Attachment 1 - Solicitation.docx

Attachment 1 - Solicitation Terms and Conditions Solicitation Number:

Fruit Fly Shipper Boxes 12639526Q0075 Statement of Requirement

The United States Department of Agriculture (USDA), Animal Plant Health Inspection Service (APHIS), Plant Protection and Quarantine (PPQ), in Waimanalo, Hawaii, requires shipping boxes and inserts for emergency and preventative Medfly Projects

Technical data and supporting documentation associated with this solicitation are available through the following sources:

· Attachment 2 – Statement of Work

Delivery Information

F.o.b. destination, is requested as the F.O.B. point for all deliverables. All offers will be considered F.O.B. Destination unless F.O.B. origin is specified AND estimated shipping costs are included.

Award Type

The Government will award a firm fixed price indefinite delivery indefinite quantity commercial supply contract to the responsible quoter whose quotation, conforming to the solicitation, is the Best Value Evaluation Criteria The provision at FAR 52.212-2, Evaluation—Commercial Products and Commercial Services is not applicable to this solicitation. In lieu of this provision, quotes will be evaluated in accordance with FAR 12.203 based on the criteria listed below. Award will be made to the offeror representing the best value to the Government.

Price: Any quantity price discounts and discounts for prompt payment should be included in this section. The offeror shall provide pricing as requested in the attached spreadsheet titled “Price Schedule”. Any quantity price discounts and discounts for prompt payment should be included in this section. Total price evaluation will be for the base and all ordering periods and in accordance with FAR 52.217-8, up to a six-month extension period. Failure to propose pricing for the base period and all option periods on individual line items may result in a quotation being excluded from further consideration. The offeror’s quotation will be evaluated in accordance with FAR 12.204, to determine if it is fair and reasonable.

Technical Acceptability: The United States Department of Agriculture (USDA) has a requirement for the following items on a brand name or equal basis.

5,000

EA

5,000

EA

Offeror’s providing “or equal” items shall include in their quotation descriptive literature such as illustrations, drawings, or a clear reference, such as a web site to information readily available to the Contracting Officer showing that the items being quoted meets all salient characteristics. Merely stating that the items meet is not acceptable. The Contracting Officer is not responsible for locating or obtaining any information not identified in the offer.

The Technical capability will be evaluated to determine an overall rating of “acceptable” or “unacceptable”. To be considered technically acceptable, the quoted product must:

1. Meet or exceed all salient characteristics of the brand name product as specified in the solicitation.

2. Be clearly identified by brand name, make, and model number, or identified as an “equal” product.

3. Include sufficient descriptive literature or documentation (e.g., product specifications, datasheets, or brochures) to demonstrate how the proposed product meets or exceeds the required salient characteristics.

4. Be available for delivery within the timeframe specified in the solicitation.

Failure to provide adequate documentation or to meet the required salient characteristics will result in a determination of technical unacceptability, and the quotation will not be considered for award.

Evaluation Method:

The Government will evaluate quotations based on the lowest price technically acceptable criteria. Only the lowest priced offer will be evaluated for Technical Acceptability. Should the lowest priced offer not receive an acceptable technical or past performance rating, the process will continue in order of lowest priced offer until the lowest price, technically acceptable offer with acceptable or neutral past performance is identified

Federal Acquisition Regulation (FAR) and United States Department of Aquiculture Acquisition Regulation (AGAR) Clauses and Provisions

The clauses and provisions contained herein are applicable to any order awarded as a result of this solicitation. The terms and conditions set forth herein supersede all other terms and conditions. Acceptance of the order in accordance with (IAW) FAR 12.201-1(b)(2) constitutes acceptance of all terms and conditions contained herein.

As part of the Revolutionary FAR Overhaul (RFO), system updates may lag policy updates. The System for Award Management (SAM) may continue to require entities to complete representations based on provisions that are not included in this solicitation. Contracting officers will rely on representations from offers based on provisions in the solicitation. Entities are not required to, nor are they able to, update their entity registration to remove these representations in SAM.

