Bid 6721 Amendment 1.pdf

PHILADELPHIA INTERNATIONAL AIRPORT BID 6721

REHABILITATION OF TAXIWAY K (BETWEEN TW Y AND TW Z) PHL-1641.24

SEPTEMBER 23, 2026 AMENDMENT NO. 1 PAGE 1 OF 1

City of Philadelphia

Department of Aviation

PHILADELPHIA INTERNATIONAL AIRPORT

REHABILITATION OF TAXIWAY K (BETWEEN TW Y AND TW Z)

AMENDMENT

Amendment No. 1 Dated: September 23, 2026

Bid No. 6721 Pre-Qualification Due Date: October 1, 2026

Bid Opening Date: October 22, 2026

NOTICE

It is the sole responsibility of the seller to ensure that it has received any and all amendments, and the Procurement Commissioner may in his/her sole discretion reject any quote for which all amendments have not been executed and returned.

PROPOSAL FOR:

Project No.: PHL-1641.24

Description: Philadelphia International Airport

Rehabilitation Of Taxiway K (Between TW Y And TW Z)

IS AMENDED AS FOLLOWS:

I. PROJECT MANUAL REVISIONS

1. Delete Page A-1 and replace with revised Page A-1.

2. Add Office of Economic Opportunity – Small and Local Business Plan, Appendix 1 –

Participation Range Memo, and Appendix 2 – Solicitation & Participation Form immediately following Section B.

II. ATTACHMENTS

1. Revised Project Manual Page A-1 (1 Page)

2. Office of Economic Opportunity – Small and Local Business Plan. (9 Pages)

3. Office of Economic Opportunity – Appendix 1 – Participation Range Memo (1 page)

4. Office of Economic Opportunity – Appendix 2 – Solicitation & Participation Form (1 page)

5. Non-Mandatory Pre-Bid Meeting Slides (30 pages)

*NOTE: SELLER MUST ACKNOWLEDGE RECEIPT OF AMENDMENTS ON PHLCONTRACTS

END OF AMENDMENT NO. 1

PHILADELPHIA INTERNATIONAL AIRPORT BID 6721

REHABILITATION OF TAXIWAY K (BETWEEN TW Y AND TW Z) PHL-1641.24

A-1 OF 1

PROJECT MANUAL

SECTION A - TABLE OF CONTENTS

TITLE PAGES

SECTION A - Table of Contents A-1

SECTION B - Bid Proposal B-1 to B-13

OFFICE OF ECONOMIC OPPORTUNITY - SMALL & LOCAL 1-9

BUSINESS PLAN

APPENDIX 1 PARTICIPATION RANGE MEMO 1

APPENDIX 2 SOLICITATION & PARTICIPATION FORM 1

DOL NEW APPRENTICESHIP REQUIREMENTS 2

BID PROCESSING FEE FLYER 1

NOTICE OF LCP TRACKING SYSTEM LCP-1

MAYOR’S EXECUTIVE ORDER 7-14 (OIG) EO-1

ACT 141 VERIFICATION FORM AT-1

WAGE RATES

City Wage Rates effective July 28, 2026 1 to 17

STANDARD CONTRACT REQUIREMENTS – September, 2025 1 to 44

SECTION C - Special Provisions C-1 to C-23

CITY OF PHILADELPHIA OCIP – Instructions to Bidders 1

THE CITY OF PHILADELPHIA – Owner Controlled Insurance 1 to 29 Program (OCIP) – Contract Insurance Amendment

THE CITY OF PHILADELPHIA – Owner Controlled Insurance 1 to 32 Program – Health & Safety Manual

THE CITY OF PHILADELPHIA - Rolling OCIP Procedures Manual 1 to 40

PHL GATE AGREEMENT G-1 to G-24

PHL RULES AND REGULATIONS, SECTION 7 7-1 to 7-33

PHL CHANGED CONDITIONS AFFECTING SECURITY GUIDELINES 1 to 6

TECHNICAL SPECIFICATIONS

SEPTEMBER 23, 2026 – AMENDMENT NO. 1

Ekpenyong Oji 9/10/26

SLBP

Rev. Date: August 2026

CITY OF PHILADELPHIA

OFFICE OF ECONOMIC OPPORTUNITY

SMALL & LOCAL BUSINESS PLAN

Forms, Instructions and Special Contract Provisions Project – PHL-1641.24 Rehabilitation of Taxiway K between Taxiways Y & Z; Bid 6721

1. INTRODUCTION

Under the authority of Executive Order No. 06-25, the City of Philadelphia (the “City”) has established a Policy for the City of Philadelphia Small Business Program (the “SBE Policy”) relating to the participation of Small Business Enterprises (“SBE”) in City contracts. The Policy is administered by the Office of Economic Opportunity (“OEO”).

