C04 Attachment 1 - Solicitation Instructions - Terms and Conditions - 1240LT26Q0080.pdf

Duchesne Office Mechanical Room Renovation

1240LT26Q0080

Ashley National Forest

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Part 12. This announcement constitutes the only solicitation. Quotations are being requested and a separate written solicitation will not be issued.

Solicitation number 1240LT26Q0080 is issued as a Request for Quotation (RFQ) for Duchesne Office Mechanical Room Renovation.

This acquisition is set-aside for small business concerns. The applicable North American Industry Classification Standard Code is 238220 The small business size standard is $19.0M This acquisition is a Total Small Business Set-Aside. All responsible sources may submit a quotation which will be considered by the agency.

Statement of Requirement

This is an urgent requirement which includes renovating the mechanical room specified in specifications and drawings. Work includes the repair of the damaged floor and subfloor and the installation of new laminate flooring, the installation and plumbing of a new mop sink and replumbing the existing water heater TPR valve water line and the furnace condensate water line to the existing grey water drain line within the crawl space.

See “Attachment 1 - Solicitation Terms and Conditions” for applicable clauses, instructions, and evaluation criteria.

The following documents are included as attachments to this solicitation:

C04 Attachment 1 – Solicitation Instructions - Terms and Conditions 1240LT26Q0080 C04 Attachment 2 – SCHEDULE OF ITEMS – 1240LT26Q0080 C04 Attachment 3 – SOW-SPECS – 1240LT26Q0080 C04 Attachment 4 - PHOTOS-DRAWINGS – 1240LT26Q0080 C04 Attachment 5 – Experience Questionnaire – 1240LT26Q0080 C04 Attachment 6 – WD UT20260079 dtd 1-2-2026 – 1240LT26Q0080

Schedule of Items - See Attachment 2 – Schedule of Items

Technical Data

Technical data and supporting documentation associated with this solicitation are available through the following sources:

Solicitation Attachments:

Attachment 3 – Statement of Work/Specifications

Attachment 4 – Photos/Drawings

Project Location

The project is located at the Duchesne District Office, 85 West Main St. in Duchesne. Utah.

Definitization of Equitable Adjustments for Change Orders -

Pursuant to FAR 36.101-4(b), information regarding USDA’s definitization of equitable adjustments for change orders under construction contracts may be found at Contracting with USDA under “Federal Acquisition Regulation 36.101-4”. USDA’s procedures that apply to the definitization of equitable adjustments for change orders under construction contracts may be found in AGAR

443.304 -70.

Federal Acquisition Regulation (FAR) and United States Department of Agriculture Acquisition Regulation (AGAR) Clauses and Provisions The clauses and provisions contained herein are applicable to any order awarded as a result of this solicitation. The terms and conditions set forth herein supersede all other terms and conditions.

Acceptance of the order in accordance with (IAW) FAR 12.201-1(b)(2) constitutes acceptance of all terms and conditions contained herein.

As part of the Revolutionary FAR Overhaul (RFO), system updates may lag policy updates. The System for Award Management (SAM) may continue to require entities to complete representations based on provisions that are not included in this solicitation. Contracting officers will rely on representations from offers based on provisions in the solicitation. Entities are not required to, nor are they able to, update their entity registration to remove these representations in SAM.

52.252-2 Clauses Incorporated by Reference Feb 1998 This solicitation incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also the full text of the clause may be accessed electronically at Internet address https://www.acquisition.gov/far-overhaul/far-part-deviation-guide/far-overhaul-part-52

52.212-4 Terms and Conditions—Commercial Products and Commercial Services (Nov 2025) ☐ Alternate I (Nov 2025) of 52.212-4

This is a commercial construction acquisition. FAR 52.212-4 is amended as follows:

(b) Inspection/Acceptance. Inspection and Acceptance will be conducted in accordance with FAR 52.246-12, Inspection of Construction (Aug 1996).

