Attachment_1_-_Specifications_FRSP_Geothermal_HVAC.pdf

GEOTHERMAL HVAC SYSTEM FOR

JACKSON SHRINE DEATH SITE

FREDERICKSBURG & SPOTSYLANIA NATIONAL MILITARY PARK

FRSP PMIS NO. 304741

DIVISION ONE &

TECHNICAL

SPECIFICATIONS

NATIONAL PARK SERVICE

DENVER SERVICE CENTER

March 2025

CONSTRUCTION DOCUMENTS

FRSP 304741

TABLE OF CONTENTS

DIVISION 01: GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 26 01 Contract Modification Procedures 01 27 00 Definition of Contract Line Items 01 31 00 Project Management and Coordination 01 32 16 Construction Schedule 01 32 33 Photographic Documentation 01 33 23 Submittal Procedures 01 35 13.22 Archeological Protection 01 35 23 Safety Requirements 01 35 91 Historic Preservation Treatment Procedures 01 40 00 Quality Requirements 01 42 00 Reference Standards 01 50 00 Temporary Facilities and Controls 01 56 39 Tree Retention and Protection 01 57 19.11 Indoor Air Quality (IAQ) Management 01 57 19.12 Noise and Acoustics Management 01 57 23 Under-an-Acre Pollution Prevention (UPPP) 01 67 00 Product Requirements 01 73 29 Cutting and Patching 01 73 40 Execution 01 74 19 Construction Waste Management and Disposal 01 77 00 Closeout Procedures 01 78 23 Operation and Maintenance (O&M) Data 01 79 00 Demonstration & Training 01 81 13 Sustainable Design Requirements- Non-LEED™ Projects 01 91 14 Total Building Commissioning

DIVISION 02: EXISTING CONDITIONS

02 41 19 Selective Demolition 02 73 29 Cutting and Patching

DIVISION 9: FINISHES

09 24 00 Cement Plastering 09 29 00 Gypsum Board 09 91 23 Interior Painting

DIVISION 23: HEATING, VENTILATING, AND AIR CONDITIONING

23 05 00 Common Work Results for HVAC 23 05 13 Common Motor Requirements for HVAC Equipment 23 05 19 Meters and Gauges for HVAC Piping 22 05 23 General Duty Valves for HVAC Piping 23 05 29 Hangers and Supports for HVAC Piping 23 05 48 Vibration and Seismic Controls For HVAC 23 05 53 Identification for HVAC Piping and Equipment 23 05 93 Testing, Adjusting, and Balancing for HVAC 23 07 13 Duct Insulation 23 07 19 HVAC Piping Insulation 23 08 00 Commissioning of Mechanical Systems 23 21 13 Hydronic Piping 23 21 16 Hydronic Piping Specialties 23 21 23 Hydronic Pumps 23 31 13 Metal Ducts 23 33 00 Air Duct Accessories 23 33 46 Flexible Ducts 23 37 13 Diffusers, Registers, and Grilles 23 57 33 Ground Heat Exchangers 23 57 33.16 Thermal Enhanced Grout 23 57 33.19 Grouting Vertical Loops 23 81 46 Water Source Heat Pumps 23 82 39.19 Wall Unit Heaters

DIVISION 26: ELECTRICAL

26 05 00 Common Work Results for Electrical 26 05 19 Low-Voltage Electrical Power Conductors and Cables 26 05 26 Grounding and Bonding for Electrical Systems 26 05 29 Hangers and Supports for Electrical Systems 26 05 33 Raceway and Boxes for Electrical Systems 26 05 44 Sleeves and Sleeve Seals for Electrical Raceways and Cabling 26 05 53 Identification for Electrical Systems 26 27 26 Wiring Devices 26 28 16 Enclosed Switches and Circuit Breakers

DIVISION 31: EARTHWORK

31 10 00 Site Clearing 31 23 33 Trenching and Backfill 31 32 50 Watering

DIVISION 32: EXTERIOR IMPROVEMENTS

32 13 13 Concrete Paving 32 13 73 Concrete Paving Joint Sealants 32 91 13 Soil Preparation 32 91 19 Topsoil 32 92 19 Seeding and Mulching

DIVISION 33: UTLITIES

33 11 00 Water Utility Distribution Piping

FRSP 304741 00 01 07 - 1

SEALS PAGE

SECTION 00 01 07 – SEALS PAGE

1.1 DESIGN PROFESSIONALS OF RECORD:

A. CIVIL ENGINEER:

Professional Certification. I hereby certify that these documents were prepared or approved by me and that I am a duly registered Professional Engineer.