The City is committed to fostering economic opportunity for all and enabling all businesses to compete for City contracts without the impediments of discrimination. The goal of the SBE Policy is to ensure that all purchasing and contracting activities are conducted in a fair and equitable manner with increased emphasis on SBE outreach, solicitation and participation. This includes implementation of effective strategies to document and monitor prime contractors’ compliance with, and commitments to, sub-contract work with SBEs.

The City’s local businesses supply vital goods and services, offer important employment opportunities, and can help to build wealth and innovate commercial change. The City seeks to increase local economic impact by redirecting a greater share of City spending toward local businesses through the Local Business Entity Program (“LBE Program”), administered by the City’s Procurement Department. The LBE Program can generate substantial economic returns through increased local spending.

In furtherance of the goals of Executive Order No. 06-25 and the SBE Policy, this Small & Local Business Plan (“SLBP”) outlines the City’s requirements for the participation of small and local businesses on this particular Project.

Further clarification of OEO’s Small Business Program, along with assistance in completing forms, can be obtained by phone at (215) 683-2071 or by email at oeophila@phila.gov. More information on Procurement’s Local Business Program can be obtained by phone at (215) 686-5940 or by email at LBEcertification@phila.gov.

2. DEFINITIONS

A. Availability. The percentage of SBEs and LBEs that are ready, willing, and able to perform specific types of government contracts or procurements, compared to all businesses in the market that are capable of performing the same type of work.

B. Best and Good Faith Efforts. Efforts undertaken in good faith in furtherance of the participation goals required under this SLBP and which a reasonable person would perceive to be of a nature and scope likely to achieve such goals, regardless of whether the goals are in fact met.

C. Certifying Agency. A recognized certification agency that verifies a business meets specific size and revenue standards. Approved Certifying Agencies are identified on OEO’s website at Certifying Agencies | Office of Economic Opportunity | City of Philadelphia.

D. Commercially Acceptable Function. A business or contractor performs a Commercially Acceptable Function when it is responsible for executing the work of a contract and is mailto:oeophila@phila.gov https://www.phila.gov/departments/office-of-business-impact-and-economic-advancement/divisions/office-of-economic-opportunity/#certification-agencies

SLBP

Rev. Date: August 2026 carrying out its responsibilities by directly performing, managing, and supervising the work involved. To perform a Commercially Acceptable Function the business or contractor must perform a distinct element of the work required by, and commensurate with the dollar amount set forth for such work in, the contract or subcontract.

E. Contract. The contract awarded by the City for the Project whether as a result of a competitive bid or request for proposals

F. Dominant in Its Field of Operation. A company that holds significant control and influence over their specific industries or markets, allowing them to shape prices, set standards, and operate with minimal competitive pressure.

G. Local Business Entity (LBE). A business that has been certified as a Local Business Entity, consistent with the City’s requirements governing eligibility for such certification.

More information about the LBE Program can be found on the City’s webpage at Procurement Department | Local Preference.

H. OEO Registry. OEO maintains a registry of businesses that have been certified as SBE by a Certifying Agency. Information about OEO’s Registry can be found on OEO’s website at OEO Registry | Office of Economic Opportunity | City of Philadelphia.

I. Participant. Any SBE or LBE engaged to perform work on the Project either as a prime contractor or as a subcontractor.

J. Project. The work to be completed under the Contract and as defined in Appendix 1:

Participation Range Memo.

K. Respondent. Any person or entity responding to a City contracting opportunity for the Project, whether by bid or proposal.

L. Small Business Enterprise (SBE). Any for-profit, independently-owned business that is domiciled in the United States that is not Dominant in Its Field, employs one hundred (100) or fewer employees, and earns forty-seven million dollars ($47,000,000) or less in average annual revenue over a three-year period. SBEs are subdivided into the following tiers according to revenue and employee number criteria, as may be updated from time to time at the sole discretion of the City:

1. “Micro-Small Business” is an SBE with one million dollars ($1,000,000) or less in average annual revenue over a three-year period and has ten (10) or fewer employees.

