FA3030-17-R-0003_Released.pdf

SEE ADDENDUM

(No Collect Calls)

FA303017R0003 10-Jul-2017

b. TELEPHONE NUMBER

(325) 654-3605

8. OFFER DUE DATE/LOCAL TIME

02:00 PM 28 Jul 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

FA30309. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

JENNIFER L. JEFFERSON

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

1 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

F1Z50V6153AW01

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

17TH CONTRACTING SQUADRON -FA3030

210 SCHERZ BLVD

BRENDA.SIZEMORE.1@US.AF.MIL

GOODFELLOW AFB TX 76908-4705

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE F1Z50V 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

17 TRSS/TSR - F1Z50V

MARK SEALS

170 GRIFFIN ST

BLDG 448

GOODFELLOW AFB TX 76908

TEL: (325) 654-3732 FAX:

(325) 654-5052FAX:

TEL: (325) 654-3821 SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$38,500,000

NAICS:

561210

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF77

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

FA303017R0003

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 12 Months Labor

FFP

Maintenance and Repair Training Aids and Devices including AGE and Historical/Static Displays IAW attached PWS.

FOB: Destination

PURCHASE REQUEST NUMBER: F1Z50V6153AW01

NET AMT

0002 1 Lot Travel

FFP

Reimbursement for Travel IAW Joint Travel Regulation. This is a Not to Exceed total.

0003 1 Lot Reimbursable Supplies

FFP

Reimbursement for supplies. This is a Not to Exceed total.

0004 16 Days Transition Period

FFP

Transition Period

1001 12 Each OPTION Labor

FFP

Maintenance and Repair Training Aids and Devices including AGE and Historical/Static Displays IAW attached PWS.

1002 1 Lot OPTION Travel

FFP

Reimbursement for Travel IAW Joint Travel Regulation. This is a Not to Exceed total

1003 1 Lot OPTION Reimbursable Supplies

FFP

Reimbursement for supplies. This is a Not to Exceed total.

2001 12 Months OPTION Labor

FFP

Maintenance and Repair Training Aids and Devices including AGE and

2002 1 Lot OPTION Travel

FFP

Reimbursement for Travel IAW Joint Travel Regulation. This is a Not to Exceed

2003 1 Lot OPTION Reimbursable Supplies

FFP

3001 12 Months OPTION Labor

FFP

Maintenance and Repair Training Aids and Devices including AGE and

3002 1 Lot OPTION Travel

FFP

Reimbursement for Travel IAW Joint Travel Regulation. This is a Not to Exceed

3003 1 Lot OPTION Reimbursable Supplies

FFP

4001 12 Months OPTION Labor

FFP

Maintenance and Repair Training Aids and Devices including AGE and

4002 1 Lot OPTION Travel

FFP

Reimbursement for Travel IAW Joint Travel Regulation. This is a Not to Exceed

4003 1 Lot OPTION Reimbursable Supplies

FFP

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government 1001 Destination Government Destination Government 1002 Destination Government Destination Government 1003 Destination Government Destination Government 2001 Destination Government Destination Government 2002 Destination Government Destination Government 2003 Destination Government Destination Government 3001 Destination Government Destination Government 3002 Destination Government Destination Government 3003 Destination Government Destination Government 4001 Destination Government Destination Government 4002 Destination Government Destination Government 4003 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 01-OCT-2017 TO

30-SEP-2018

N/A 17 TRSS/TSR - F1Z50V

MARK SEALS

170 GRIFFIN ST

BLDG 448

GOODFELLOW AFB TX 76908

(325) 654-3732

F1Z50V

0002 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0003 POP 01-OCT-2017 TO

N/A (SAME AS PREVIOUS LOCATION)

0004 POP 18-SEP-2017 TO

30-SEP-2017

N/A (SAME AS PREVIOUS LOCATION)

1001 POP 01-OCT-2018 TO

30-SEP-2019

N/A (SAME AS PREVIOUS LOCATION)

1002 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

1003 POP 01-OCT-2018 TO

N/A (SAME AS PREVIOUS LOCATION)

