16 SIR 16R00176_Atch 1_SPECS ZMA div 01-26 - 13May16.pdf

Miami Air Route Traffic Control Center Miami, Florida

REPLACE ROOF ‘B’ OF THE POWER SERVICES BUILDING

AND AUTOMATION WING STAIRS ROOF

FINAL REVIEW DESIGN SPECIFICATIONS

MARCH 2016

SPEC. # FAA-ZMA-1404046

Prepared by: Federal Aviation Administration ATO Tech Ops Engineering Services

Atlanta En Route/FSS Unit

REPLACE PARTIAL PSB ROOF MARCH 2016

MIAMI, (ZMA) AIR ROUTE TRAFFIC CONTROL CENTER

TABLE OF CONTENTS

DIVISION 1 - GENERAL REQUIREMENTS

01 00 00 GENERAL REQUIREMENTS

01 03 00 SITE ACCESS, CONSTRUCTION LIMITS, USE OF FACILITIES AND WORK HOURS

01 04 00 COORDINATION AND TESTING

01 04 02 CONSTRUCTION SCHEDULES

01 10 00 SUMMARY OF WORK

01 33 00 SUBMITTALS

01 52 16 OSHA SAFETY REQUIREMENTS

01 65 01 MATERIALS AND EQUIPMENT

01 71 33 PROTECTION OF WORK

01 74 00 SAFETY AND HEALTH REQUIREMENTS

01 74 13 CLEANING

01 77 00 CONTRACT CLOSEOUT

DIVISION 2 – SITEWORK (NOT USED)

DIVISION 3 – CONCRETE (NOT USED)

DIVISION 4 - MASONRY (NOT USED)

DIVISION 5 – METALS

05 50 00 METAL FABRICATIONS

DIVISION 6 - WOOD AND PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

DIVISION 7 - THERMAL AND MOISTURE PROTECTION

07 01 50 PREPARATION FOR RE-ROOFING

07 54 23 TPO MEMBRANE ROOFING SYSTEM

07 62 00 SHEET METAL FLASHING AND TRIM

07 72 00 ROOF ACCESORIES

07 92 00 JOINT SEALANTS

DIVISION 8 – OPENINGS (NOT USED)

DIVISION 9 - FINISHES (NOT USED)

DIVISION 10 – SPECIALTIES (NOT USED)

DIVISION 11 - EQUIPMENT (NOT USED)

DIVISION 12 - FURNISHINGS (NOT USED)

DIVISION 13 - SPECIAL CONSTRUCTION (NOT USED)

DIVISION 14 - CONVEYING SYSTEMS (NOT USED)

DIVISION 22 – PLUMBING (NOT USED)

DIVISION 23 – HVAC (NOT USED)

REPLACE PARTIAL PSB ROOF MARCH 2016

MIAMI, (ZMA) AIR ROUTE TRAFFIC CONTROL CENTER

TABLE OF CONTENTS 00 00 02 - 2

DIVISION 26 – ELECTRICAL

26 41 13 LIGHTNING PROTECTION FOR STRUCTURES

APPENDIX A – FAA STD-019e

APPENDIX B – ASO Asbestos Control Program

APPENDIX C – NRCA Standard Details for Single Ply Roofs

END OF TABLE OF CONTENTS 00 00 02

REPLACE A PORTION OF PSB ROOF MARCH 2016

MIAMI (ZMA) AIR ROUTE TRAFFIC CONTROL CENTER FAA-ZMA-1404046

GENERAL REQUIREMENTS 01 00 00 -1

SECTION 01 00 00 GENERAL REQUIREMENTS

PART 1 – GENERAL

1.1 SCOPE

Scope - These specifications, together with referenced specifications, standards, and construction drawings specified on the Contract Documents and the conditions of the Construction Contract cover the requirements of the Federal Aviation Administration (FAA) for the work associated with this project.

1.2 REPAIRS AND PROTECTION

A. General: Upon completion of inspection, testing, sample taking and similar services, repair damaged construction and restore substrates and finishes.

B. Protect construction exposed by or for quality control service activities, and protect repaired construction.

C. Contractor is responsible for, but not limited to, all repair and protection of existing equipment, systems and services, associated with or affected by the contract requirements and work area.

1.3 INDUSTRY STANDARDS

A. Applicability of Standards: Unless the Contract Documents include more stringent requirements, applicable construction industry standards have the same force and effect as if bound or copied directly into the Contract Documents to the extent referenced. Such standards are made a part of the Contract Documents by reference.

B. Publication Dates: Comply with the standards in effect as of the date of the Contract Documents.

C. Conflicting Requirements: Where compliance with two or more standards is specified and the standards establish different or conflicting requirements for minimum quantities or quality levels, comply with the most stringent requirement. Refer uncertainties and requirements that are different but apparently equal to the COR for a decision before proceeding.

1. Minimum Quantity or Quality Levels: The quantity or quality level shown or specified shall be the minimum provided or performed. The actual installation may comply exactly with the minimum quantity or quality specified, or it may exceed the minimum within reasonable limits. To comply with these requirements, indicated numeric values are minimum or maximum, as appropriate, for the context of the requirements. Refer uncertainties to the COR for a decision before proceeding.

D. Copies of Standards: Each entity engaged in construction on the Project must be familiar with industry standards applicable to its construction activity. Copies of applicable industry standards are not bound with the Contract Documents.

1. Where copies of standards are needed to perform a required construction activity, the Contractor shall obtain copies directly from the publication source and make them available on request.

