FA4417-11-R-0033 Solicitation Cathodic.pdf

-Project Number FTEV 08-1035, Specif ications dated 20 Jun 2011and Draw ings dated 20 Jun 2011

Enter prices in Section B, use TYPEWRITER OR BLACK INK

-THIS ACQUISITION IS A TOTAL SMALL BUSINESS SET ASIDE. OFFERORS ARE BEING SOLICITED FOR ALL SMALL BUSINESS CONCERNS.

See FAR Clause 52.219-6 Notice of Small Business Set-Aside

-Disclosure of magnitude of construction: the estimated amount of this project is betw een $100,000 and $250,000

-This solicitation w ill be aw arded in accordance w ith FAR Part 15, Contracting by Negotiation. Your attention is directed to Sections L and M for proposal preparation.

-DISCUSSION OF OFFER: The government may aw ard a contract solely on initial offers received w ithout discussions of such offer.

Accordingly, each initial offer should be submitted on the most favorable terms from both a price and technical standpoint.

THIS REQUEST FOR PROPOSAL (RFP) IS BEING ISSUED UNDER SPECIAL STRADDLE BID AUTHORITY. FUNDS ARE NOT PRESENTLY

AVAILABLE FOR THIS PROJECT. NO AWARD WILL BE MADE UNDER THIS RFP UNTIL FUNDS ARE AVAILABLE THE GOVERNMENT

RESERVES THE RIGHT TO CANCEL THIS RFP AT ANY TIME BEFORE OR AFTER THE PROPOSED CLOSING DATE WITH NO OBLIGATION TO

THE OFFEROR.

SEE CONTINUATION PAGE FOR ADDITIONAL BLOCK 10 INFORMATION.

MARY E HALLMON 850-884-6626

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

30-Jun-2011

(RFP)

(IFB)

X

CALL:

Install Cathodic Telementry Water Tanks

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________120 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________02 Aug 2011 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______59 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

1 SOCONS

350 TULLY ST

HURLBURT FIELD FL 32544-5810

FA4417

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

FTEV 08-1035

8. ADDRESS OFFER TO (If Other Than Item 7)

850-884-2041FAX:TEL: 850-884-2169 TEL: FAX:

FA4417-11-R-0033 41

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA4417-11-R-0033

Section A - Solicitation/Contract Form

SECTION A, CONTINUATION

BLOCK 10 CONTINUATION

- All offerors MUST complete the Online Representations and Certifications Application (ORCA) @ https://orca.bpn.gov/. Failure to complete all required Representations and Certifications will make your proposal ineligible for award.

- NAICS Code: 237110 Size Standard: $33,500,000

- ENTER CONTRACTOR DUNS NO. ______________________

- ENTER CONTRACTOR CAGE CODE: _______________________

- A SITE VISIT HAS BEEN SCHEDULED FOR 18 Jul 2011 at 1000 AM LOCAL TIME AT THE 1ST SPECIAL

OPERATIONS CONTRACTING SQUADRON, 350 TULLY ST, HURLBURT FIELD, FL 32544. E-mail or fax written request with the name of those who will attend the meeting to Mary Hallmon, Contract Specialist, e-mail mary.hallmon@hurlburt.af.mil and Tina Kneip, Contracting Officer, email tina.kneip@hurlburt.af.mil or fax

(850) 884-2041. Requests must be received by 15 Jul 2011 at 9:00 AM local time. You must enter the base from the main gate (off HWY 98). Please allow extra time to obtain your pass.

- SUBMISSION OF PROPOSALS. Questions regarding this solicitation must be submitted in writing in Word format to the individuals listed above no later than close of business 5 calendar days after the site visit.

- SUBMISSION OF PROPOSALS. Offerors are responsible for submitting proposals so as to reach the Government office designated in the solicitation by the date/time specified. Personnel requiring access to Hurlburt Field for the purpose of delivering a proposal must fax (850) 884-2041or email a written request containing the company time and the name of the person(s) requiring access to Mary Hallmon, Contract Specialist, email mary.hallmon@hurlburt.af.mil and Tina Kneip, Contracting Officer at tina.kneip@hurlburt.af.mil. Requests must be received NLT 72 hours prior to the date and time established for receipt of proposals. You must enter the base from the main gate (off HWY 98). Please allow extra time to obtain your pass.