License No.____________________

Expiration Date:________________

Martin/Martin Consulting Engineers

042068465

03/03/2025

07/31/2026

Limited to the following Specifications:

01 57 23 UNDER-AN-ACRE POLLUTION PREVENTION

31 10 00 SITE CLEARING

31 23 33 TRENCHING AND BACKFILLING

32 13 13 CONCRETE PAVING

32 13 73 CONCRETE PAVING JOINT SEALANTS

33 11 00 WATER UTILITY DISTRIBUTION PIPING

FRSP 304741 00 01 07 - 2

B. LANDSCAPE ARCHITECT:

Professional Certification. I hereby certify that these documents were prepared or approved by me and that I am a duly registered Landscape Architect.

License No._____0406002290 _________

Expiration Date:___ July 2025_________

DHM Design

FRSP 304741 00 01 07 - 3

C. ARCHITECT:

and that I am a duly registered Architect.

License No.______009386______________

Expiration Date:___February 2026________ ajc architects

FRSP 304741 00 01 07 - 4

D. MECHANICAL & PLUMBING ENGINEER:

and that I am a duly registered Professional Engineer.

License No.____________________

360 Engineering, Inc.

0402054801

04/30/2027

FRSP 304741 00 01 07 - 5

E. ELECTRICAL ENGINEER:

and that I am a duly registered Professional Engineer.

License No.____________________

AE Design

04/24/2025

040029

6/30/2026

FRSP 304741 00 01 07 - 6

A. GEOTHERMAL ENGINEER:

Professional Certification. I hereby certify that these documents were prepared or approved by me and that I am a duly registered Professional Engineer.

License No.____126526_________

Expiration Date:_12/31/2026_____

Geo-Energy Services, LLC

END OF SECTION

FRSP 304741 01 11 00 - 1

112723 SUMMARY OF WORK

FRSP 304741

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes the following:

1. Work Covered by Contract Documents

2. Work Phases

3. Work Under Other Contracts

4. Government-Furnished Materials

5. Construction Contractor Use of Site

6. Public Use of Site

7. Occupancy Requirements for Buildings

8. Conduct of Operations

9. Work Restrictions

10. Special Construction Requirements

11. Reports

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: “Stonewall” Jackson Death Site, Fredericksburg and Spotsylvania National Military Park, 12019 Stonewall Jackson Road, Woodford, Virgina 22580.

B. The Work consists of:

1. Design of a geothermal HVAC system at the historic, two-story wood-framed Jackson Shrine Death site.

2. Work includes but is not limited to; minor architectural modifications to accommodate mechanical penetrations; demolition of existing mechanical equipment and ductwork, installation of new water source heat pump and associated equipment and ductwork; minor electrical modifications to support new HVAC system; boring and installation of ground heat exchangers; additional site utility installation; and vegetation restoration at areas of disturbance.

C. Project will be constructed under a single prime contract.

1.3 WORK PHASES

A. The Work shall be conducted in a single phase.

FRSP 304741 01 11 00 - 2

1.4 WORK UNDER OTHER CONTRACTS

A. General: Cooperate with separate Construction Contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate Work of this Contract with work performed under separate contracts.

1.5 GOVERNMENT-FURNISHED MATERIALS

A. In case of Government -furnished materials:

1. Government will arrange and pay for delivery of Government-furnished items according to Construction Contractor's Construction Schedule.

2. Construction Contractor is responsible for initial inspection, receiving, unloading, and handling Government-furnished items at Project site.

3. Government will inspect delivered items for damage after delivery. Construction Contractor shall be present for and assist in Government's inspection.

4. Government will arrange for replacement if Government-furnished items are damaged, defective, or missing.

5. Construction Contractor is responsible for protecting Government-furnished items from damage during storage and handling, including damage from exposure to the elements.

6. If Government-furnished items are damaged as a result of Construction Contractor's operations, Construction Contractor shall repair or replace them.

7. Construction Contractor shall install and otherwise incorporate Government-furnished items into Work.

B. Government-Furnished Materials:

1. Wood bollards: The government will provide the wooden bollards required for the rehabilitation describe under section 31 23 33 -12 paragraph 3.15 B.