2. “Emerging Small Business” is an SBE with more than one million dollars ($1,000,000) but less than ten million dollars ($10,000,000) in average annual revenue over a three-year period and has twenty-five (25) or fewer employees.

3. “Midsize Business” is an SBE with more than ten million dollars ($10,000,000) but less than twenty-three million five hundred thousand dollars ($23,500,000) in average annual revenue over a three-year period with fifty (50) or fewer employees.

4. “Macro Business” is an SBE with more than twenty-three million five hundred thousand dollars ($23,500,000) but less than forty-seven million dollars ($47,000,000) in average annual revenue over a three-year period with one hundred (100) or fewer full-time employees.

To account for differences in industry, the City will use the United States Small Business Administration’s (“SBA”) method of identifying SBEs for industries with high value, low volume products—such as wholesale/distribution/manufacturing firms, and heavy equipment or vehicle sales—by counting employees rather than revenue, to avoid disqualifying small firms that generate high revenue with minimal staff. This system ensures a fair and consistent method for determining SBE eligibility across industries.

https://www.phila.gov/departments/procurement-department/local-preference/ https://www.phila.gov/departments/office-of-business-impact-and-economic-advancement/divisions/office-of-economic-opportunity/#oeo-registry

SLBP

Rev. Date: August 2026

The SBA regularly updates these standards to align with economic conditions, industry trends, inflation, and federal contracting needs. Businesses must identify the correct NAICS code, confirm they meet the applicable size metric, and maintain documentation supporting ownership, control, receipts, and workforce levels.

M. S/LBE. An entity that qualifies as both a Small Business Enterprise and Local Business Entity.

N. Submission. A Respondent’s response to the City contracting opportunity for the Project, whether by bid or proposal.

O. Utilization. The percentage of contract dollars awarded to SBEs or LBEs over a given reporting period.

3. SBE PARTICIPATION GOALS & REQUIREMENTS

A. SBE GOALS

OEO has calculated SBE participation goals based upon the Availability of SBEs for the scope of work identified for the Project, the total dollar value of the Project, and an assessment of past performance of similar work. The SBE participation goals for this Project are set forth in Appendix 1: Participation Range Memo. If OEO has not set participation ranges, then the Respondent is still required to exercise Best and Good Faith Efforts to include SBEs in its Submission.

These goals represent the level of participation that should be attained by SBEs from business opportunities existing in the available market through the exercise of Best and Good Faith Efforts and in the absence of discrimination in the solicitation.

B. SBE REQUIREMENTS

1. SBE Participant Credit

If Respondent is an SBE and will self-perform work on the Project, the SBE Respondent will be credited for the participation range for its certification category.

Participation will be credited to SBE Participants only if the following conditions are met:

a) SBE Participant is certified by a Certifying Agency at the time of contract award;

b) SBE Participant is in the OEO Registry at the time of contract award; and

c) SBE Participant performs a Commercially Acceptable Function.

2. SBE Joint Venture Partner Participation Credit

If an SBE is a partner in a joint venture created for purposes of performing work on the Project, that SBE partner will be credited for the participation ranges only to the extent of the SBE partner’s ownership interest in the joint venture and only if the SBE partner meets the following criteria:

a) SBE partner is certified by a Certifying Agency at the time of contract award;

b) SBE partner is identified in the OEO Registry at the time of contract award;

SLBP

Rev. Date: August 2026

c) SBE partner derives a “substantial benefit” from the Contract;

d) SBE partner is substantially involved in all phases of the Contract including planning, staffing, and daily management; and

e) The business arrangement is customary (i.e., each partner shares in the risk and profits of the joint venture commensurate with their ownership interest, contributes working capital, and other resources, etc.).

4. LBE PARTICIPATION GOALS & REQUIREMENTS

A. LBE GOALS

The City may calculate LBE or S/LBE participation goals based upon the Availability of LBEs for the scope of work identified for the Project, the total dollar value of the Project, and an assessment of past performance of similar work. If applicable, the LBE participation goals for this Project are set forth in Appendix 1: Participation Range Memo.

