B08_Solicitation_Attach_1_Specifications.pdf

Div. 1 V. 2023-11-11 Page | 1

THEODORE ROOSEVELT NATIONAL PARK

MEDORA, NORTH DAKOTA

REPLACE BOUNDARY FENCE – PHASE 1

PMIS 258443

Drawing No: 80125

PROJECT SPECIFICATIONS

NATIONAL PARK SERVICE

NOVEMBER 2024

Page | 2

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

Section 01 10 00 - Division 01 Short Form General Requirements

DRAWINGS

1 COVER

2 L0.1 GENERAL NOTES

3 L1.0 OVERALL SITE PLAN, ALIGNMENT, ACCESS, AND STAGING

4 L1.1 SITE LAYOUT STATON 0+00- 55+00

5 L1.2 SITE LAYOUT STATION 55+00 – 90+00

6 L1.3 SITE LAYOUT STATION 90+00 – 103+70

7 L2.1 CONSTRUCTION DETAILS

8 L2.2 CONSTRUCTION DETAILS

9 L2.3 CONSTRUCTION DETAILS

10 L2.4 CONSTRUCTION DETAILS

Page | 3

SECTION 01 10 00

DIVISION 1 SHORT FORM GENERAL REQUIREMENTS

PART 1 – GENERAL

ITEM 1 - DESCRIPTION OF WORK

1.1 Background: The South Unit (46,000 acres) boundary fence of Theodore Roosevelt National Park is an essential component in effective natural resource management. Many tourists visit the park to view the bison and horse herds. The park boundary fence directly affects the animals and the related visitor experience while touring the park. The NPS has the responsibility to maintain its fences to develop and maintain good relationships with park neighbors, protect the general public, and protect the various species of animals located within the park boundary.

This project will provide conservation work through replacement of a segment of existing boundary fence with new fence to protect and manage the bison, elk, and feral horse herds within the South Unit of the park. The existing fence is approximately 6-feet in height and comprised of wood posts, steel pipe posts, steel U-channel and T-posts carrying livestock grade woven wire mesh fencing. New fence shall be constructed to a height of 7’-0” and comprised of galvanized steel pipe posts carrying heavy duty livestock rated woven wire mesh. Two gate structures shall be included in the Base Bid scope of work for construction. Length of new fence construction and existing fence removal shall be approximately 1.44 miles (7600 L.F.) under a Base Bid line item and as Bid Additive, subject to availability of funds, continue with new fence construction of an additional 0.56 miles (2920 L.F.) (distances approximated from NPS performed survey and county available LiDAR topographic surface).

The park must maintain its boundary fence in good condition to keep cattle from encroaching on park land which prevents resource damage, and to keep large park ungulates (bison, elk and horses) contained and managed. Conflicts with traffic and animals can occur when animals escape through damaged portions of the fence. Serious injury or death to visitors, park neighbors, vehicle passengers traversing I-94, and/or animals can result.

1.2 Work Covered by the Contract Documents:

A. Project Location: Medora, North Dakota aligning west bound Interstate 94 from the Little

Missouri River bridge to East River Road (park entry road) – located within mile markers

24,25 and 26.

B. Work consists of: Providing all materials, equipment and labor to remove approximately 7600 linear feet of existing boundary fence and replace with new fence constructed to the drawings and specifications defined within these contract documents (specifications and drawings) as a Base Bid. Base Bid scope of work terminates with installation of gate and double H-brace

Page | 4 structures. Tie existing fence remaining to double H-brace structure on the free end of gate.

Additionally, as a Bid Additive which the NPS may elect to award, based on availability of funds, the removal and replacement of an additional 2920 linear feet of boundary fence beginning from the termination of the base bid fence and extending to the existing livestock guard crossing on East River Road (park entry road).

New fence shall consist of galvanized steel round posts with shop prepared thru-holes to receive tie wire, high strength woven wire mesh rolled fencing as manufacturer recommended for bison livestock uses, varied gauges of wire for tying off mesh and H-brace assemblies, 3/8” steel aircraft cabling, and 2 steel framed and hinged permanent gate structures. All materials listed define the salient characteristics of the minimum level of performance to be provided by respective materials. Basis of design acceptable manufacturers named are for Contractor reference and consideration only as they meet the salient characteristics.