1.6 CONSTRUCTION CONTRACTOR USE OF SITE

A. General: Construction Contractor shall have limited use of site for construction operations. Limit use of premises to areas within the construction activities indicated on drawings. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine construction operations to areas of work for drilling and stockpiling as shown on drawings.

2. Access to NPS Employee Housing to remain throughout project duration.

3. The Government will either remove furniture or relocate furniture within the building prior to the start of construction.

B. Storage of Materials: Confine storage of materials to storage area shown on plans. No hazardous materials may be stored on site unless approved by the Contracting Officer’s Representative.

C. Parking: Confine parking to storage area and driveway to NPS Employee Housing shown on Drawing Sheet G0.1, Construction Staging and Access Plan.

FRSP 304741 01 11 00 - 3

D. Stockpiling: Confine stockpiling to proposed staging area shown on Drawing Sheet G0.1, Construction Staging and Access Plan. Coordinate final location with Contracting Officer.

E. All vehicles should be equipped with absorptive pads while on park property in order to quickly contain any spills of oil or hydraulic fluid. Any such spills must be reported to the Contracting Officer as soon as is safely possible.

F. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with

Contracting Officer (CO) and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

G. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to Government employees, and emergency vehicles at all times. Do not use for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

H. Construction Camp: Establishment of a camp within park will not be permitted.

I. Hauling Restrictions: Comply with legal load restrictions in hauling of materials. Load restrictions on park roads are identical to state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Construction Contractor of liability for damage which may result from moving of equipment.

J. Bridge Restrictions: Comply with all legal load restrictions in the hauling of materials. Contractor shall identify jurisdictions, load restrictions, permit requirements, time and calendar restrictions. A special permit will not relieve the Contractor of liability for damage which may result from equipment.

K. Damage to pavements, utilities, and other improvements and areas of protection, caused during work under this Contract, shall be repaired to original condition or better at no additional cost to the National Park Service

1.7 PUBLIC USE OF SITE

A. The building and site may be partially closed to the public during construction.

B. Construction Contractor shall conduct his operations to ensure the least inconvenience to public.

Contractor shall make any and all necessary measures to protect the general public from the

FRSP 304741 01 11 00 - 4

construction sites. Temporary walk closures will be permitted, when required, upon specific approval of Contracting Officer for a maximum amount of time as approved by NPS.

1. Contractor to coordinate vehicular and pedestrian detour plan with Contracting Officer.

Temporary closures to be approved by the Contracting Officer.

1.8 OCCUPANCY REQUIRMENTS FOR BUILIDINGS

A. Existing Buildings

1. Partial Government Occupancy: Government may occupy premises during entire construction period, with exception of areas under construction. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform Work so as not to interfere with Government’s operations.

Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from Contracting Officer.

1.9 CONDUCT OF OPERATIONS

A. Construction Contractor shall conduct his operations in conformance with rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed unless stated in the Work Restrictions below or without prior consent from the Contracting Officer. Submit requests 3 business days in advance of the work to the Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.10 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 7:30 a.m. to 4:30 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend Hours: Only with notification and prior approval by the Contracting Officer.

2. Early Morning Hours: Only with notification and prior approval by the Contracting Officer.

3. Hours for Core Drilling: Within normal business working hours noted above.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Construction Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

FRSP 304741 01 11 00 - 5

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two business days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

3. Hours and length of Utility Shutdowns: Two hours.

D. Nonsmoking Building/Tobacco Use/Vaping: Smoking is not permitted within building or within 25 feet of entrances, operable windows, or outdoor air intakes.

1.11 SPECIAL CONSTRUCTION REQUIREMENTS

A. Any uncovered archeological resources will take a minimum of one day to clear. Durations to be assessed on a case-by-case basis.

B. Delegated Design: The contractor shall provide all investigative work, obtain field measurements, reports, design and repairs as required to complete delegated designs indicated within technical specifications.

C. Contractor to provide all third-party testing and inspections. Contractor to submit reports to the Contracting Officer.

