B.08.02 Solicitation W912HY21B0009-Specs - SIGNED Final 20210416.pdf

PROJECT MANUAL FOR

DEPARTMENT OF THE ARMY

GALVESTON DISTRICT, CORPS OF ENGINEERS

P.O. BOX 1229

GALVESTON, TEXAS

"INCREASE PROFIT - SUBMIT VECP'S"

SWG FILE NO.: 0401-0586 SOLICITATION NO.: W912HY21B0009

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 00 00 SOLICITATION, OFFER AND AWARD, SF-1442

00 11 00.00 45 BID SCHEDULE

00 21 00 INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

00 45 00 REPRESENTATION AND CERTIFICATIONS

00 72 00 CONTRACT CLAUSES

00 73 00.01 45 SPECIAL CONTRACT REQUIREMENTS, STANDARD

00 73 46 WAGE RATES

DIVISION 01 - GENERAL REQUIREMENTS

01 10 00.01 45 NON-REGULATED SPECIAL CONTRACT REQUIREMENTS

01 22 00.10 45 MEASUREMENT AND PAYMENT

01 32 01.01 45 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26.00 45 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 01.00 QUALITY CONTROL

01 50 00.00 45 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 20.00 45 ENVIRONMENTAL PROTECTION

01 58 13.01 45 PROJECT IDENTIFICATION

01 58 13.04 45 BULLETIN BOARD

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 20 23.16 45 PIPELINE DREDGING

35 20 23.33 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM PIPELINE

HYDRAULIC DREDGE

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

THIS PAGE INTENTIONALLY LEFT BLANK

PROJECT TABLE OF CONTENTS Page 2

THIS SOLICITATION IS BEING ISSUED AS AN UNRESTRICTED PROCUREMENT FOR FY 21 HOUSTON SHIP CHANNEL , TEXAS, BAYPORT TO MORGAN’S BAYPORT SHIP CHANNEL AND BARBOURS FLARE PIPELINE DREDGING IN HARRIS AND CHAMBERS COUNTIES, TEXAS.

ESTIMATED CONSTRUCTION RANGE (FAR 36.204)- THE ESTIMATED PRICE RANGE OF THE PROPOSED CONSTRUCTION IS BETWEEN

$10,000,000.00 AND $25,000,000.00.

The Bidder Inquiry Key for this solicitation is: 26S779-7YB4FD

X

JO A MCCUE

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

16-Apr-2021

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS) jo.a.mccue@usace.army.mil 409-766-6306

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________240 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________00 73 00.00 45

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________17 May 2021 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIVISION

US ARMY CORPS OF ENGINEERS

2000 FT. POINT RD.

GALVESTON TX 77550

W912HY

PAGE OF PAGES

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

409 766-3010FAX:TEL: 409 766-3847 TEL: FAX:

W912HY21B0009 5 OF 264

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 11 00.00 45

BID SCHEDULE

SWG 07/19

PART 1 GENERAL

1.1 BID SCHEDULE

1.1.1 Schedule No. 1

1.1.2 Option No. 1

1.1.3 Option No. 2

1.1.4 Option No. 3

1.1.5 Option No. 4

1.2 EVALUATION OF OPTIONS (July 1990) (FAR 52.217-5)

-- End of Section Table of Contents --

DOCUMENT 00 11 00.00 45 Page 1

THIS PAGE INTENTIONALLY LEFT BLANK

DOCUMENT 00 11 00.00 45 Page 2

SECTION 00 11 00.00 45

BID SCHEDULE

SWG 07/19

PART 1 GENERAL

1.1 BID SCHEDULE

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.1 Schedule No. 1

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

SCHEDULE NO. 1

0001 Mobilization and Demobilization

1 JOB SUM $___________

0002 Pipeline Management 1 JOB SUM $___________

0003 Dredging, Houston Ship Channel, Section 1 through 7

983,100 C.Y. $_________ $___________

0004 Dredging Bayport Channel, Sections 8 through 13

1,342,700 C.Y. $_________ $___________

0005 Sound Protection Measures

1 JOB SUM $___________

0006 Site Management

1 JOB SUM $___________

TOTAL SCHEDULE NO. 1 $___________

NOTE: Completion time stated in SECTION 00 73 00.01 45 SPECIAL CONTRACT REQUIREMENTS, STANDARD is for Schedule No. 1 work.

DOCUMENT 00 11 00.00 45 Page 3

BID SCHEDULE (CONT'D)

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.2 Option No. 1

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 1

0007 Dredging PHA Docks at Bayport Section

182,700 C.Y. $_________ $___________

Debris Removal 30 TON $_________ $___________

0009 Standby for Docks

100 HOUR $_________ $___________

TOTAL OPTION NO. 1 $___________

TOTAL SCHEDULE NO. 1 AND OPTION NO. 1 $___________

NOTE FOR OPTION NO. 1: The Government may exercise this Option by written notice to the Contractor prior to completion of all authorized work. An additional time of 30 calendar days will be added to this Contract for completion of this Option.