The Contractor shall be responsible for determination of all final quantities. See respective notes and details within the construction documents which define minimum line post spacing, required location criteria for single or double H-brace structures, and use of rigid livestock panel wire panels to supplement woven wire in locations that warrant greater rigidity in fence material.

The project will be conducted in phases of one-half mile increments. The contractor shall leave the existing fence in place as means to define limits of construction and wildlife management as new fence is constructed with an offset of 12’-0” or greater as shown or approved by the CO. Upon installation of new fence half mile interval, the Contractor shall request an inspection from the CO/COR in order to approve the installed section of fence.

Upon written receipt of government acceptance for the completed half-mile segment, the

Contractor shall proceed with removal and off-site lawful disposal of the half-mile segment of existing fence paralleling the newly installed segment. The Contractor shall then proceed with new fence installation in the subsequent next half mile segment. Any deviations to this length of interval for acceptance the Contractor proposes shall be permissible only with written approval from the CO.

Accessing the project area will be predominantly through Interstate 94 right-of-way with a limited extent of access from East River Road (park entry road). The Contractor shall strictly adhere to all conditions of the permit issued by the North Dakota Department of

Transportation, as enforced by the NPS which addresses sole locations of access, staging, and traversing through the right-of-way from the interstate. Parameters of the permit cited within these specifications and construction drawings.

C. All work will be performed under a single contract.

D. Period of performance: Work for the Base Bid shall be completed within 320 calendar days of the start date provided on the Notice to Proceed. This period shall include any required adverse winter weather break periods in the work, including an anticipated on-site work winter stoppage beginning approximately mid-November and resume late March or earlier based on seasonal conditions and government approval. Work for Bid Additive 1, if NPS elects to award, shall be completed within an additional 45 calendar days. This period shall also include any required adverse weather break periods in the work.

Page | 5

a. Clarification: The Notice to Proceed will be issued with a period of performance that is all inclusive of supply lead times, material deliveries, removals, installation, anticipated average weather days for location, including winter conditions shut down, and acceptance of last segment of completed work. The contractor will be expected to provide a project schedule with adequate critical path details to ensure all work is completed within the stated calendar days from issuance of the Notice to Proceed. If weather impacts project beyond typical average weather patterns, including duration of winter conditions prohibiting ability to install new fence, contractor shall provide documentation in request for additional days.

1.3 Existing Condition Protections:

A. Preservation of Historical and Archeological Fabric:

i. The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

ii. IF, in connection with operations under this contract, the Contractor, subcontractors, or employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the discovery and notify the

Contracting Officer immediately, when safe to do so, and follow up in writing within 2 days, giving the location and nature of the findings. No objects of cultural resource value may be removed. Contracting Officer will contact other entities as required.

iii. Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with Changes clause.

iv. The Contractor will be responsible for protecting the cultural resources within and adjacent to the project area from damage. In addition, the Contractor will be liable for all damage to the cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting

Officer or their representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

v. The Contractor agrees to include this language within all subcontracts.

ITEM 2 – PROTECTING EXISTING UTILITIES

2.1 Protecting Existing Utilities: Notify Contracting Officer (CO), Contracting Officer’s Representative

(COR) and utility companies as required to request location services prior to and to coordinate any excavation/digging operations, and/or for demolition if within Scope of Work.

2.2 Contractor shall be responsible for locating and preventing damage to known utilities on site. If contractor damage occurs, alert CO and COR as soon as safely possible, and repair utility at no additional expense to the Government. If damage occurs to an unknown utility, contact CO and

COR as soon as safely possible.

Page | 6

2.3 Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated below:

A. Notify CO and COR not less than two business days in advance of proposed utility interruptions.

B. Hours for Utility Shutdowns: Shutdowns shall not exceed 2 to 3 hours. Temporary provisions will be needed by the Contractor for periods longer than stated allowance or if required for critical systems as determined by COR.