(d) Changes. Changes will be handled in accordance with the following FAR clause(s):

☐ FAR 52.243-4, Changes (Nov 2025) ☒ FAR 52.243-5, Changes and Changed Conditions (Nov 2025)

52.203-17 Contractor Employee Whistleblower Rights (Nov 2023) 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) 52.222-50 Combating Trafficking in Persons (Nov 2025)

☐ Alternate I (Nov 2025) of 52.222-50 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) 52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013) 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) 52.233-3 Protest After Award (Sep 2025) 52.233-4 Applicable Law for Breach of Contract Claim (Sep 2025) 52.240-91 Security Prohibitions and Exclusions (Nov 2025)

☐ Alternate I (Nov 2025) of 52.240-91 52.244-6 Subcontracts for Commercial Products and Commercial Services (Nov 2025)

☐ 52.203-6 Restrictions on Subcontractor Sales to the Government (Jun 2020) with Alternate I (Nov 2021) of 52.203-6 ☐ 52.203-13 Contractor Code of Business Ethics and Conduct (Nov 2021) ☒ 52.204-9 Personal Identity Verification of Contractor Personnel Jan 2011 ☒ 52.204-13 System for Award Management—Maintenance (Nov 2025) ☐ 52.204-91 Contractor identification (Nov 2025) ☐ 52.209-6 Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Sep 2025) ☐ 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (Sep 2025) ☒ 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (Sep 2025) ☐ 52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Nov 2025) ☒ 52.219-6 Notice of Total Small Business Aside (Nov 2025)

☐ Alternate I (Mar 2020).

☐ 52.219-8 Utilization of Small Business Concerns (Nov 2025) ☐ 52.219-9 Small Business Subcontracting Plan (Nov 2025)

☐ Alternate III (Nov 2025) of 52.219-9.

☐ Alternate IV (Nov 2025) of 52.219-9

☒ 52.219-14 Limitations on Subcontracting (Nov 2025) ☐ 52.219-16 Liquidated Damages—Subcontracting Plan (Nov 2025) ☐ 52.219-33 Nonmanufacturer Rule (Nov 2025) ☒ 52.222-3 Convict Labor (June 2003) ☒ 52.222-19 Child Labor—Cooperation with Authorities and Remedies (Nov 2025)

☐ 52.222-35 Equal Opportunity for Veterans (Nov 2025) ☐ Alternate I (Jul 2014) of 52.222-35

☒ 52.222-36 Equal Opportunity for Workers with Disabilities (Nov 2025) ☐ Alternate I (Jul 2014) of 52.222-36

☐ 52.222-37 Employment Reports on Veterans (Nov 2025) ☐ 52.222-40 Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) ☐ 52.222-41 Service Contract Labor Standards (Aug 2018) ☐ 52.222-42 Statement of Equivalent Rates for Federal Hires (May 2014)

This Statement is for Information Only:

It is not a Wage Determination

Employee Class Monetary Wage -- Fringe Benefits

Aircraft Mechanic $XX.XX

☐ 52.222-43 Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) ☐ 52.222-44 Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) ☒ 52.222-51 Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ☒ 52.222-53 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (Nov 2025) ☐ 52.222-54 Employment Eligibility Verification (Nov 2025) ☒ 52.222-62 Paid Sick Leave Under Executive Order 13706 (Jan 2022) ☒ 52.222-90 Addressing DEI Discrimination by Federal Contractors (Apr 2026) ☐ 52.223-2 Reporting of Biobased Products Under Service and Construction Contracts (Nov 2025) ☐ 52.223-9 Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008)

☐ Alternate I (May 2008) of 52.223-9 ☐ 52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Nov 2025) ☐ 52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Nov 2025) ☐ 52.223-23 Sustainable Products and Services (Nov 2025) ☐ 52.224-3 Privacy Training (Jan 2017)

☐ Alternate I (Jan 2017) of 52.224-3 ☒ 52.225-1 Buy American-Supplies (Nov 2025)

☐ Alternate I (Oct 2022) of 52.225-1 ☐ 52.225-3 Buy American--Free Trade Agreements--Israeli Trade Act (Nov 2025)

☐ Alternate II (Nov 2025) of 52.225-3.

☐ Alternate III (Nov 2025) of 52.225-3.