If the Project does not have participation goals for LBEs, note that the City may consider Respondent’s intent to utilize LBEs when evaluating local impact criteria, if applicable. The City strongly encourages the use of LBEs at all tiers of the Project when feasible.

B. LBE REQUIREMENTS

If Respondent is an LBE and will self-perform work on the Project, the LBE Respondent will be credited for the participation range for its certification category. Participation will be credited to LBE Participants only if the following conditions are met:

1. LBE Participant is certified as an LBE by the Procurement Department at the time of contract award; and

2. LBE Participant performs a Commercially Acceptable Function.

5. SUBMISSION REQUIREMENTS

A. Responsiveness

1. Respondent’s compliance with this SLBP, including the submission of any required forms and supporting documentation, is an element of responsiveness to the contract opportunity for the Project and failure to submit the required forms and documentation may result in rejection of Respondent’s Submission.

2. To be deemed responsive, Respondent’s Submission must contain documentary evidence of any Participants that have been solicited and will be used by Respondent on the Contract, if awarded. Documentary evidence must be submitted in accordance with the instructions outlined in this SLBP and in response to each of the participation ranges included in Appendix 1, as applicable.

3. After reviewing the Respondent’s Submission and any other information OEO deems relevant to its evaluation, OEO will make a written determination as to Respondent’s responsiveness that will be forwarded to the awarding City Department. If Respondent is determined non-responsive by OEO, Respondent will be notified and may file a

SLBP

Rev. Date: August 2026 written appeal with the Deputy Director of OEO within forty-eight (48) hours of the date of notification. The decision of the Deputy Director of OEO shall be final.

4. Respondent must verify that all forms, information, and documentation submitted to the City are true and correct and acknowledge that the submission of false information by Respondent is subject to the penalties of 18 Pa.C.S. §4904 relating to unsworn falsification to authorities, which may include payment of a fine of at least $1,000 and a term of imprisonment of not more than two years.

B. Solicitation & Participation Form

1. Respondent must complete Appendix 2: Solicitation & Participation Form (“S&P

Form”) to document all solicitations and commitments made by Respondent. A completed S&P Form must be included in Respondent’s Submission regardless of whether commitments resulted.

a) Respondent should only make actual solicitations of Participants whose services or materials are within the scope of the Project. Mass mailing of a general nature or similar methods to Participants will not be deemed as solicitation but rather will be treated as informational notification only.

b) A reasonable period of time should be given to all solicited Participants to ensure there is sufficient time to adequately prepare quotes/subproposals.

c) Respondent’s listing of a commitment with a Participant constitutes a representation that Respondent has made a legally binding commitment to contract with such Participant upon award of a Contract by the City (“Contract Commitment(s)”).

2. Failure to Submit S&P Form. Failure to submit a completed S&P Form may result in rejection of Respondent’s Submission as nonresponsive. The City, at its sole discretion, may allow Respondents to submit or amend Submissions at any time prior to award which may result in revision to Respondent’s participation commitments.

3. Joint Venture Eligibility Information Form. If Respondent has entered into a joint venture with a partner, Respondent must also submit the “Joint Venture Eligibility Information Form,” available by request from OEO, for the City’s review and approval of the joint venture arrangement.

C. Best and Good Faith Efforts

1. Respondents are required to use Best and Good Faith Efforts in the solicitation and recruitment of SBE or LBE Participants to work on the Project, even if OEO has not established participation ranges for the Project.

a. If Respondent does not fully meet each of the participation goals established for the Project, Respondent must demonstrate that it exercised Best and Good Faith Efforts to achieve the participation goals and submit a written request, on letterhead, for the reduction of part or all of the participation goals (“Request For Reduction/Waiver”).

b. If OEO has not established participation ranges for the Project, Respondent must demonstrate that it exercised Best and Good Faith Efforts to solicit and recruit SBEs and/or LBEs for the Project.

SLBP

2. Respondent’s documentary evidence must show that Respondent took all necessary steps and made reasonable efforts to achieve the participation goals or to include SBEs and/or LBEs in the Project, even if these efforts were not fully successful.

3. Failure to provide such documentary evidence may result in rejection of the

Submission as nonresponsive. The City, at its sole discretion, may allow Respondent to submit or amend its Submission at any time prior to award which may result in revision to Respondent’s participation commitments.

