26 JBCGS GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00 JBCGS QUALITY CONTROL FOR MINOR CONSTRUCTION

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 50 10 JBCGS ENVIRONMENTAL

01 54 00 JBCGS GREEN PROCUREMENT

01 57 20 JBCGS WASTE MANAGEMENT

01 57 50 JBCGS TEMPORARY ENVIRONMENTAL CONTROLS

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 41 16.00 10 PLASTIC-LAMINATE-CLAD ARCHITECTURAL CABINETS

06 61 16 SOLID POLYMER (SOLID SURFACING) FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 14 00 WOOD DOORS

08 42 29.43 IMPACT RATED SLIDING AUTOMATIC ENTRANCES

08 43 13 ALUMINUM-FRAMED ENTRANCES AND STOREFRONTS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

DIVISION 09 - FINISHES

09 22 00 SUPPORTS FOR GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 30 00 CERAMIC TILE

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 68 00 CARPET

09 83 13 ACOUSTICAL WALL COATING

09 90 00 PAINTS

PROJECT TABLE OF CONTENTS Page 1

DIVISION 10 - SPECIALTIES

10 21 13 TOILET COMPARTMENTS

10 28 13 TOILET ACCESSORIES

DIVISION 21 - FIRE SUPPRESSION

21 13 00.00 40 FIRE-SUPPRESSION SPRINKLER SYSTEMS

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

23 05 15 COMMON PIPING FOR HVAC

23 05 48.00 40 VIBRATION AND SEISMIC CONTROLS FOR HVAC PIPING AND

EQUIPMENT

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 64 26 CHILLED, CHILLED-HOT, AND CONDENSER WATER PIPING SYSTEMS

23 81 23.00 20 COMPUTER ROOM AIR CONDITIONING UNITS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 05 00.00 40 COMMON WORK RESULTS FOR ELECTRICAL

26 05 48.00 10 SEISMIC PROTECTION FOR ELECTRICAL EQUIPMENT

26 08 00 APPARATUS INSPECTION AND TESTING

26 09 23.00 40 LIGHTING CONTROL DEVICES

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 24 16.00 40 PANELBOARDS

26 51 00 INTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

27 51 16 RADIO AND PUBLIC ADDRESS SYSTEMS

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 05 26.00 40 GROUNDING AND BONDING FOR ELECTRONIC SAFETY AND SECURITY

28 31 76.00 00 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION 00 31 26

INFORMATION AVAILABLE TO PROPOSERS

03/01

PART 1 GENERAL

1.1 SUMMARY

These documents furnish the following physical data as attachments.

a. Limited Hazardous Materials Assessment Report dated September 9, 2015

1.2 PROPOSERS RESPONSIBILITY

Data and information furnished in the attached document produced by S&ME, Mount Pleasant, SC is for the Proposer's information. The Government shall not be responsible for any interpretation of, or conclusion drawn from, the data or information by the Proposer.

PART 2 NOT USED

PART 3 NOT USED

-- End of Section --

DOCUMENT 00 31 26 Page 1

SECTION 01 11 00

JBCGS SUMMARY OF WORK

06/15

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Utility Outage Requests; G

Road Closure Requests; G

Air Force Work Clearance Permit; G

Contractor's Proposed Laydown Area Plan; G

1.2 Project Description

The work includes HVAC replacement and incidental related work. The work also includes demolition of existing finishes and lighting, instalation of new flooring, wall finishes, ceiling finishes and lighting. Bathrooms are being renovated and there is new millwork installation.

1.3 Location

The work is located at building 169, Joint Base Charleston, Air Base, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.4 OCCUPANCY OF PREMISES

Building will not be occupied during performance of work under this Contract.

Before work is started, the Contractor shall arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.5 PROJECT ENVIRONMENTAL GOALS

Contractor shall distribute copies of the Environmental Goals to each subcontractor and the Contracting Officer. The overall goal for design, construction, and operation is to produce a building that meets the functional program needs and incorporates the principles of sustainability. Specifically:

a. Preserve and restore the site ecosystem and biodiversity; avoid site degradation and erosion. Minimize offsite environmental impact.

SECTION 01 11 00 Page 1

b. Use the minimum amount of energy, water, and materials feasible to meet the design intent. Select energy and water efficient equipment and strategies.

c. Use environmentally preferable products and decrease toxicity level of materials used.

d. Use renewable energy and material resources.

e. Optimize operational performance (through commissioning efforts) in order to ensure energy efficient equipment operates as intended. Consider the durability, maintainability, and flexibility of building systems.

f. Manage construction site and storage of materials to ensure no negative impact on the indoor environmental quality of the building.

g. Reduce construction waste through reuse, recycling, and supplier take-back.

1.6 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

[1.7 GOVERNMENT-INSTALLED WORK

The Government will reinstall all AV/IT and computer work station equipment. Furniture will be installed under another separate contract.

1.8 ON-SITE PERMITS

Obtain a work clearance/digging permit prior to start of excavation. The Contractor is responsible for marking and verifying all utilities. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated to be specified or removed but indicated or discovered in locations to be traversed by piping, ducts, and other work to be conducted or installed. Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.8.1 NOTIFICATION

Notify the Contracting Officer at least 72 hours prior to starting excavation work.