DOCUMENT 00 11 00.00 45 Page 4

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.3 Option No. 2

Item No. Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 2

0010 Dredging Barbours Flare, Section 14 242,700 C.Y. $_________ $___________

TOTAL OPTION NO. 2 $___________

TOTAL SCHEDULE NO. 1 AND OPTIONS NOS. 1 AND 2 $___________

NOTE FOR OPTION NO. 2: The Government may exercise this Option by written notice to the Contractor prior to completion of all authorized work. An additional time of 25 calendar days will be added to this Contract for

DOCUMENT 00 11 00.00 45 Page 5

(TO BE ATTACHED TO STANDARD FORM 1442)

1.1.4 Option No. 3

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 3

Dredging PHA Docks at Barbours Sections 16 and

153,700 C.Y. $_________ $___________

0012 Debris Removal 30 TON $_________ $___________

0013 Standby for Docks

100 HOUR $_________ $___________

TOTAL OPTION NO. 3 $___________

TOTAL SCHEDULE NO. 1 AND OPTIONS NOS. 1, 2, AND 3 $___________

NOTE FOR OPTION NO. 3: The Government may exercise this Option by written notice to the Contractor prior to completion of all authorized work. An additional time of 42 calendar days will be added to this Contract for completion of this Option.

1.1.5 Option No. 4

Item No.

Description Estimated Quantity

Unit Unit Price Estimated Amount

OPTION NO. 4

Re-Dredging Bayport Flare, Section 8

268,300 C.Y. $_________ $___________

0015 Pipeline Management 1 JOB SUM $___________

TOTAL OPTION NO. 4 $___________

TOTAL SCHEDULE NO. 1 AND OPTIONS NOS. 1, 2, 3, AND 4 $___________

NOTE FOR OPTION NO. 4: The Government may exercise this Option by written

DOCUMENT 00 11 00.00 45 Page 6 notice to the Contractor prior to completion of all authorized work. An additional time of 30 calendar days will be added to this Contract for

DOCUMENT 00 11 00.00 45 Page 7

(TO BE ATTACHED TO STANDARD FORM 1442)

1.2 EVALUATION OF OPTIONS (July 1990) (FAR 52.217-5)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

-- End of Document --

DOCUMENT 00 11 00.00 45 Page 8

SWG FILE NO.: 04010586 SOLICITATION NO.:W912HY21B0009

Section 00 21 00 - Page 1

Section 00 21 00

1.1 ESTIMATED CONSTRUCTION PRICE RANGE (FAR 36.204)

The estimated price range of the proposed construction is between $10,000,000 and $25,000,000.

1.2 AVAILABILITY OF PLANS AND SPECIFICATIONS ON BETA.SAM.GOV WEBSITE (FAR

5.102(a)(1))

After solicitation issuance, contractors may register to be placed on the Interested Vendors List, view and/or download this solicitation and all amendments at https://beta.sam.gov/ .

Plans and specifications will not be available in paper format or on compact disc. It is the offeror’s responsibility to monitor the Beta Sam website daily (using the above link) for amendments to the solicitation. You must be registered in the System For Award Management (SAM) to receive a government contract award. The website for SAM https://www.sam.gov/SAM/ .

1.3 TECHNICAL INFORMATION DREDGING (FAR 14.211)

(a) For technical information regarding the plans and specifications submit questions in PROJNET, see paragraph 1.9 of this section for details.

(b) The Contractor [ ] shall [ X ] shall not be permitted to use self-propelled hopper dredges to perform the work specified herein.

1.4 PREAWARD INFORMATION DREDGING (FAR 9.105-1)

The apparent low bidder shall submit within (2) working days after Bid Opening, the following information:

(a) A statement as to whether he is now or ever has been engaged in performing dredging of [ X ] deep or [ ] shallow draft channels.

(b) A list of key personnel available for the current project and their qualifications.

(c) A copy of the bidder's latest financial statement, including the names of banks or other financial institutions with which the bidder conducts business. If the financial statement is more than 60 days old, a certificate should be attached stating that the financial condition is substantially the same, or if not the same, the changes that have taken place. Such statement will be treated as confidential.

(d) A list of present commitments, including the dollar value thereof, name of office under which the work is being performed, the scheduled completion date of each, days ahead or behind schedule and the name of the dredge(s) to be used on the job.

(e) Name and location of the firm's dredging plant to perform the work under this contract, the date this plant will commence work, and the plants capability to perform the work as required by the specifications.

(f) A preliminary schedule showing anticipated dates for start of work, based upon availability of contractor resources, and the plan for completing work within the contract performance period. For dredging contracts, this includes production rates for proposed dredging equipment together with an analysis showing how work will be accomplished within the contract performance period.

