B.08.03 - Amendment 0002 (released) - W912HP20B0004 - Post 45 Dredging Contract 5.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to make the follow ing updates:

1) The bid opening date is hereby changed from 25 August 2020 to 1 September 2020.

2) Clause 52.211-10 is hereby updated.

3) Specification Section 35 20 23 Dredging is hereby updated.

All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 21-Aug-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912HP20B0004

X 9B. DATED (SEE ITEM 11)

23-Jul-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

21-Aug-2020

CODE

U.S. ARMY CORPS OF ENGINEERS, CHARLESTON

DISTRICT, CONTRACTING DIVISION

69-A HAGOOD AVENUE

CHARLESTON SC 29403

W912HP 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HP20B0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SECTION 00 00 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION, CONTRACT LINE ITEM NUMBER (CLIN) SCHEDULE

The required response date/time has changed from 25-Aug-2020 01:00 PM to 01-Sep-2020 01:00 PM.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 641 calendar days. * The time stated for completion shall include final cleanup of the premises.

Supplemental Instructions:

1. Charleston Upper Harbor (Acceptance Sections 1-8), Pier X-Ray South, TC Dock, MARADS Piers S,T,U

(a) Prosecution of Work

The Contractor shall provide the Government a schedule not later than 10 calendar days after date of the Notice to Proceed depicting, at a minimum, the following information.

- Commencement dates of initial mobilization and all subsequent demobilizations (if any) and remobilizations (if any) including the final demobilization

- Date dredging shall begin following each mobilization effort

- Duration of dredging (must at least meet specified completion date)

- Date dredging is to be completed, at a minimum, for each acceptance section

- Anticipated schedule of earnings

Once this schedule is approved, it will be incorporated into the contract by a no cost modification and become the performance period for the contract. Liquidated damages will be assessed for every day work continues beyond this incorporated scheduled completion date (as adjusted for excusable delays as allowed per other clauses within the contract).

(End of clause)

(End of Summary of Changes)