SECTION 01 11 00 Page 2

1.8.2 OUTAGE REQUESTS

Utility outages and road closures required during the prosecution of work shall be arranged for the convenince of the Government. Utility outages and connections shall be scheduled outside regular working hours. Utility outage, and road closure requests shall be submitted to the Contracting Officer for coordination and Government approval at least 30 days prior to the desired outage or closure date. Requests shall clearly identify the need for the outage or closure, the requested date(s) for the outage or closure, the expected length of the outage or closure and proposed backup dates.

1.9 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged shall remain the property of the Government.

The salvaged property shall be segregated, itemized, delivered, and off-loaded at a Government designated storage area located on Joint Base Charleston.

Contractor shall maintain property control records for material or equipment designated as salvage. Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 11 00 Page 3

SECTION 01 14 00

JBCGS WORK RESTRICTIONS

06/15

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel; G

1.2 CONTRACTOR ACCESS AND USE OF PREMISES

1.2.1 Activity Regulations

It should be recognized that requirements for security and base accessories between various locations within Joint Base Charleston. It is incumbent on the Contractor to ascertain the current security and base access requirements appropriate to the project location and incorporate the cost, if any, for compliance to said requirements into Contractor's proposal.

Lack of knowledge of current requirements does not constitute a basis for an adjustment to the contract. Should requirements change during the construction timeframe, Contractor may be eligible, subject to documentation acceptable to the Government, for an adjustment to the contract.

Ensure that all Contractor personnel employed on Joint Base Charleston become familiar with and obey Installation regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear hard hats in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Mark Contractor equipment for identification.

1.2.1.1 Subcontractors and Personnel Contacts

Furnish a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.2.1.2 Identification Badges and Installation Access

Identification badges, if required, may be furnished without charge under certain circumstances. Confirm security requirements with the Contracting Officer. Application for and use of badges will be as directed.

Immediately report instances of lost or stolen badges to the Contracting Officer.

SECTION 01 14 00 Page 1

1.2.1.3 Tobacco Use Policy

Tobacco use is prohibited within and outside of all buildings on installation, except in designated Tobacco Use Areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated Tobacco Use Areas.

1.2.2 Working Hours

Regular working hours shall consist of an 8 1/2 hour period established by the Contractor Officer, between 7:00 a.m. and 3:30 p.m., Monday through Friday, excluding Government holidays.

1.2.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work shall be lighted in a manner approved by the Contracting Officer.

1.2.4 Occupied Buildings

Do not enter occupied buildings without prior approval of the Contracting Officer.

Existing buildings and their contents must be kept secure at all times.

Provide temporary closures as required to maintain security as directed by the Contracting Officer.

Provide dust covers or protective enclosures to protect existing work that remains and Government material during the construction period.

Leave attached equipment in place, and protect against damage, or temporarily disconnect, relocate, protect, and reinstall at the completion of the work.

1.2.5 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in the paragraph "Work Outside Regular Hours."

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, and natural gas shall be considered utility cutovers pursuant to the paragraph entitled "Work Outside Regular Hours."

d. Operation of Station Utilities: The Contractor must not operate nor disturb the setting of control devices in the station

SECTION 01 14 00 Page 2 utilities system, including water, sewer, electrical, and steam services without Government notification and approval. The Contractor must notify the Contracting Officer giving reasonable advance notice when such operation is required.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 14 00 Page 3

SECTION 01 22 00.00 10

UNIT PRICE PAYMENT

04/06

PART 1 GENERAL

1.1 UNIT PRICE PAYMENT ITEMS

Payment items for the work of this contract on which the contract unit price payments will be made are listed in the BIDDING SCHEDULE and described below. The unit price and payment made for each item listed shall constitute full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for each of the unit price items.

1.1.1 Gypsum Board

1.1.1.1 Payment

Payment will be made for costs associated with replacement of existing 5/8" type X gypsum board damaged by removal of wall covering, and other incidentals necessary to complete the work required by Section 09 29 00 GYPSUM BOARD. No payment will be made for defective areas until corrected.

1.1.1.2 Measurement

Gypsum board will be measured for payment based upon the number of square feet used in the accepted work.

1.1.1.3 Unit of Measure

Unit of measure: Square feet.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 22 00.00 10 Page 1

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

06/15

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

View Location Map; G

Progress and Completion Pictures; G

Resume for Superintendent; G

1.2 VIEW LOCATION MAP

Submit, prior to or with the first digital photograph submittals, a sketch or drawing indicating the required photographic locations. Update as required if the locations are moved.

1.3 PROGRESS AND COMPLETION PICTURES

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, 1600x1200x24 bit true color 5 MegaPixel minimum resolution in JPEG file format showing the sequence and progress of work.