(g) If bidder is a Large Business, a Sub-Contracting Plan, if required, must be submitted within (2) working days after Bid Opening.

1.5 DISPOSAL OF EXCAVATED MATERIAL

https://beta.sam.gov/ https://www.sam.gov/SAM/

Section 00 21 00 - Page 2

The following owners in the vicinity of the work to be accomplished under this Invitation for Bids are known to desire fill material:

NAME ADDRESS

If any of the areas owned by the above-listed owners are proposed to be utilized by the Contractor in the performance of the work, the provision for use of alternate areas DREDGING: PLACEMENT OF EXCAVATED MATERIAL of the specifications will be applicable.

1.6 BIDDER'S QUALIFICATIONS (FAR 9.105-1)

Before a bid is considered for award, the bidder may be requested by the Government to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial resources, and plant available to be used in performing the work.

1.7 NOTICE TO BIDDERS (FAR 52.214-18)

All information required by the terms of the solicitation must be furnished.

MISTAKES OR OMISSIONS CAN BE COSTLY. Important items for you to check are included in but not limited to, those listed below. This checklist is furnished only to assist you in submitting a proper offer. Check as you read.

Have you acknowledged all amendments?

Have you completed SECTION 00 45 00, REPRESENTATIONS &

CERTIFICATIONS portion of the solicitation package to include 52.204-24 and 52.204-26?

Is your offer properly signed?

If a bid guarantee is required, is it included with your offer?

(A late bid guarantee is treated the same as a late offer).

Is your bid guarantee in the proper amount? Bid guarantee shall be in the amount of 20 percent of the amount of the offer, or $3 million, whichever is less.

If your bid guarantee is in the form of a bid bond, is the bond properly signed by both the bidder and surety and are all required seals affixed?

Is the name in which you submitted the offer the same as your bid bond?

If required have you entered a unit price for each item? (The solicitation will specifically state when this is necessary).

Are decimals in unit prices in the proper places? Are your figures legible?

Are the extensions of your unit prices, and your total offer price correct?

Are all erasures or corrections initialed by the person signing the offer?

I have not restricted my offer by altering the provisions of the solicitation.

REMINDER TO BIDDERS

REMINDER #1 - Acknowledge all Amendments on the reverse side of SF 1442, Item 19, Solicitation, Offer, and Award.

REMINDER #2 - The Contracting Officer signing this contract is the Primary Contracting Officer. However, any Contracting Officer assigned to the

Section 00 21 00 - Page 3

Galveston District may take formal action. See Section entitled "Specific Project Requirements".

1.8 SPECIAL INSTRUCTIONS PERTAINING TO ELECTRONIC BID SUBMISSION: (FAR

14.302 and 14.304)

Bids and a copy of the SF24 Bid Bond must be submitted via email to SWG-CT- Execution-Proposals@usace.army.mil, not later than the response date and time indicated in the solicitation. Identify the Solicitation Number W912HY21B0009 in subject line of the emai1. BID OPENING WILL BE BY TELECONFERENCE. THE

TELECONFERENCE INFORMATION IS AS FOLLOWS:

https://usace1.webex.com/usace1/j.php?MTID=m243d5281d2ec78bc3c86a9f355853e70

Meeting number (access code): 199 816 1333 +1-844-800-2712 US Toll Free Access Code: 199816133 +1-669-234-1177 US Toll Access Code: 199816133

1.9 BIDDER INQUIRY – PROJNET (FAR 14.211)

1. Prospective Offerors should submit questions concerning this solicitation via Bidder Inquiry in ProjNet at www.projnet.org/projnet .

A. To submit and review bid inquiry items, bidders will need to be a current registered user or self register into the system. To self-register, go to the aforementioned web page and click on the BID tab. Select Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your email address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

***Please Note: Offerors shall only submit one question per inquiry.

Inquiries containing multiple questions may be rejected.

B. From this page, you may view all bidder inquiries or add inquiry.

C. Offerors will receive an acknowledgement of their question via email, followed by an answer to their question after it has been processed by our technical team.

D. The Solicitation Number is: W912HY21B0009 The Bidder Inquiry Key is: 26S779-7YB4FD

2. The Bidder Inquiry System will be unavailable for new inquires fifteen

(15) calendar days prior to offer submission in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation if necessary.