1.12 REPORTS

A. Regulated Building Materials Survey Report – Design Geothermal HVAC System for The Jackson Shrine Death Site (SJDS), NPS-GSA Northeast Fredericksburg and Spotsylvania National Military Park – CBF Jackson Shrine, August 30, 2024, prepared by Mabbett is available for Construction Contractor review.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

FRSP 304741 01 26 01 - 1

012721 CONTRACT MODIFICATION PROCEDURES

FRSP 304741

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with preparation of modifications will not be allowed. Costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager (PM), Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

FRSP 304741 01 26 01 - 2

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: Costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate.

The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on project site. Modification costs for salaried workers are only allowed within the structure of a 40-hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: The hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens; includes insurance and taxes the business must pay on behalf of the worker to government entities and educational forums, such as:

1) Social Security

2) Medicare

3) Workers Compensation – Policy and company calculation to be made available.

4) Federal Unemployment Tax Act (FUTA) - Cap Rate and percentage to be proportionally allocated over one year.

FRSP 304741 01 26 01 - 3

5) State Unemployment Tax Act (SUTA) - Cap Rate and percentage to be proportionally allocated over one year.

6) Union agreement costs - Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects Contractor from claims resulting from bodily injury or property damage to a third party. Include as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees the Contractor will pay the labor and material costs incurred. Banks and Insurance companies charge a premium for individual project based on a sliding scale related to the size of the project.

Include as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: Covers the contractor’s loss due to fire, high winds, or other natural forces. Not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Proposal be received in the format and within the time frame specified in the Request for Proposal (RFP) letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. Proposal shall be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed they are included in the hourly rate shown, or contractor is not requesting reimbursement. Contractor may

FRSP 304741 01 26 01 - 4

utilize the government provided Contractor Estimate Form, or their own form, provided that it contains the same information and level of detail as the Government’s form.

3. Requests for extensions of contract time as a result of change must be justified with a Time Impact Analysis (TIA). Refer to Section 01 32 16 "Construction Schedule", for time impact analysis requirements. TIA and associated costs shall be received with the proposal by the date shown within the Request for Proposal letter. Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer (CO) upon request.

5. Contractor shall review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing hours required for each craft directly engaged in modification work. Any work proposed requiring overtime work or premium pay shall be itemized separately. Rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, Federal Insurance Contributions Act (FICA), FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. Labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. Estimated cost for materials shall include quotes from multiple sources. Material prices shall include applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for work being performed.

2. Do not include costs for "miscellaneous tools and equipment", in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 shall be broken out separately.

3. Regardless of ownership, rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. United States (U.S.) Army Corps of Engineers, Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

FRSP 304741 01 26 01 - 5

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. Estimated equipment rates shall include operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires and tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per Federal Acquisition Regulation (FAR) 31.105(d)(2)), depreciation, storage, insurance, and all incidentals. Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate full rate for equipment only for duration that equipment will be utilized to accomplish work of the modification.

6. Standby unit rates used in accordance with paragraph 1.3, D, 2, above. If the U.S. Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then 1/2 of equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, established standby rate shall apply from the first day of the delay.

8. Equipment not used and on job site for up to five consecutive days may be classified at standby rates, provided the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work.

Equipment still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………..5% Profit……………………8%

2. Total aggregate limit of markup (OH&P) for Contractor and Subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

3. If Contractors form a partnership, partnership may only receive home office overhead and profit in same amount as an individual Contractor (refer to paragraph 1.3,E,1 above). It is the responsibility of the partners to decide on division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, overhead and profit mark-ups are required on net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

FRSP 304741 01 26 01 - 6

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 012601

FRSP 304741 01 27 00 - 1

012721 DEFINITION OF CONTRACT LINE ITEMS

FRSP 304741

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. Section explains in general, what is and is not included in a contract line item, and limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of work, include costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item Number 01: Geothermal HVAC System.

1. This item consists of, but is not limited to: all materials, labor and testing associated with minor architectural and electrical modifications to the historic Jackson Shrine Death Site, a historic two-story wood-framed building, to accommodate new mechanical equipment and ductwork. Work also includes boring and installation of ground heat exchangers, charged fire suppression water line including but not limited to piping, fitting, valves, thrust blocks and related appurtenances to provide a complete system, electrical conduit and seeding and mulching at areas of disturbance.