Take a minimum of 20 digital photographs each week throughout the entire project from a minimum of ten views from points located by the Contracting Officer. Submit with the monthly invoice two sets of digital photographs, each set on a separate compact disc (CD) or data versatile disc (DVD), cumulative of all photos to date. Indicate photographs demonstrating environmental procedures. Provide photographs for each month in a separate monthly directory and name each file to indicate its location on the view location sketch. Also provide the view location sketch on the CD or DVD as a digital file. Include a date designator in file names. Cross reference submittals in the appropriate daily report. Photographs provided are for unrestricted use by the Government.

1.4 MINIMUM INSURANCE REQUIREMENTS

Procure and maintain during the entire period of performance under this contract the following minimum insurance coverage:

a. Comprehensive general liability: $500,000 per occurrence

b. Automobile liability: $200,000 per person, $500,000 per occurrence for bodily injury, $20,000 per occurrence for property damage

c. Workmen's compensation as required by Federal and State workers'

SECTION 01 30 00 Page 1 compensation and occupational disease laws.

d. Employer's liability coverage of $100,000, except in States where workers compensation may not be written by private carriers.

e. Others as required by State law.

1.5 CONTRACTOR SPECIAL REQUIREMENTS

1.5.1 Space Temperature Control, HVAC TAB, and Apparatus Inspection

All contract requirements of Section Section 23 05 93 TESTING, ADJUSTING AND BALANCING FOR HVAC and Section 26 08 00 APPARATUS INSPECTION AND TESTING shall be accomplished directly by a first tier subcontractor, including the Commissioning Agent. No work required by Section 23 05 93 or 26 08 00 shall be accomplished by a second tier subcontractor.

1.6 SUPERVISION

Have at least one qualified supervisor capable of reading, writing, and conversing fluently in the English language on the job site during working hours. In addition, if a Quality Control (QC) representative is required on the contract, then that individual shall also have fluent English communication skills.

1.6.1 SUPERINTENDENT

Superintendent must have a minimum of 5 years experience as a project manager, project engineer, superintendent, or quality control manager on projects similar in size, scope and complexity to this project. The project superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to ensure timely completion. Furthermore, the Contracting Officer may issue an order stopping work on all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop work orders shall be made the subject of a claim for extension of time for excess costs or damages by the contractor.

Approval of the project superintendent is required prior to the start of construction. Provide a resume for the proposed superintendent describing their experience with references and qualifications to the contracting officer for approval. The contracting officer reserves the right to interview the proposed project superintendent at any time in order to verify the submitted qualifications.

1.7 PRECONSTRUCTION CONFERENCE

After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer to discuss and develop a mutual understanding relative to the administration of the contract and safety program, preparation of the schedule of prices, shop drawings, and other submittals, scheduling programming, prosecution of the work, and clear expectations of the "Interim DD Form 1354" Submittal. Major subcontractors who will engage in the work shall also attend.

1.8 PARTNERING

To most effectively accomplish this contract, the Government requires the formation of a cohesive partnership within the Project Team whose members

SECTION 01 30 00 Page 2 are from the Government, the Contractor and their Subcontractors. Key personnel from the Supported Command, the End User (who will occupy the facility), the Contractor and Subcontractors, and the Designer of Record will be invited to participate in the Partnering process. The Partnership will draw on the strength of each organization in an effort to achieve a project that is without any safety mishaps, conforms to the Contract, and stays within budget and on schedule.

The Contracting Officer will provide Information on the partnering process and a list of key and optional personnel who should attend partnering meetings.

1.8.1 Informal Partnering

The Contracting Officer will organize partnering sessions with key personnel of the project team, including Contractor personnel and Government personnel.

The Initial Partnering session will be a part of the Pre-Construction Meeting. Partnering sessions will be held at a location agreed to by the Contracting Officer and the Contractor.

1.9 AVAILABILITY OF CADD DRAWING FILES

After award and upon request, the electronic "Computer-Aided Drafting and Design (CADD)" drawing files will only be made available to the Contractor for use in preparation of construction drawings and data related to the referenced contract subject to the following terms and conditions.

Data contained on these electronic files shall not be used for any purpose other than as a convenience in the preparation of construction drawings and data for the referenced project. Any other use or reuse shall be at the sole risk of the Contractor and without liability or legal exposure to the Government. The Contractor shall make no claim and waives to the fullest extent permitted by law, any claim or cause of action of any nature against the Government, its agents or sub consultants that may arise out of or in connection with the use of these electronic files. The Contractor shall, to the fullest extent permitted by law, indemnify and hold the Government harmless against all damages, liabilities or costs, including reasonable attorney's fees and defense costs, arising out of or resulting from the use of these electronic files.

These electronic CADD drawing files are not construction documents.

Differences may exist between the CADD files and the corresponding construction documents. The Government makes no representation regarding the accuracy or completeness of the electronic CADD files, nor does it make representation to the compatibility of these files with the Contractors hardware or software. In the event that a conflict arises between signed and sealed construction documents prepared by the Government and the furnished CADD files, the signed and sealed construction documents shall govern. The Contractor is responsible for determining if any conflict exists. Use of these CADD files does not relieve the Contractor of duty to fully comply with the contract documents, including and without limitation, the need to check, confirm and coordinate the work of all contractors for the project.