2001 POP 01-OCT-2019 TO

30-SEP-2020

N/A (SAME AS PREVIOUS LOCATION)

2002 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

2003 POP 01-OCT-2019 TO

N/A (SAME AS PREVIOUS LOCATION)

3001 POP 01-OCT-2020 TO

30-SEP-2021

N/A (SAME AS PREVIOUS LOCATION)

3002 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

3003 POP 01-OCT-2020 TO

N/A (SAME AS PREVIOUS LOCATION)

4001 POP 01-OCT-2021 TO

30-SEP-2022

N/A (SAME AS PREVIOUS LOCATION)

4002 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

4003 POP 01-OCT-2021 TO

N/A (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.203-6 Alt I Restrictions On Subcontractor Sales To The Government

(Sep 2006) -- Alternate I

OCT 1995

52.203-13 Contractor Code of Business Ethics and Conduct OCT 2015 52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreeements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.212-1 Instructions to Offerors--Commercial Items JAN 2017 52.212-4 Contract Terms and Conditions--Commercial Items JAN 2017 52.217-5 Evaluation Of Options JUL 1990 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting JAN 2017 52.222-3 Convict Labor JUN 2003 52.222-17 Nondisplacement of Qualified Workers MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-41 Service Contract Labor Standards MAY 2014 52.222-43 Fair Labor Standards Act And Service Contract Labor

Standards - Price Adjustment (Multiple Year And Option Contracts)

MAY 2014

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-11 Ozone-Depleting Substances and High Global Warming

Potential Hydrofluorocarbons.

JUN 2016

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.223-20 Aerosols JUN 2016 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.228-5 Insurance - Work On A Government Installation JAN 1997 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.237-1 Site Visit APR 1984 52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation

APR 1984

52.237-3 Continuity Of Services JAN 1991 52.242-13 Bankruptcy JUL 1995 52.242-15 Stop-Work Order AUG 1989 52.245-1 Government Property JAN 2017 52.245-9 Use And Charges APR 2012 52.246-4 Inspection Of Services--Fixed Price AUG 1996 52.247-34 F.O.B. Destination NOV 1991 52.247-55 F.O.B. Point For Delivery Of Government-Furnished

Property

JUN 2003

52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.211-7007 Reporting of Government-Furnished Property AUG 2012 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7012 Preference For Certain Domestic Commodities DEC 2016 252.225-7013 Duty-Free Entry--Basic (May 2016) MAY 2016 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

SEP 2004

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.239-7001 Information Assurance Contractor Training and Certification JAN 2008 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property APR 2012 252.245-7003 Contractor Property Management System Administration APR 2012 252.245-7004 Reporting, Reutilization, and Disposal SEP 2016 252.247-7023 Transportation of Supplies by Sea APR 2014 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

5352.223-9001 HEALTH AND SAFETY ON GOVERNMENT

INSTALLATIONS

NOV 2012

CLAUSES INCORPORATED BY FULL TEXT

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS (APR 2014)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C. 4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and FAR 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section 3.908 of the Federal Acquisition Regulation.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold.

(End of clause)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC

2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of clause)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

a. Basis for Contract Award

This is a best value source selection conducted in accordance with Federal Acquisition Regulation (FAR) 15.3, Source Selection, as supplemented by the Defense Federal Acquisition Regulation Supplement (DFARS), and the Air Force Federal Acquisition Regulation Supplement (AFFARS). These regulations are available electronically at the Air Force (AF) FARSite, http://farsite.hill.af.mil. The Government will select the best overall offer, based upon an integrated assessment of Technical, Past Performance, and Price. A Contract may be awarded to the offeror who is deemed responsible in accordance with the FAR, as supplemented, whose proposal conforms to the solicitation’s requirements (to include all stated terms, conditions, representations, certifications, and all other information required by Section L of this solicitation) and is judged, based on the evaluation factors and subfactors to represent the best value to the Government. Technical tradeoffs will not be made and no additional credit will be given for exceeding acceptability. Award will be made to the Acceptable offeror with a (1) Technically Acceptable proposal

(2) Acceptable Past Performance and (3) The lowest Total Evaluated Price (TEP), which is deemed to be reasonable and balanced. The evaluation process shall proceed in accordance with (IAW) the evaluation instructions listed below. The SSA will base the source selection decision on an integrated assessment of proposals against all source selection criteria in the solicitation (described below). While the Government source selection evaluation team and the SSA will strive for maximum objectivity, the source selection process, by its nature, is subjective; and therefore, professional judgment is implicit throughout the entire process.