2. Measurement for payment will be percentage of work completed in the previous month.

3. Payment will be made at the contract lump sum price (LS).

END OF SECTION 01 27 00

FRSP 304741 01 31 00 - 1

112723 PROJECT MANAGEMENT AND COORDINATION

FRSP 304741

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination

3. Submittals

4. Coordination Drawings

5. Requests for Information (RFIs)

6. NPS Project Management and Communication Software

7. Project Meetings

8. Environmental Coordination

9. Permits

B. Related Requirements:

1. Section 01 32 16 "Construction Schedule" for preparing and submitting Construction Contractor’s construction schedule.

2. Section 01 73 40 "Execution" for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 "Closeout Procedures" for coordinating closeout of the Contract.

4. Section 01 91 14 "Total Building Commissioning" for coordinating the work with Owner’s

Commissioning Authority.

1.2 DEFINITIONS

A. Agency with Jurisdiction B. Construction Permits – Contractor Provided C. Government Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

FRSP 304741 01 31 00 - 2

1. Schedule construction operations in sequence required to obtain best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Construction Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other Construction Contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to:

1. Preparation of Construction Contractor Construction Schedule

2. Preparation of the Schedule of Values

3. Installation and removal of temporary facilities and controls

4. Delivery and processing of submittals

5. Progress meetings

6. Permit requirements

7. Pre-installation conferences

8. Project closeout activities

9. Commissioning activities

1.4 SUBMITTALS

A. Coordination Drawings: Prepare Coordination Drawings if limited space availability necessitates maximum utilization of space for efficient installation of different components or if coordination is required for installation of products and materials fabricated by separate entities.

1. Content: Project-specific information, drawn accurately to scale. Do not base Coordination Drawings on reproductions of Contract Documents or standard printed data. Include following information, as applicable:

a. Indicate functional and spatial relationships of components of architectural, structural, civil, mechanical, and electrical systems.

b. Indicate dimensions shown on Contract Drawings and make specific note of dimensions that appear to be in conflict with submitted equipment and minimum clearance requirements. Provide alternate sketches to Contracting Officer (CO) for resolution of such conflicts.

c. Indicate space requirements for routine maintenance and anticipated replacement of components during the life of the installation.

FRSP 304741 01 31 00 - 3

d. Show location and size of access doors required for access to concealed dampers, valves, and controls.

e. Indicate required installation sequences.

2. Refer to individual Sections for Coordination Drawing requirements for Work in those Sections.

3. Follow NPS DSC Electronic Drawing Standards. See CAD/BIM (Computer Aided Design/Building Information Modeling) & Drafting Standards page > DSC Requirements section.

B. Coordination Drawing Organization: Organize coordination drawings as follows:

1. Floor Plans and Reflected Ceiling Plans: Show architectural, structural, mechanical, plumbing, fire-protection, fire-alarm, and electrical elements. Show locations of visible ceiling-mounted devices relative to acoustical ceiling grid. Supplement plan drawings with section drawings where required to adequately represent the Work.

2. Plenum Space: Indicate sub-framing for support of ceiling and wall systems, mechanical and electrical equipment, and related Work. Locate components within ceiling plenum to accommodate layout of light fixtures indicated on Drawings. Indicate areas of conflict between light fixtures and other components.

3. Mechanical Rooms: Provide coordination drawings for mechanical rooms showing plans and elevations of mechanical, plumbing, fire-protection, fire-alarm, and electrical equipment.

4. Structural Penetrations: Indicate penetrations and openings required for all disciplines.

5. Slab Edge and Embedded Items: Indicate slab edge locations and sizes and locations of embedded items for metal fabrications, sleeves, anchor bolts, bearing plates, angles, door floor closers, slab depressions for floor finishes, curbs and housekeeping pads, and similar items.

6. Mechanical and Plumbing Work:

a. Sizes and bottom elevations of ductwork, piping, and conduit runs, including insulation, bracing, flanges, and support systems.

b. Dimensions of major components, such as dampers, valves, diffusers, access doors, cleanouts and electrical distribution equipment.

c. Fire-rated enclosures around ductwork.

7. Electrical Work:

a. Runs of vertical and horizontal conduit 1-1/4 inches (32 millimeters) in diameter and larger.

b. Light fixture, exit light, emergency battery pack, smoke detector, and other fire-alarm locations.

c. Panel board, switch board, switchgear, transformer, busway, generator, and motor control center locations.

d. Location of pull boxes and junction boxes, dimensioned from column center lines.

8. Fire-Protection System:

a. Locations of standpipes, mains piping, branch lines, pipe drops, and sprinkler heads.

