Att_02_Specifications.pdf

CRATER LAKE NATIONAL PARK

REPLACE PARK GUARDRAILS

PMIS No. 239775

CONSTRUCTION SPECIFICATIONS

NATIONAL PARK SERVICE

PACIFIC WEST REGION

July 2021

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 26 01 Contract Modification Procedures 01 27 00 Definition of Contract Line Items 01 31 00 Project Management & Coordination 01 31 00a RFI Form 01 32 16 Construction Schedule 01 33 23 Submittal Procedures 01 33 23a CM16 - Transmittal 01 35 25 Safety Requirements 01 40 00 Quality Requirements 01 40 00a Daily Inspection Form 01 42 00 Reference Standards 01 73 40 Execution 01 77 00 Closeout Procedures

PLANS

TOC-1

CRLA 239775 01 11 00 - 1

012721 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes the following:

1. Work Covered by Contract Documents

2. Work Under Other Contracts

3. Government-Furnished Materials

4. Contractor Use of Site

5. Public Use of Site

6. Occupancy Requirements for Buildings

7. Conduct of Operations

8. Work Restrictions

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Various roadway locations throughout Crater Lake National Park. See plan sheets.

B. This project consists of repairing and replacing segments of highway guardrail within the park boundary. The existing guardrails have areas of damage and/or lifecycle wear. Several segments are non-compliant with existing safety standards.

C. Project will be constructed under a single prime contract.

1.3 WORK UNDER OTHER CONTRACTS

A. General: Cooperate with separate contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate Work of this Contract with work performed under separate contracts.

1.4 GOVERNMENT-FURNISHED MATERIALS

A. In case of Government -furnished materials:

1. Government will arrange and pay for delivery of Government-furnished items according to Contractor's Construction Schedule.

2. Contractor is responsible for initial inspection, receiving, unloading, and handling Government-furnished items at Project site.

3. Government will inspect delivered items for damage after delivery. Contractor shall be present for and assist in Government's inspection.

4. Government will arrange for replacement if Government-furnished items are damaged, defective, or missing.

CRLA 239775 01 11 00 - 2

5. Contractor is responsible for protecting Government-furnished items from damage during storage and handling, including damage from exposure to the elements.

6. If Government-furnished items are damaged as a result of Contractor's operations, Contractor shall repair or replace them.

7. Contractor shall install and otherwise incorporate Government-furnished items into Work.

B. Government-Furnished Materials:

1. None

1.5 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of site for construction operations. Limit use of premises to work in areas indicated on drawings. Do not disturb portions of Project site beyond areas in which the Work is indicated.

B. Storage of Materials: Confine storage of materials to areas within the work limits

C. Parking: Confine parking to existing parking within the park

D. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with

Contracting Officer (CO) and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

E. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to Government employees, and emergency vehicles at all times. Do not use for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

F. Construction Camp: Establishment of a camp within park will not be permitted.

G. Hauling Restrictions: Comply with legal load restrictions in hauling of materials. Load restrictions on park roads are identical to state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

CRLA 239775 01 11 00 - 3

H. Bridge Restrictions: Identify jurisdictions, load restrictions, permit requirements, time and calendar restrictions as outlined.

1.6 CONDUCT OF OPERATIONS

A. Contractor shall conduct his operations in conformance with rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed unless stated in the Work Restrictions below or without prior consent from the Contracting Officer. Submit requests 3 business days in advance of the work to the Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.7 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 8:00 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than two business days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

D. Nonsmoking Building/Tobacco Use/Vaping: Smoking is not permitted within building or within 25 feet of entrances, operable windows, or outdoor air intakes. Smoking is prohibited when fire restrictions are in place.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

CRLA 239775 01 26 01 - 1

012721 CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with preparation of modifications will not be allowed. Costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager (PM), Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

6. Scheduling

CRLA 239775 01 26 01 - 2

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: Costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate.