If the Contractor uses, duplicates and/or modifies these electronic CADD files for use in producing construction drawings and data related to this contract, all previous indicia of ownership (seals, logos, signatures, SECTION 01 30 00 Page 3 initials and dates) shall be removed.

1.10 ELECTRONIC MAIL (E-MAIL) ADDRESS

The Contractor shall establish and maintain electronic mail (e-mail) capability along with the capability to open various electronic attachments in Microsoft, Adobe Acrobat, and other similar formats. Within 10 days after contract award, the Contractor shall provide the Contracting Officer a single (only one) e-mail address for electronic communications from the Contracting Officer related to this contract including, but not limited to contract documents, invoice information, request for proposals, and other correspondence. The Contracting Officer may also use email to notify the Contractor of base access conditions when emergency conditions warrant, such as hurricanes, terrorist threats, etc. Multiple email address will not be allowed.

It is the Contractor's responsibility to make timely distribution of all Contracting Officer initiated e-mail with its own organization including field office(s). The Contractor shall promptly notify the Contracting Officer, in writing, of any changes to this email address.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 30 00 Page 4

SECTION 01 32 16.00 20

JBCGS PROJECT SCHEDULE AND PROGRESS DOCUMENTATION

11/09

PART 1 GENERAL

Pursuant to Contract Clause "FAR 52.236-15, Schedules for Construction Contracts," a Project Schedule as described below shall be prepared.

Scheduling of construction shall be the responsibility of the Contractor.

Contractor management personnel actively participate in the development of the project schedule. Contractor management personnel shall coordinate closely with Contracting Officer/CEMNP in the maintenance of the schedule.

Subcontractors and suppliers working on the project shall also contribute in developing and maintaining an accurate schedule. The approved schedule shall be used to measure the progress of work, to aid in evaluating time extensions, and to provide the basis of all progress payments.

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Qualifications; G

Baseline Project Schedule; G 628 CES/CENMP

Initial Contract Progress Report (AF IMT 3065); G 628 CES/CENM

Initial Contract Progress Schedule (AF IMT 3064); G 628 CES/CENM

SD-07 Certificates

Monthly Project Schedule Update; G 628 CES/CENMP

Bi-Weekly Contract Progress Reports (AF IMT 3065); G

Monthly Contract Progress Schedule (AF IMT 3064); G

1.2 QUALIFICATIONS

The Contractor shall designate an authorized representative responsible for preparing and maintaining the project schedule for this contract. This individual shall have prepared and maintained at least 3 previous schedules of similar size, scope and complexity to this contract. A resume outlining the individual's qualifications shall be submitted for acceptance by the Contracting Officer.

1.3 PROJECT SCHEDULE

1.3.1 Basis for Payment

The Project Schedule shall be the basis for measuring Contractor progress.

SECTION 01 32 16.00 20 Page 1

Lack of an approved updated project schedule may result in an inability of the Contracting Officer to evaluate the Contractor's progress for the purposes of payment. The Baseline Project Schedule shall be submitted for approval within 30 calendar days after the Notice to Proceed (NTP) has been acknowledged. Acceptance of an error free current Project Schedule is a condition precedent to processing any Contractor's pay request except bond payments. In the cases where Project Schedule revisions have been directed by the Contracting Officer and those revisions have not been included in the Project Schedule, the Contracting Officer may hold retainage up to the maximum amount allowed by the contract, each payment period, until their visions have been made.

Review comments made by the Government on the Contractor's schedule(s) will not relieve the Contractor from compliance with the requirements of the Contract Documents. The Contractor is responsible for scheduling, sequencing and prosecuting work to comply with the requirements of the Contract Documents. Government acceptance extends only to the activities of the Contractor's schedule that the Government has been assigned responsibility and agrees it is responsible. Comments offered on other parts of the schedule, to which the Contractor is assigned responsibility, are offered as a courtesy and are not conditions of Government acceptance;

but are for the general conformance with established industry scheduling concepts.

1.3.2 Schedule Format

1.3.2.1 Use of Critical Path Method

The Contractor shall use the critical path method (CPM) and the Precedence Diagram Method (PDM) to schedule and control project activities.

1.3.2.2 Scheduling Software

Project schedules shall be prepared and maintained using a commercially available scheduling software program capable of providing all requirements of this specification. Manual methods used to produce any required information shall require prior approval by the Contracting Officer.

1.3.2.3 Level of Detail Required

The Project Schedule shall include an appropriate level of detail to appropriately reflect the complexity of work and to clearly show all construction activities planned for the project as well as all other activities which could impact project completion if delayed, including but not limited to; submittals, government review periods, environmental permitting, material/equipment delivery, utility outages, anticipated weather delays, inspection, testing, and closeout activities. Government and Contractor on-site work activities shall be driven by calendars that reflect Saturdays, Sundays and all Federal Holidays as non-work days.

Activities on the critical path shall be clearly indicated. Separate activities shall be created for each Phase, Area, Floor Level and Location the activity is occurring. On-site construction activities with anticipated durations in excess of 20 working days shall be broken into multiple activities. Tasks related to procurement of long lead materials or equipment (procurement cycles of over 90 days) shall be included as separate activities.