E. Abbreviations and Names: Trade association names and titles of general standards are frequently abbreviated. Where abbreviations and acronyms are used in the Specifications or other Contract Documents, they mean the recognized name of the trade association, standards-generating organization, authorities having jurisdiction, or other entity applicable to the context of the text provision. Refer to Gale

GENERAL REQUIREMENTS 01 00 00 -2

Research's "Encyclopedia of Associations" or Columbia Books' "National Trade & Professional Associations of the U.S.," which are available in most libraries.

1.4 RECORD DRAWINGS

The Government shall provide the Contractor with an electronic copy of the record drawings in .PDF format.

Changes to the original plans, drawings or shop drawings shall be annotated in red.

END OF SECTION 01 00 00

SITE ACCESS CONSTRUCTION LIMITS 01 03 00 - 1

SECTION 01 03 00 SITE ACCESS, CONSTRUCTION LIMITS, USE OF FACILITIES AND WORK

HOURS

1.1 SUMMARY

A. Existing facility operations. - Construction/demolition shall in no way interfere with Air Traffic Control

Operations. The ARTCC is a 24-hour, seven day a week facility. Extreme care shall be exercised so as not to cause any interference or interruption of service from this facility. Controller functions are vital to the safety of the flying public. It is absolutely mandatory that the contractor protect FAA personnel and existing FAA communication, electrical and mechanical equipment both inside and outside buildings from damage caused by impact, water, debris, dust or odor. The contractor shall have the overall responsibility for the performance and enforcement of all forms of protection within the ARTCC premises against any damages due to work performed under this contract. Any damages incurred, as a result of construction activity during the performance of this contract will be repaired/replaced immediately by the contractor at no cost to the FAA.

Any work or activity that may impact the National Airspace System (NAS), such as work on critical equipment or circuits, will require coordination with the Contractor Office Representative (COR). The COR will prepare and submit a work or activity specific “Risk Assessment” for the facility’s review and approval.

This process may take one week to complete. Typically, this type of work or activity is performed from midnight to 05:00 AM and/or on weekends.

B. Construction limits and access. -

1. Construction limits.- The contractor shall confine operations, activities, storage of materials and employee parking within the designated areas, as indicated on the construction staging plan, or as designated by the COR. Additional space the contractor deems necessary shall be obtained off site, at no additional cost to the Government.

2. Access. - Access route for the contractor, subcontractors, employees, deliveries, etc., shall be through the main gate, or as designated by the COR. Access to all, parking areas, and loading dock shall be kept unobstructed. If temporary access obstruction is unavoidable, the contractor shall advise the COR immediately. Vehicles transporting materials shall not be loaded beyond the capacity prescribed by federal, state, or local laws. Obstruction of existing roadways, driveways, to the ARTCC is strictly prohibited.

3. Damage to site. - Damage to existing paving, lawns, curbs, sidewalks, and utilities caused by the contractor's activities shall be repaired immediately. Any damage to the building, interior or exterior, that are a result of the contractor’s activities shall be repaired. The contractor shall pay all costs of repairs. After notice to proceed and prior to the commencement of construction, the contractor and COR shall conduct joint inspections of the existing areas affected by the construction. Existing damage or defects shall be noted and will be used as the basis for determination of damages caused by the contractor's operations.

4. The Contractors’ employees shall not use the Cafeteria.

C. Inspection of site by contractor. - It is strongly urged that the contractor carefully examine the premises to determine the extent of work and the conditions under which it must be done.

SITE ACCESS CONSTRUCTION LIMITS 01 03 00 - 2

D. Government use and access to premises. - The Government reserves the right to enter the construction area at any time for work inspection and for the operation of the facility.

E. Work hours. - All work hours, shifts, and overtime work shall be coordinated with the COR. Before commencing construction, furnish to the COR a statement of hours per day and days per week to normally be worked and approximate number of persons on the job for a normal work shift.

F. Security requirements.

1. Personnel List. - Contractor shall provide the COR with a list of contractor personnel who require access to the ARTCC. The list shall be submitted immediately after contract award. The list shall be kept current during the project and shall include the following:

Full name, including middle initial Federal or State issued photo ID Date of Birth Place of Birth

2. Security Investigation and identification. - Contractor's personnel may be subject to security investigation by FAA. The contractor shall promptly complete all security forms provided by the CO. Contractor's personnel shall report to the FAA security guard at entrance to the facility and submit proper identification when signing in to obtain an FAA badge which will be worn on an outside garment, above the waist and below the neck, facing forwards, at all times while on the ARTCC premises. This badge shall be returned daily to the security guard when leaving the premises, unless otherwise noted.

3. Vehicle identification. - Vehicle identification tags will be issued for contractor and contractor's employees' vehicles that require access into the ARTCC site. The identification tags shall be displayed in the windshield of the vehicle at all times when the vehicle is on the site. The contractor shall be responsible for the collection and return of all vehicle tags that are no longer required.

4. Escort requirement. - Contractor is responsible to provide an escort for his employees. This will required a security background investigation by the FAA. Contractor's personnel shall not violate any security regulations pertaining to the ARTCC facility. Violators may be removed from the premises with the right to reenter revocable. Contractor's day-to-day work schedules in the classified areas shall be so arranged to allow for minimum escort.

5. Right to search. - Current procedures at FAA facilities include the "right to search." If in the judgment of the FAA a cause to search a vehicle or the person of personnel exists, such search will be made.