4. OEO will evaluate the scope, intensity, and appropriateness of these efforts to ascertain whether they could reasonably be expected to achieve participation commensurate with the goals range taking into account the Availability of SBEs and LBEs.

5. Documentation of Best and Good Faith Efforts undertaken may include, but is not limited to:

a) Types and amount of work made available to Participants

b) Solicitation of certified Participants

c) Any and all quotes received from any Participant and firm selection process notes

d) Reasons for not committing with any Participants that submitted a quote/subproposal, regardless of whether the quote/subproposal was solicited by Respondent

e) Advertisements for participation

f) The extent to which Respondent sought assistance from government agencies to facilitate solicitation of Participants

g) Information provided by Respondent to Participants regarding the Project

h) Assistance with bonding, financing and resources

i) Any additional supporting data and documentation or other relevant information

j) Where Respondent intends to perform services itself, without subcontracting, an explanation of the rationale for doing so

6. Respondent's documentary evidence will be reviewed by OEO to determine, at its sole discretion, whether Respondent exercised Best and Good Faith Efforts to achieve the Project’s participation goals or to include SBEs and/or LBEs in the Project.

7. OEO’s review may include, without limitation:

a) Whether Participants were treated at least as favorably as other businesses in the solicitation and commitment process. For example, OEO may investigate whether Participants were given the same information, access to the plans and requirements of the Contract and given adequate amount of time to prepare a quote/subproposal as others who were solicited by Respondent.

SLBP

Rev. Date: August 2026

b) Whether all eligible Participants were accorded the same level of outreach as other similarly situated Participants and whether Participants received outreach at least as favorable as outreach to non-Participant entities. For example, OEO may investigate whether Respondent short-listed any Participants for participation or solicited any Participants at any pre-proposal meetings.

c) Whether Respondent's contracting decisions were based upon policies which disparately affect Participants. OEO may consider whether Respondent employs policies which facilitate the participation of Participants on City contracts such as segmentation of the Contract or prompt payment practices.

d) Whether Respondent’s selected portions of work or material needs are consistent with the capacity of available Participant subcontractors and suppliers.

6. SPECIAL CONTRACT PROVISIONS

A. Contract Requirements

1. Contract Documents. This SLBP, including Appendix 1 as applicable, Respondent’s completed S&P Form and any accompanying documents regarding the solicitation of and commitments with Participants, shall be considered a part of the Contract and will be expressly incorporated into the Contract upon award. Respondent agrees to provide any additional information and to complete any additional forms required by OEO prior to execution of the Contract.

2. Participant Subcontracts. Upon award of the Contract, the successful Respondent is required to enter into legally binding agreement(s) with Participants (“Participant Subcontract(s)”) for the services and in the dollar amount(s) and percentage(s) as so committed pursuant to the Contract Commitment(s).

3. Changes to Contract Commitments. Participation commitments are to be maintained throughout the term of the Contract and shall apply to the total value of the Contract (including any increase/change orders). Any change in Contract Commitments, including but not limited to, substitutions for the listed Participants, changes or reductions in the work to be performed by Participants, and/or listed dollar/percentage amounts to be paid to Participants, must be pre-approved in writing by OEO.

4. Prompt Payment. The successful Respondent is required to pay any Participant subcontractors or suppliers promptly for services performed pursuant to the Contract (including the supply of materials) in an amount of its proportionate share.

5. Reports. On a monthly basis, the successful Respondent shall submit to OEO all required information, including but not limited to Participant data, certified payroll, and demographic data. When applicable, the successful Respondent shall submit workforce demographic data to the City’s Labor Standards Unit (“LSU”) in accordance with LSU’s requirements.

6. Electronic Payment Systems. In connection with the payment of Participants, the successful Respondent is required to use the City’s electronic systems for payment verification (B2GNOW Contract Compliance Reporting System) and certified payrolls (LCP Tracker) and/or any successor systems as may be determined by the City from time to time. Participants are required to verify receipt of payment in said systems. Failure to verify payment or to submit certified payrolls in said system(s) may result in withholding of payment.

SLBP

Rev. Date: August 2026

7. Access to Information. OEO shall have the right to make site visits to Respondent’s place of business and/or job site and obtain documents and information from any Respondent, SBE Participant, subcontractor, supplier, manufacturer or contract participant that may be required in order to ascertain Respondent’s responsiveness and responsibility. Failure to cooperate with OEO in its review may result in termination of the Contract.