-VALID ID: For either meetings, site visits and/or submission of proposals, all personnel requesting access to

Hurlburt Field must possess a valid State or Government picture identification card. Personnel requesting vehicle access to Hurlburt Field must provide a valid driver's license, current vehicle registration, and valid vehicle insurance mailto:tina.kneip@hurlburt.af.mil

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lump Sum Install Cathodic Telementry

FFP

The contractor shall furnish all labor, materials, tools, supervision, and equipment to perform all operations necessary to Install Cathodic Telementry on water tanks basewide in accordance with project specifications and drawings, dated 20 Jun

2011.

FOB: Destination

SIGNAL CODE: A

NET AMT

Section E - Inspection and Acceptance

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 PERIOD OF

PERFORMANCE SHALL

BE 120 CALENDAR

DAYS AFTER ISSUANCE

OF NOTICE TO

PROCEED

1 1SOCES

JAMES PERKINS

415 INDEPENDENCE RD

HURLBURT FIELD FL 32544-5267

884-7655

FOB: Destination

F2F323

52.247-34 F.O.B. Destination NOV 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $157.70 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Section H - Special Contract Requirements

HF004 REQUIRED INSURANCE (IAW FAR 28.306(b))

Reference FAR clause entitled ―Insurance...‖ the Contractor shall, at its own expense, procure and thereafter maintain the following kinds of insurance with respect to performance under the contract. The Contractor will have the option to complete a form entitled ―Notification of Compliance with Contract Insurance Requirements‖ that will be provided by the Government at time of award, or to submit an insurance certificate before any work commences on the installation.

a. Workman’s Compensation and Employers Liability Insurance as required by law except that if this contract is to be performed in a state which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such state will be satisfactory. The required Workmen’s compensation insurance shall extend to cover employer’s liability for accidental bodily injury or death and for occupational diseases with a minimum liability limit of $100,000.00.

b. General Liability Insurance. Bodily injury liability insurance, in the minimum limits of $500,000.00 per occurrence shall be required on the comprehensive form of policy.

c. Automobile Liability Insurance. This insurance shall be required on the comprehensive form of policy and shall provide bodily injury liability and property damage liability covering the operation of all automobile used in connection with the performance of the contract. At least the minimum limits of $200,000.00 per person and

$500,000.00 per occurrence for bodily injury and $20,000 per occurrence for property damage shall be required.

HF005 EXCLUSION OF PAYMENT FOR MATERIALS STORED ON SITE

Payment in advance of installation, for materials stored on site, will not be considered under this contract.

HF009 DESIGNATION OF GOVERNMENT INSPECTOR

The Base Civil Engineer (or his/her authorized representative) is designated as the representative of the Contracting

Officer for purpose of serving as the Government's Construction Contract Inspector (CCI). This includes performing technical surveillance, including workmanship, and ensuring compliance with the plans and specifications under this contract. This provision in no way authorizes anyone other than the Contracting Officer to commit the Government to changes in the terms of this contract.

HF010 PREPARATION OF MATERIAL APPROVAL SUBMITTALS

Submittals contemplated by the clause herein entitled "Material and Workmanship" shall be accomplished on and in accordance with instructions pertaining to AF Form 3000 (Material Approval Submittal).

HF011 PREPARATION OF SCHEDULE FOR CONSTRUCTION CONTRACTS

The reports contemplated by clause entitled "Schedule for Construction Contracts" shall be accomplished on and in accordance with instructions pertaining to AF Form 3064 (Contract Progress Schedule) and AF Form 3065 (Contract

Progress Report).

HF012 POST-AWARD/PRE-PERFORMANCE CONFERENCE

A Pre-Performance Conference shall be conducted in accordance with FAR 52.236-26 (IAW FAR 36.522).