6. Replacement of lost identification. - The FAA will provide personnel badges and vehicle identification tags as described above. It is the contractor's responsibility to return these badges and tags daily and upon completion of the project. The contractor shall be liable to pay for any FAA badge or tag not returned or replaced at the completion of the work. The payment for lost I.D. will be $10.00 for each and every tag or badge not returned or replaced, except for temporary badges.

7. Physical Security. - At the end of each workday, the contractor shall secure all construction areas by closing and locking all doors and gates. The contractor is responsible for the

SITE ACCESS CONSTRUCTION LIMITS 01 03 00 - 3

security of the staging area, and shall provide the required measures at no additional expense to the government.

END OF SECTION 01 03 00

SITE ACCESS CONSTRUCTION LIMITS 01 03 00 - 4

This page was intentionally left blank

COORDINATION, LOCAL PERMITS AND TESTING 01 04 00-1

SECTION 01 04 00 COORDINATION, LOCAL PERMITS AND TESTING

1.1 SUMMARY

A. Project coordination. - It shall be the duty of the Contractor to prepare a detailed schedule of work and work layout to resolve conflicts and to assure coordination of the work by different trades.

B. Weekly Meeting. - Coordination between the COR and Contractor shall take place weekly at the site. Special meetings will be scheduled if requested by either the COR or Contractor. The subjects to be discussed at the progress meetings shall included, but are not limited to, the following:

-Safety concerns/Issues -Progress of Work -Previous meeting action items/issues -Field problems -Material and Equipment delivery status -Submittal status/schedules -Progress planned during the upcoming week(s) -Review of changes, and potential effects on the schedule -Construction schedule revisions -Schedule Revisions -Other current business

The following persons will be expected to attend meetings; FAA COR, Prime Contractor

Superintendent, Project Manager and Project Manager/Superintendents for other major trades.

C. Facility Coordination Meeting. - Weekly coordination meeting shall take place between the facility managers, COR and the Contractor’s Project Superintendent.

D. Work Affecting Operational Systems. - The contractor shall coordinate all work which has any or may have any impact on any operational system within the facility through the COR.

The contractor shall immediately cease any work that is adversely impacting the operation of the ARTCC and shall immediately repair or restore any portion of the operational system that has been damaged or suffered diminished performance as a result of the contractor's activities.

E. Local permits and Coordination. - The Contractor will be responsible for obtaining and payment of all building fees, inspection fees, utility connection charges and any other fees or charges that may be incurred in the performance of this contract.

F. Applicable documents. - The contractor shall comply with all local city, county, and state construction codes.

1.2 TESTING

A. Contractor's responsibility.- Unless otherwise indicated as the responsibility of another identified entity, Contractor shall provide certified testing and inspection agencies, inspections, tests, and other quality-control services specified elsewhere in the Contract Documents and required by authorities having jurisdiction.

COORDINATION, LOCAL PERMITS AND TESTING 01 04 00-2

1. Where individual Sections specifically indicate that certain inspections, tests, and other quality-control services are the Contractor's responsibility, the Contractor shall employ and pay a qualified independent testing agency to perform quality-control services.

2. Where individual Sections specifically indicate that certain inspections, tests, and other quality-control services are the Government's responsibility, the Government will employ and pay a qualified independent testing agency to perform those services.

a. Where the Government has engaged a testing agency for testing and inspecting part of the

Work, and the Contractor is also required to engage an entity for the same or related element, the Contractor shall not employ the entity engaged by the Government, unless agreed to in writing by the Government.

B. Retesting - The Contractor is responsible for retesting where results of inspections, tests, or other quality-control services prove unsatisfactory and indicate noncompliance with Contract Document requirements, regardless of whether the original test was Contractor's responsibility.

1. The cost of retesting construction, revised or replaced by the Contractor, is the Contractor's responsibility where required tests performed on original construction indicated noncompliance with Contract Document requirements.

C. Selection and payment. - The contractor shall pay for all testing. The contractor shall select and use a certified and qualified testing laboratory to perform the requirements of this contract. The American Association of Laboratory Accreditation shall certify the testing laboratory.

D. Rejected materials or workmanship.- All materials or workmanship or both which have been rejected by the COR by reasons of failure to conform to the requirements of the Contract Documents shall be removed and replaced with new, acceptable materials by the contractor at the contractor's own expense. Contractor shall also pay for testing of new materials that have been installed in place of rejected materials.

1. The testing laboratory will furnish three copies of each report directly to the COR covering all of its determinations and conclusions. Reports will show all data customarily listed by the laboratory in reporting on quantities, qualities, and types of materials, together with their correlation with the project and applicable Specification Section.

END OF SECTION 01 04 00

CONSTRUCTION SCHEDULES 01 04 02 - 1

SECTION 01 04 02 CONSTRUCTION SCHEDULES

A. Description. - The work plan and schedule prepared by the contractor shall consist of a Gantt and Critical Path Math (CPM) chart(s) and logical narrative plan. The charts shall show all significant activities and shall include detailed activities when critical work is to be performed.

1.2 PRODUCTS

A. Diagrams -

1. Show the order of the activities.

2. Include construction activities, the submittal and approval of materials, samples and shop drawings, the procurement of critical materials and equipment, fabrication of special materials and equipment along with their installation and testing, and costs associated with each activity in the bar chart.

B. Progress Schedules. - Within 30 calendar days of contract award, the contractor shall submit the schedule and work plan. A Notice to Proceed will not be issued until the schedule is approved.