The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on project site. Modification costs for salaried workers are only allowed within the structure of a 40-hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: The hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens; includes insurance and taxes the business must pay on behalf of the worker to government entities and educational forums, such as:

1) Social Security

2) Medicare

3) Workers Compensation – Policy and company calculation to be made available.

4) Federal Unemployment Tax Act (FUTA) - Cap Rate and percentage to be proportionally allocated over one year.

5) State Unemployment Tax Act (SUTA) - Cap Rate and percentage to be proportionally allocated over one year.

CRLA 239775 01 26 01 - 3

6) Union agreement costs - Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects Contractor from claims resulting from bodily injury or property damage to a third party. Include as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees the Contractor will pay the labor and material costs incurred. Banks and Insurance companies charge a premium for individual project based on a sliding scale related to the size of the project.

Include as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: Covers the contractor’s loss due to fire, high winds, or other natural forces. Not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Proposal be received in the format and within the time frame specified in the Request for Proposal (RFP) letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. Proposal shall be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed they are included in the hourly rate shown, or contractor is not requesting reimbursement. Contractor may utilize the government provided Contractor Estimate Form, or their own form, provided that it contains the same information and level of detail as the Government’s form.

http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank http://www.nps.gov/dscw/publicforms.htm#CP___PAGEID=396735|

CRLA 239775 01 26 01 - 4

3. Requests for extensions of contract time as a result of change must be justified with a Time Impact Analysis (TIA). Refer to Section 01 32 16 "Construction Schedule", for time impact analysis requirements. TIA and associated costs shall be received with the proposal by the date shown within the Request for Proposal letter. Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer (CO) upon request.

5. Contractor shall review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing hours required for each craft directly engaged in modification work. Any work proposed requiring overtime work or premium pay shall be itemized separately. Rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, Federal Insurance Contributions Act (FICA), FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. Labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. Estimated cost for materials shall include quotes from multiple sources. Material prices shall include applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for work being performed.

2. Do not include costs for "miscellaneous tools and equipment", in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 shall be broken out separately.

3. Regardless of ownership, rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. United States (U.S.) Army Corps of Engineers, Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

CRLA 239775 01 26 01 - 5

4. Estimated equipment rates shall include operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires and tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per Federal Acquisition Regulation (FAR) 31.105(d)(2)), depreciation, storage, insurance, and all incidentals. Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate full rate for equipment only for duration that equipment will be utilized to accomplish work of the modification.

6. Standby unit rates used in accordance with paragraph 1.3, D, 2, above. If the U.S. Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then 1/2 of equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, established standby rate shall apply from the first day of the delay.

8. Equipment not used and on job site for up to five consecutive days may be classified at standby rates, provided the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work.

Equipment still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 012601

CRLA 239775 01 27 00 - 1

012721 DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

1.1 SUMMARY

A. This section explains in general, what is and is not included in a contract line item, and limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of work, include costs in a related item.

PART 2 - PRODUCTS

PART 3 - EXECUTION

3.1 BASE BID CONTRACT LINE ITEMS

A. The Base Bid locations include areas described as Elephant Back and Annie Falls PA.

B. Contract Line Item Number 0001: Mobilization and Demobilization

1. This item consists of mobilizing and demobilizing equipment and personnel to the site.

2. This line item is only included with the base bid. No additional payment shall be made for mobilization related to the award of bid options.

3. Measurement for payment will be on a lump sum basis.

C. Contract Line Item Number 0002: Remove Guardrails & Posts

1. This item consists of removing existing guardrail, and guardrail posts and components, at the described locations.

2. Measurement for payment will be on a lump sum basis.

D. Contract Line Item Number 0003: Install Guardrail Posts

1. This item consists of installing standard (center) guardrail posts at the described locations.

2. Measurement for payment will be on a lump sum basis.

E. Contract Line Item Number 0004: Install Guardrail

1. This item consists of installing standard (center) guardrail, blocking, and miscellaneous components at the described locations.