ITEM 3 - CONTRACTOR’S USE OF PREMISES

3.1 Conduct of Operations: At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park

Service, and applicable park rules and regulations prescribed by the Park Superintendent.

Superintendent's Compendium - Theodore Roosevelt National Park (U.S. National Park Service)

(nps.gov)

A. Communications: Contractor shall provide the Contracting Officer and COR with methods of communications including land and/or cell phone numbers (note some areas of work have limited service coverage), email and in case of emergency 24-hour contact options for duration of time operations.

B. No signs or advertisements (except those specified herein and as required for safety) shall be displayed on the construction site or within the park unless approved by the Contracting

Officer.

C. Smoking is not permitted within any Federal building or within 25 feet of entrances, operable windows, or outdoor air intakes.

D. Public Use of Site: Contractor shall at all times conduct operations to ensure the least inconvenience to the public. Primary point of potential engagement with the public is at the

East River Road (park entry road) intersection with the fence. Work in direct proximity of East

River Road which may incur a temporary road shut down or traffic control measures shall be as approved by the CO/COR.

3.2 On-site work hours: Work shall be generally performed during normal business working hours of

7:30 a.m. to 4:30 p.m., Monday through Friday, except when otherwise indicated.

A. Work on Saturdays, Sundays, Federal holidays, early morning, or at night may not be performed without prior consent from the CO and COR. Submit requests for work outside of the stated normal business hours to the CO and COR for approval at least 48 hours in advance of the work.

The following Federal holidays are observed by the National Park Service:

New Year Day

Martin Luther King, Jr’s Birthday https://www.nps.gov/thro/learn/management/superintendent-s-compendium.htm https://www.nps.gov/thro/learn/management/superintendent-s-compendium.htm

Page | 7

Washington’s Birthday

Memorial Day

Juneteenth National Independence Day

Independence Day

Labor Day

Columbus Day

Veterans Day

Thanksgiving Day

Christmas Day

B. Note: Any of the above holidays falling on a Saturday will be observed on the preceding

Friday; holidays falling on Sunday will be observed on the following Monday. The specific day that each holiday is recognized for each year can be found at the following site: Federal

Holidays (opm.gov).

3.3 Contractor Use of Site:

A. General: Contractor shall have limited use of the site for construction operations. Limit use of premises to construction area as shown on site plan. Points of approved access from

Interstate 94 through right-of-way to fence line limited to as shown on plan and defined in the

ND DOT permit. Staging of equipment and materials as well as work lane along the fence right of way shall be limited to a 50-foot offset into the park from the existing fence alignment or a 40-foot corridor where new fence alignment diverts from the existing fence alignment for new work. During removal of existing fence, an additional 15-feet may extend into the interstate right-of-way for the physical actions of removal. Staging of equipment or materials, including stacking removed material for haul off, is NOT allowed within the interstate right-of-way (outside the existing fence alignment). Do not disturb portions of Project site beyond areas in which the Work is defined herein or where indicated on the drawings.

B. Driveways and Entrances: Keep driveways, access roads, and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials. Schedule deliveries to minimize use of interstate shoulder, roadways and entrances.

C. Do Not disturb site outside of noted disturbance area, including earthwork and clearing of vegetation.

D. Utilities

1. General: Cost or use charges for temporary facilities shall be included in the Contract Sum as required.

2. Water Service: Water from existing water system is not available for use without metering and without payment of use charges. Provide connections and extensions of services as required for construction operations without any additional permit costs. Use resources wisely and minimize waste of water.

3. Electric Power Service: Electric power from existing system is not available for use without metering and without payment of use charges. Provide connections and extensions of services as required for construction operations without any additional permit costs. Power may or may not meet your construction power tool requirements, https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/#url=2022 https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/#url=2022

Page | 8 provide generators if questionable. Use power in a resourceful manner and avoid excess power waste.