1.3 EXECUTION

A. Review and Evaluation. - The Contractor shall participate in a review and evaluation of the proposed schedule with the Contracting Officer. Any revisions necessary as a result of the review shall be re-submitted for approval of the Contracting Officer within 14 days after the conference.

The contractor for planning, organizing, and directing work, reporting progress, and requesting payment for work accomplished shall then use the approved schedule. If the contractor, thereafter, desires to make changes in the schedule, the Contracting Officer shall be notified in writing, stating the reasons for the change. If the Contracting Officer considers the change to be of a major nature, the contractor may be required to revise the schedule and submit it for approval, without additional cost to the government.

B. Monthly Update. - The contractor shall meet with the COR at monthly intervals to discuss the construction progress. If the project is behind schedule and requires a change in the schedule, the contractor shall submit a revised schedule with a description of the delaying factors and their impact, and an explanation of corrective actions taken or proposed.

C. Payment. - The monthly update shall show the activities or portions of activities completed during the reporting period, and their total value will be the basis for the contractor's periodic request for payment. Payment will be based on the total value of such activities completed or partially completed after verification by the Contracting Officer.

D. Submission Requirements. - Schedule charts shall be on (minimum) 11" x 17" size paper. Update charts shall show the date of the latest revision. Schedule charts with revisions and monthly updates shall be submitted in three copies.

CONSTRUCTION SCHEDULES 01 04 02 - 2

E. Requirements for Schedule Chart. -

1. Activities.- The significant activities to be included in the schedule chart shall include, but not be limited to:

a) The milestones listed in 01010 1.2. D.

b) Any system shutdowns or cut-overs

c) Any other significant activities that the contractor or FAA believes is necessary.

2. Format - Contractor should use Microsoft Project, cost loaded. A minimum of 30 activities should be included.

F. Shutdown and Cut Over.

1. Mechanical Systems. - All shutdowns when permitted and cut overs of computer air handling units shall be coordinated with COR. Only one air handling unit shall be off and unavailable at any given time. Equipment shutdown and lock-out shall be accomplished by FAA personnel.

2. Electrical Systems. - New construction shall have no impact on the critical or essential electrical service at this facility. However, all electrical connections within live power panels will be scheduled with the COR at least 14 days in advance. All electrical connections to existing panels shall be coordinated with FAA personnel. Equipment shutdown and lock-out shall be accomplished by FAA personnel.

3. Startup - The contractor will complete initial startup testing and training.

G. Acceptance and Warranties

1. The Contractor shall warranty material and equipment furnished by the various manufacturers in writing for period of two (2) years (or not less than the industry standard for the material specified, nor the manufacturer’s standard warranty period, whichever is greater) on building systems finishes or equipment from the date of final project acceptance by the FAA.

Mechanical equipment in particular (HVAC equipment,) shall be warranted in writing for period of three (2) years (or not less than the manufacturer’s standard warranty period whichever is greater), from date of final project acceptance by the FAA. The cost of any extended warranties will be included in the contract sum.

H. New utility work.

Interface all existing utility work with new work as indicated in the plans and specifications.

END OF SECTION 01 04 02

SUMMARY OF WORK 01 10 00 - 1

SECTION 01 10 00 SUMMARY OF WORK

PART 1 - GENERAL

A. Scope of Work - These specifications, together with the referenced specifications, standards, and drawings specified in the contract documents cover the requirements for all work associated with the following general description of work:

Contractor to furnish labor, equipment and materials to replace a portion of the Power Services Building (PSB) roof and the Automation Wing stair roof including removal of existing system and installation of new TPO system (insulation, underlayment board, cover board, membrane, flashing, coping, fasteners, anchors, blocking, nailers, adhesives, caulking, sealants, and access ladders) and to remove lightning protection system and re-install as indicated/specified. The contractor will be responsible for hiring a Florida registered structural engineer to inspect and make recommendations to reinforce the existing metal deck for the current Florida Building Code requirements.

The General Contractor (GC) shall be expected to work during day times, 7:00 AM to 4:30 PM.

Some work may have to be coordinated after-hours with the COR, from 4:30 PM to 6:00 AM.

Extensive coordination between the GC and FAA personnel shall be required at all times in order to maintain an operational facility. Prospective bidders are strongly recommended to perform a site visit to assess the actual conditions before submitting a bid. Site visits should be arranged thru the Contracting Officer’s Office.

B. FAA Holiday Moratorium - No work shall be scheduled or take place during the week of and the weekend preceding and following: The Thanksgiving, Christmas, and New Year’s Holidays. Only emergency work to restore critical services to the Facility will be considered and a moratorium waiver must be submitted and approved. The moratorium period will not be counted against the contract construction duration of the project.

C. FAA Holidays Observed - The FAA also observed the following Holidays:

1. Birthday of Martin Luther King, Jr.

2. Washington’s Birthday

3. Memorial Day

4. Independence Day

5. Labor Day

6. Columbus Day

7. Veterans Day

If the Contractor thinks that work will be required on any of these Holidays he will need to coordinate with the Contracting Officer Technical Representative (COTR) two weeks in advanced. The Holidays observance will not be counted against the contract construction duration of the project.

D. Intent of Specifications - This specification identifies all material, labor, and equipment required to perform this work. All work performed and all materials and equipment used are subject to approval by the Contracting Officer (CO) and /or the Resident Engineer (RE). This shall include but is not limited to inspection, scheduling, reporting and submittals.