2. Measurement for payment will be on a linear foot basis not to exceed the listed linear footage.

F. Contract Line Item Number 0005: Install End Treatments - LST

1. This item consists of installing guardrail end treatments at the described locations. The type of treatment shall be as shown in the plans.

CRLA 239775 01 27 00 - 2

2. Measurement for payment shall be on a per unit basis and shall include all components required to construct the proposed end treatment including, posts, blocks, beams, anchors, bracing, end sections, and all other components to construct the end treatment as shown in the plans.

G. Contract Line Item Number 0006: Traffic Control

1. This item consists of providing traffic control in accordance with the plans.

2. Measurement for payment shall be on a lump sum basis.

3.2 BID OPTION A LINE ITEMS

A. Bid Option A locations include areas described as Corkscrew Lower and Upper.

B. Contract Line Item Number A001: Remove Guardrails & Select Posts

1. This item consists of removing existing guardrail and select guardrail posts and component at the described locations. Select posts are those that are determined to be in need of replacement up to 20 percent of existing. This item also includes removing all posts within the existing end treatment areas.

2. Measurement for payment will be on a lump sum basis.

C. Contract Line Item Number A002: Install Select Guardrail Posts

1. This item consists of installing select standard (center) guardrail posts at the described locations. Posts to be replaced include those that were removed.

2. Measurement for payment will be on a lump sum basis.

D. Contract Line Item Number A003: Install Guardrail

1. This item consists of installing standard (center) guardrail, blocking, and miscellaneous components at the described locations.

2. Measurement for payment will be on a linear foot basis not to exceed the listed linear footage.

E. Contract Line Item Number A004: Install End Treatments – Parabolic Flare

1. This item consists of installing guardrail end treatments at the described locations. The type of treatment shall be as shown in the plans.

2. Measurement for payment shall be on a per unit basis and shall include all components required to construct the proposed end treatment including, posts, blocks, beams, anchors, bracing, end sections, and all other components to construct the end treatment as shown in the plans.

F. Contract Line Item Number A005: Traffic Control

CRLA 239775 01 27 00 - 3

3.3 BID OPTION B LINE ITEMS

A. Bid Option B locations include areas described as First Guiderail.

B. Contract Line Item Number B001: Remove Guardrails & Select Posts

1. This item consists of removing existing guardrail and select guardrail posts and component at the described locations. Select posts are those that are determined to be in need of replacement up to 20 percent of existing. This item also includes removing all posts within the existing end treatment areas.

2. Measurement for payment will be on a lump sum basis.

C. Contract Line Item Number B002: Install Select Guardrail Posts

1. This item consists of installing select standard (center) guardrail posts at the described locations. Posts to be replaced include those that were removed.

2. Measurement for payment will be on a lump sum basis.

D. Contract Line Item Number B003: Install Guardrail

1. This item consists of installing standard (center) guardrail, blocking, and miscellaneous components at the described locations.

2. Measurement for payment will be on a linear foot basis not to exceed the listed linear footage.

E. Contract Line Item Number B004: Install End Treatments – Parabolic Flare

1. This item consists of installing guardrail end treatments at the described locations. The type of treatment shall be as shown in the plans.

2. Measurement for payment shall be on a per unit basis and shall include all components required to construct the proposed end treatment including, posts, blocks, beams, anchors, bracing, end sections, and all other components to construct the end treatment as shown in the plans.

F. Contract Line Item Number B005: Traffic Control

1. This item consists of providing traffic control in accordance with the plans.

2. Measurement for payment shall be on a lump sum basis.

3.4 BID OPTION C LINE ITEMS

A. Bid Option A locations include areas described as Big Tree Upper & Lower.

B. Contract Line Item Number C001: Remove Guardrails & Select Posts

1. This item consists of removing existing guardrail and select guardrail posts and component at the described locations. Select posts are those that are determined to be in need of replacement up to 20 percent of existing. This item also includes removing all posts within the existing end treatment areas.