☐ Alternate IV (Oct 2022) of 52.225-3

☐ 52.225-5 Trade Agreements (Nov 2023) ☐ 52.225-19 Contractor Personnel in a Designated Operational Area or Supporting a Diplomatic or Consular Mission outside the United States (May 2020) ☐ 52.225-26 Contractors Performing Private Security Functions Outside the United States (Oct 2016) ☐ 52.226-4 Notice of Disaster or Emergency Area Set-Aside (Nov 2007) ☐ 52.226-5 Restrictions on Subcontracting Outside Disaster or Emergency Area (Aug 2025) ☐ 52.229-12 Tax on Certain Foreign Procurements ☐ 52.232-29 Terms for Financing of Purchases of Commercial Products and Commercial Services (Nov 2021) ☐ 52.232-30 Installment Payments for Commercial Products and Commercial Services (Nov 2021) ☒ 52.232-33 Payment by Electronic Funds Transfer— System for Award Management (Oct 2018) ☐ 52.232-34 Payment by Electronic Funds Transfer—Other Than System for Award Management (Jul 2013) ☐ 52.232-36 Payment by Third Party (Nov 2025) ☐ 52.240-92 Security Requirements (Nov 2025)

☐ Alternate II (Nov 2025) of 52.240-92 ☐ 52.240-93 Basic Safeguarding of Covered Contractor Information Systems (Nov 2025) ☐ 52.242-13 Bankruptcy (July 1995) ☒ 52.246-21 Warranty of Construction (Mar 1994) ☐ 52.247-64 Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2025)

☐ Alternate I (Apr 2023) of 52.247-64.

☐ Alternate II (Nov 2021) of 52.247-64

FAR 52.225-9 Buy American Act-Construction Materials (NOV 2025)

(a) Definitions. As used in this clause—Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial product (as defined in paragraph (1) of the definition of “commercial product” at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued);

or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105. Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Domestic construction material means—

(b) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(1) An unmanufactured construction material mined or produced in the United States; or

(2) A construction material manufactured in the United States, if–

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or (B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all component used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together.

Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States. Produced in the United States means that all manufacturing processes of the iron or steel must take place in the

United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. Chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(c) This requirement does not apply to information technology that is a commercial product or to the construction materials or components listed by the Government as follows:

NONE

(d) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(1) The cost of domestic construction material would be unreasonable.

(i) For domestic construction material that is not a critical item or does not contain critical components.

• The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

• For construction material that is not a COTS item and does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that is manufactured in the United States and does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest offer of foreign construction material that exceeds 55 percent domestic content as a domestic offer and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(A)(1) of this clause.

• The procedures in paragraph (b)(3)(i)(A)(2) of this clause will no longer apply as of January 1, 2030.

(e) For domestic construction material that is a critical item or contains critical components.

(1) The cost of a particular domestic construction material that is a critical item or contains critical components, subject to the requirements of the Buy American statute, is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent plus the additional preference factor identified for the critical item or construction material containing critical components listed at FAR 25.105.

(2) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest foreign offer of construction material that is manufactured in the United States and exceeds

55 percent domestic content as a domestic offer, and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(B)(1) of this clause.

(3) The procedures in paragraph (b)(3)(i)(B)(2) of this clause will no longer apply as of January

1, 2030.

(3) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(4) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1) (i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the

Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material.

However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction Material Description Unit of Measure Quantity Price (Dollars)* Item1

Foreign construction material Domestic construction material Item 2 Foreign construction material Domestic construction material [*Include all delivery costs to the construction site and any applicable duty (whether or not a dutyfree entry certificate is issued)].

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.]

(End of clause)

52.233-1 Disputes.

As prescribed in 33.205-9(a) , insert the following clause:

DISPUTES (DEVIATION DATE)

(a) Definitions. As used in this clause- Claim means a written demand or written assertion by one of the contracting parties seeking, as a matter of right, the payment of money in a sum certain, the adjustment or interpretation of contract terms, or other relief arising under or relating to this contract. However, a written demand or written assertion by the Contractor seeking the payment of money exceeding $100,000 is not a claim under 41 U.S.C. chapter 71 until certified. A voucher, invoice, or other routine request for payment that is not in dispute when submitted is not a claim under 41 U.S.C. chapter 71. The submission may be converted to a claim under 41 U.S.C. chapter 71, by complying with the submission and certification requirements of this clause, if it is disputed either as to liability or amount or is not acted upon in a reasonable time.