E. Title - Titles to division and sections of the specifications and notes and titles on drawings referring to subcontractors, division of work by trade, or type of work, are introduced merely for convenience in

SUMMARY OF WORK 01 10 00 - 2

reading the specifications and drawings and do not imply any separate contractual arrangements of work assignments. Such separations into titled divisions and sections shall not operate to make the Government an arbiter to establish subcontract limits between the contractor and subcontractors, or between the subcontractors themselves.

F. Contract Documents - The drawings, as shown on the "List of Drawings" in Attachment 2 in each specification package, General, Architectural, Mechanical, Electrical, and Southern Standards, all form a part of the construction requirements for this project. The renovation of these systems shall be in accordance with the lines and grades shown on the drawings. The Contractor shall not use dimensions scaled from drawings. All dimensions shown on the drawings shall be field verified by the contractor prior to any modifications and fabrications. Any discrepancies between the drawings and specifications and the existing conditions shall be referred to the CO for adjustment before any work affected is performed.

G. Precedence of Contract Documents - In the event of a difference between the following contract provisions, the order of precedence to determine which provision shall govern is:

1. Contract Clauses and Provisions

2. Project Specifications

3. Project Drawings

Any discrepancies between the contract provisions, the specifications and the contract drawings shall be referred to the CO for a written determination in accordance with Contract Clause entitled Order of Precedence.

H. Contracting Officer -The term "Contracting Officer" (CO) as used herein denotes the person designated to act on behalf of the Government in the performance of this contract. Where reference is made to "Federal Aviation Administration" (FAA), "Resident Engineer" (RE), "Contracting Officer's Representative" (COR), or the like, this shall mean the Contracting Officer or his/her authorized representative.

I. Contractor Superintendence - In accordance with Contract Clause entitled SUPERINTENDENCE BY THE CONTRACTOR, the Contractor shall at all times during performance of this contract and until the work is completed and accepted, directly superintend the work or assign and have on site a competent superintendent with the authority to act for the Contractor.

The Contractor shall submit a Project Organizational Chart with the key personnel identified and their qualifications for the Government’s review and approval.

1.2 SPECIAL REQUIREMENTS

A. Asbestos Containing Materials. - No new materials supplied by the contractor for this construction shall contain asbestos or lead-based products. The contractor shall verify that all materials, including those supplied by third parties, are asbestos free and/or lead-based free materials.

1. Contractor certification requirements. - The contractor shall provide to the Contracting

Officer (CO) a signed and notarized document stating that to the best of his/her knowledge, no asbestos containing or lead-based materials were used during the construction, renovation, and/or modernization of this facility.

2. Material Safety Data Sheets. - The contractor shall submit Material Safety Data Sheets

(MSDS) with all submittals for review and approval by the Contracting Officer. New

SUMMARY OF WORK 01 10 00 - 3

materials found to contain asbestos and/or lead-based products will be automatically disapproved. Copies of all MSDS sheets shall be provided to the facility FAA personnel for the building records. The contractor shall comply with all health and safety provisions outlined in each MSDS and shall follow all OSHA guidelines regarding personnel protection.

3. Hazardous materials.- If the FAA RE suspects the presence of asbestos or lead-based products in the new materials, the FAA will sample the suspect material to verify that no asbestos containing material or lead-based material were used. If these materials are found to contain asbestos or lead-based products, the cost of the survey and all subsequent removal/replacement of any hazardous materials shall be at the contractors’ expense.

B. Work plan and scheduling. – Prior to the Contracting Officer issuing the Notice to Proceed (NTP), the contractor shall submit for approval a plan and schedule of his work. This schedule shall include all of the requirements as defined in Section 01042 of this specification.

C. Sequence of work. - The contractor shall be responsible for scheduling all aspects of the work and coordinating among the different trades involved in the project. The contractor shall follow the guidelines outlined in the sequence of work as described in the contract drawings. The Federal Aviation Administration has developed a list of milestones that the contractor shall be required to meet.

D. Construction Activities and Milestones. – Construction Activities and Milestones below shall be included in the submitted schedule. They are provided for guidance, but are not intended to direct how and when contract activities shall be ordered or take place in the submitted schedule.

1. SUBMITTAL APPROVAL

2. ORDER LONG LEAD ITEMS

3. NOTICE TO PROCEED

4. ESTABLISH PROTECTION OF PERSONNEL AND EQUIPMENT

5. START DEMOLITION AND MODIFICATION ACTIVITIES

6. INSTALLATION OF ALL NEW AND DISTURBED COMPONENTS

7. TEST AND INSPECT ACTIVITIES

8. CLOSE JOB

E. Driveway Closures - Contractor shall maintain access to the loading dock at all times.

END OF SECTION 01 10 00

SUMMARY OF WORK 01 10 00 - 4

SUBMITTALS 01 33 00 - 1

SECTION 01 33 00 SUBMITTALS

Applicable provisions of this Section and other provisions and requirements of the Contract Documents apply to all sections, except as modified in Sections of Divisions 2 through 16.

1.1 SUMMARY

Submit Shop Drawings, product data, samples, warranties, certificates, test reports and third party disposal letters as required by the contract documents.

1.2 SUBMITTALS

Submittals required include, but are not necessarily limited to, the following:

A. Submittal schedule

B. Construction progress schedule

C. Submittal log

1.3 SUBMISSION REQUIREMENTS

A. Number of Copies - Submit in ample time for approval before installation. Unless otherwise noted, submit five (5) copies of documents to the Resident Engineer (RE). The RE will retain Three (3) copies. If additional copies are required, provide the quantity and submit additional copies to meet this requirement.

