Attachment 1 - Schedule of Items.pdf
PDF 624 KB Posted
- Solicitation number
- 1240LU26Q0065
- Issued by
-
Department of Agriculture Forest Service
About this file
This is a Schedule of Items pricing template for a federal construction contract involving well drilling services at the Salmon River Seed Orchard on the Nez Perce-Clearwater National Forests in Idaho County, Idaho. The document is designated FAC 2025-04 with an effective date of June 11, 2025.
The base contract includes 13 line items for well drilling and associated work, with quantities and units specified for pricing. Base items include mobilization (1 LS), sediment control (1 LS), drilling permit (1 EA), drilling services in two diameters (38 LF of 12" drilling and 264 LF of 10" drilling), steel casing installation (38 LF of 10" outer casing and 152 LF of 6" casing), PVC well casing (282 LF of 4" diameter), PVC well screen (20 LF), temporary well cap (1 EA), grouting (38 LF), yield and drawdown testing (72 HRS), chemical water analysis (1 LS), and bacteriological testing (1 EA). Four optional items are included: Option 1 covers Priority 2 Well Drilling & Development (300 LF) and Abandon Priority 1 Well (300 LF); Option 2 covers Abandon Priority 2 Well (300 LF); Option 3 covers evaluation and proposal for connection from the new well to the personnel building (1 LS); and Option 4 covers a lump sum proposal to address items identified in Option 3 (1 LS). Optional Items 1 and 2 may be exercised only if well drilling fails to produce water and before the period of performance completion date, while Optional Items 3 and 4 may be exercised on or before May 1, 2027. The schedule requires contractors to submit pricing for all items, with one award to be made from the solicitation.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
FAC 2025-04 June 11, 2025
SCHEDULE OF ITEMS
SALMON RIVER SEED ORCHARD WELL DRILLING
NEZ PERCE-CLEARWATER NATIONAL FORESTS IDAHO
COUNTY, IDAHO
SCHEDULE OF ITEMS
Pay Item Number Item
Qty Unit of Issue
Unit Price Total Price
2010.4.1.A.1 Mobilization 1 LS $ $ 1001.4.1.A.1 Sediment Control 1 LS $ $
SP
2100.4.1.A Drilling Permit 1 EA $ $
SP
2100.4.1.B 12” Drilling 38 LF $ $
SP
2100.4.1.C 10” Drilling 264 LF $ $
SP
2100.4.1.D 10” Diameter Outer Steel Casing 38 LF $ $
SP
2100.4.1.E 6” Diameter Steel Well Casing 152 LF $ $
SP
2100.4.1.F 4” Diameter PVC Well Casing 282 LF $ $
SP
2100.4.1.G PVC Well Screen 20 LF $ $
SP
2100.4.1.H 6” Temporary Well Cap 1 EA $ $
SP
2100.4.1.I Grouting 38 LF $ $
SP
2100.4.1.J Testing For Yield And Drawdown 72 HRS $ $
SP
2100.4.1.K Chemical Analysis Of Water 1 LS $ $
SP
2100.4.1.L Bacteriological Test 1 EA $ $
TOTAL BASE
PRICE
OPTIONAL ITEM 1
SP
2100.4.1.M Priority 2 Well Drilling &
Development
300 LF $ $
SP
2100.4.1.N Abandon Priority 1 Well 300 LF $ $
TOTAL OPTION 1
PRICE
OPTIONAL ITEM 2
SP
2100.4.1.O
Abandon Priority 2 Well 300 LF $ $
TOTAL OPTION 2
PRICE
OPTIONAL ITEM 3
SP
2100.4.1.P
Evaluate and Propose Connection from new well to the personnel building
1 LS $ $
TOTAL OPTION 3
PRICE
OPTIONAL ITEM 4
SP
2100.4.1.Q
Lump sum proposal to address items identified in Option 3.