Defective certification means a certification that alters or otherwise deviates from the language in paragraph (d)(2)(iii) of this clause or which is not executed by a person authorized to bind the contractor with respect to the claim. Failure to certify must not be deemed to be a defective certification.

(b) This contract is subject to 41 U.S.C. chapter 71, Contract Disputes.

(c) Except as provided in 41 U.S.C. chapter 71, all disputes arising under or relating to this contract must be resolved under this clause.

(d)

(1) A claim by the Contractor must be made in writing and, unless otherwise stated in this contract, submitted within 6 years after accrual of the claim to the Contracting Officer for a written decision.

A claim by the Government against the Contractor must be subject to a written decision by the Contracting Officer.

(2)

(i) The Contractor must provide the certification specified in paragraph (d)(2)(iii) of this clause when submitting any claim exceeding $100,000.

(ii) The certification requirement does not apply to issues in controversy that have not been submitted as all or part of a claim.

(iii) The certification must state as follows: “I certify that the claim is made in good faith; that the supporting data are accurate and complete to the best of my knowledge and belief; that the amount requested accurately reflects the contract adjustment for which the Contractor believes the Government is liable; and that I am authorized to certify the claim on behalf of the Contractor.”

(3) The certification may be executed by any person authorized to bind the Contractor with respect to the claim.

(e) For Contractor claims of $100,000 or less, the Contracting Officer must, if requested in writing by the Contractor, render a decision within 60 days of the request. For Contractor-certified claims over $100,000, the Contracting Officer must, within 60 days, decide the claim or notify the Contractor of the date by which the decision will be made.

(f) The Contracting Officer's decision must be final unless the Contractor appeals or files a suit as provided in 41 U.S.C. chapter 71.

(g) If the claim by the Contractor is submitted to the Contracting Officer or a claim by the Government is presented to the Contractor, the parties, by mutual consent, may agree to use alternative dispute resolution (ADR). If the Contractor refuses an offer for ADR, the Contractor must inform the Contracting Officer, in writing, of the Contractor's specific reasons for rejecting the offer.

(h)

(1) The Government must pay interest on the amount found due and unpaid from the date that-

(i) The Contracting Officer receives the claim (certified, if required); or

(ii) Payment otherwise would be due, if that date is later, until the date of payment.

(2) For claims having defective certifications, interest must be paid from the date that the Contracting Officer initially receives the claim. Simple interest on claims must be paid at the rate, fixed by the Secretary of the Treasury as provided in the Act, which applies to the period during which the Contracting Officer receives the claim and then at the rate that applies for each 6-month period as fixed by the Treasury Secretary while the claim is pending.

(i) The Contractor must proceed diligently with performance of this contract, pending final resolution of any request for relief, claim, appeal, or action arising under the contract. The Contractor must comply with any decision of the Contracting Officer.

(End of clause)

52.249-10 Default (Fixed-Price Construction).

As prescribed in 49.504(c)(1), insert the following clause:

DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed. In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor’s refusal or failure to complete the work within the specified time, whether or not the Contractor’s right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the- work.

(b) The Contractor’s right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if-

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include-

(i) Acts of God or of the public enemy;

(ii) Acts of the Government in either its sovereign or contractual capacity;

(iii) Acts of another Contractor in the performance of a contract with the Government;

(iv) Fires;

(v) Floods;

(vi) Epidemics;

(vii) Quarantine restrictions;

(viii) Strikes;

(ix) Freight embargoes;

(x) Unusually severe weather; or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.

(c) If, after termination of the Contractor’s right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

(d) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.

The Contractor shall comply with the following FAR Clauses for Commercial Construction.