B. Time for Approval - Receive submittal approvals prior to starting the work. Time necessary for government approval or disapproval of samples, certificates, test reports, and shop drawings will not be more than 30 calendar days after receipt of a submittal.

All materials installed in the work shall match the approved submittals. After a submittal has been approved, the RE will permit no substitutions without written approval. No extension of Contract Time will be authorized because of failure to transmit to the RE sufficiently in advance of the Work to permit processing.

C. Submittal Approval - The checking, marking or approval of the submittal by the FAA shall not be construed as a complete check, but will indicate only that the product or method of construction and detailing is satisfactory. Approval will not relieve the contractor of the responsibility for compliance with the specifications or for any error that may exist. The Contractor shall be responsible for the dimensions and design of adequate connections, details, and satisfactory construction of all work. Possible approval actions taken by the FAA include:

1. Approved as submitted - If the RE marks a submittal "approved as submitted" each copy of the submittal will be identified as having received such approval by being stamped and dated. After submittal has been approved, the RE will permit no substitutions without written approval.

SUBMITTALS 01 33 00 - 2

2. Approved as noted - If the RE marks “approved as noted”, the submittal is satisfactory contingent upon Contractor acceptance of corrections, notations, or both, and if accepted, does not require resubmittal.

3. Not approved - If the RE marks “not approved”, the submittal data does not meet job requirements and the Contractor must resubmit. If the submittal is disapproved, the Contractor shall resubmit the corrected material in the same quantity as specified for the original submittal. Correct disapproved submittals and resubmit for approval by the RE. Approval of resubmittals requires an additional fourteen (14) calendar days.

4. Submittal Schedule - Identify within the Contractor’s Construction Schedule a schedule of submittals for shop drawings, material approval, etc., showing the dates when submittals will be submitted for the project.

a) Contents - On the schedule indicate the following information:

1) Schedule date for submittal

2) Related Section number.

3) Submittal category (Shop Drawings, Product Data, or Samples)

4) Name of the subcontractor (if applicable)

5) Description of the part of the Work covered.

5. Distribution - Following response to the initial submittal, print and distribute copies to the RE, Government, subcontractors, and other parties required to comply with submittal dates indicated. When revisions are made, distribute to the same parties. Delete parties from distribution when they have completed their assigned portion of the Work and are no longer involved in construction activities.

6. Schedule Updates - Revise the schedule after each meeting or activity where revisions have been recognized or made.

D. Construction Progress Schedule – The progress chart to be prepared by the Contractor pursuant to the Contract Clause entitled “SCHEDULES FOR CONSTRUCTION CONTRACTS” shall consist of network analysis system, or pertchart (barchart). The contractor shall be required to complete the work within the contract time limits after receipt of Notice to Proceed excluding the FAA holiday moratorium as specified in section 01010.

1. Contractor should use Microsoft Project, cost loaded. A minimum of 30 activities should be included.

2. The diagram shall show a continuous activity flow from left to right. The diagram shall show the sequence in which the work is to be accomplished as planned by the Contractor.

3. Dates shall be shown on the diagram for start of the project, any milestones required by the contract, and contract completion.

SUBMITTALS 01 33 00 - 3

4. The critical path shall be clearly identified.

5. Network activities shown shall include submittal and review of shop drawings and samples and procurement of materials and construction activities.

6. Government activities that affect progress shall be shown. These include but are not limited to: Notice-to-Proceed, approvals, and inspections.

NO PHYSICAL CONSTRUCTION WORK AT THE SITE MAY TAKE PLACE UNTIL THE

CONTRACTOR SUBMITS AND THE GOVERNMENT APPROVES THE SCHEDULE.

Government review of schedule submittal(s) will not exceed 30 calendar days. Resubmittal, if necessary shall not exceed fourteen (14) calendar days.

E. Two-week "Look Ahead" schedule - This schedule may be of the contractor's choosing, either bar chart or CPM form. Only activities scheduled to be occurring during the forecasted two-week time periods are to be shown. Schedules shall be submitted weekly.

Early and Late Start and Finish dates, and subcontractors involved are data to be included in the schedule.

F. Submittals - Submit shop drawings, material and equipment lists, and all other data required under various headings of these specifications necessary to permit commencement of work. RE will return the submittals within 30 calendar days after receipt, indicating approval or disapproval.

G. Submittal Preparation - Place a permanent label or title block on each submittal for identification. Indicate the name of the entity that prepared each submittal on the label or title block.

1. Transmittals - transmittal letters identifying the contents of the submittal shall accompany all submittals. It shall be clearly indicated on the transmittal letter with a statement and signature of the Contractor that the submittal item was verified for compliance with the contract requirements and approved by the Contractor. Transmittal letters shall consist of one original.

2. Contents - Submittals shall be complete and detailed and assembled into sets.

Lack of completeness or clarity or inadequate description will be justification for disapproval. Submittals shall bear the following information:

a) Name of project or facility and contract number;

b) Date of submission;

c) Contract drawing number and latest revision;

d) Specification page and paragraph number;

e) Name of contractor and subcontractor or supplier/manufacturer;

f) Clearly identified contents and location of work;

g) Any proposed variances to specification requirements;

h) Contractor’s approval certifying he checked and coordinated the work of other trades.