4. Waste Operation:

a. Toilets: Contractor must provide toilets for contractor personnel, sufficiently lighted and ventilated toilet facilities in weatherproof, sight proof, handicap accessible (if required), sturdy enclosures with privacy locks. Coordinate with COR for approved locations that are reasonable for Contractor use, ability to service and deliver/remove, and not conflict with the public.

b. In the event the Contractor’s staff is not able to divert to the provided temporary toilet, THRO rules for visitors within the backcountry of the park shall apply. Acceptable means of defecation shall be to use a commercially available portable waste bag system (‘WAG-BAG’ or similar) and remove the waste bag to lawfully dispose of off site. Second option - employ a ‘cat-hole’. The cat-holing process is to carefully open a 6” diameter by 8” deep round trowel/shovel hole in the soil to receive the bodily waste. Utilize the cat-hole once and replace excavated earthen material to seal the waste within the hole. The Contractor shall provide appropriate hand sanitizer and toiletries for all staff in all provisions of toilet needs.

c. Waste Removal / Recycling: Contractor is responsible for removing all waste created by the project. Contractor shall recycle to the highest degree possible and empty dumpsters as necessary to avoid debris on site. Locate approved debris containment methods as coordinated with COR.

E. Security and Protection facilities:

1. Environmental Protection: Provide protection, operate temporary facilities, and conduct construction in ways and by methods that comply with state and federal environmental regulations and that minimize possible air, waterway, and subsoil contamination or pollution or other undesirable effects.

2. Cleaning of Equipment: The Contractor shall ensure that prior to moving on to the Project Area, all equipment, is free of soil, seeds, vegetative matter, or other debris that could contain or hold seeds. Ensure that all equipment has been pressure washed and is free of exotic species prior to start-up of operations and moving of equipment to Project Area.

Equipment shall be considered free of soil, seeds, and other debris when a visual inspection by the COR does not disclose such material. Disassembly of equipment components or specialized inspection tools are not required.

3. Tree and Plant Protection: As part of Environmental Protection, the Contractor shall not conduct activities that exceed the reasonably necessary level of impact to complete the work. The work area is within tallgrass plant communities native to the region. Remaining within the allowed work area, limiting circulation to defined routes, and strictly avoiding wildfires from heated vehicles or other equipment or other causes all contribute to plant protection. Obtain written approval from the CO/COR for methods that include mowing grass in equipment staging or work areas to reduce wildfire or other significant impacts to vegetation. Control burning shall not be allowed by the Contractor under any circumstances.

4. Pest Control: N/A

5. Temporary Enclosures: N/A

Page | 9

6. Site Enclosure Fence: N/A

7. Hot Work Permit: Hot Work, defined as use of tools or equipment that produces a flame or spark, shall not be permitted. Allowed cutting on site of concrete embedded steel posts in removal of existing fence shall be by non-spark emitting methods such as reciprocating saw or other as approved by the COR.

3.4 Storage - Staging Areas:

A. Confine Storage of materials and equipment to the project staging areas defined as the 50-foot corridor offset from the existing fence alignment into the park. Any storage units provided by the contractor shall be in a clean and acceptable condition to the COR. Security of the materials and equipment on site is the Contractor’s responsibility.

3.5 Preservation of Natural Features: The entire landscape (vegetated and geological) and wildlife present within Theodore Roosevelt National Park is considered a natural feature of the park warranting daily housekeeping and construction practices to minimize impacts beyond reasonable to conduct the work.

3.6 Hauling Restrictions: Contractor shall verify and be responsible for the path accessing the site and obtaining / maintaining all local, state and federal permits/licenses associated with hauling/road requirements and dumping of materials associated with the project.

3.7 Housekeeping:

A. Keep project neat, orderly, and in a safe condition at all times.

1. Dispose of waste materials and recycling legally outside the park. The contractor shall not use park dumpsters.

2. Address Recycling: Government goal is to salvage and recycle as much nonhazardous construction waste as possible. Use sustainable methods to extent possible during this project, recycling material as is probable with local means. Maintain accurate documentary records for submittal of all recycled materials used in new construction.

Documenting Recycled Metal: The Contractor is encouraged to specifically document by load tickets from recycling centers all metal material that is diverted from the landfill and submit to the COR if recycling is chosen method of lawful disposal. While recycling the material is not a requirement of the contract, if conducted, THRO annual documentation of recycling metrics will include what submitted load tickets results from this project.