At a minimum, each activity shall include the following information:

SECTION 01 32 16.00 20 Page 2

a. Activity ID

b. Activity Description

c. Original Duration in Work Days

d. Early Start Date

e. Early Finish Date

f. Late Start Date

g. Late Finish Date

h. Total Float

i. Bid Item

j. Percent Complete

All activities shall be identified in the Project Schedule by the Bid Item to which the activity belongs. An activity shall not contain work in more than one bid item.

k. Feature of Work

All activities shall be identified in the Project Schedule according to the Contractor designated Definable Feature of Work to which the activity belongs. An activity shall not contain work in more than one feature of work.

l. Responsibility

All activities shall be identified in the Project Schedule according to the party responsible for accomplishing the work encompassed by the activity.

Responsibility includes, but is not limited to, the subcontracting firm, contractor work force, or government agency performing a given task.

Activities shall not be assigned to more than one responsible party in the Project Schedule.

Project Start Date Milestone: The Contractor shall include as the first activity on the schedule a start milestone titled "Contract Award", which shall have a Mandatory Start constraint equal to the Contract Award Date.

Projected Completion Milestone: The Contractor shall include an unconstrained finish milestone on the schedule titled "Projected Completion", indicating the point in time at which the project is complete and ready for its intended use. This milestone shall have the Contract Completion Date (CCD) as its only successor.

Contract Completion Date (CCD) Milestone: The Contractor shall include as the last activity on the schedule a finish milestone titled "Contract Completion (CCD)", which shall have a Mandatory Finish constraint equal to the Contract Completion Date. The only predecessor to the Contract Completion Date Milestone shall be the Projected Completion milestone.

With the exception of the Contract Award and Contract Completion Date (CCD)milestone activities, no activity shall be open-ended; each activity

SECTION 01 32 16.00 20 Page 3 shall have predecessor and successor ties. Once an activity exists on the approved schedule, it shall not be deleted or renamed to change the scope of the activity, nor shall it be removed from the schedule logic without approval from the Contracting Officer.

Date/time constraint(s) and/or lags, other than those required by the contract, shall not be allowed unless accepted by the Contracting Officer.

1.3.2.4 Submittals and Procedures

Submit project schedule and updates in hard copy and on electronic media acceptable to the Contracting Officer. Submittals shall be understood to be the Contractor's certification that the submitted schedule meets all requirements of the Contract documents, represents the Contractor's plan on how the work shall be accomplished, and accurately reflects the work that has been accomplished and how it was sequenced (as-built logic).

Actual start and Finish dates shall not be automatically updated by default mechanisms that may be included in the CPM scheduling software system.

Actual Start and Finish dates shall match those dates from the Contractor Quality Control Reports. Updating of the percent complete and the remaining duration of any activity shall be independent functions. Program features which calculate one of these parameters from the other shall be disabled.

1.3.3 Project Schedule Updates

The Project Schedule shall be kept current, reflecting actual activity progress and plan for completing the remaining work. Contractor and Government representatives shall meet at monthly intervals to review and agree on the information presented in the updated project schedule. Updated Project Schedules shall also be submitted for Government approval in conjunction with any Contractor requests for additional time. Submit copies of purchase orders and confirmation of delivery dates as directed by the Contracting Officer.

1.3.3.1 Narrative Report

Each updated project schedule shall be accompanied by a narrative report identifying and justifying;

a. progress made in each area of the project

b. the current Critical Path

c. date/time constraint(s), other than those required by the contract

d. changes in the following;

i. added or deleted activitiest

ii. original and remaining durations for activities which have not started

iii. logic

iv. milestones

v. planned sequence of operations

SECTION 01 32 16.00 20 Page 4

vi. critical path

e. pending items and status thereof, including permits, changes orders, and time extensions;

f. status of Contract Completion Date and interim milestones;

g. current and anticipated delays (describe cause of delay and corrective actions)

h. description of current and future schedule problem areas.

Each entry in the narrative report will cite the respective Activity ID and Activity description, the date and reason for the change, and description of the change.

1.4 PROGRESS DOCUMENTATION

1.4.1 Contract Progress Report

Prior to commencement of work, submit the Initial Contract Progress Report(AF IMT 3065). The number of line items on the Contract Progress Schedule shall appropriately reflect the complexity of the work, phasing requirements and other project constraints. At a minimum, the Contract Progress Report shall include a line item for each Definable Feature of Work identified in the approved Quality Control Plan. Once the Initial Contract Progress Report has been approved by the Contracting Officer, submit updated Monthly Contract Progress Reports (AF IMT 3065) for Government approval for the duration of the contract.

1.4.2 Contract Progress Schedules

Prior to commencement of work, submit the Initial Contract Progress Schedule(AF IMT 3064). Work elements shall be identical to the elements listed on the Contract Progress Report (AF IMT 3065) and the overall progress schedule shall reflect the more detailed Project Schedule. Once the Initial Contract Progress Schedule has been approved by the Contracting Officer, submit updated Monthly Contract Progress Schedule (AF IMT 3064) for Government approval for the duration of the contract.