1.4 SHOP DRAWINGS

A. Applicable Documents -

SUBMITTALS 01 33 00 - 4

B. Presentation - Present drawings in a clear and thorough manner. Identify details by reference to sheet and detail, building wing and section shown on contract drawings.

1. Submit newly prepared information drawn accurately to scale. Highlight, encircle, or otherwise indicate deviations from the Contract Documents. Do not reproduce Contract Documents or copy standard information as the basis of Shop Drawings. Standard information prepared without specific reference to the Project is not a Shop Drawing.

2. Shop Drawings include fabrication and installation Drawings, setting diagrams, schedules, patterns, templates and similar Drawings.

C. Contents - Provide the following information on each submittal:

1. Submittal number (paragraph 2.1 of this Section) and identify as "Part A" or "Part B" item

2. Date of submission

3. Name of project and facility (full name)

4. Name of Contractor or Subcontractor

5. Reference to drawing number (with revision, if applicable) and/or specification section.

6. Clearly identify contents and location of work.

7. Contractor's approval certifying he checked and coordinated the work of other trades.

8. Dimensions.

9. Identification of products and materials included by sheet and detail number.

10. Compliance with specified standards.

11. Notation of coordination requirements.

12. Notation of dimensions established by field measurement.

13. Sheet Size: Except for templates, patterns and similar full-size Drawings, submit Shop Drawings on sheets at least 8-1/2 by 11 inches but no larger than 36 by 48 inches.

D. Submittal - Submit blue- or black-line prints for the RE's review. Submit five copies, of which the RE will retain three.

1. One of the prints returned shall be marked up and maintained as a "Record Document."

2. Do not use Shop Drawings without an appropriate final stamp indicating action taken.

1.5 PRODUCT DATA

A. Collect Product Data into a single submittal for each element of construction or system.

Product Data includes printed information, such as manufacturer's installation instructions, catalog cuts, Material Safety Data Sheets (MSDS), standard color charts, roughing-in diagrams and templates, standard wiring diagrams, and performance curves, for all materials brought on site.

B. Preparation

SUBMITTALS 01 33 00 - 5

1. Clearly mark or highlight each copy to identify pertinent site specific products or models the Contractor intends to use

2. Highlight/clearly indicate all performance characteristics and capacities

3. Highlight/clearly indicate all dimensions and clearances required

Note: If the submittal is not clearly marked, regarding the above pertinent data, the submittal will be returned marked "DISAPPROVED".

1.6 WARRANTIES/GUARANTIES

A. Assemble two (2) copies with original signatures of warranties executed by each of the respective manufacturers, suppliers, and subcontractors into a warranty book and prepare a Table of Contents.

B. Additional Data - Provide complete information for each item, include the following:

1. Product or work team

2. Firm, with name of principal, address, and telephone

3. Scope

4. Effective dates of warranty based on Final Acceptance of the item.

5. Information for owner's personnel on proper procedures to evoke the warranty in case of failure and instances which might affect the validity of warranty

C. Warranties: Effective after project completion and acceptance by the FAA.

1.7 CERTIFICATES

Assemble certificates executed by each of the respective manufacturers, suppliers, and subcontractors.

A. Additional Data - Provide complete information for each item to certify compliance with contract documents.

1. Product or work item

2. Firm, with name of principal

3. Scope of compliance

4. Signature by an officer of the manufacturer or other individual authorized to sign documents on behalf of the company.

PART 2 – MATERIAL

NOT USED

SUBMITTALS 01 33 00 - 6

PART 3 – EXECUTION

3.1 GENERAL

Submittals are required for, but not limited to, the items listed in the specifications or on the drawings. The following is a partial list of submittals required: Schedules, Manufacturer's Literature, Shop Drawings, Samples, Test Reports, Warranties, Certificates, Design Calculations, MSDS, and Installation Instructions. This list should not be construed as a complete list of all submittals required. Submittal dates shall comply with this specification unless a more stringent date is specified. Substitutions and all requested changes will require a submittal.

3.2 SCHEDULE FOR SUBMITTALS

No later than two weeks after the contract has been awarded, the Contractor shall be available to participate in a meeting/telecom with the Contracting Officer, Resident Engineer and Office Project Engineer to discuss and coordinate the following:

1) Contractor’s FAA point of contact for submitting the Submittals.

2) Discuss the submittal process and forms.

3) Discuss process and forms for request of FAA security badges.

4) Discuss the proposed date for Notice to Proceed (NTP)

PART 4 – QUALITY ASSURANCE

END OF SECTION 01 33 00

OSHA SAFETY REQUIREMENTS 01 52 16 - 1

PART 1 – SECTION 01 52 16 OSHA SAFETY REQUIREMENTS

PART 2 – GENERAL

1.1 SCOPE

A. This section identifies some of the requirements of the OSHA Construction Standard.

B. Formulation of a site specific safety plan

1.2 CONTRACTOR RESPONSIBILITY

A. General Safety Provisions - The Contractor shall bear full responsibility to provide safe working conditions for its employees and Contractors. The Contractor shall not permit any employee or Subcontractor to work in surroundings or under working conditions that are unsanitary, hazardous, or dangerous to the health and safety of the employee.

B. Accident Prevention - The Contractor shall bear the responsibility of maintaining an accident prevention program such that frequent and regular inspections of the job site, materials and equipment are made by a competent person designated by the employer.

C. Use of Equipment - The Contractor shall not permit the use of any machinery, tool, material, or equipment that is not in compliance with OSHA regulations. The employer shall permit only those employees qualified by training and/or experience to operate equipment and machinery.