2. Measurement for payment will be on a lump sum basis.

C. Contract Line Item Number C002: Install Select Guardrail Posts

CRLA 239775 01 27 00 - 4

1. This item consists of installing select standard (center) guardrail posts at the described locations. Posts to be replaced include those that were removed.

2. Measurement for payment will be on a lump sum basis.

D. Contract Line Item Number C003: Install Guardrail

1. This item consists of installing standard (center) guardrail, blocking, and miscellaneous components at the described locations.

2. Measurement for payment will be on a linear foot basis not to exceed the listed linear footage.

E. Contract Line Item Number C004: Install End Treatments – Parabolic Flare

1. This item consists of installing guardrail end treatments at the described locations. The type of treatment shall be as shown in the plans.

2. Measurement for payment shall be on a per unit basis and shall include all components required to construct the proposed end treatment including, posts, blocks, beams, anchors, bracing, end sections, and all other components to construct the end treatment as shown in the plans.

F. Contract Line Item Number C005: Traffic Control

1. This item consists of providing traffic control in accordance with the plans.

2. Measurement for payment shall be on a lump sum basis.

3.5 BID OPTION D LINE ITEMS

A. Bid Option D locations include areas described as Annie Falls.

B. Contract Line Item Number D001: Remove Guardrails & Select Posts

1. This item consists of removing existing guardrail and select guardrail posts and component at the described locations. Select posts are those that are determined to be in need of replacement up to 20 percent of existing. This item also includes removing all posts within the existing end treatment areas.

2. Measurement for payment will be on a lump sum basis.

C. Contract Line Item Number D002: Install Select Guardrail Posts

1. This item consists of installing select standard (center) guardrail posts at the described locations. Posts to be replaced include those that were removed.

2. Measurement for payment will be on a lump sum basis.

D. Contract Line Item Number D003: Install Guardrail

1. This item consists of installing standard (center) guardrail, blocking, and miscellaneous components at the described locations.

2. Measurement for payment will be on a linear foot basis not to exceed the listed linear footage.

E. Contract Line Item Number D004: Install End Treatments – Parabolic Flare

CRLA 239775 01 27 00 - 5

1. This item consists of installing guardrail end treatments at the described locations. The type of treatment shall be as shown in the plans.

2. Measurement for payment shall be on a per unit basis and shall include all components required to construct the proposed end treatment including, posts, blocks, beams, anchors, bracing, end sections, and all other components to construct the end treatment as shown in the plans.

F. Contract Line Item Number D005: Traffic Control

1. This item consists of providing traffic control in accordance with the plans.

2. Measurement for payment shall be on a lump sum basis.

3.6 BID OPTION E LINE ITEMS

A. Bid Option A locations include areas described as Old South.

B. Contract Line Item Number E001: Remove Guardrails & Select Posts

1. This item consists of removing existing guardrail and select guardrail posts and component at the described locations. Select posts are those that are determined to be in need of replacement up to 20 percent of existing. This item also includes removing all posts within the existing end treatment areas.

2. Measurement for payment will be on a lump sum basis.

C. Contract Line Item Number E002: Install Select Guardrail Posts

1. This item consists of installing select standard (center) guardrail posts at the described locations. Posts to be replaced include those that were removed.

2. Measurement for payment will be on a lump sum basis.

D. Contract Line Item Number E003: Install Guardrail

1. This item consists of installing standard (center) guardrail, blocking, and miscellaneous components at the described locations.

2. Measurement for payment will be on a linear foot basis not to exceed the listed linear footage.

E. Contract Line Item Number E004: Install End Treatments – Parabolic Flare

1. This item consists of installing guardrail end treatments at the described locations. The type of treatment shall be as shown in the plans.

2. Measurement for payment shall be on a per unit basis and shall include all components required to construct the proposed end treatment including, posts, blocks, beams, anchors, bracing, end sections, and all other components to construct the end treatment as shown in the plans.