3.8 Occupancy Requirements for Buildings: N/A

3.9 Photo Documentation:

A. Contractor must provide existing condition, progress, and completion photos. All photos shall be in focus, show maximum range of depth of field general photo and then close up detail photo as needed. Shall be in JPEG digital form and submitted preferably electronically by email or optional via CD-R Archival Gold or DVD-R Archival Gold media with printed labels and 8 mega pixels minimum within 7 days from time of taken or as approved by COR.

Page | 10

B. Existing Condition Images:

1. Before starting construction, take color, dated, digital images of project site and adjacent property/roads/etc. that may be impacted by construction activity/traffic. Include existing items to remain or be salvaged from different vantage points and with context for location identification.

C. Construction Progress Images:

1. Document all sub-surface work/ trenches etc. prior to backfill with photos covering enough overall field view to show location and then zoom in for details. (if applicable)

2. Maintain organized index for photos with date, description, etc.

3. Additional images as needed when questions or emergency situations occur. Submit within 24 hours.

D. Completion Images:

1. Document all completed work within scope of work.

2. Maintain organized index for photos with date, description, etc..

3. Additional images as needed when questions or emergency situations occur. Submit within 24 hours.

3.10 Fire and Life Safety:

B. As a minimum, conduct one weekly 15 minute "toolbox" safety meetings. These meetings shall be conducted by a foreman or supervisor and attended by all construction personnel at the worksite. Topics need to coincide with work scheduled for the following week. Document and submit meeting minutes to the CO and COR within one day after the meeting and document the meetings on the daily reports.

C. Comply with the requirements of NFPA 241 (Standard for Safeguarding Construction, Alteration, and Demolition Operations). Take all necessary precautions to prevent fire during construction. Provide adequate ventilation during use of volatile or noxious substances.

D. Store and handle hazardous materials in accordance with manufacturers and OSHA 29CFR1926 Subpart D requirements 1926 | Occupational Safety and Health Administration (osha.gov). Maintain readily available, on site, MSDS/Safety Data Sheets (SDS) for each chemical.

1. Immediately report all spills of hazardous materials to the CO, COR, and park.

2. Maintain a spill emergency response kit.

3. Train employees how to respond to a spill and use the emergency response kit.

3.11 Noise and Acoustics Management

A. Contractor shall not have personal radios or other media sources audible beyond the immediate work area and they shall not be broadcast within NPS property. Remain aware of the distance and reverberation of sounds across the badlands type landscape. The COR retains the right throughout the task order to direct Contractor to reduce volume or discontinue use of radio/media sources while on the jobsite.

https://www.osha.gov/laws-regs/regulations/standardnumber/1926 https://www.osha.gov/laws-regs/regulations/standardnumber/1926

Page | 11

ITEM 4 - COMMENCEMENT, PROSECUTION, AND COMPLETION

4.1 The Contractor shall commence work in accordance with the terms and conditions of the contract.

Contractor shall coordinate and incorporate long lead and delivery time items within the schedule.

ITEM 5 - EXAMINATION OF THE SITE

5.1 All bidders are urged to visit the job site and examine existing conditions before submitting bids.

Contractors will be accountable for understanding existing conditions. No cost changes for items visible during site visit will be allowed.

ITEM 6 - ABBREVIATIONS

6.1 The list of abbreviations, standards and organizations which may be used in/referred within the

Construction Specifications or Special Provisions, may be found linked from the listed page below. On the home page, follow the link under “Contracting and Procurement” labeled “NPS

Reference Standards.” https://www.nps.gov/orgs/1671/do-business-with-us.htm

ITEM 7 - ACCIDENT PREVENTION

7.1 Description: The work of this section consists of establishing and implementing an effective accident prevention program (APP) and providing a safe environment for all personnel and visitors.