1.4.3 3-Week Look Ahead Schedule

The Contractor shall prepare and issue a 3-Week Look Ahead schedule to provide a more detailed day-to-day plan of upcoming work identified on the Project Schedule. The work plans shall cover the planned work for the current and following two-week period and shall include upcoming outages, closures, preparatory meetings, and initial meetings. Identify critical path activities on the Three-Week Look Ahead Schedule. Three hard copies and one electronic file of the 3-Week Look Ahead Schedule shall be delivered to the Contracting Officer no later than 9 a.m. each Monday and reviewed during the CQC Coordination Meetings.

1.5 CORRESPONDENCE AND TEST REPORTS

All correspondence (e.g., letters, Requests for Information (RFIs), e-mails, meeting minute items, Production and QC Daily Reports, material delivery tickets, photographs, etc.) shall reference Schedule activities that are being addressed. All test reports (e.g., concrete, soil

SECTION 01 32 16.00 20 Page 5 compaction, weld, pressure, etc.) shall reference schedule activities that are being addressed.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

3.1 OWNERSHIP OF FLOAT

Float available in the schedule, at any time, shall not be considered for the exclusive use of either the Government or the Contractor.

3.2 CONTRACT MODIFICATION

Submit a Time Impact Analysis (TIA) with each cost and time proposal for a proposed change clearly illustrating the influence of each change or delay on the Contract Completion Date (CCD) or milestones. TIAs shall be in both narrative and schedule form demonstrating the delay impact. The TIA shall identify the predecessors to new activities and demonstrate impacts to successor activities. The TIA shall show all activity progress as of the date of the proposal. If the impact to the schedule occurs prior to the proposal submission, the TIA schedule shall be updated to show all activity progress as of the time of the impact. If the proposed change does not impact the CCD, a TIA shall not be required.

SECTION 01 32 16.00 20 Page 6

C O

N

TR

A C

T P

R O

G R

E S

S S

C H

E D

U

LE

Fo rm

A pp ro ve d O

M B

N O

-0

(S ee

C on tr ac to r's

In st ru ct io ns o n

R ev er se

P ub lic re po rt in g bu rd en fo r t hi s co lle ct io n of in fo rm at io n is e st im at ed to a ve ra ge m in ut es p er re sp on se , i nc lu di ng th e tim e fo r r ev ie w in g in st ru ct io ns , s ea rc hi ng e xi st in g da ta s ou rc es , g at he rin g an d m ai nt ai ni ng th e da ta n ee de d, a nd c om pl et in g an d re vi ew in g th e co lle ct io n of in fo rm at io n.

S en d co m m en ts re ga rd in g th is b ur de n es tim at e or a ny o th er a sp ec t o f t hi s co lle ct io n of in fo rm at io n, in cl ud in g su gg es tio ns fo r r ed uc in g th is b ur de n to

D ep ar tm en t o f D ef en se

, W as hi ng to n

H ea dq ua rte rs

S er vi ce s, D ire ct or at e fo r I nf or m at io n, O pe ra tio ns a nd

R ep or ts

, 1

Je ffe rs on D av is

H ig hw ay

, S ui te

4, A rli ng to n V

A

-4

2, a nd to th e

O ffi ce o f M an ag em en t a nd B ud ge t P ap er w or k

R ed uc tio n P ro je ct

4-

, W as hi ng to n

D C

P le as e

D O

N O

T R

E

TU

R N y ou r f or m /q ue st io nn ai re to e ith er o f t he se a dd re ss es . S en d yo ur c om pl et ed fo rm /q ue st io nn ai re to

S A

F/ A

Q C

P , 1

A ir

Fo rc e P en ta go n, W as hi ng to n

D C

-1

D A

TE

S

IG

N

E D

D A

TE

S

IG

N

E D

C O

N

TR

A C

TI

N

G O

FF

IC

E R

'S S

IG

N

A

TU

R E

C O

N

TR

A C

TO

R

'S N

AM

E

(L as t, Fi rs t, M id dl e

In iti al

1.

C

O N

TR

A

C T

N O

8.

P R

O

JE

C T

TI

TL

E

3.

C

O M

P

LE

TI

O

N D

A

TE

4.

P

U R

C H

A S

E R

E Q

U E

S T

N O

LI

N

E

N O A

W O

R K

E

LE

M E

N

TS

% C

W E

E K

S

D E

F G

H I

J K

L M

N O

P Q

A P

P R

O V

A L

R E

C O

M M

E N

D E

D B

Y:

D A

TE

S

IG

N

E D

2.

S

TA

R

TI

N

G D

A

TE

IN

S

TA

LL

A

TI

O N

S E

N G

IN

E

E R

'S S

IG

N

A

TU

R E

5.

P

R O

JE

C

T N

O

6.

A

C

TU

A L

S

TA

R

TI

N G

D A

TE

7.

A

C

TU

A L

C O

M P

LE

TI

O N

D A

TE

9.