Prior to any evaluations, the Source Selection Evaluation Team (SSET) will capture the TEP for each offer and rank them lowest to highest. After they are arranged the evaluations will begin for the three lowest priced proposals.

First, the Technical Volume (Volume I) will be evaluated. Second, the Past Performance Volume (Volume II) will be evaluated for all technically acceptable proposals. Proposals that have been rated as "Acceptable" in both the Technical and Past Performance factors will then be evaluated based on the reasonableness and balance of the price.

The lowest priced proposal, found to be reasonable and balanced, and has been rated “Acceptable” in both technical and past performance factors will be awarded the contract.

If any of the three lowest offeror’s are deemed unacceptable regarding Technical and/or Past Performance the next lowest proposal(s) will be evaluated in accordance with the evaluation instructions listed below ensuring at least two acceptable proposals are able to be compared for competitive pricing.

b. Number of Contracts to be awarded

The Government intends to make a single award as a result of this solicitation.

c. Competitive Advantage from Use of GFP.

The Government will eliminate any competitive advantage resulting from an offeror's proposed use of Government-furnished property (GFP). The government will not assess any fees for use of the GFP on this acquisition and the accountability for GFP is outlined in the contract documents. GFP is to be used only in performing work under this contract. GFP is provided on Solicitation Attachment 2.

d. Discussions

If, during the evaluation period, it is determined to be in the best interest of the Government to hold discussions, offeror responses to Evaluation Notices (ENs) and the Final Proposal Revision (FPR) will be considered in making the source selection decision. If the offeror’s proposal has been evaluated as acceptable at the time discussions are closed, any changes or exceptions in the Final Proposal Revision are subject to evaluation and may introduce risk that the offeror’s proposal be determined unacceptable and ineligible for award.

e. Solicitation Requirements, Terms and Conditions

Offerors are required to meet all solicitation requirements, such as terms and conditions, representations and certifications, and technical requirements, in addition to those identified as factors or subfactors. Failure to comply with the terms and conditions of the solicitation may result in the offeror being ineligible for award. Offerors must clearly identify any exception to the solicitation terms and conditions and must provide complete supporting rationale. The Government reserves the right to determine any such exceptions unacceptable.

EVALUATION FACTORS

a. Evaluation Factors and Subfactors

The following evaluation factors and subfactors will be used to evaluate each proposal. The Government will evaluate proposals for acceptability, but will not rank the proposals by the non-price factors or subfactors.

Factor 1: Price

Factor 2: Technical

Subfactor One – Staffing and Organizational charts of all functional elements to include staffing by labor category and skill mix for basic and each option period.

Subfactor Two – Demonstrated Experience Subfactor Three – Certifications

Factor 3: Past Performance

b. Price Factor

Offerors whose price is determined to be unreasonable or unbalanced may not be considered for award.

(1) Initially, offers will be ranked according to total evaluated price (TEP), to include option prices. An offeror’s TEP will be determined by multiplying the quantity identified in Section B by the proposed unit price for Contract Line Item Numbers (CLINs) X001 to confirm the extended amount for each. Contract Line Item Numbers X002 & X003 will not be factored into the TEP as they are cost-reimbursable CLINs.

(2) Evaluation of options shall not obligate the Government to exercise options.

(3) Reasonableness: The offeror’s Price proposal will be evaluated to ensure it is fair and reasonable, pursuant to FAR 15.404. For additional information see FAR 31.201-3.