1.3 SUBMITTALS

A. Submittals required include, but are not necessarily limited to, the following:

1. Contractor Safety Plan

1.4 CONTRACTOR RESPONSIBILITY

A. The FAA shall not be held responsible for safety inspections to assure Contractor conformance with the OSHA safety regulations. The FAA, however, reserves the right to notify the Contractor of any deficiencies regarding worker safety.

B. The FAA will evaluate the Contractor on its safety performance, including that of its Subcontractors. The number and severity of safety and security violations will be considered in this evaluation. Contractor safety violations are cause for termination for default, may result in notification of the Contractor’s bonding company, and will affect the Contractor’s opportunity to propose on future work. Failure to correct such deficiencies may impact the Contractor’s ability to work on future FAA contracts.

OSHA SAFETY REQUIREMENTS 01 52 16 - 2

1.5 OSHA REGULATIONS

A. The Contractor shall comply with the latest Occupational Safety and Heath Administration regulations (CFR 29 Part 1926) regarding safety in the work area.

B. The Contractor shall be responsible for obtaining copies of non-FAA referenced documents without additional cost to the FAA. If Contractor requests a copy of FAA directives, they may be obtained by contacting the Contracting Officer.

C. The Contractor is not relieved from adhering to other OSHA requirements not listed herein. The Contractor shall consult the latest referenced OSHA documents for safety regulations.

1. Documents:

a) OSHA Documents:

1) CFR 29 Part 1926Safety and Health Regulations for Construction

2) CFR 29 Part 1910 General Industry Standards Applicable to

Construction Industry

b) FAA Documents:

1) FAA Order 3900.49 Control of Hazardous Energy During

Maintenance, Servicing and Repair

1.6 SAFETY PLAN

The contractor must develop and implement a site specific comprehensive Health and Safety Plan (HASP) based on the scope of work, for his or her employees as well as others in the area and the properties around. It shall cover all aspects of onsite construction operations and activities associated with the contract. This plan must comply with 29 CFR 1926, FAA Order 3900.19B, other applicable health and safety regulations and any project-specific requirements. The contractor must provide the Contracting Officer with a copy of this plan. Acceptance of the contractor's HASP only signifies that the plan generally conforms to the requirements of the contract. It does not relieve the contractor of the responsibility for providing with a safe and healthful work environment. At a minimum the HASP shall address the following:

A. Workplace address

B. Name and address of the principal contractor

C. Key Personnel, phone nos and addresses

D. Estimated duration of the work

E. Hazard assessment and identification of the hazards in the scope of work

F. Mitigation of hazards and proposed control measures for the risks

OSHA SAFETY REQUIREMENTS 01 52 16 - 3

G. Hazard Communication methods

H. How the controls will be implemented

I. Personal Protective Equipment

J. Training

K. Temperature Extreme

L. Medical Surveillance

M. Exposure Monitoring and Air Sampling

N. Site Control

O. Emergency Response/Contingency Plan

P. Emergency Action Plan

Q. Confined Space Entry

R. Spill Containment

S. Documentation and Record Control

T. Arrangements for monitoring and reviewing controls

U. Lock-out and Tag-out

The plan must be written so it is easy to understand, signed and dated by the General Contractor.

It must be available for the length of the project. The General Contractor cannot allow work to start unless the plan has been discussed with or a copy given to all relevant people and the plan is readily available for inspection. The plan must be amended if there are changes in how risks will be managed. The General Contractor must inform any affected person of the change.

PART 3 – MATERIAL

NOT USED

PART 4 – EXECUTION

3.1 CFR 29 PART 1926 - SAFETY AND HEALTH REGULATIONS FOR CONSTRUCTION

A. This section contains a partial listing of the referenced OSHA standards. The Contractor is responsible for adhering to all applicable regulations including those not specifically referenced herein.

1. Subpart D (Occupational Health and Environmental Controls) - Contractor shall furnish adequate supply of potable water in containers clearly marked as potable

OSHA SAFETY REQUIREMENTS 01 52 16 - 4

water. Containers containing non-potable water shall be clearly marked.

Contractor shall furnish toilet facilities based on the number of employees present on the job-site. A minimum of 1 facility is required for less than 20 employees. See CFR 29 Part 1926 Subpart D for complete requirements.

2. Subpart E (Personal Protective Equipment) - The Contractor shall provide adequate protection for the head, hearing, and eyes for all employees working in an area where hazards to the head, ear and eyes exist. See CFR 29 Part 1926 Subpart E for complete requirements.

3. Subpart I (Tools) - All hand tools and power tools and similar equipment whether furnished by the Contractor or the employee shall be maintained and operated in a safe condition. Personal protection shall be used when applicable. The use of tools shall be limited to the intended use of said tools. See CFR 29 Part 1926 Subpart I for complete requirements.

4. Subpart K (Electrical) - The Contractor shall furnish ground fault protection for all electrical equipment used on the jobsite. Extension cords shall be three wire ground in good shape. Installation of the facilities will require energizing numerous circuits. The Contractor shall protect against electrical shock by methods such as posting warning signs, supplying insulated gloves, locking out and tagging de-energized circuits, and other similar methods. See CFR 29 Part 1926 Subpart K for complete requirements.

3.2 CFR 29 PART 1910 - GENERAL INDUSTRY STANDARDS APPLICABLE TO

CONSTRUCTION INDUSTRY

A. This section contains a partial listing of the referenced OSHA standards.