8. Records. The successful Respondent shall maintain all books and records relating to

Participants, Participant Subcontracts, and Contract Commitments (e.g. copies of quotations, subcontracts, joint venture agreement, correspondence, cancelled checks, invoices, telephone logs) for a period of at least five (5) years following expiration of the Contract. These records shall be made available for inspection by OEO and/or other appropriate City officials. The successful Respondent agrees to submit reports and other documentation to OEO as deemed necessary by OEO to ascertain the successful Respondent’s fulfillment of its Contract Commitments.

B. Breach and Remedies

1. Breach. Respondent’s failure to comply with the requirements of the SBE Policy, this

SLBP, its Contract Commitment(s), or any other contract documents constitutes a material breach the Contract. If OEO determines that the Respondent has discriminated against an SBE or LBE at any time during the term of the Contract, OEO may recommend to the Procurement Commissioner the imposition of sanctions and the exercise of remedies.

2. Remedies. Notwithstanding any additional rights or remedies available under the Contract or in law or equity, in the event the City determines that the successful Respondent has failed to comply with any of the requirements of the SBE Policy, this SLBP, or the Contract, including substantial compliance with any Contract Commitment, the City may:

a) Debar the successful Respondent from proposing on and/or participating in any future contracts for a period determined by the City not to exceed three (3) years;

b) Withhold payment at the sole discretion of the City until corrective action is taken to the satisfaction of the City, in which case such withholding shall not be considered a penalty. If corrective action is not taken, the withheld payment shall serve as liquidated damages for the Respondent’s failure to comply with the Contract;

and/or

c) Terminate the Contract.

The City may exercise any or all remedies set forth in this SLBP, each of which may be pursued separately or in conjunction with any other remedies as the City in its sole discretion shall determine.

3. Sole Benefit of the City. These remedies are for the sole benefit of the City and City’s failure to enforce any provision or the City’s indulgence of any non-compliance with any provision of any policy, this SLBP, or the Contract, shall not operate as a waiver of any of the City’s rights in connection with the Contract nor shall it give rise to actions by any third parties, including identified Participants.

4. No Third-Party Beneficiaries. No privity of contract exists between the City and any Participant identified in any contract awarded for the Project. The City does not intend to give or confer upon any such Participant any legal rights or remedies in connection with subcontracted services pursuant to this SLBP or by reason of any contract awarded for the

SLBP

Rev. Date: August 2026

Project. Nothing herein prevents the Participant from seeking a private cause of action under any legally binding contract to which it may be a party.

SLBP – Appendix 1

CITY OF PHILADELPHIA

APPENDIX 1

Participation Range Memo

TO : Lou Fabritiis, Senior Project Manager, Aviation

FROM : Ekpenyong Oji, Bus. Enterprise Coordinator, Office of Economic Opportunity

SUBJECT : Project – PHL-1641.24 Rehabilitation of Taxiway K between Taxiways Y & Z; Bid 6721

Mayor’s Executive Order No. 06-25 – Small Business Enterprise (SBE) and Local Business Entity (LBE) Participation Ranges

DATE : September 10, 2026

Pursuant to Executive Order No. 06-25, OEO has set the below Participation Ranges for the subject Project, after reviewing, among other things, the type and scope of the Project at issue, the estimated dollar value of the Project, the number of SBEs and LBEs that may be available to participate on the type of Project, and applicable legal requirements for the contract or project:

SBE Ranges Micro %

Emerging % Midsize % Macro %

Other (if, applicable) % Total SBE Range 5%

LBE or S/LBE Ranges LBE Range %

S/LBE Range %

NAICs Code XXX – Description- 2367310, 238210 Admin support, Civil construction Trade Contractors and supplies

S BP – Appendix

SBE Information

Name of SBE Contact Information including, address, telephone number, and e-mail address

Scope of Work NAICS Code

Subcontractor or Supplier

Dollar Amount for

SBE

Percent of Total Proposal

Quote Received (Y/N)

Registry (Y/N)

I hereby certify that the above information is accurate to the best of my knowledge (Title) ( )

Additional Sheets May Be Used as Necessary

Bid 6721

City of Philadelphia, Department of Aviation

Rehabilitation of Taxiway K (Between TW Y and TW Z)