S

U B

M

IT

TE

D

B Y: A D

D R

E S

S (S tre et

, C ity

, S ta te , Z ip C od e)

C O

N

TR

A C

TO

R

'S S

IG

N

A

TU

R E

A P

P R

O V

E D

B Y:

A F

IM

T

, 2

1, V

P

R E

V

IO

U S

E D

IT

IO

N S

A R

E O

B S

O

LE

TE

C lic k to s ig n

C lic k to s ig n C lic k to s ig n

IN

S

TR

U

C

TI

O N

S T

O C

O N

TR

A

C

TO

R S

1.

P re pa re th re e co pi es o f A F

Fo rm

4, in a cc or da nc e w ith th es e in st ru ct io ns , a nd s ub m it to th e co nt ra ct in g of fic er a t t he ti m e st at ed in th e co nt ra ct o r a s es ta bl is he d by th e co nt ra ct in g of fic er

2.

B lo ck s 1, , a nd

E nt er th e co nt ra ct n um be r, st ar tin g da te

, a nd c om pl et io n da te a s sh ow n on th e co nt ra ct

3.

B lo ck

E nt er th e tit le o f t he p ro je ct a s sh ow n on th e co nt ra ct

4.

B lo ck

E nt er n am e an d ad dr es s of y ou r f irm

Th e th re e co pi es s ub m itt ed to th e co nt ra ct in g of fic er m us t b e da te d an d si gn ed b y th e co nt ra ct or o r a n au th or iz ed re pr es en ta tiv e of th e fir m

5.

L in es th ro ug h

M aj or e le m en ts o f w or k (w he th er u ni t p ric e or lu m p su m c on tra ct

)s uc h as e xc av at io n, c on cr et e w or k, c ar pe nt ry , e ng in ee rin g, in st al la tio n of c om m un ic at io n el ec tro ni c fa ci lit ie s, e tc w ill b e sh ow n in C ol um n B in lo gi ca l s eq ue nc e an d in s uf fic ie nt d et ai l t o id en tif y th e el em en t.

If th e co nt ra ct c al ls fo r m or e th an w or k el em en ts , a dd iti on al c op ie s of th e A

F Fo rm m ay b e us ed as a c on tin ua tio n fo r t he w or k el em en ts

6.

T he p er ce nt ag e of e ac h lis te d w or k el em en t t o th e co m pl et e jo b w ill b e sh ow n op po si te e ac h el em en t i n

C ol um n

C

A s an e xa m pl e, if w or k el em en ts a re s ho w n:

e xc av at io n, c on cr et e w or k, a nd b ac kf ill an d it is e st im at ed th at e xc av at io n is

0% o f t he to ta l j ob , c on cr et e

, a nd b ac kf ill

0%

, t he se p er ce nt ag es w ill b e sh ow n op po si te e ac h el em en t.

T he to ta l m us t e qu al

7.

C ol um ns D th ro ug h

Q w ill b e us ed to s ho w p la nn ed p er io di c pr og re ss

, a s re qu ire d by th e co nt ra ct in g of fic er

, d ur in g th e pe rio d of th e co nt ra ct

O nl y th e to p ha lf of th e sp ac e un de r t he se c ol um ns w ill b e us ed b y co nt ra ct or s.

U si ng th e ex am pl e ci te d ab ov e an d as su m in g th at th e co nt ra ct p er io d fo r p er fo rm an ce is w ee ks , a nd it is p la nn ed to a cc om pl is h o f t he e xc av at io n w or k th e

1s t w ee k an d ea ch w ee k un til e xc av at io n is c om pl et e, w ou ld b e sh ow n in th e up pe r h al f o f L in e un de r C ol um n

D , 2 un de r C ol um n E

, a nd un de r C ol um n

F fo r a to ta l o f 5 0%

If it is p la nn ed to a cc om pl is h th e co nc re te w or k du rin g th e 4t h, th , a nd th w ee ks in e qu al a m ou nt s, w ou ld b e en te re d un de r C ol um ns

G , H

, a nd

I on

L in e 2.

A ss um in g th e ba ck fil l w ill b e ac co m pl is he d du rin g th e

7t h an d

8t h w ee ks w ou ld b e en te re d un de r C ol um ns

J a nd K o n

Li ne

If th e co nt ra ct e xt en ds b ey on d w ee ks , a dd iti on al c op ie s of A

F Fo rm m ay b e us ed a s a co nt in ua tio n of p er fo rm an ce re co rd

8.

T ot al a m ou nt o f w or k pl an ne d at in te rv al s as s ho w n in

C ol um ns

D th ro ug h Q w ill b e to ta le d an d en te re d in th e to p ha lf of th e sp ac e un de r t he a pp ro pr ia te c ol um n of

L in e

A ga in

, u si ng th e ex am pl e ci te d ab ov e, th e to ta ls u nd er C ol um ns D th ro ug h

K w ou ld re ad

0, 0, 0, 0, 0, 0, 0, fo r a to ta l o f 1

Th es e to ta ls w ill b e us ed to p lo t a n ov er la y gr ap h us in g

Li ne s th ro ug h

, b eg in ni ng w ith

C ol um n D a nd e xt en di ng to th e rig ht th e nu m be r o f c ol um ns

(w ee ks au th or iz ed b y th e co nt ra ct fo r p er fo rm an ce ti m e.