52.252-1 Solicitation Provisions Incorporated by Reference Feb 1998 This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): https://www.acquisition.gov/far-overhaul/far-part-deviation-guide/far-overhaul-part-52

52.212-1 Instructions to Offerors - Commercial Products and Commercial Services (Nov 2025)

FAR 52.212-1 is amended as follows:

Period for acceptance of offers.

The Offeror agrees to hold the prices in its offer firm for 90 calendar days from the date specified for receipt of offers.

Questions Questions shall be submitted via email to linda.w.washington@usda.gov and are due no later than April 8, 2026, at 1:00 PM Eastern Standard Time. This will ensure enough time to respond before the solicitation period ends. Please include the solicitation name and number as the subject line of the email.

The following provisions are applicable if checked:

☐ Alternate I (Nov 2025) to 52.204-7

AGAR Provisions Until we have the AGAR posted in its entirety on a public facing site, you will need to include AGAR provisions and clauses in full text. There are additional new provisions in RFO AGAR, so be sure to check for any that may be required for your solicitation. This template will be updated as things change through the RFO process.

52.252-2 Clauses Incorporated by Reference Feb 1998 This solicitation incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also the full text of the clause may be accessed electronically at Internet address https://www.acquisition.gov/far-overhaul/far-part-deviation-guide/far-overhaul-part-52

☐ Alternate I (Nov 2025) of 52.222-50

☐ Alternate I (Nov 2025) of 52.240-91 52.244-6 Subcontracts for Commercial Products and Commercial Services (Nov 2025)

The following provisions are applicable if checked: .

☐ 52.203-6 Restrictions on Subcontractor Sales to the Government (Jun 2020) ☐ Alternate I (Nov 2021) of 52.203-6

☐ Alternate I (Mar 2020).

☐ Alternate I (Nov 2025) of 52.219-9.

☐ Alternate II (Nov 2025) of 52.219-9.

☐ Alternate III(Nov 2025) of 52.219-9.

☐ Alternate IV (Nov 2025) of 52.219-9

☐ Alternate I (Jul 2014) of 52.222-35 ☐ 52.222-36 Equal Opportunity for Workers with Disabilities (Nov 2025) ☐ Alternate I (Jul 2014) of 52.222-36

☐ Alternate I (May 2008) of 52.223-9

☐ Alternate I (Jan 2017) of 52.224-3 ☒ 52.225-1 Buy American-Supplies (Nov 2025) ☐ Alternate I (Oct 2022) of 52.225-1 ☐ 52.225-3 Buy American--Free Trade Agreements--Israeli Trade Act (Nov 2025) ☐ Alternate II (Nov 2025) of 52.225-3.

☐ Alternate III (Nov 2025) of 52.225-3.

☐ Alternate IV (Oct 2022) of 52.225-3

☐ Alternate II (Nov 2025) of 52.240-92 ☐ 52.247-64 Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2025) ☐ Alternate I (Apr 2023) of 52.247-64.

☐ Alternate II (Nov 2021) of 52.247-64

Other Applicable Clauses

Add any other clauses that apply to this procurement. Consider Parts 16, 17, 27, 39, 36, 45, 47, etc. Some common clauses are (this is not an inclusive list):

AGAR Clauses Until we have the AGAR posted in its entirety on a public facing site, you will need to include AGAR provisions and clauses in full text. Text in black is a required clause. There are additional new clauses in RFO AGAR, so be sure to check for any that may be required for your solicitation. This template will be updated as things change through the RFO process.

452.204–70 Modification for Contract Closeout (Nov 2025)

(a) If unliquidated funds in the amount of $1000 or less remain on the contract, the Contracting Officer (Contracting Officer) shall issue a unilateral modification for deobligation. The contractor will receive a copy of the modification but will not be required to provide a signature. The Contracting Officer shall immediately proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

(b) Upon contract closeout for contracts utilizing SAP: if unliquidated funds of more than $1000 remain on the contract, the Contracting Officer shall issue a bilateral modification for deobligation. The contractor will receive a copy of the modification and will be required to provide a signature. (The Contracting Officer may also request a “Contractor Release of Claims” be completed by the contractor, although not required for contracts and orders using SAP.) If the bilateral modification and Release of Claims are not returned to the Contracting Officer within 60 days, the Contracting Officer shall release the modification as unilateral and proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

(c) Upon contract closeout for contracts utilizing anything other than cost reimbursement, if unliquidated funds of more than $1000 remain on the contract, the Contracting Officer shall issue a bilateral modification for deobligation. The contractor will receive a copy of the modification and a ‘‘Contractor Release of Claims’’ and will be required to provide a signature on both forms. If the bilateral modification and Release of Claims are not returned to the Contracting Officer within 120 days, the Contracting Officer shall release the modification as unilateral and proceed with contract closeout upon completion of the period of performance, receipt and acceptance of supplies or services, and final payment.

