Att9_230053_Liquidated Damages Spreadsheet.pdf
PDF 102 KB Posted
- Solicitation number
- FA813726R0023
About this file
This is a Liquidated Damages assessment document for federal contract WWYK230053, titled "REPLACE Vault and Fuel Tank, B3202." The document establishes daily liquidated damages of $227.75 per calendar day for any delays in completing work on this contract/delivery order, in accordance with FAR 36.206 and DFARS 236.206.
The liquidated damages calculation comprises two components: Engineering costs totaling $122.36 per day, which include 0.5 hours each for an Engineering Manager ($28.85) and Project Engineers ($19.23), 1 hour each for a Project Manager ($36.06) and Engineering Tech/Inspector ($28.52), and 0.5 hours for Clerical support ($9.71); and Government costs totaling $105.39 per day, consisting of 0.5 hours for FAS (GS-12/5) at $19.60, 1 hour for Legal (GS-13/5) at $46.60, and 1 hour for Contracting (GS-12/5) at $39.19. The assessment is based on the contractor's complete control of work pace, the contract's provision for daily delay penalties, and the reasonableness of the established rate. The document was signed by Contracting Officer Sara Hinds on April 21, 2026.
View the file
Other files
Show all 18
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PROJECT NUMBER & TITLE: WWYK230053 REPLACE Vault and Fuel Tank, B3202
FACILITY/USER DAMAGES Impact / Day Daily Consideration of Delivery Extension -$
ENGINEERING TITLE Hrs RATE TOTAL Engineering Manager 0.5 57.69$ 28.85$ Project Manager 1 36.06$ 36.06$ Engineering Tech, Inspector 1 28.52$ 28.52$ Project Engineers 0.5 38.46$ 19.23$ Clerical 0.5 19.41$ 9.71$
SUBTOTAL 122.36$
GOVERNMENT TITLE Hrs RATE TOTAL
FAS (GS-12/5) 0.5 39.19$ 19.60$
Legal (GS-13/5) 1 46.60$ 46.60$ Contracting (GS-12/5) 1 39.19$ 39.19$
SUBTOTAL 105.39$
TOTAL AMOUNT OF LIQUIDATED DAMAGES PER DAY - PHASE 1 227.75$
Contracting Officer (Signature)
Contracting Officer (Print)
Date:
LIQUIDATED DAMAGES
In accordance with FAR 36.206 and DFARS 236.206, liquidated damages (LDs) will be assessed for each calendar day of delay required to complete work on the subject contract/delivery order. As a minimum, LDs in the amount of $227.75 for each day thereafter will be changed based upon the following:
a. The contractor has complete control of the pace of work.
b. The contract provides for LDs for delay of work for each calendar day of the contract.
c. Considering the requirement, the rate of assessment is reasonable.
Sheet1
| 2026-04-21T12:20:36-0500 | |
| HINDS.SARA.MUSE.1150957075 |
| Contracting Officer Print: Sara Hinds |
| Date: 4/21/26 |
File details come from the government source that posted it. Updated .