52.222-6 Construction Wage Rate Requirements 52.222-7 Withholding of Funds 52.222-8 Payrolls and Basic Records 52.222-9 Apprentices and Trainees 52.222-10 Compliance with Copeland Act Requirements 52.222-11 Subcontracts (Labor Standards) 52.222-12 Contract Termination-Debarment 52.222-14 Disputes Concerning Labor Standards 52.222-15 Certificate of Eligibility 52.236-5 Material and Workmanship

The following clauses are applicable when checked:

☐ 52.222-30 Construction Wage Rate Requirements-Price Adjustment (None or Separately Specified Pricing Method (Aug 2018) ☐ 52.222-31 Construction Wage Rate Requirements-Price Adjustment (Percentage Method) (Aug 2018) ☐ 52.222-32 Construction Wage Rate Requirements-Price Adjustment (Actual Method) (Nov 2025) ☒ 52.225-9 Buy American-Construction Materials (Nov 2025) ☐ Alternate I (Oct 2022) of 52.25-9 ☐ 52.225-11 Notice of Buy American Requirement-Construction Materials under Trade Agreements (Nov 2025) ☐ Alternate I (Nov 2025) (of 52.225-11 ☐ Alternate II (Oct 2022) of 52.225-11 ☐ 52.228-2 Additional Bond Security (Oct 1997) ☐ 52.228-5 Insurance-Work on Government Installation (Jan 1997) ☐ 52.228-11 Individual Surety-Pledge of Assets (Feb 2021) ☐ 52.228-13 Alternative Payment Protections (Jul 2020) ☐ 52.228-14 Irrevocable Letter of Credit (Nov 2014) ☐ 52.228-15 Performance and Payment Bonds-Construction (Jun 2020) ☐ 52.228-17 Individual Surety-Pledge of Assets (Bid Guarantee) (Feb 2021) ☒ 52.236-2 Differing Site Conditions (Jul 2025) ☒ 52.236-3 Site Investigation and Conditions Affecting the Work (Jul 2025) ☒ 52.236-6 Superintendent by the Contractor (Jul 2025) ☒ 52.236-7 Permits and Responsibilities (Jul 2025) ☒ 52.236-8 Other Contracts (Jul 2025) ☒ 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (Jul 2025)

☒ 52.336-10 Operations and Storage Areas (Jul 2025) ☒ 52.236-11 Use and Possession Prior to Completion (Jul 2025) ☒ 52.236-12 Cleaning Up (Jul 2025) ☒ 52.236-13 Accident Prevention (Jul 2025) ☐ Alternate I (Nov 1991) of 52.236-13 ☒ 52.236-14 Availability and Use of Utility Services (Jul 2025) ☐ 52.236-15 Schedules for Construction Contracts (Jul 2025) ☐ 52.236-16 Quantity Surveys (Jul 2025) ☐ Alternate I (Apr 1984) of 52.236-16 ☐ 52.236-17 Layout of Work (Jul 2025) ☒ 52.236-21 Specifications and Drawings for Construction (Jul 2025) ☐ Alternate I (Apr 1984) of 52.236-21 ☐ Alternate II (Apr 1984) of 52.236-21 ☒ 52.242-14 Suspension of Work (Apr 1984) ☐ 52.248-3 Value Engineering (Oct 2025) ☐ Alternate I (Apr 1984) of 52.248-3

Other Applicable Clauses

52.247-34 F.O.B. Destination (Jan 1991)

AGAR Clauses

452.203-71 Anti-Discrimination and Diversity, Equity, and Inclusion (DEI) Compliance (Dec 2025)

(a) By entering into this contract, the contractor certifies that:

(1) It is compliant with all applicable Federal anti-discrimination laws and the Equal Protection principles of the U.S. Constitution, and it will remain compliant for the duration of the contract.

(2) Neither it nor any subcontractor or teaming partner operates or funds any program, policy, or initiative that promotes DEI in a manner that violates any applicable Federal anti-discrimination laws, including but not limited to Title VI and VII of the Civil Rights Act of 1964, or the Equal Protection principles of the U.S. Constitution, and the contractor and any subcontractor or teaming partner will not do so for the duration of the contract.