7.2 Submittals:

A. Accident Prevention (Safety) Plan (APP): Submit a site-specific accident prevention (safety) plan. The Plan shall be written to comply with OSHA and project requirements (a generic plan is not acceptable) including but not limited to the following:

1. Name and qualifications of responsible supervisor to carry out the program.

2. First aid and rescue procedures.

3. Training, both initial and continuing.

4. Outline of each phase of the work, the hazards associated with each major phase, and the methods proposed to provide for property protection and safety of the public, National

Park Service personnel, and Contractor's employees. Identify the work included under each phase, with a Job Hazard Analysis (JHA)/Job Safety Analysis (JSA), etc. A sample

JHA template may be provided upon request.

5. Planning for possible emergency situations, such as cave-ins, earthquake, explosions, fires, floods, power outages, slides, windstorms, and wildlife encounters which may include but not limited to bison, undomesticated horse, or rattlesnake. Such planning shall take into consideration the nature of construction, site conditions, and degree of exposure of persons and property.

6. Contractor to identify nearest location of medical facility for emergencies

7. Recognition that works will be performed in remote areas with limited communication or cell phone coverage if applicable.

8. Supplemental hazard specific plans may be required IAW 29 CFR 1926 or 1910.

https://www.nps.gov/orgs/1671/do-business-with-us.htm

Page | 12

B. Meeting and Inspection Reports: Safety Meetings: As a minimum, conduct 15 minute

"toolbox" safety meetings. These meetings shall be conducted by a foreman and attended by all construction personnel at the worksite. Submit a report of safety meetings and inspections to CO and COR within one day after the meeting and document the meetings on the daily reports.

7.3 Qualification of Employees:

A. Ensure that employees are physically qualified to perform their assigned duties in a safe manner to include operators of vehicles and equipment. Provide operating instructions for all equipment.

B. Do not allow employees to work whose ability or alertness is impaired because of drugs, fatigue, illness, intoxication, or other conditions that may expose themselves or others to injury.

7.4 Accident Reporting: The Contractor shall report all accidents to the CO and COR as soon as safely possible and assist the CO and COR and other officials as required in the investigation of the accident.

7.5 First Aid Facilities: Provide access to facilities for the number of employees and appropriate to the hazards associated with the types of ongoing construction work at the site.

7.6 Emergency Instructions: Post telephone numbers and reporting instructions for ambulance, physician, hospital, fire department, and police in conspicuous locations at the work site.

7.7 Personal Protective Equipment (PPE): It is the Contractor's responsibility to require all those working on or visiting the site to wear necessary protective equipment at all times.

A. PPE must meet requirements of applicable ANSI standards. Selection shall conform to OSHA

29CFR 1926 Subpart E.

B. A hard hat use area shall be designated by the Contractor. The hard hat area shall be posted by the Contractor in a manner satisfactory to the Contracting Officer.

C. All PPE will be serviceable at all times. At a minimum, maintain two standby sets of PPE including hard hats and all other Accident Prevention Plan required equipment beyond one set per each employee on site.

7.8 Hazardous Materials: It shall be the responsibility of all operators and contractors, functioning within the park to properly cleanup, mitigate and remediate if necessary, all unauthorized discharges of hazardous materials or non-hazardous chemical and biological products released from fleet and/or other support vehicles or stationary sources. Response shall be consistent with guidelines established by federal, state, and local regulations, and as outlined within the operator's Safety or Hazardous Materials Business Plan.

A. If a spill, leak, or other release occurs, the operator shall as soon as possible, without impeding cleanup, notify the local 911 Emergency Response, COR and or the National Park

Service Emergency Dispatch.

Page | 13

ITEM 8 - PRECONSTRUCTION CONFERENCE

8.1 If the Contracting Officer decides to conduct a preconstruction conference, the successful offeror will be notified and will be required to attend. The Contracting Officer’s notification will include specific details regarding the date, time, and location of the conference, any need for attendance by subcontractors, and information regarding the items to be discussed. See Item 9.1C below.

ITEM 9 - SUBMITTALS

9.1 General Contracting Submittal Procedures:

A. General: Prepare and submit submittals required by individual Technical Specification

Sections. Types of submittals are indicated in individual specific sections.