(4) Unbalanced Pricing: The Government will analyze proposals to determine whether they are unbalanced with respect to separately priced line items in accordance with FAR 15.404-1. An offer may be rejected if the contracting officer determines that the lack of balance poses an unacceptable risk to the Government.

c. Technical Factor

The Government’s technical evaluation team shall evaluate the technical proposals on an acceptable or unacceptable basis, assigning one of the ratings described below for each subfactor. Any subfactor evaluated as “Unacceptable” will render the entire proposal unacceptable and, therefore, unawardable. Only those proposals determined to be technically acceptable, either initially or as a result of discussions, will be considered for award. However, the offeror is reminded that the Government reserves the right to award this effort based on the initial proposal, as received, without discussion.

The proposals shall be evaluated against the following technical subfactors:

Subfactor 1: Staffing/Manning

TABLE 1 - TECHNICAL RATINGS

Rating Description

Acceptable Proposal clearly meets the minimum requirements of the solicitation.

Unacceptable Proposal does not clearly meet the minimum requirements of the solicitation.

Description: Staffing and Organizational Chart(s) of all functional elements, to include staffing by labor category and skill-mix (for basic period and each option period).

Measure of Merit: This requirement is met when the offeror’s proposal does the following:

a) Provides a complete organizational structure, including charts and rationale for the proposed organization, to include roles, responsibilities, and relationships for each organizational element.

b) If cross-utilization of personnel is proposed, provides an adequate methodology to cross utilize personnel within each functional area and indicates the percentage of workforce that will be cross-utilized to reduce manning and still maintain the proper skill mix and staff levels to execute the mission as stated in the Performance Work Statement (PWS).

c) Addresses adequate processes for sustaining trained and qualified personnel, including training management and instructor staffing approaches that ensure employees are fully trained, task proficient, and task certified throughout the life of the contract.

d) Describes an adequate approach for Collective Bargaining Agreements that are already in place and contingencies that will assure there will be no interruption of services due to labor disruption and disputes.

Subfactor 2: Demonstrated Experience

Description: Submit a narrative and/or other documentation (i.e. proposed employee work experience or resumes) demonstrating a thorough understanding of the following skills and applicable work experience:

a) Aircraft Mechanic

b) Maintenance Pipe Fitter

c) Aircraft Quality Control Inspector

d) Self-Contained Breathing Apparatus Technician

e) Maintenance Carpenter

f) Aircraft Painter

g) Welder

h) Life Support Specialist

i) Production Control Clerk

j) Fabric Worker

k) Survival Equipment Specialist

l) Aerospace Ground Equipment Mechanic

Measure of Merit: This requirement is met when the offeror’s provides sufficient information demonstrating a thorough understanding and applicable work experience for all of the listed skill sets above.

Subfactor 3: Certifications

Description: Submit certifications for the following:

a) Survival Equipment Specialist Certification name is: Mine Safety Appliance Company (MSA) - M7 Responder Certified Air Mask

Education (C.A.R.E.) Technician Air Pack Facility must be a certified C.A.R.E. Authorized Repair Center

b) Aerospace Ground Equipment (AGE) Mechanic

Certificate for Processing Chlorofluorocarbon (CFC) / Hydrochlorofluorocarbon (HCFC) Refrigerants

Measure of Merit: This requirement is met when the offeror’s proposed employee(s) show certification required within subfactor 3 as described above.

d. Performance Factor

The Past Performance evaluation results in an assessment of the offeror’s probability of meeting the solicitation requirements. Offerors must receive a past performance rating of “Acceptable” to be eligible for award.

(1) Ratings. The Past Performance factor will receive one of the ratings described below.

(2) Evaluation Process. The past performance evaluation considers each offeror’s demonstrated recent and relevant record of performance in supplying services that meet the solicitation requirements. In conducting the Past Performance evaluation, the Government reserves the right to use both the information provided in the offeror’s Past Performance proposal volume and information obtained from other sources available to the Government, to include, but not limited to: the Past Performance Information Retrieval System (PPIRS); Federal Awardee Performance and Integrity Information System (FAPIIS); Electronic Subcontract Reporting System (eSRS), or other databases; and interviews/questionnaires with Program Managers, Contracting Officers and Fee Determining Officials, the Defense Contract Management Agency (DCMA), and commercial sources.