3. Offerors are requested to review the specification in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

4. The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800-428-HELP.

1.10 CONSTRUCTION WAGE RATE REQUIREMENTS (FAR 52.222-6)

mailto:SWG-CT-Execution-Proposals@usace.army.mil mailto:SWG-CT-Execution-Proposals@usace.army.mil https://usace1.webex.com/usace1/j.php?MTID=m243d5281d2ec78bc3c86a9f355853e70 http://www.projnet.org/projnet

Section 00 21 00 - Page 4

Paragraph entitled CONSTRUCTION WAGE RATE REQUIREMENTS of (CONTRACT CLAUSES - Section 00 72 00, FAR 52.222-6) is applicable to this solicitation. Wage Rates will be incorporated by amendment, if they are not included in this

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and

Withdrawals of Bids

NOV 1999

52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission of Offers In The English Language APR 1991 52.214-35 Submission of Offers In U.S. Currency APR 1991 52.215-20 Requirements for Certified Cost or Pricing

Data or

OCT 2010

Information Other Than Certified Cost or Pricing Data

52.217-4 Evaluation of Options Exercised At The Time Of Contract

JUN 1988

Award 52.217-5 Evaluation of Options JUL 1990 52.232-13 Notice of Progress Payments APR 1984 52.232-14 Notice of Availability of Progress Payments

Exclusively For

APR 1984

Small Business Concerns 52.232-38 Submission of Electronic Funds Transfer

Information with

JUL 2013

Offer 52.252-1 Solicitation Provisions Incorporated by

Reference

FEB 1998

CLAUSES INCORPORATED BY FULL TEXT

52.214-15 PERIOD FOR ACCEPTANCE OF BIDS (APR 1984)

In compliance with the solicitation, the bidder agrees, if this bid is accepted within 60 calendar days from the date specified in the solicitation for receipt of bids, to furnish any or all items upon which prices are bid at the price set opposite each item, delivered at the designated point(s), within the time specified in the Schedule.

(End of clause)

52.216-1 TYPE OF CONTRACT (APR 1984)

Section 00 21 00 - Page 5

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

Harris County 27.3% Chambers County 27.4%

6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant

Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

Section 00 21 00 - Page 6

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

Texas, Harris and Chambers County

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Contracting Officer, US Army Corps of Engineers, Galveston District, PO Box 1229, Galveston, Texas 77553- 1229, submitting the protest at SWG-CT-protests@usace.army.mil

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

The site is available to the public and can be visited by the contractor at will.

mailto:SWG-CT-protests@usace.army.mil mailto:SWG-CT-protests@usace.army.mil

SWG FILE NO.: 04010586 SOLICITATION NO.: W912HY21B0009

Section 00 45 00 - Page 1

CLAUSES INCORPORATED BY REFERENCE

52.204-16 Commercial and Government Entity Code

Reporting

AUG 2020

52.204-19 Incorporation by Reference of Representations and

DEC 2014

Certifications.

252.247-

Representation of Extent of Transportation by Sea.

JUN 2019

52.203-2 CERTIFICATE OF INDEPENDENT PRICE DETERMINATION (APR 1985)

(a) The offeror certifies that --

(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to –

(i) Those prices,

(ii) The intention to submit an offer, or

(iii) The methods of factors used to calculate the prices offered:

(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and

(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.

(b) Each signature on the offer is considered to be a certification by the signatory that the signatory --

(1) Is the person in the offeror's organization responsible for determining the prices offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision; or

(2) (i) Has been authorized, in writing, to act as agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision (insert full name of person(s) in the offeror's organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror's organization);

(ii) As an authorized agent, does certify that the principals named in subdivision

(b)(2)(i) above have not participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) above; and

Section 00 45 00 - Page 2

(iii) As an agent, has not personally participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision.

(c) If the offeror deletes or modifies subparagraph (a)(2) of this provision, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

(End of Provision)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2020)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $30,000,000.00.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm- fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in

Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence

Section 00 45 00 - Page 3

Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain

Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation.

This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--

Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than

DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when

Section 00 45 00 - Page 4 contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals- -Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate.

(Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in

Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification.

This provision applies to all solicitations.

Section 00 45 00 - Page 5

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer: [Contracting Officer check as appropriate.] X (i) 52.204-17, Ownership or Control of Offeror.

X (ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor

Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor

Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted

Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

http://www.sam.gov/

Section 00 45 00 - Page 6

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (OCT 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204- 26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Items. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered

Section 00 45 00 - Page 7 telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the

System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [] will, [] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [] does, [] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

Section 00 45 00 - Page 8

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained:

Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained:

Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (OCT

2020)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Section 00 45 00 - Page 9

(b) Procedures. The Offeror shall review the list of excluded parties in the

System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representations.

(1) The Offeror represents that it [ ] does, [ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ] does, [ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services. (End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings).

This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite- quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

Section 00 45 00 - Page 10

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through

(c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2020)

(a) This provision implements section 523 of Division B of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts.

(b) If the Offeror is proposing a total contract price that will exceed $5.5 million (including options), the Offeror shall certify that, to the best of its knowledge and belief, it--

(1) Has [ ] filed all Federal tax returns required during the three years preceding the certification;

(2) Has not [ ] been convicted of a criminal offense under the Internal Revenue Code of…