1. CM-16 Transmittal Form: All submittals shall be transmitted via electronic email using

National Park Service form CM-16 form. The form will be provided by the Contracting

Officer. No action will be taken on a submittal item unless accompanied by the CM-16 transmittal form. Submit completed CM-16 forms to the CO and the COR

B. Submittal List: administrative required submittals are listed below in 9.1.C and does not include technical section submittal requirements included in each technical section.

C. Preconstruction Conference Submittal: Satisfactory evidence of liability insurance coverage and workman’s compensation, and any applicable bonds, must be submitted within 10 calendar days of Notice of Award. The following items are to be submitted prior to the

Preconstruction Conference or as specified at the CO’s discretion. The timeline for the documents to be submitted will be addressed at the pre-construction conference for those items that were not received and approved prior. Notice to Proceed may not be issued, and the Contracting Officer will consider other contractual remedies if not resolved as directed.

Work shall not commence until written Notice to Proceed has been issued. Contracting

Officer will notify Contractor of tentative date for the Pre-Construction Conference:

1. Letter designating Project Superintendent.

2. Construction Schedule. (Must include shop drawings, procurement time including long lead time items, mobilization, trade work progression and completion at minimum.)

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention (Safety) Plan (see section 7 of this document).

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses (SF1413).

7. Quality Control Plan.

8. Waste Management Plan: Metal Recycling

9.2 Project Submittal Process (Shop Drawings, Product Data, and Samples): Contracting Officer will provide sample cover sheet and a list of required submittals is included in each technical specification or attached at the end of this document.

Page | 14

A. Shop Drawings: Indicate all coordinating materials and work impacting the installation coordination, connection details, anchorage requirements, hardware locations, and installation details and locations.

1. Submit Shop Drawings according to Part 9.1 of this section to include one digital file (.PDF or .TIF) and two full size hardcopy documents to COR.

B. Product Data: Provide component construction and specification data sheets, anchorage requirements and any other product specific data.

1. Submit Product Data according to Part 9.1 of this section to include one digital file (.PDF or .TIF) to COR.

C. For submittals specified above, forward submittals to Contracting Officer and COR at least 15 days before need for approval (depends on length of project).

D. After approving submittals, Contracting Officer and/or COR will return one copy to the

Contractor. If submittals are not approved, Contracting Officer will return all copies to

Contractor with reasons for rejection. Resubmit, identifying changes. Any work done before approval shall be at Contractor's own risk.

9.3 Approved Equals: All brand names noted are subject to ‘or equal’ products. If an item in this solicitation is identified as “brand name or equal” or lists more than 1 manufacturer, the description of the proposed item must reflect the characteristics and level of quality that will satisfy the Government’s needs as demonstrated by the salient physical, functional, or performance characteristics that “equal” products must meet and/or exceed that as specified in the solicitation or relevant specification. Contractor shall incorporate and be responsible for all collateral costs due to the or equal proposed as required to provide a complete project.

A. For each item proposed as an “approved equal,” submit supporting data, including:

1. Drawings and samples as appropriate.

2. Comparison of the characteristics of the proposed item with that specified and with the salient characteristics provided.

3. Changes required in other elements of the work because of the substitution.

4. Name, address, and telephone number of vendor.

5. Manufacturer’s literature justifying equivalency.

B. A request for approval constitutes a representation that General Contractor:

1. Has investigated and shall provide documentation in request showing that the proposed item is equal or superior in all respects to the salient characteristics specified.

2. Will meet or exceed warranties for the proposed item specified.

3. Has determined that the proposed item is compatible with interfacing items.

4. Will coordinate the installation of an approved item and make all changes required in other elements of the work because of the substitution.

5. Waives all claims for additional expenses that may be incurred as a result of the substitution.

Page | 15

C. Approved Equals will be evaluated and approved/disapproved during the submittal process.

9.4 Schedule of Values: Submit the Schedule of Values a minimum of one week prior to the

Preconstruction Conference for COR review. Schedule of Values shall include defined work line items with cost break downs including labor, material, and equipment for COR approval.