1 LS $ $
TOTAL OPTION 4
PRICE
Phone ( )
Price quotation furnished by:
Name
Address ___________________________________
UEI#______________________________________ Signature______________________
SCHEDULE NOTES
a) Items labeled as optional items are not required to be exercised by the government. If exercised, the contractor will be required to perform the optional work in accordance with the terms and conditions of this contract. Optional Items 1 and 2 may be exercised before the end of the period of performance completion date and only if well drilling fails to produce water. Optional Items 3 and 4 may be exercised on or before 05/01/2027.
b) One award will be made from this solicitation; contractors must submit pricing for all items.
| 1240LU25Q0037 (1) |
| 0- Solicitation 1240LU25Q0037 Salmon River Seed Orchard Well Drilling |
| SECTION B--SUPPLIES OR SERVICES AND PRICES/COSTS |
| SALMON RIVER SEED ORCHARD WELL DRILLING |
| NEZ PERCE-CLEARWATER NATIONAL FORESTS |
| IDAHO COUNTY, IDAHO |
| B.1 SCHEDULE OF ITEMS |
| B.2 SCHEDULE NOTES |
| SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK |
| C.1 SCOPE OF CONTRACT |
| C.2 PROJECT LOCATION |
| C.3 MAGNITUDE OF CONSTRUCTION PROJECT |
| C.4 SITE VISIT |
| C.5 PERIOD OF PERFORMANCE |
| C.6 GOVERNMENT-FURNISHED PROPERTY |
| No government-furnished property will be provided. |
| C.7 DRAWINGS (Entitled “Salmon River Seed Orchard Well Construction Drawings”) |
| The following drawings are a part of this solicitation and any resulting contract: |
| SECTION D--PACKAGING AND MARKING |
| D.1 PACKING AND MARKING |
| D.2 PROJECT LABELING FOR OFFICIAL CORRESPONDENCE |
| SECTION E--INSPECTION AND ACCEPTANCE |
| E.1 CLAUSES |
| SECTION F--DELIVERIES OR PERFORMANCE |
| F.1 CLAUSES |
| SECTION G--CONTRACT ADMINISTRATION DATA |
| G.1 CLAUSES |
| G.2 OTHER REQUIREMENTS |
| PART II--CONTRACT CLAUSES |
| SECTION I--CONTRACT CLAUSES |
| I.1 CLAUSES |
| PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS |
| SECTION J--LIST OF ATTACHMENTS |
| J.1 ATTACHMENTS |
| PART IV--REPRESENTATIONS AND INSTRUCTIONS |
| SECTION K--REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF OFFERORS OR RESPONDENTS |
| K.1 PROVISIONS |
| K.2 OTHER STATEMENTS OF OFFERORS OR RESPONDENTS |
| SECTION L--INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS OR RESPONDENTS |
| L.1 PROVISIONS |
| L.2 QUOTE PREPARATION INSTRUCTIONS: |
| SECTION M-- EVALUATION FACTORS FOR AWARD |
| M.1 QUOTE EVALUATION |
| Quotes will be evaluated using a best value approach. This allows the Government to accept other than the lowest priced quotes. The Government may perform a comparative evaluation (comparing offers to each other) to select the contractor that provides... |
| M.2 TECHNICAL EVALUATION FACTORS |
| Factor 1. Past Performance |
| Past performance is a measure of the degree to which the offeror (including major subcontracts) has satisfied previous customers and complied with Federal, State and Local laws and regulations. The Government may contact references to assess the quali... |
| The Government will consider the currency and relevance of the information, source of the information, context of the data and general trends in contractor performance. The Government shall consider this information, as well as information obtained fr... |
| Factor 2. Relative Experience |
| The Government will assess the specialized experience and skill of the firm with a focus on experience that is relevant to the specified project. |
| Factor 3. Price |
| The proposed price will be evaluated for reasonableness and will be weighed in conjunction with the technical factors to determine the proposal offering the best value to the government. |
File details come from the government source that posted it. Updated .