FRSP 304741 01 31 00 - 4

9. Review: Contracting Officer will review coordination drawings to confirm Work is being coordinated; details of coordination are Construction Contractor's responsibility. If Contracting Officer determines coordination drawings are not prepared in scope or detail, or are otherwise deficient, Contracting Officer will inform Construction Contractor, who shall make changes and resubmit.

10. Coordination Drawing Prints: Prepare coordination drawing prints according to requirements in Section 01 33 23 "Submittal Procedures."

C. Coordination Digital Data Files: Prepare coordination digital data files according to:

1. File Preparation Format: Same digital data software program, version, and operating system as original Drawings.

2. File Submittal Format: Submit or post coordination drawing files using Portable Document Format (PDF) file format.

3. Contracting Officer will furnish Construction Contractor one set of digital data files (AutoCad.dwg) of Drawings for use in preparing coordination digital data files.

a. Contracting Officer makes no representations as to accuracy or completeness of digital data files as they relate to Drawings.

b. Digital Data Software Program: Drawings are available in AutoCad.dwg.

D. Division 1 documents:

1. Letter designating Project Superintendent

2. Construction Schedule

3. A Comprehensive Schedule of Values

4. Accident Prevention Plan

5. A List of Subcontractors for this project

6. Written statements from Subcontractors certifying compliance with applicable labor standard clauses.

7. Certificates of Insurance and Standard Form SF1413 for Contactor and all Subcontractors

8. Waste Management Plan

9. Quality Control Plan

10. Under-An-Acre Pollution Prevention Plan (UPPP)

11. Indoor Air Quality (IAQ) Management Plan

12. Construction Contractor Commissioning Plan

13. Historic Preservation Treatment Plan (HPTP)

14. Archeological Protection Requirements

15. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit

b. Agency(ies) with Jurisdiction issuing the permit

c. Information required from Government to complete permit application

E. Provide items listed to Contracting Officer at least one week prior to Pre-Construction Conference, or as directed by Contracting Officer.

1. Failure to submit items may result in:

a. Construction conference may be cancelled, Notice to Proceed may not be issued, and Contracting Officer will consider other contractual remedies.

b. Work shall not commence until written Notice to Proceed has been issued and Certificates of Insurance and SF1413 documents are received for Construction Contractor and all Subcontractors.

FRSP 304741 01 31 00 - 5

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of Contract Documents, Construction Contractor shall prepare and submit an RFI utilizing form created on NPS project management and communication software.

1. Contracting Officer will not respond to RFIs submitted by other entities controlled by Construction Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of RFI: Include detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially

2. Date

3. RFI subject

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Construction Contractor's suggested resolution: If suggested resolution impacts Contract

Time or Contract Sum, Construction Contractor shall state impact in RFI.

8. Construction Contractor's signature

9. Requested date for response

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. RFI Form: Complete and submit on NPS project management and communication software.

D. Contracting Officer’s Action: Contracting Officer will review each RFI, determine action required, and respond. Contracting Officer will determine critical nature of each RFI and issue response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Construction Contractor's means and methods.

d. Requests for coordination information already indicated in Contract Documents.

e. Requests for adjustments in Contract Time or Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. Contracting Officer's action may include a request for additional information; time for response will date from time of receipt of additional information.

3. Contracting Officer's action on RFIs may result in need for a change to Contract Time or Contract Sum. All contract changes will be processed following terms and conditions of contract.

FRSP 304741 01 31 00 - 6

1.6 PROJECT MANAGEMENT AND COMMUNICATION SOFTWARE

A. Use to manage project communication and document sharing during contract period on:

1. Project directory

2. Project correspondence

3. Meeting agendas and minutes

4. Contract modifications forms and logs

5. RFI form and processing

6. Task and issue management

7. Photo documentation

8. Baseline schedule, schedule updates and calendar management

9. Submittal form and processing

10. Payment coordination documentation

11. Reminder and tracking functions

12. Archiving functions

13. Notification of submittal and RFI statuses and current responsible party

14. Permits and addendums

B. Some documents are not suitable to be shared using NPS project management and communication software. Documents containing Personal Identifying Information (PII) (i.e. certified payrolls) shall not be shared and shall be coordinated with project team as appropriate.