(b) If the contractor participates in, facilitates, or funds programs that implicate Title VI of the Civil Rights Act of 1964 or Title IX of the Education Amendments of 1972, as amended, including but not limited to grants to or for schools, colleges, universities, 4-H programs, non-governmental organization (NGO) programs, sports programs, and education-related grants to prisons or other detention facilities, the contractor certifies that it will remain compliant with those laws, including the requirements set forth in Executive Order 14168, Defending Women from Gender Ideology Extremism and Restoring Biological Truth to the Federal Government, and Executive Order 14173, Ending Illegal Discrimination and Restoring Merit-Based Opportunity.

(c) The contractor affirms that the above requirements are conditions of payment that go to the essence of the contract and are therefore material terms of the contract. Payments under the contract are predicated on compliance with the above requirements, and therefore the contractor is not eligible for funding under the contract or to retain any funding under the contract absent compliance with the above requirements.

(d) This certification reflects a change in the Government’s position regarding the materiality of the foregoing requirements and therefore any prior payment of similar claims does not reflect the materiality of the foregoing requirements to this contract.

(e) Submission of a knowing false statement relating to contractor’s compliance with the above requirements and/or eligibility for the contract may subject the contractor to liability under the False Claims Act, 31 U.S.C. § 3729, and/or criminal liability, including under 18 U.S.C. §§ 287 and 1001.

(f) The contractor must include the provisions of this clause in all subcontract solicitations.

(g) Failure on the part of the contractor or its subcontractors to comply with the terms of this clause may be grounds for the Contracting Officer to terminate this contract for default.

(End of Clause)

AGAR 452.203-72 Unenforceable Supplier Terms (MAY 2026)

(a) Definitions.

Supplier terms mean provisions customarily drafted by vendors of supplies or services and intended to create a binding legal obligation on the end user. The term applies:

(1) Regardless of the format or style of the document. For example, supplier terms may appear in standard terms of sale or lease, Terms of Service (TOS), End User License Agreement (EULA), or another similar legal instrument or agreement, and may be presented as part of a proposal or quotation responding to a solicitation for a contract or order or otherwise become effective after the contract date.

(2) Regardless of the media or delivery mechanism used. For example, supplier terms may be presented as one or more paper documents or may appear on a computer or other electronic device screen during a purchase, software installation, other product delivery, registration for a service, or another transaction.

(b) Applicability. When any supply or service acquired under this contract is subject to supplier terms, the supplier terms are deemed part of the contract only to the extent they are consistent with this clause. Supplier terms that conflict with any part of this clause, the contract, or Federal law are void and will not be considered incorporated into a contract, even if they are physically present in a contract documentation or systems. In the event of any inconsistency between supplier terms and this contract, this clause and the terms of the Government contract must govern and supersede any supplier terms in all cases.

(c) Authorization Required. Notwithstanding any other provision, no supplier terms must be binding on the Government unless the term is expressly authorized on the USDA Supplier Terms Authorization Form signed by the Contracting Officer, and the completed Authorization Form has been incorporated into the contract.

(d) Unenforceable Terms. Any supplier terms that impose obligations or restrictions inconsistent with applicable Federal law are unenforceable against the Government and deemed stricken from the agreement. This includes, but is not limited to, any clause that:

(1) Requires the Government to pay future fees, penalties, interest, legal costs, early‑termination fees, cancellation fees, minimum purchase commitments, true‑up payments, seat‑count minimums, usage minimums, continued‑use charges, or any other financial obligation not expressly authorized by the contract.

(2) Requires the Government to indemnify the contractor or any other entity.

(3) Restricts the Government’s ability to obtain similar supplies or services from another source.

(4) Imposes any penalty, financial or otherwise, based on the Government’s decision not to exercise an option.

(5) Subjects the United States Government to the laws of any U.S. state, territory, district, municipality, or foreign nation, except where Federal law expressly permits such application.

(6) Requires dispute resolution in a forum or venue other than one prescribed by applicable Federal law.

(7) Establishes a period of limitations for bringing an action that differs from that provided by applicable Federal law.

(8) Grants the contractor rights to use, mine, access, aggregate, analyze, or otherwise exploit Government data, usage data, or metadata.