F. Contract Line Item Number E005: Traffic Control

CRLA 239775 01 31 00 - 1

012721 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination

3. Submittals

4. Coordination Drawings

5. Requests for Information (RFIs)

6. Project Meetings

7. Environmental Coordination

8. Permits

B. Related Requirements:

1. Section 01 32 16 "Construction Schedule" for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 "Execution" for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 "Closeout Procedures" for coordinating closeout of the Contract.

1.2 DEFINITIONS

A. Agency with Jurisdiction B. Construction Permits – Contractor Provided C. Government Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make provisions to accommodate items scheduled for later installation.

http://www.nps.gov/dscw/definitionsdc_a.htm#awj http://www.nps.gov/dscw/definitionsdc_c.htm#cpcp http://www.nps.gov/dscw/definitionsdc_g.htm#gfperm

CRLA 239775 01 31 00 - 2

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to:

1. Preparation of Contractor's Construction Schedule

2. Preparation of the Schedule of Values

3. Installation and removal of temporary facilities and controls

4. Delivery and processing of submittals

5. Progress meetings

6. Permit requirements

7. Pre-installation conferences

8. Project closeout activities

9. Commissioning activities

1.4 SUBMITTALS

A. Coordination Drawings: Prepare Coordination Drawings if limited space availability necessitates maximum utilization of space for efficient installation of different components or if coordination is required for installation of products and materials fabricated by separate entities.

1. Content: Project-specific information, drawn accurately to scale. Do not base Coordination Drawings on reproductions of Contract Documents or standard printed data. Include following information, as applicable:

a. Indicate functional and spatial relationships of components of architectural, structural, civil, mechanical, and electrical systems.

b. Indicate dimensions shown on Contract Drawings and make specific note of dimensions that appear to be in conflict with submitted equipment and minimum clearance requirements. Provide alternate sketches to Contracting Officer (CO) for resolution of such conflicts.

c. Indicate space requirements for routine maintenance and anticipated replacement of components during the life of the installation.

d. Show location and size of access doors required for access to concealed dampers, valves, and controls.

e. Indicate required installation sequences.

B. Division 1 documents: The following items shall be submitted a minimum of one week prior to Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for Pre- Construction Conference.

CRLA 239775 01 31 00 - 3

1. Letter designating Project Superintendent

2. Construction Schedule

3. A Comprehensive Schedule of Values

4. Accident Prevention Plan

5. A List of Subcontractors for this project

6. Written statements from Subcontractors certifying compliance with applicable labor standard clauses.

7. Certificates of Insurance or SF1413 for Contactor and all Subcontractors

8. Quality Control Plan

9. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit

b. Agency(ies) with Jurisdiction issuing the permit

c. Information required from Government to complete permit application

C. Provide items listed to Contracting Officer before Pre-Construction Conference. If all documents have not been received one week prior to scheduled Pre-Construction Conference date, conference may be cancelled, Notice to Proceed may not be issued, and Contracting Officer will consider other contractual remedies. Work shall not commence until written Notice to Proceed has been issued.

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of Contract Documents, Contractor shall prepare and submit an RFI utilizing form created on NPS/DSC management software website.

1. Contracting Officer will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of RFI: Include detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially

2. Date

3. RFI subject

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution: If Contractor's suggested resolution impacts Contract

Time or Contract Sum, Contractor shall state impact in RFI.

8. Contractor's signature

9. Requested date for response

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

CRLA 239775 01 31 00 - 4

C. RFI Form: Complete RFI Form on NPS/DSC Project Website as follows:

1. Enter general information at the top of the form.

2. Under the "Action" section at the bottom of the form, select "Question" then select "CMR" in drop-down of "Send to" box.

3. Enter details of question and attach related documents.

4. Select "Submit Form" at bottom of page.

D. Contracting Officer’s Action: Contracting Officer will review each RFI, determine action required, and respond. Contracting Officer will determine critical nature of each RFI and issue response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in Contract Documents.

e. Requests for adjustments in Contract Time or Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. Contracting Officer's action may include a request for additional information; time for response will date from time of receipt of additional information.