(End of Clause)

452.204-71 Personal Identity Verification of Contractor Employees (Nov 2025)

(a) The contractor shall comply with the personal identity verification (PIV) policies and procedures established by the United States Department of Agriculture (USDA) Directives 4620-002 series.

(b) Should the USDA Directives 4620-002 require the exclusion of a contractor's employee, the contracting officer will notify the contractor in writing. The contractor must appoint a representative to manage compliance with the PIV policies established by the USDA Directives 4620-002 and to maintain a list of employees eligible for a USDA LincPass required for performance of the work.

(c) The responsibility of maintaining a sufficient workforce remains with the contractor. Contractor employees may be barred by the Government from performance of work should they be found ineligible or to have lost eligibility for a USDA LincPass. Failure to maintain a sufficient workforce of employees eligible for a USDA LincPass may be grounds for termination of the contract.

(d) The contractor shall insert this clause in all subcontracts when the subcontractor is required to have routine unaccompanied physical access to a Federally controlled facility and/or routine unaccompanied access to a Federally controlled information system.

(e) The PIV Sponsor for this contract is a designated program point of contact, which in most cases is the COR, unless otherwise specified in this contract. The PIV Sponsor will be available to receive contractor identity information from [hours and days to be added by CO] to [hours and days to be added by CO] at [office address for registration to be added by CO]. The Government will notify the contractor if there is a change in the PIV Sponsor, the office address, or the office hours for registration; however, it is the contractor's responsibility to meet all aspects of paragraphs (c), (d), and (e).

(End of Clause)

452.211-72 Delivery of Excess Quantities (Sep 2025) The Contractor must deliver item quantities within allowable variations. Excess quantities received by the Government are considered delivered for the Contractor's convenience. The Government may keep excess quantities up to $250 in value without compensating the Contractor therefor, and the Contractor waives all rights, title, or interests therein. For excess quantities over $250, the Government may return the items at the Contractor’s expense or retain and pay at the contract unit price.

(End of clause)

452.211-73 Variation in Estimated Quantity (Sep 2025) If the actual quantity of a unit-priced item varies by more than 15% from the estimated quantity, either party may request an equitable adjustment in the contract price. The adjustment will be based on cost changes due to variations above 115% or below 85% of the estimated quantity. If this variation delays completion, the Contractor may request a time extension in writing. The request must be received by the Contracting Officer within 10 days of the delay's start or within such further period granted by the Contracting Officer before the final contract settlement. The Contracting Officer will review the request and, if justified, extend the completion date.

(End of clause)

NOTICE FOR FILING AGENCY PROTESTS

United States Department of Agriculture (USDA) Ombudsman Program

The USDA is committed to issuing solicitations and awarding contracts in a fair and prompt manner. The Ombudsman Program for Agency Protests (OPAP) was established to address protest issues within the agency, providing an alternative to costly and time-consuming litigation. Operating independently, OPAP offers relief comparable to that granted by the Government Accountability Office (GAO). Interested parties are encouraged to resolve concerns through USDA’s internal Alternative Dispute Resolution (ADR) process before pursuing external forums such as the GAO. Concerns may be addressed informally or through a formal agency protest filed with either the Contracting Officer or the Ombudsman.

Informal Forum with the Ombudsman

1. Initial Point of Contact: Interested parties who believe a specific USDA procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer.

2. Escalation: If the Contracting Officer is unable to address their concerns, interested parties are encouraged to contact the USDA Ombudsman for Agency Protests. Under this informal process, the agency is not required to suspend contract award performance. Utilization of the informal forum does not suspend any time requirement for filing a formal protest with the agency or other forums.