Evaluation_Factors_TARGET_SHOOTING__8_3_2021.docx

EVALUATION FACTORS

TAOS FIELD OFFICE

RECREATIONAL TARGET SHOOTING PROJECT

NEPA

The Bureau of Land Management intends to award the contract to a responsible party whose proposal is responsive to the solicitation process for the Recreational Target Shooting Project and provides “Best Value to the Government” on a Lowest Priced Technically Acceptable (LPTA) basis.

A technical Evaluation Panel consisting of no less than three members will conduct the initial evaluation. The panel will include the government project manager who is technically qualified to evaluate all proposals. Upon completion of the evaluation period, the panel will review each proposal and make their final award recommendation to the Contracting Officer. Provide your bid in two separate volumes:

Volume 1-Pricing.

Volume 2 – Non-pricing, which includes information that addresses the evaluation factors.

All evaluation factors other than price, when combined will be weighted equally. Offerors are encouraged to review BLM Manual Supplement H-8100-1 for all requirements of permitting, field work and reporting prior to submitting a proposal. The evaluation factors listed below will be used to select the contractor that offers the BLM the LPTA offer.

FACTOR 1 - Key Personnel

· Provide the names and resumes of staff which will be assigned to this project throughout the duration of this requirement.

FACTOR 2 – Past Performance/Experience:

· The Contractor shall have successfully completed a minimum of two similar or comparable projects within the last five years. Provide the information listed below for the two most recent projects.

· In addition to the information submitted in accordance with the Solicitation, the BLM will seek out and consider other information obtained from both commercial and government systems (i.e. PPIRS, BBB, etc.). The Offeror shall submit the following past performance information which shall include a list of these projects identifying:

· Name of the project (to include address)

· Project leader

· Issuing agency or company

· Contract/Identification number

· Start and completion dates

· Brief description of the scope of work

· Award amount (in whole dollars)

· How the work is substantially similar or comparable to the proposed project

· No less than two valid references that includes:

· Agency/company’s name, point of contact, phone number, and email address FACTOR 3 – Schedule

· The proposal shall include a narrative explaining the project schedule that demonstrates your company’s ability to meet or exceed the completion of the order in less than one year. Provide a schedule that identifies all project milestones and the critical path.