3. Contracting Officer's action on RFIs may result in need for a change to Contract Time or Contract Sum. All contract changes will be processed following terms and conditions of contract.

1.6 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. Meeting agenda will include the following as a minimum:

1. Roles & Responsibilities / Lines of Authority

2. Park rules and regulations

3. Jobsite Safety

4. Resolution of comments on required Division 1 documents

5. Coordination of Subcontractors

6. Labor law application

7. Modifications

8. Payments to Contractor

9. Payroll reports

10. Contract time

11. Liquidated damages

12. Contractor Performance Evaluation

13. Display of Hotline posters

14. Notice to proceed

15. Correspondence procedures

16. Acceptance/rejection of work

CRLA 239775 01 31 00 - 5

17. Progress meetings

18. Submittal procedures

19. NPS Final Accessibility Inspection

20. Environmental requirements

21. Permit requirements

22. As-constructed drawings/operation and maintenance (O&M) manuals.

23. Saturday, Sunday, holiday and night work.

24. Reference materials

25. Value engineering

26. Schedule of Values

B. Progress Meetings: Contracting Officer will schedule weekly meetings with Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented. Participants at meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. Meeting agenda will include:

a. Approval of minutes of previous meetings

b. Submittal status

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications

f. Work in progress and projected.

g. Inspections of work in progress and projected (Special inspections, Accessibility, etc.)

h. Construction Schedule update (provide updated Critical Path Method (CPM)).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements

C. Preinstallation Conferences: Conduct at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend meeting. Advise Contracting Officer of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for particular activity under consideration, including requirements for:

a. Contract Documents

b. Options

c. Related RFIs

d. Related Change Orders

e. Purchases

f. Deliveries

g. Submittals

CRLA 239775 01 31 00 - 6

h. Review of mockups

i. Possible conflicts

j. Compatibility requirements

k. Time schedules

l. Weather limitations

m. Manufacturer's written instructions

n. Warranty requirements

o. Compatibility of materials

p. Acceptability of substrates

q. Temporary facilities and controls

r. Space and access limitations

s. Regulations of agency(ies) with jurisdiction

t. Testing and inspecting requirements

u. Installation procedures

v. Coordination with other work

w. Required performance results

x. Protection of adjacent work

y. Protection of construction and personnel

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if conference cannot be successfully concluded. Initiate whatever actions are necessary to resolve impediments to performance of Work and reconvene conference at earliest feasible date.

1.7 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate on-site party responsible for overseeing Contractor’s conformance to environmental goals for project and implementing procedures for environmental protection.

1. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Present overview of environmental issues and summarize site specific procedures relating to management plans at Preconstruction conference.

c. Training for Contractor personnel in accordance with position requirements.

d. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements

2. Regulatory Requirements

3. Construction Waste Management

CRLA 239775 01 31 00 - 7

1.8 PERMITS

A. General:

1. Permits and Responsibilities: Contractor shall, without additional expense to the Government, be responsible for obtaining necessary licenses and permits, and for complying with Federal, State and municipal laws, codes, and regulations applicable to the performance of the work. Contractor shall also be responsible for damages to persons or property that occur as a result of Contractor’s fault or negligence; and for materials delivered and work performed until completion and acceptance of the work.

2. For the purpose of this contract, Contractor will not be considered an agent of the Government. Contractor shall comply with appropriate Federal, State and local laws.

B. Government Furnished Permits: During development of the project’s design, permits listed below were negotiated and agreed to by the Government. Terms and provisions of these permits shall be adhered to for the duration specified in each permit.

1. None

C. Potential Permits: Permits listed below were identified during the design process as likely to be required based on typical means and methods of construction. The list is provided to assist Contractor in determining which permits will be required for contract’s chosen means and methods. The list shall not be considered complete; it is the Contractors’ responsibility to determine means and methods and obtain required permits. Contractor shall obtain all permits required to legally conduct work.