9.

I n th e ev en t t he c on tra ct is m od ifi ed b y th e co nt ra ct in g of fic er u nd er te rm s of th e co nt ra ct

, c ha ng in g th e pr og re ss o f w or k as o rig in al ly s ch ed ul ed

, a dd in g or d el et in g w or k or c ha ng in g th e or ig in al co m pl et io n da te

, a re vi se d pr og re ss s ch ed ul e w ill b e pr ep ar ed a nd s ub m itt ed to th e co nt ra ct in g of fic er fo r a pp ro va l.

In p re pa rin g th e re vi se d sc he du le , t he a m ou nt o f w or k co m pl et ed w ill b e co ns id er ed to ge th er w ith th e ch an ge d ne w c om pl et io n da te s et fo rth in th e co nt ra ct m od ifi ca tio n.

C on si de rin g th es e fa ct or s, th e w or k un de r t he c on tra ct w ill b e re sc he du le d ov er th e ne w to ta l p er fo rm an ce ti m e in th e sa m e m an ne r t ha t t he o rig in al s ch ed ul e w as p re pa re d.

T he n ew c om pl et io n da te w ill b e en te re d in B lo ck

"F irs t R ev is ed

S ch ed ul e, "S ec on d

R ev is ed

S ch ed ul e, et c.

, w ill b e en te re d to th e le ft of th e fo rm ti tle

Ti m e of s ub m is si on o f t he re vi se d sc he du le w ill b e de te rm in ed b y th e co nt ra ct in g of fic er

A t s uc h in te rv al s as m ay b e es ta bl is he d by th e co nt ra ct in g of fic er

, t he c on tra ct or w ill s ub m it to th e co nt ra ct in g of fic er A

F Fo rm

5, C on tra ct P ro gr es s

R ep or t," in di ca tin g th e pe rc en ta ge o f w or k ac co m pl is he d fo r e ac h w or k el em en t d ur in g th e es ta bl is he d re po rti ng p er io d.

A cc ur at e re po rts a re o f t he u tm os t i m po rta nc e to th e co nt ra ct or a nd to th e

G ov er nm en t, si nc e th e pe rc en ta ge o f c om pl et io n, or p ro gr es s, th us re po rte d is u se d in a dm in is tra tio n of th e co nt ra ct a nd m ay b e us ed in c on ne ct io n w ith a pp ro va l o f p ar tia l p ay m en ts u nd er th e co nt ra ct

C ar e sh ou ld b e ta ke n to p la n th e w or k in s uc h m an ne r t ha t i t c an b e ac co m pl is he d as s ta te d in th is s ch ed ul e.

I f, fo r a ny re as on , i t b ec om es k no w n th at a ny p ar t o f t he p ro gr es s un de r t hi s co nt ra ct w ill b e de la ye d, th is fa ct s ho ul d be re po rte d to th e co nt ra ct in g of fic er im m ed ia te ly

A F

IM

T

, 2

1, V

P

R E

V

IO

U S

E D

IT

IO

N S

A R

E O

B S

O

LE

TE

OMB NO. 0704-0188CONTRACT PROGRESS REPORT

Public reporting burden for this collection of information is estimated to average 15 minutes per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to the Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports (OMB No. 9000-0058), 1215 Jefferson Davis Highway, Suite 1204, Arlington VA 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number.

PLEASE DO NOT RETURN YOUR FORM TO THE ABOVE ADDRESS. RETURN COMPLETED FORM TO : SAF/AQCO, 1060 Air Force Pentagon, Washington DC 20330-1060.

CONTRACTOR ADDRESS

REPORT NO. PERIOD COVERED

FROM:

PROJECT NO. CONTRACT NO. COMPLETION DATE

TO:

LINE

NO.

% OF

TOTAL JOB

% COMPLETED

THIS PERIOD

% COMPLETED

CUMULATIVE

WORK ELEMENT

TOTAL

REMARKS

At the Contracting Officer's discretion and according to the payments clause of the contract, the information provided on this form may be used for computing progress payments.

PROGRESS OR COMPLETION CERTIFICATE

I hereby certify that the contractor has satisfactorily completed the indicated percentage of the contract per contract specifications.

SUBMITTED BY OR FOR

CONTRACTOR BASE CIVIL ENGINEER

TYPE OR PRINT NAME AND TITLE SIGNATURE DATE

REVIEWED BY OR FOR CONTRACTING OFFICER

TYPE OR PRINT NAME AND TITLE SIGNATURE DATE

AF IMT 3065, 19960401, V1 PREVIOUS EDITION IS OBSOLETE.

Click to sign

Click to sign

SECTION 01 33 00

JBCGS SUBMITTAL PROCEDURES

05/11

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to start of construction (work).

Certificates of insurance Surety bonds List of proposed subcontractors

Project Schedule Contract Progress Schedule Submittal register Health and safety plan Work plan Quality control(QC) plan Environmental protection plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or unfabricated physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of…