(i) Recency Assessment. An assessment of the past performance information will be made to determine if it is recent. To be recent, the effort must be ongoing or must have been performed during the past 3 years from the date of issuance of this solicitation. Past performance information that fails this condition will not be evaluated.

(ii) Relevancy Assessment. The Government will conduct an evaluation of all recent performance information obtained to determine whether the products provided/services performed under those contracts relate to the Technical subfactors and Price factor. For each recent past performance citation reviewed, the relevance of the work performed will generally be assessed for the Technical subfactors and Price Factor (however, all aspects of performance that relate to this acquisition may be considered). Consideration will be given to relevant contracts include those within the same scope (magnitude, character, and duration) and for similar work classified under NAICS Code 561210, Facilities Support Services. A relevancy determination of the offeror’s past performance will be made based upon the aforementioned considerations, including joint venture partner(s) and major and critical subcontractor(s). In determining the relevancy of effort performed under individual past performance contracts, the government will only consider the specific effort or portion consistent with that proposed by the prime, subcontractor or teaming partner. The past performance questionnaire and information obtained from other sources will be used to establish the relevancy of past performance. The Government will use the following relevancy definitions when assessing recent, relevant contracts:

TABLE 3 – PAST PERFORMANCE RELEVANCY RATINGS

TABLE 2- PAST PERFORMANCE EVALUATION RATINGS

Rating Description

Acceptable Based on the offeror’s performance record, the Government has a reasonable expectation that the offeror will successfully perform the required effort, or the offeror’s performance record is unknown. (See note below.)

Unacceptable Based on the offeror’s performance record, the Government has no reasonable expectation that the offeror will be able to successfully perform the required effort.

Note: In the case of an offeror without a record of relevant past performance or for whom information on past performance is not available or so sparse that no meaningful past performance rating can be reasonably assigned, the offeror may not be evaluated favorably or unfavorably on past performance (see FAR 15.305(a)(2)(iv)). Therefore, the offeror shall be determined to have unknown past performance. In the context of acceptability/unacceptability, “unknown” shall be considered “acceptable”.

Rating Definition

RELEVANT Present/past performance effort involved similar scope and magnitude of effort and complexities this solicitation requires.

NOT RELEVANT Present/past performance effort involved little or none of the scope and magnitude of effort and complexities this solicitation requires.

(iii) Performance Quality Assessment. The Government will consider the performance quality of recent, relevant efforts (how well the contractor performed on the contracts). For each recent, relevant past performance citation reviewed, the performance quality of the work performed will be assessed for the Technical subfactors and Price Factor (however, all aspects of performance that relate to this acquisition may be considered Pursuant to DFARS 215.305(a)(2), the assessment will also consider the extent to which the offeror’s evaluated past performance demonstrates compliance with FAR 52.219-8, Utilization of Small Business Concerns.) The quality assessment may result in satisfactory, unsatisfactory and not available findings. Unsatisfactory is defined as past performance information that supports an unsatisfactory rating on any evaluation element or any unfavorable comment received from sources without a formal rating system. The Government will use the following quality levels when assessing recent, relevant efforts:

TABLE 4 – PAST PERFORMANCE QUALITY ASSESSMENT

Quality Assessment Description

SATISFACTORY During the contract period, contractor performance is substantially meeting (or substantially met) contract requirements. For any problems encountered, contractor took effective corrective action.

UNSATISFACTORY During the contract period, contractor performance is not meeting (or did not meet) some contract requirements. For problems encountered, corrective action appeared only marginally effective, not effective, or not fully implemented. Customer involvement was required.

NOT AVAILABLE Quality and/or performance information is not available.

(3) Assigning Ratings. As a result of the relevancy and performance quality assessments of the recent contracts evaluated, offerors will receive an integrated past performance rating at the factor level (see Table 2). More recent performance will have a greater impact on the Past Performance rating than less recent effort.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)

(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___ . [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___…