PHL-1641.24

Bid No. 6721

Pre-Bid Meeting

September 22, 2026

Introductions / Project Points of Contact

Project Location

Key Dates

Notice to Bidders

Bid Submission Requirements

Office of Economic Opportunity

Wage Requirements

Section C

Gate Access

Airport Security

Insurance/OCIP

Permits

Scope of Work & Project Duration

Sustainability

A g e n d a

Design Team

AtkinsRéalis

ADCI

Project

Manager John Carollo

215-240-3931

John.carollo@phl.org

Airport

Assistant

Engineering

Manager Lee Sutanto

215-681-9605

Lee.Sutanto@phl.org

Airport

Engineering

Manager

Imad Haq, P.E.

215-937-7878

Imad.haq@phl.org

Project Points of Contact

Project Location

Imagery per NearMap dated 9 October 2025

PROJECT LOCATION

Deadline for Financial Questionnaire: October 1, 2026

Deadline for Bidder Questions: October 1, 2026

All Questions due by 5:00 PM

Deadline for Bid Submission: October 22, 2026

All Bids due before 10:30 AM. Submit electronically.

Bidder Questions must be submitted on the ‘Q&A’ Tab of the Prequalification Requisition in PHL Contracts (www.phlcontracts.phila.gov)

K e y D a te s

Bid Opening: October 22, 2026– 10:30 AM

Held Virtually via Zoom http://www.phlcontracts.phila.gov/

▪ Electronic copies of bid documents available for free download at www.PHLContracts.Phila.gov

▪ Bids valid for 60 calendar days after bid opening

▪ LBE Preference does not apply to this project

▪ Project Labor Agreement does not apply to this project

▪ Single Prime Bid

Notice to

Bidders http://www.phlcontracts.phila.gov/

▪ Any and all Bid Amendments will be issued through PHLContracts

▪ Bid Bond – 10% of the gross amount of the bid

▪ Bid Processing Fee – See Clause 2.9 of the

Standard Contract Requirements

▪ Bids must be submitted on PHLContracts before 10:30 AM on the bid opening date

Bid

Submission

Requirements

OEO Contact:

Ekpenyong (Nina) Oji

Business Enterprise Coordinator

Phone: (215) 683-2078

SBE Participation Range: 5%

Office of

Economic

Opportunity

Wage

Requirements

▪ Labor Standards Representative: Cheryl

Waters

▪ City Wage Rates included, updated

7/28/2026

▪ Certified payrolls with copies provided to the project manager shall be submitted via the Labor Standards Unit through electronic system – LCP Tracker

▪ Certified payrolls will be required to be submitted on a weekly basis after NTP, even if there is no work.

• The City will provide the successful bidder with one (1) electronic copy of the plans and project manual in PDF format; no hard copies.

• Contractors must obtain all permits and licenses.

• Project is located in Delaware County (Tinicum Township).

• Contractors must have a dedicated Project Manager. Plan on weekly progress meetings and scheduling meetings. Plan on workshops with stakeholders prior to each phase.

• Airport Security – Access to the project area from the airfield side will be limited to the gates shown on the Construction Safety and Phasing Plans – Gate 28. All Contractors must be badged prior to entering the airfield. Read the security documents provided in the bid specifications, Section PHL Rules and Regulations.

• Project Duration:

• 95 Consecutive Calendar Days (including mobilization). No winter shutdown anticipated for project.

Section C – General Information

Gate Access

Gate 28

Gate Access

Gate 28

Airport

Security

▪ PHL Rules and Regulations

▪ PHL Changed Conditions Affecting Security

Guidelines

▪ Security Identification Display Area Training

▪ Complete Security Threat Assessment (STA)

▪ Complete Criminal History Record Check

(CHRC)

▪ Physical Vehicle Inspection Training

▪ Basic Security Awareness Training

▪ Fingerprinting: $32

▪ ID Badge: $33

Vehicular and

Equipment

Travel

▪ Airport Badge

▪ Airfield Driver Training – Non-Movement

Area Training

▪ Movement Area Training – For Badged (Non-

Contractor) Personnel and ASO Only

▪ Properly Marked Company-Owned Vehicles

▪ Checkered Flags, Beacons

Insurance/

OCIP

▪ Insurance Requirements

▪ City of Philadelphia – Mentioned in Project Manual

▪ Additional Insured

▪ City of Philadelphia (officers and agents)

▪ Tinicum Township

Permitting

▪ Permit/Airspace Analysis Requirements

▪ Notification of Construction/Airport Airspace Analysis

(7460 Submission) – Contractor to provide crane information and lift plan for processing of 7460.