None Known

D. Coordination with Agency(ies) with Jurisdiction Issuing Permits

1. Coordination: Contact the Agency(ies) with Jurisdiction as needed and sufficiently in advance to avoid delaying work: Coordinate meetings, reporting requirements, inspections, and other requirements.

E. Administrative Procedures:

1. Coordinate scheduling and timing of required administrative provisions of project permits with Agency(ies) with Jurisdiction, Construction Manager, and Park to avoid conflicts.

2. Supply needed information to Agency(ies) with Jurisdiction issuing permits, pay fees required and provide material needed to comply with permit’s conditions and provisions.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

Request for Information (RFI) Form, 2-18-20 page 1 of 1

Request for Information (RFI) Form National Park Service (NPS) - Denver Service Center (DSC) | 2-18-20

RFI Number:

Project: CRLA 239775 Replace Guardrails

Contract Number:

Date:

To:

Carbon Copy (CC):

From:

Subject:

Please provide the following information or clarification:

Response Required By:

Date:

To:

From:

Subject: Response to RFI Number:

Response:

CRLA 239775 01 32 18 - 1

012721 CONSTRUCTION SCHEDULE

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. Section consists of Construction Schedule requirements including:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The Construction Schedule ensures adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. It shall assist the Contractor and Contracting Officer (CO) in monitoring the progress of the work, evaluating proposed changes, and processing Contractor's monthly progress payments. It shall include the dates in the contract, phases, milestones, occupancies, holidays, weather consideration, a critical path, and the requirements of this section.

1.2 DEFINITIONS

A. Activity: A discrete part of a project identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: Allocation of the Schedule of Values for completion of an activity as scheduled.

The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. Critical Path Method (CPM): Method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: Longest connected chain of interdependent activities through the network schedule that establishes minimum overall Project duration and contains no float.

E. Float: Measure of leeway in starting and completing an activity.

1. Float: Not for the exclusive use or benefit of the Government or Contractor but is jointly owned.

2. Free Float: Amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

CRLA 239775 01 32 18 - 2

3. Total Float: Measure of leeway in starting or completing an activity without adversely affecting planned Project completion date.

F. Resource Loading: Allocation of manpower and equipment necessary for completion of an activity as scheduled.

1.3 SUBMITTALS

A. Electronic Copies: Schedules and reports submitted shall be posted on the NPS/DSC management software website in native electronic file formats. The intent of the Government is to limit the number of printed reports to those determined by the project team as essential.

B. Schedule of Values: After contract award and before Pre-Construction conference, submit schedule of dollar values based on Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before Pre-Construction conference, submit baseline schedule, large enough to show entire schedule for entire construction period.

Utilize Schedule of Values in preparation of Construction Baseline Schedule.

D. Critical Path Method (CPM) Reports: Concurrent with CPM schedule, submit the following computer-generated reports. For each activity, include activity number, activity description, cost and resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity Report: List of activities sorted by activity number and then early start date, or actual start date if known.

2. Logic Report: List of predecessor and successor tasks for activities sorted in ascending order by activity number and then early start date, or actual start date if known.

3. Total Float Report: List of activities sorted in ascending order of total float.

E. Construction Schedule Updates: On or before 7th day preceding progress payment request date, submit estimates of percent completion of each schedule activity and necessary supporting data.

Provide two paper copies.

F. Construction Schedule Revisions and Time Impact Analysis: For each Construction Schedule revision, submit a Time Impact Analysis.

1.4 QUALITY ASSURANCE

A. Contractor shall meet with Contracting Officer on day of the preconstruction conference to go over:

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Review delivery dates for Government-furnished products.

4. Review schedule for work of separate Government contracts.

5. Review time required for review of submittals and re-submittals.

6. Review requirements for tests and inspections by independent testing and inspecting agencies.

CRLA 239775 01 32 18 - 3

7. Review time required for completion and startup procedures.

8. Review time required for obtaining and activating permits.

9. Review and finalize list of construction activities…