HF015 TELEPHONE COMSEC MONITORING

All communications with DOD organizations are subject to COMSEC review. Contractor personnel will be aware that telecommunications networks are continually subject to intercept by unfriendly intelligence organizations. The

DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls originating from or terminating at DOD organizations. Therefore, civilian contractor personnel are advised that any time they place a call to or receive a call from a military organization, they are subject to COMSEC procedures. The contractor will assume the responsibility for ensuring wide and frequent dissemination of the above information to all employees dealing with official DOD information.

HF016 AVAILABILITY OF UTILITIES SERVICES

Notwithstanding provisions of Contract Clause, FAR 52.236-14, "AVAILABILITY AND USE OF UTILITY

SERVICES," reasonable required amounts of water, gas, electricity, etc., essential to contract performance, will be made available at no cost to the contractor from existing systems, outlets, and supplies. Temporary connections, outlets, and distribution lines as required shall be installed by the contractor at his own expense.

HF017 VEHICLE OPERATION AND REGISTRATION

The prime contractor is responsible for all employees or sub-contracting employees performing duties on the Air

Force installation cited in the contract. The contractor shall obtain base identification and a vehicle pass for all contractor personnel who make frequent visits to or perform work while on the Air Force installation cited in the contract. Upon receipt of award, the contractor will be provided a letter signed by the Contracting Officer to be taken to the Pass and Registration section to obtain a visitor pass.

HF018 HOURS OF WORK

Normal hours of work on Hurlburt Field are 7:00 AM to 4:00 PM (CST), Monday through Friday, excluding holidays. Access to work sites is restricted to these hours and days unless otherwise approved by the Contracting

Officer three (3) workdays in advance.

HF019 INSTALLATION RULES AND REGULATIONS

Rules and regulations of Hurlburt Field apply to all contractors and their employees. Regulations include, but are not limited to, presenting valid picture identification for base entrance, obtaining and using vehicle passes for all contractor-owned and/or privately owned vehicles, obeying all posted directives, and strictly adhering to security police direction where security police have been dispatched to a particular location.

HF020 HURRICANE SEASON

Hurricane season for the state of Florida is normally the period from 1 June through 30 November. During an actual hurricane condition, you may be contacted by this office and requested to secure equipment and clean up your work area. In accordance with contracts clauses FAR 52.236-9 and FAR 52.236-12, you are required to maintain your work area free of debris and in a safe and secure condition at the completion of each workday, with particular care during the hurricane season.

HF029 WORK BY THE GOVERNMENT OR OTHERS

The government reserves the right to undertake performance by government forces or other contractors the same type or similar work as the government deems necessary or desirable and to do so will not breach or otherwise violate this contract.

HF037 WIDE AREA WORK FLOW DODAAC AND EMAIL DISTRIBUTION TABLE

DFARS 252.232-7003 Electronic Submission of Payment Requests applies to this contract.

USE OF WAWF IS MANDATORY – Requests for payment shall be processed electronically via the Wide Area

Work Flow (WAWF) system. There are no charges or fees to use WAWF. If you are not currently registered with

WAWF, contact the WAWF Help Desk at 1-866-618-5988 or 1-801-605-7095. Web Based Training is located at http://www.wawftraining.com/ and a live training database is located at https://wawftraining.eb.mil/. For specific questions, contact your administrator listed on the front of this contract.

Questions concerning payment should be directed to the Defense Finance Accounting Services (DFAS) Limestone at

1-800-390-5620 or faxed to 1-866-392-7091. You must have your contract number and invoice number ready when inquiring about payment status. Payment information can also be accessed at the DFAS web site:

http://www.dfas.mil.

The following codes will be required to route your invoices and emails through WAWF.