9.5 Progress Reporting: The initial Construction Schedule and Schedule of Values are required a minimum of one week prior to the Preconstruction Conference. After the Notice to Proceed is issued and after on-site work begins, progress will be documented via daily logs and by providing an updated Construction Schedule and Schedule of Values when requested, but minimally with each pay application. Submit digital copy electronically (PDF preferred) of all required documents.

Construction Schedules are normally in bar chart form and indicate estimated starting and completion dates for each part of the work. For a pay application to be reviewed and processed in a timely manner, the following information must either be submitted prior to or accompany submission of the pay application:

A. Daily/weekly progress reports during construction as part of the administration process.

B. Updated Schedule of Values: Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The Schedule of

Values will form the basis for payment. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. A sample Schedule of Values format may be provided upon request.

ITEM 10 – TEMPORARY SERVICES

10.1 It is the Contractor’s responsibility to provide temporary services, equipment, tools, and skilled labor as required for the chosen means and methods to perform the work in accomplishing this

Contract.

ITEM 11 - PROJECT CLOSEOUT

11.1 Description: The work of this section consists of final cleanup, closeout submittals, final inspection procedures of phased completion of the fence working toward Final Acceptance.

11.2 Cleaning: Remove all tools, equipment, surplus materials, and rubbish. At time of final inspection, project shall be thoroughly clean and ready for intended use. Inspector holds the right to reschedule if project is not ready for inspection.

11.3 Completion and Inspection of Phased Installation: The project shall progress in a phased sequence of one-half mile increments defined as new fence constructed and existing fence removed. Contractor shall submit written certification of each project one-half mile phase completion and request a final inspection to the Contracting Officer and COR for that specific one-half mile section. The Contracting Officer or designee will make an inspection of completed fencing at the earliest opportunity at a mutually agreeable time.

Page | 16

A. When the work of the one-half mile segment is determined to be complete following the final inspection, the COR will provide a Punch List to the Contractor noting outstanding items to be addressed. The Contractor shall correct noted discrepancies before proceeding with new work. The Contractor shall immediately proceed with the corrections. Once re-accomplished, the government will re-inspect the work.

B. NOT USED.

C. NOT USED

D. Once Contractor completes all items of work on the discrepancies for the first and sequential one-half mile phases of fence segments under this Scope of Work and all contractually required items are accepted for each respective one-half mile, the Contracting Officer will provide written acceptance for each section of work fully inspected and completed and issue

Letter of Final Acceptance of Work once all segments of fence are completed.

E. Once Contractor completes each one-half mile fence segment under this Scope of Work and has been accepted by the government, they may request a progress payment for the completed work.

F. NOT USED

G. Disposition of any permits and warranties required by the specifications in this section.

11.4 Final Acceptance of the Work: After all punch list deficiencies have been corrected, a Letter of

Final Acceptance will be issued. A Release of Claims document must be executed and submitted to the Contracting Officer before final payment can occur.

11.5 Warranties

A. Construction Warranty shall be based on date of incremental final acceptance of the work segmented phases and remain in effect for one year.

B. Provide all manufacturer warranty information of products installed. All contact information, extent of coverage and conditions shall be clearly noted as well as date of overall final acceptance.

ITEM 12 - DEFINITION OF CONTRACT LINE ITEMS

12.1 Summary

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

12.2 List of Contract Line Items

A. Contract Line Item No. 001:

Page | 17

1. This items consists of providing all materials, equipment and labor to remove exiting fence and construct new fence beginning a the I-94 bridge to a terminating point approximate distance of 7600 linear feet as the Base Bid. Terminate fence construction by tying into existing fence remaining with new double H-brace corner structure.

2. Payment will be made per the contract and percentage of completion level.

B. Bid Additive 1:

1. Contract Line Item No. 002:

a. This item consists of providing all materials, equipment and labor to remove exiting fence and construct new fence beginning a the Base Bid terminating point and extend an approximate distance of 2920 linear feet. Terminate fence construction by tying into existing cattle guard on the west side of East River Road (park entry road).

b. Payment will be made per the contract and percentage of completion level.

PART 2 – PRODUCTS (NOT USED)

PART 3 – EXCUTION (NOT USED)

END OF SECTION