1.7 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Construction Contractor. Meeting agenda will include the following as a minimum:

1. Roles & Responsibilities / Lines of Authority

2. Park rules and regulations

3. Jobsite Safety

4. Resolution of comments on required Division 1 documents

5. Coordination of Subcontractors

6. Labor law application

7. Modifications

8. Payments to Construction Contractor

9. Payroll reports

10. Contract time

11. Liquidated damages

12. Construction Contractor Performance Evaluation

13. Display of Hotline posters

14. Notice to proceed

15. Correspondence procedures

16. NPS project management and communication software

17. Acceptance/rejection of work

18. Progress meetings

19. Submittal procedures

20. NPS Final Accessibility Inspection

21. Environmental requirements

FRSP 304741 01 31 00 - 7

22. Tree protection requirements

23. Archeological requirements

24. HPTP requirements

25. Permit requirements

26. As-constructed drawings/operation and maintenance (O&M) manuals.

27. Saturday, Sunday, holiday and night work.

28. Reference materials

29. Value engineering

30. Schedule of Values

31. Commissioning requirements

B. Progress Meetings: Contracting Officer will schedule weekly meetings with Construction Contractor.

1. Attendees: In addition to Government Representatives, each Construction Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented.

Participants at meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. Meeting agenda will include:

a. Approval of minutes of previous meetings

b. Submittal status

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections, Accessibility, etc.)

h. Construction Schedule update (provide updated Critical Path Method (CPM)).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements

C. Preinstallation Conferences: Conduct at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend meeting. Advise Contracting Officer of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for particular activity under consideration, including requirements for:

a. Contract Documents

b. Options

c. Related RFIs

d. Related Change Orders

e. Purchases

FRSP 304741 01 31 00 - 8

f. Deliveries

g. Submittals

h. Sustainable design requirements.

i. Review of mockups

j. Possible conflicts

k. Compatibility requirements

l. Time schedules

m. Weather limitations

n. Manufacturer's written instructions

o. Warranty requirements

p. Compatibility of materials

q. Acceptability of substrates

r. Temporary facilities and controls

s. Space and access limitations

t. Regulations of agency(ies) with jurisdiction

u. Testing and inspecting requirements

v. Installation procedures

w. Coordination with other work

x. Required performance results

y. Protection of adjacent work

z. Protection of construction and personnel

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if conference cannot be successfully concluded. Initiate whatever actions are necessary to resolve impediments to performance of Work and reconvene conference at earliest feasible date.

1.8 ENVIRONMENTAL COORDINATION

A. Construction Contractor’s Environmental Manager: Designate on-site party responsible for overseeing Construction Contractor’s conformance to environmental goals for project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to this project; familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of Waste Management Plan (WMP).

c. Implementation of Indoor Air Quality (IAQ) Management Plan.

d. Implementation of Under-An-Acre Pollution Prevention Plan (UPPP).

e. Present overview of environmental issues and summarize site specific procedures relating to management plans at Preconstruction conference.

f. Training for Construction Contractor personnel in accordance with position requirements.

FRSP 304741 01 31 00 - 9

g. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements

2. Regulatory Requirements

3. Indoor Air Quality (IAQ) Management

4. Noise and Acoustics Management

5. Under-An-Acre Pollution Prevention Environmental Management

6. Construction Waste Management

C. Construction Contractor’s Environmental Training Program: Construction Contractor shall provide environmental training for workers performing work on project site. Training shall include:

1. Overview of environmental issues related to building industry.

2. Overview of environmental issues related to Project.

3. Review of site-specific procedures and management plans:

a. Construction Waste Management

b. Indoor Air Quality (IAQ) Management

c. Noise and Acoustics Management

d. Under-An-Acre Pollution Prevention

4. Pollution Prevention (P2) practices: Submit evidence of familiarity with P2 practices.

5. Green Building Rating Programs: Submit evidence of familiarity with United States Green Building Council-Leadership in Energy and Environmental Design (USGBC-LEED).

6. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Construction Contractor 40 CFR (Code of Federal Regulations) employee training records upon request of Contracting Officer.

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, IAQ Management Plan, and Storm Water Pollution Prevention Plan.

1.9 PERMITS

A. General:

1. Permits and Responsibilities: Construction Contractor shall, without additional expense to the Government, be responsible for obtaining necessary licenses and permits, and for complying with Federal, State and municipal laws, codes, and regulations applicable to the performance of the work.