CAGE CODE:

ISSUE DODAAC: FA4417

ADMIN DODAAC: FA4417

http://www.wawftraining.com/ https://wawftraining.eb.mil/ http://www.dfas.mil/

INSPECT BY DODAAC: F2F332

SERVICE ACCEPTOR: F2F332

SHIP-TO CODE: F2F323

PAY DODAAC: F67100

FSC CODE: Z245

EMAIL POINT OF CONTACT LISTING: (Send emails to the following personnel):

SERVICE ACCEPTOR: TINA.KNEIP@HURLBURT.AF.MIL

CONTRACT ADMINISTRATOR: MARY.HALLMON@HURLBURT.AF.MIL

CONTRACTING OFFICER: RANDALL.POWELL@HURLBURT.AF.MIL

ADDITIONAL CONTACTS:

TYPE OF INVOICE: Recommend using the type of invoice indicated with "X" below:

__ Invoice as 2-in-1 (Recommended for Services)

__ Invoice and Receiving Report (Combo) (Recommended for Supplies)

__ Invoice Only

_X_ Construction (NOTE: Invoices to be submitted only AFTER receipt of approved AF Form 3065, Contract Progress Report)

HF038 BASE RECYCLE PROGRAM

The contractor shall support and comply with all requirements of the Hurlburt Field Qualified Recycling Program

(QRP). The following instruction outlines procedures for the collection and handling of applicable recyclable materials:

Hurlburt Field Instruction (HFI) 32-7002 ―Qualified Recycling Program‖ dated 1 May 2002 – contact

1SOCES/CEV, 884-7964 for current copy

PROCESSING APPROVAL AND REPORTING USAGE OF HAZARDOUS MATERIALS ON HURLBURT

FIELD

Contractor shall comply with ALL rules and regulations for processing/using hazardous materials on Hurlburt Field, FL. The following regulations are applicable:

Air Force Instruction (AFI) 32-7086 ―Hazardous Materials Management‖ dated 1 Nov 2004

Download at: http://www.e-publishing.af.mil/pubfiles/af/32/afi32-7086/afi32-7086.pdf

HF042 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (JUN 08)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) Contractors will be required to complete the following forms (to be provided at the pre-performance conference) in order for employees to gain access to the installation:

(1) Contractor Employee Listing

(2) Hurlburt Field Contractor Access Badge Affidavit (CAB)

(3) Department of Homeland Security Form I-9 (DHS I-9)

(i) The Contractor Employee List. This form must list every employee requiring access. Every time employees change, it must be updated to reflect additions and/or deletions. Identify those individuals you wish to have escort authority by including the word ―escort‖ next to their names. Limit the number of individuals designated as escorts to a reasonable number (i.e. one or two). For work locations please use building numbers or areas (i.e.

Bldg 90618 or Red Horse, AMMO Area, etc.). Once completed, email the list to the Contracting Office representative in EXCEL or WORD format. The Contracting Officer will then prepare and attach a cover letter, and forward the Employee List to the Visitor Control Center.

(ii) Upon notification that your employee list has been forwarded to the Visitor Control Center, the other two forms (DHS I-9 & CAB) must be completed and hand carried to the Visitor Control Center by the employee. If everything is in order, they will receive a contractor badge. If an employee will be driving on Hurlburt Field they are required to provide a valid driver’s license, vehicle registration, and proof of insurance. NOTE: The section of the

Visitor Control Center administrating this function is closed after 1400 (2:00 p.m.), therefore, employees must arrive prior to this time in order for their documentation to be processed.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel

Security Program Management, citing the appropriate paragraphs as applicable.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Failure to comply with these requirements may result in withholding of final payment.

(End of clause) http://www.e-publishing.af.mil/search.asp?keyword=AFI+31-101&Go.x=8&Go.y=10 http://www.e-publishing.af.mil/pubfiles/af/31/afi31-501/afi31-501.pdf

Section I - Contract Clauses

52.202-1 Definitions JUL 2004

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees APR 1984

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures OCT 2010

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-4 Printed or Copied Double-Sided on Recycled Paper AUG 2000

52.204-7 Central Contractor Registration APR 2008

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

DEC 2010

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.219-6 Notice Of Total Small Business Set-Aside JUN 2003