(9) Deems the Government to have accepted initial or revised terms based on silence, continued performance, or failure to object.

(10) Grants the supplier the right to audit Government facilities, systems, records, or use of the product or service, except as expressly authorized by the contract and applicable Federal law.

(11) Requires the Government to accept supplier security requirements, network access requirements, monitoring, penetration testing, or other technical or security measures.

(12) Permits the supplier to suspend, degrade, or terminate access to products or services based on alleged non‑payment, alleged breach, automated security triggers.

(13) Limits the Government’s right to use, install, access, test, evaluate, or transfer the licensed product or service in any manner consistent with the contract and Federal law.

(14) Requires the Government to store, process, maintain, or transmit data in a particular geographic location, or permits the supplier to transfer Government data outside the United States, except as expressly authorized by applicable Federal law.

(15) Authorizes the supplier to use the Government’s name, seal, trademark, logo, or any reference to the Government as an end user or customer for marketing, publicity, promotional activities, press releases, or similar purposes.

(16) Incorporates by reference, or requires the Government to accept, terms or conditions imposed by any third party, subcontractor, or upstream service provider, unless such terms are expressly incorporated into the contract by bilateral modification.

(17) Limits, conditions, or negates the contractor’s performance obligations, service levels, or remedies through a supplier‑provided service level agreement (SLA).

(18) Uses Government data, usage data, metadata, prompts, content, or interactions to train, fine‑tune, improve, or derive any artificial intelligence, machine learning, or automated decision‑making model.

(19) Subjects the Government to automated decision‑making, automated risk scoring, automated content moderation, or any algorithmic process that may affect access, performance, or rights under the contract.

(20) Utilizes artificial intelligence or algorithmic tools that produce decisions, recommendations, or outputs affecting contract performance without providing transparency, explainability, auditability, and bias‑mitigation consistent with applicable Federal law and policy.

(21) Profiles, tracks, or analyzes Government user behavior, preferences, communications, or interactions for personalization, marketing, or algorithmic optimization purposes.

(e) Non-binding Actions. Neither the Government nor any Government authorized end user is deemed to have consented to any term, condition, or clause by virtue of its inclusion in the supplier agreement or through the use of clickwrap, browsewrap, “I agree” mechanisms, or similar means.

Execution of such mechanisms does not bind the Government or its authorized end users to any unenforceable terms.

(f) End user. The supplier agreement must bind the ordering activity as the end user to the extent it does not conflict with the terms of this clause, but it must not bind or impose personal liability on any Government employee or any person acting on behalf of the Government in their personal capacity.

(g) Law and disputes. The supplier agreement is governed by Federal law.

(h) Statutory exception. This clause does not apply to indemnification or any other payment by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(i) Continued performance. The supplier or licensor must not unilaterally revoke, terminate, or suspend any rights granted to the Government except as allowed by the contract. If the supplier or licensor believes the ordering activity to be in breach of the supplier agreement, it must pursue its rights under the Contract Disputes Act or other applicable Federal statute while proceeding diligently with performance, pending final resolution of any dispute in accordance with the Disputes Clause at FAR 52.212‑4(d) or FAR 52.233‑1, as applicable.

(j) Arbitration. Binding arbitration must not be used unless specifically authorized by agency guidance.

(k) Equitable or injunctive relief. Equitable or injunctive relief, including the award of attorney fees, costs, or interest, may be awarded against the United States Government only when explicitly provided by statute (e.g., the Prompt Payment Act or the Equal Access to Justice Act).

(l) Revisions to supplier agreements. Any revisions to the supplier agreement must be incorporated into the contract using a bilateral modification. Unilateral revisions are not binding on the Government.

(m) No automatic renewals. If any license or service tied to periodic payment is provided under the supplier agreement (e.g., annual software maintenance or annual lease term), such license or service must not renew automatically upon expiration of its current term without prior express written consent from an authorized Government representative.

(n) Indemnification. Any clause of the supplier agreement requiring the supplier or licensor to defend or indemnify the end user is amended to provide that the U.S. Department of Justice has the sole right to represent the United States in any such action, in accordance with 28 U.S.C. 516.