▪ Minimum 120 days for approval.

▪ Environmental Permits

▪ Permits, if required, pursued by Department of Aviation

▪ State: PA Department of Environmental Protection

NPDES Permit not anticipated

▪ Local: Tinicum Township Stormwater Management and

Floodplain Permitting

Fees

▪ Permit Fees

▪ Tinicum Township Grading and Building Permits – 2

Percent of the Bid Price of work performed. Allocated under pay item C-105-7.2. Fees will be reimbursed for direct costs with no markup.

▪ Contractor and subcontractor registration with

Township is required for work to be performed.

▪ Training, Insurance, Bonds, Airport Security

Training

▪ All costs to be paid by the Contractor.

▪ There will not be a separate bid item for these items;

they should be included within the bid cost.

Scope of Work – Bid No. 6721 Includes but is not limited to the following:

• Pavement markings and marking removal

• Pavement milling

• Electrical utility demolition and installation

• Cable and transformer replacement, light base top section adjustments

• New taxiway centerline fixtures, reuse of taxiway edge light fixtures

• Limited replacement of existing single-piece light base cans

• Taxiway and shoulder pavement overlay

• Erosion and Sediment Control measure installation and maintenance

• Limited topsoiling and seeding

• Temporary safety device installation and maintenance

• Field survey

Overall Schedule – Bid No. 6721

Construction Duration: Total 95 Consecutive Calendar Days

• 15 CCD, occurring April 2027. See Drawing G-108.

• Airfield/Airline Impacts

• Taxiway K Closure between Taxiway Y and Taxiway K8 (Extended)

• Taxiway K7 Closure (Extended)

Work Area 1

• 20 CCD, occurring April/early May 2027. See Drawing G-109.

• Airfield/Airline Impacts

• Taxiway K Closure between West Apron and Taxiway K7 (Extended)

• Taxiway K8 Closure (Extended)

• Easternmost spot of West Apron available for parking only (Extended)

• Traffic only one way in/out via Taxiway J to West Apron

Work Area 2

General Overview – Bid No. 6721

Mill Existing Asphalt – Taxiway Overlay (FG-8”)

P a v e m e n t

D e m o li ti o n

S e c ti o n s

Mill Existing Asphalt – Taxiway Overlay (FG-6”) a v e m e n t

D e m o li ti o n

S e c ti o

Mill Existing Asphalt – Shoulder Overlay a v e m e n t

D e m o li ti o n

S e c ti o

Taxiway K Typical Section - 8-inch Overlay

T y p ic a l S e c ti o

Taxiway K Typical Section - 6-inch Overlay

T y p ic a l S e c ti o

• Existing base can survey and height measurement form – E-101/E-102, note 6

• Proposed light fixtures are a combination of existing fixtures removed & stored and new fixtures – E-101 and E-102

• Airfield guidance sign transformers to be removed and replaced – E-101 and E-102

• Cable replacement and connection to existing circuits – E-103 and E-104

Electrical

• Construction Waste Management Plan with Target Waste Diversion Rate (Development of plan detailed in P-101, additional requirements in various Civil Specifications)

• Construction and Demolition Waste Tracking (Requirements detailed in Civil Specifications)

• Use of DOA Construction/Demolition Waste Tracking Forms (Use of forms detailed in P-101)

• Obtain Environmental Product Declarations for materials (Required –See P-401, P-403, P-610 for required EPDs)

• Retain and reuse soils and other excavated materials on site to maximum extent practicable to reduce transportation and environmental impacts (Encouraged, if applicable)

• Maximize use of recycled materials, including materials with recycled content (Encouraged)

• Utilize supplementary cementitious materials (Encouraged)

• Minimize hauling to the maximum extent practicable to reduce environmental and transportation impacts (Encouraged)

Sustainability

Questions?

All bid questions and RFIs must be submitted in writing on PHLContracts (www.phlcontracts.phila.gov) and must be received by 5 PM on October 1, 2026.

http://www.phlcontracts.phila.giv/