52.219-8 Utilization of Small Business Concerns JAN 2011

52.219-14 Limitations On Subcontracting DEC 1996

52.222-1 Notice To The Government Of Labor Disputes FEB 1997

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-6 Davis Bacon Act JUL 2005

52.222-7 Withholding of Funds FEB 1988

52.222-8 Payrolls and Basic Records JUN 2010

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) JUL 2005

52.222-12 Contract Termination-Debarment FEB 1988

52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility FEB 1988

52.222-21 Prohibition Of Segregated Facilities FEB 1999

52.222-26 Equal Opportunity MAR 2007

52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-35 Equal Opportunity for Veterans SEP 2010

52.222-36 Affirmative Action For Workers With Disabilities OCT 2010

52.222-37 Employment Reports on Veterans SEP 2010

52.222-50 Combating Trafficking in Persons FEB 2009

52.222-54 Employment Eligibility Verification JAN 2009

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997

52.223-5 Pollution Prevention and Right-to-Know Information AUG 2003

52.223-6 Drug-Free Workplace MAY 2001

52.223-14 Toxic Chemical Release Reporting AUG 2003

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges Of Assets SEP 2009

52.228-12 Prospective Subcontractor Requests for Bonds OCT 1995

52.228-14 Irrevocable Letter of Credit DEC 1999

52.228-15 Performance and Payment Bonds--Construction OCT 2010

52.229-3 Federal, State And Local Taxes APR 2003

52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002

52.232-17 Interest OCT 2010

52.232-18 Availability Of Funds APR 1984

52.232-23 Alt I Assignment of Claims (Jan 1986) - Alternate I APR 1984

52.232-27 Prompt Payment for Construction Contracts OCT 2008

52.232-33 Payment by Electronic Funds Transfer--Central Contractor

Registration

OCT 2003

52.233-1 Disputes JUL 2002

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Items DEC 2010

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2010

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (May 2004) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Alt A Central Contractor Registration (52.204-7) Alternate A SEP 2007

252.204-7006 Billing Instructions OCT 2005

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7006 Prohibition On Storage And Disposal Of Toxic And

Hazardous Materials

APR 1993

252.225-7012 Preference For Certain Domestic Commodities JUN 2010

252.227-7033 Rights in Shop Drawings APR 1966

252.231-7000 Supplemental Cost Principles DEC 1991

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

MAR 2008

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment MAR 1998

252.244-7000 Subcontracts for Commercial Items and Commercial

Components (DoD Contracts)

NOV 2010

252.247-7023 Transportation of Supplies by Sea MAY 2002

252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2009)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and

Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the

Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in

ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237110.

(Contractor to sign and date and insert authorized signer's name and title).

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of ―recovered material.‖

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to

1 SOCONS/LGCB

350 Tully St

Hurlburt Field, FL 32544

52.225-9 BUY AMERICAN ACT—CONSTRUCTION MATERIALS (SEP 2010)

(b) (2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: NONE

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

(a) Except as authorized by the Office of Foreign Assets Control (OFAC) in the Department of the Treasury, the

Contractor shall not acquire, for use in the performance of this contract, any supplies or services if any proclamation, Executive order, or statute administered by OFAC, or if OFAC's implementing regulations at 31 CFR chapter V, would prohibit such a transaction by a person subject to the jurisdiction of the United States.

(b) Except as authorized by OFAC, most transactions involving Cuba, Iran, and Sudan are prohibited, as are most imports from Burma or North Korea, into the United States or its outlying areas. Lists of entities and individuals subject to economic sanctions are included in OFAC's List of Specially Designated Nationals and Blocked Persons at

TerList1.html. More information about these restrictions, as well as updates, is available in the OFAC's regulations at

31 CFR chapter V and/or on OFAC's Web site at http://www.treas.gov/offices/enforcement/ofac/.

(c) The Contractor shall insert this clause, including this paragraph (c), in all subcontracts.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

HTTP://FARSITE.HILL.AF.MIL

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any DEFENSE FEDERAL ACQUISITION REGULATION (48

CFR CHAPTER 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and http://farsite.hill.af.mil/

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

See Section J

252.247-7023 Transportation of Supplies by Sea (MAY 2002)

(a) Definitions. As used in this clause --

(1) "Components" means articles, materials, and supplies incorporated directly into end products at any level of manufacture, fabrication, or assembly by the Contractor or any subcontractor.