(o) Taxes or surcharges. Any taxes or surcharges which the supplier or licensor seeks to pass along to the Government as end user will be governed by the terms of the associated Government contract or order and must be submitted to the Contracting Officer for a determination of applicability prior to invoicing unless specifically agreed otherwise.

(p) Non‑assignment. The supplier agreement may not be assigned, nor may any rights or obligations thereunder be delegated, without the Government’s prior approval, except as expressly permitted by FAR 52.212-4(b) or FAR 52.232-23, as applicable.

(q) Confidential information. If the supplier agreement includes a confidentiality clause, such clause is amended to state that neither the agreement nor the contract price list, as applicable, must be deemed “confidential information.” Issues regarding release of “unit pricing” will be resolved consistent with the Freedom of Information Act. Notwithstanding anything in the supplier agreement to the contrary, the Government may retain any confidential information as required by law, regulation, or its internal document retention procedures for legal, regulatory, or compliance purposes; provided, however, that all such retained confidential information will continue to be subject to the confidentiality obligations of the supplier agreement.

(r) Conflict with Federal law. If any other language, provision, or clause of the supplier agreement conflicts or is inconsistent with Federal law or the terms and conditions of this contract, such language, provisions, or clauses will be considered null and void and will not be binding on the United States Government.

(End of Clause)

452.204–70 Modification for Contract Closeout (Apr 2026)

(a) If unliquidated funds in the amount of $1000 or less remain on the contract, the Contracting Officer (Contracting Officer) may issue a unilateral modification for deobligation. The contractor will receive a copy of the modification but is not required to provide a signature. The Contracting Officer will immediately proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

(b) For commercial contracts not exceeding the simplified acquisition procedure threshold under FAR 12.001(c), if more than $1,000 in unliquidated funds remain at closeout, the Contracting Officer will issue a bilateral deobligation modification. Only the modification requires the contractor’s signature, though a Release of Claims may be requested. If the required documents are not returned within 60 days, the Contracting Officer will issue a unilateral modification and proceed with closeout once performance is complete, acceptance is confirmed, and final payment is made.

(c) For all other non-commercial or non–cost‑reimbursement contracts, if more than $1,000 in unliquidated funds remain at closeout, the Contracting Officer will issue a bilateral deobligation modification and a Release of Claims, both requiring contractor signature. If these documents are not returned within 120 days, the Contracting Officer will issue a unilateral modification and proceed with closeout upon completion of performance, acceptance, and final payment.

(End of Clause)

452.232-71 Progress Payments for Commercial Construction Contracts (May 2026)

(a) Contractor entitlement to progress payments. The contractor may request progress payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer, on estimates of work accomplished that meets the standards of quality established under the contract, as approved by the Contracting Officer.

(b) Computation of amounts. Progress payments will be authorized when the payment requested is properly due in accordance with this contract; the work will be performed in accordance with the contract; and there has been no impairment or diminution of the Government’s security under this contract. The Contracting Officer may authorize consideration of:

(1) Materials delivered on site and preparatory work;

(2) Materials delivered to the contractor at locations other than the site, if:

i. Specifically authorized by the contract; and

ii. The contractor provides satisfactory evidence of title and intended use in the contract.

(c) Contractor request for progress payments. The contractor’s request for progress payments must include the following:

(1) An itemization of the amounts requested, related to the various elements of work required by the contract;

(2) A listing of the amount included for work performed by each subcontractor;

(3) A listing of the total amount of each subcontract;

(4) A listing of the amounts previously paid to each subcontractor; and

(5) Additional supporting data in a form and detail required by the Contracting Officer.

(d) Contractor Certification. Each request for progress payment must be accompanied by the following certification:

I hereby certify, to the best of my knowledge and belief, that—

(1) The amounts requested are only for performance in accordance with the specifications, terms, and conditions of the contract;

(2) All payments due to subcontractors and suppliers from previous payments received under the contract have been made, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and the requirements of Chapter 39 of Title 31, United States Code;

(3) This request for progress payments does not include any amounts which the prime contractor intends to withhold or retain from a subcontractor or supplier in accordance with the terms and…