Attachment 3 Supplemental Contract Requirements.pdf
PDF 125 KB Posted
- Attached to
- Navy Ops Support Center Federal contract opportunity
- Solicitation number
- W9123820R0058
About this file
This document contains supplemental contract requirements and details for a federal solicitation for a Navy operations support center. The solicitation is for a design-build contract to design and construct a low-rise training facility to support training, recruiting, and administration for a Navy Reserve unit. The scope of work includes civil, architectural, structural, mechanical, electrical, and communications work. The performance period is 840 calendar days and liquidated damages for delays are $2,440 per day. The contract will use the Davis Bacon wage determination for Utah and lists anticipated adverse weather days by month. Only the contracting officer is authorized to modify the contract terms.
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| SF1442 Phase 1 W9123820R00058 Amendment 0001.pdf | ||
| Form Past Performance Questionaire.pdf | ||
| Form Pre Award Survey.pdf | ||
| Form Offeror Project Experience.pdf | ||
| Form for Proposal Data Sheet.pdf | ||
| Attachment 2 P203 NOSC Concept Design Drawings (FINAL).pdf | ||
| Attachment 1 Summary of Work.pdf | ||
| Attachment 4 Wage Determination 01 01 2021.pdf | ||
| SF1442 Phase 1_W9123820R0058 NAVY OPS 13JAN2021.pdf | ||
| Attachment 5 Instructions.pdf |
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment 2
SUPPLEMENTAL CONTRACT REQUIREMENTS
1. Performance Period: Refer to contract section 00700, FAR 52.211-10. The performance period for the work stated above shall be 840 calendar days.
2. Liquidated Damages: Refer to contract section 00700, FAR 52.211-12, Liquidated Damages-Construction. Liquidated damages for this work are $2,440.00 for each day of delay.
3. Authorities: “Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.”
4. Wage Determination: General Decision No. UT18062, or its most current modification at the time of award is hereby applicable to work performed under this task order. The most current decision or its modification can be found at:
https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&keywords=&is_active=true&sort=-modifiedDate&date_filter_index=0&date_rad_selection=date&wdType=dbra&construction_typ e=Building&state=UT&county=17774&page=1
6. Time Extensions For Unusually Severe Weather: Refer to FAR 52.249.10, Default (Fixed- Priced Construction). All weather delay will need to be submitted and approved by the Contracting Officer Representative.
MONTHLY ANTICIPATED ADVERSE WEATHER DELAY
WORK DAYS BASED ON (5) DAY WORK WEEK-HILL AFB
JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC
(22) (19) (15) (07) (04) (03) (01) (02) (02) (05) (15) (22) https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&keywords=&is_active=true&sort=-modifiedDate&date_filter_index=0&date_rad_selection=date&wdType=dbra&construction_type=Building&state=UT&county=17774&page=1 https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&keywords=&is_active=true&sort=-modifiedDate&date_filter_index=0&date_rad_selection=date&wdType=dbra&construction_type=Building&state=UT&county=17774&page=1 https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&keywords=&is_active=true&sort=-modifiedDate&date_filter_index=0&date_rad_selection=date&wdType=dbra&construction_type=Building&state=UT&county=17774&page=1 https://beta.sam.gov/wage-determination/UT20200083/0?index=wd&keywords=&is_active=true&sort=-modifiedDate&date_filter_index=0&date_rad_selection=date&wdType=dbra&construction_type=Building&state=UT&county=17774&page=1
SUPPLEMENTAL CONTRACT REQUIREMENTS
File details come from the government source that posted it. Updated .