(2) "Department of Defense" (DoD) means the Army, Navy, Air Force, Marine Corps, and defense agencies.

(3) "Foreign flag vessel" means any vessel that is not a U.S.-flag vessel.

(4) "Ocean transportation" means any transportation aboard a ship, vessel, boat, barge, or ferry through international waters.

(5) "Subcontractor" means a supplier, materialman, distributor, or vendor at any level below the prime contractor whose contractual obligation to perform results from, or is conditioned upon, award of the prime contract and who is performing any part of the work or other requirement of the prime contract.

(6) "Supplies" means all property, except land and interests in land, that is clearly identifiable for eventual use by or owned by the DoD at the time of transportation by sea.

(i) An item is clearly identifiable for eventual use by the DoD if, for example, the contract documentation contains a reference to a DoD contract number or a military destination.

(ii) "Supplies" includes (but is not limited to) public works; buildings and facilities; ships; floating equipment and vessels of every character, type, and description, with parts, subassemblies, accessories, and equipment; machine tools; material; equipment; stores of all kinds; end items; construction materials; and components of the foregoing.

(7) "U.S.-flag vessel" means a vessel of the United States or belonging to the United States, including any vessel registered or having national status under the laws of the United States.

(b)(1) The Contractor shall use U.S.-flag vessels when transporting any supplies by sea under this contract.

(2) A subcontractor transporting supplies by sea under this contract shall use U.S.-flag vessels if--

(i) This contract is a construction contract; or

(ii) The supplies being transported are--

(A) Noncommercial items; or

(B) Commercial items that--

(1) The Contractor is reselling or distributing to the Government without adding value (generally, the Contractor does not add value to items that it contracts for f.o.b. destination shipment);

(2) Are shipped in direct support of U.S. military contingency operations, exercises, or forces deployed in humanitarian or peacekeeping operations; or

(3) Are commissary or exchange cargoes transported outside of the Defense Transportation System in accordance with 10 U.S.C. 2643.

(c) The Contractor and its subcontractors may request that the Contracting Officer authorize shipment in foreign-flag vessels, or designate available U.S.-flag vessels, if the Contractor or a subcontractor believes that --

(1) U.S.-flag vessels are not available for timely shipment;

(2) The freight charges are inordinately excessive or unreasonable; or

(3) Freight charges are higher than charges to private persons for transportation of like goods.

(d) The Contractor must submit any request for use of other than U.S.-flag vessels in writing to the Contracting

Officer at least 45 days prior to the sailing date necessary to meet its delivery schedules. The Contracting Officer will process requests submitted after such date(s) as expeditiously as possible, but the Contracting Officer's failure to grant approvals to meet the shipper's sailing date will not of itself constitute a compensable delay under this or any other clause of this contract. Requests shall contain at a minimum --

(1) Type, weight, and cube of cargo;

(2) Required shipping date;

(3) Special handling and discharge requirements;

(4) Loading and discharge points;

(5) Name of shipper and consignee;

(6) Prime contract number; and

(7) A documented description of efforts made to secure U.S.-flag vessels, including points of contact (with names and telephone numbers) with at least two U.S.-flag carriers contacted. Copies of telephone notes, telegraphic and facsimile message or letters will be sufficient for this purpose.

(e) The Contractor shall, within 30 days after each shipment covered by this clause, provide the Contracting Officer and the Maritime Administration, Office of Cargo Preference, U.S. Department of Transportation, 400 Seventh

Street SW., Washington, DC 20590, one copy of the rated on board vessel operating carrier's ocean bill of lading, which shall contain the following information:

(1) Prime contract number;

(2) Name of vessel;

(3) Vessel flag of registry;

(4) Date of loading;

(5) Port of loading;

(6) Port of final discharge;

(7) Description of commodity;

(8) Gross weight in pounds and cubic feet if available;

(9) Total ocean freight in U.S. dollars; and

(10) Name of the steamship company.

(f) The Contractor shall provide with its final invoice under this contract a representation that to the best of its knowledge and belief--

(1) No ocean transportation was used in the performance of this contract;

(2) Ocean transportation was used and only U.S.-flag vessels were used for all ocean shipments under the contract;

(3) Ocean transportation was used, and the Contractor had the written consent of the Contracting Officer for all non-

U.S.-flag ocean transportation; or

(4) Ocean transportation was used and some or all of the shipments were made on non-U.S.-flag vessels without the written consent of the Contracting Officer. The Contractor shall describe these shipments in the following format:

ITEM CONTRACT QUANTITY

DESCRIPTION LINE ITEMS

TOTAL_______________________________________________________________

(g) If the final invoice does not include the required representation, the Government will reject and return it to the

Contractor as an improper invoice for the purposes of the Prompt Payment clause of this contract. In the event there has been unauthorized use of non-U.S.-flag vessels in the performance of this contract, the Contracting Officer is entitled to equitably adjust the contract, based on the unauthorized use.

(h) In the award of subcontracts for the types of supplies described in paragraph (b)(2) of this clause, the Contractor shall flow down the requirements of this clause as follows:

(1) The Contractor shall insert the substance of this clause, including this paragraph (h), in subcontracts that exceed the simplified acquisition threshold in part 2 of the Federal Acquisition Regulation.

(2) The Contractor shall insert the substance of paragraphs (a) through (e) of this clause, and this paragraph (h), in subcontracts that are at or below the simplified acquisition threshold in part 2 of the Federal Acquisition Regulation.

5352.201-9101 OMBUDSMAN (AUG 2005)

OMBUDSMAN (AUG 2005)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, concerned parties may contact the Center/MAJCOM ombudsmen Lt Col Eric Brewington, HQ AFSOC/A7K, 427 Cody Avenue, Suite 225, Hurlburt Field, FL 32544;

Phone: (850) 884-3990, fax: (850) 884-2476. Concerns, issues, disagreements, and recommendations that cannot be resolved at the MAJCOM/DRU level, may be brought by the concerned party for further consideration to the Air

Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force

Pentagon, Washington DC 20330-1060, phone number (703) 588-7004, facsimile number (703) 588-1067.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.223-9000 ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODSs) (APR

2003)

(a) Unless the requiring activity has obtained prior Senior Acquisition Official (SAO) approval, contractors may not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and http://www.whitehouse.gov/omb/circulars/a076/a76_rev2003.pdf http://www.e-publishing.af.mil/pubfiles/af/32/afi32-7086/afi32-7086.pdf

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

(c) The requiring activity has obtained SAO approval to permit the contractor to use the following Class I ODS(s):

Class I ODS/ Application or Use/Quantity (lbs.) per contract period of performance

NONE

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

5352.242-9000 Contractor access to Air Force installations.

As prescribed in 5342.490-1, insert a clause substantially the same as the following clause in solicitations and contracts:

Clause replaced by HF042 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/af_afmc/affars/5342.htm#P35_364

Section J - List of Documents, Exhibits and Other Attachments

LIST OF ATTACHMENTS

ATCH TITLE DATE NR OF PAGES

1. Specifications 20 Jun 2011 72

2. Drawings 20 Jun 2011 10

3. Schedule of Wage Rates 21 Jan 2011 5

Decision No.: FL20080128

4. Past Performance Questionnaire Undated 3

5. Financial Institution Reference Sheet Undated 1

AMENDMENTS: Amendments issued to this solicitation will be part of any resultant contract and will be listed above at the time of award.

Section K - Representations, Certifications and Other Statements of Offerors

52.236-28 Preparation of Proposals--Construction OCT 1997

252.209-7001 Disclosure of Ownership or Control by the Government of a

Terrorist Country

JAN 2009

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2011)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237110.

(2) The small business size standard is $33,500,000.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the clause at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the clause at 52.204-7 is not included in this solicitation, and the offeror is…