S- 10-0026 B .docx

AG-82B1-S-10-0026 BRIDGE REPLACEMENT, BLUE SKY TRAIL, FORTINE RD 4

Section C - Description/Specifications/Statement of Work………………………………4

(MAR 2009)

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

BLUE SKY TRAIL BRIDGE REPLACEMENT

Fortine Ranger District Kootenai National Forest Lincoln County, Montana

B-1 SCHEDULE OF ITEMS

LSQ = Lump Sum Quantity; DQ = Design Quantity; AQ = Actual Quantity

B- 1 - SCHEDULE OF ITEMS

ITEM

NO.

DESCRIPTION

METHOD OF MEAS.

PAY

UNIT

EST.

QTY.

UNIT

PRICE

TOTAL

PRICE

201B(01)

Clearing & Brushing

DQ

MI

16.85

202(02)

Removal of Obstructions (rock removal)

DQ

EA

203(19)

Drainage Excavation, Type Outlet Ditch

AQ

LF

203(23)

Earth Berms

DQ

LF

306(01)

Reconditioning of Roadbed, Compaction A

DQ

MI

16.85

306(04)

Miscellaneous Reconditioning

LSQ

LS

412(16)

Calcium Chloride Flake @ 77% minimum Pellet 94% Concemtration, Preparation Method 1

AQ

TON

601(01)

Mobilization

LSQ

LS

603(01)18C

18” CMP (incl culv exc), 0.064” Thickness for Steel or 0.060” Thickness for Aluminum, Method C

AQ

LF

619(03)5

Machine-Placed Riprap, Class V

DQ

CY

TOTAL (ALL ITEMS)

*Designated Method of Measurement: DQ – Designed Quantities; AQ – Actual Quantities;

LSQ – Lump Sum Quantities

B- 2: Quote on all items. BIDS MUST BE QUOTED TO THE NEAREST DOLLAR.

N Note: Payment for bond premiums in accordance with FAR Clause 52.232-5, Payment Under Fixed-Price Co Construction Contracts, shall not be in addition to the contract price.

SECTION C - DESCRIPTION AND SPECIFICATIONS

C- 1 - PROJECT DESCRIPTION AND LOCATION

(a) - Description of Work. Replacement of the Blue sky Trail timber bridge by removal of the existing timber bridge and replacement with a timber bridge of structural timber and lumber, in accordance with the specificatin herein, which are titled “Forest Service Supplemental Specifications” dated August 2009.

(b) - Project Location. The project is located in the north west corner of Montana, identified as Township 36 North, Range 25 West, Section 12.

(c) - Price Range. Between $50,000 and $100,000

(d) - Pre-Bid Tour. None

(e) - Start Work. It is estimated that work will begin on August 1, 2010.

(f) - Contract Time. Contract Time will run continously and all work shall be completed not later than September 30, 2010.

C- 2 - STATEMENT OF WORK/SPECIFICATIONS (AGAR 452.211-72) (FEB 1988). The Contractor shall furnish all the necessary personnel, material, equipment, services and facilities (except as otherwise specified), necessary to perform the work.

C- 3 - GOVERNMENT-FURNISHED PROPERTY. None.

C- 4 – Safety & Camping. If the Contractor anticipates camping within or adjacent to the project area, it shall obtain and comply with the requirements of a District Camping Permit.

C- 5 - STANDARD SPECIFICATIONS "Forest Service Specifications for Construction of Roads & Minor Drainage Structures" (April 1985) are included in this solicitation by reference only. The requirements contained in these Specifications are hereby made a part of this solicitation and any resultant contract.

Copies of the "Forest Service Specifications for Construction of Roads & Bridges" (April 1985) are available in loose leaf form from the Idaho Panhandle National Forests, 3815 Schreiber Way, Coeur d'Alene, Idaho 83815-8363 or by calling (208) 765-7234.

C-6 – SPECIAL PROJECT SPECIFICATIONS. The following Forest Service Special Project Specifications are applicable to this contract and are physically included in this section:

SECTION D - Packaging and Marking

Intentionally blank

SECTION E - Inspection and Acceptance

Periodic field inspections will be made by the Contracting Officer’s Representative (COR) or the COR’s designated Inspector. Work not completed to contract standards shall not be rejected and reworked without additional compensation to the Contractor.

52.246-1 Contractor Inspection Requirements. (APR 1984)

52.246-12 Inspection of Construction. (APR 1996)

F - Deliveries or Performance

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed. The completion date for this contract is September 30, 2010. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.242-14 Suspension of Work. (APR 1984)

452.236-75 Maximum Workweek - Construction Schedule. (NOV 1996)

Within 7 calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval:

(a) A schedule as required by FAR clause 52.236-15, Schedules for Construction Contracts, and

(b) The hours (including the daily starting and stopping times) and days of the week the Contractor proposes to carry out the work.

The maximum workweek that will be approved is to be coordinated with the COR and approved by the Contracting Officer..

(End of clause)

SECTION G - Contract Administration Data

452.215-73 Postaward Conference. (NOV 1996)

A post award conference with the successful offeror is required. It will be scheduled within 14 days after the date of contract award. The conference will be held at: at a mutually agreed time and place.

(End of Clause)

.SECTION H - Special Contract Requirements

H- 1 - Fire Control

(a) Contractor's Responsibility for Contractor-Caused Fires. The Contractor, whether or not directed by the Forest Service, shall immediately extinguish, without expense to the Government, all fires on or in the vicinity of the project which are caused by Contractor's employees, whether set directly or indirectly as a result of Contractor operations. The Contractor may be held liable for all damages and costs of additional labor, subsistence, equipment, supplies, and transportation resulting from fires set or caused by the Contractor's employees or resulting from contract operations.

(b) Other Fires. For the purpose of fighting forest fires on or in the vicinity of the project which are not caused by the Contractor or the Contractor’s employees, the Contractor when requested by the Contracting Officer shall place the employees and equipment temporarily at the disposal of the Forest Service. Payment for such services will be made by the Government at not less than the current rate for fire-fighting services established by the Forest Service in the area concerned.

Any employees and equipment furnished will be relieved from fire fighting as soon as the Forest Service finds that it is practicable to employ other labor and equipment adequate for the protection of the area.

An equitable adjustment in contract time may be made for this period.

(c) Fire Protection Requirements - Fire Plan. At all times during closed fire season period, as specified by State law, the Contractor shall comply with each of the following provisions to the extent applicable to the Contractor’s operation under the contract.

(1) Fire Tools. The Contractor will provide for each employee in the contract area at least one approved handtool of a type appropriate in the contract area, such as shovel, pulaski, or ax. Tools required and furnished under (2) and (4) below, shall count toward fulfillment of the above requirement. Where additional tools, beyond those required under (2) and (4) below, are to be provided, the Contractor shall seal such tools in one or more boxes painted red and marked "Tools for Fire Only." All tools required herein shall be kept sharp and in good serviceable condition and maintained at locations to be designated by the Forest Service.

(2) Fire Extinguishers and Tools on Mobile or Stationary Equipment. Each unit of powered equipment used in connection with this contract, including automobiles, trucks, tractors, etc., shall be equipped with serviceable tools and fire extinguishers as follows:

One - fire extinguisher, dry chemical type of not less than 2-1/2 pound capacity with 4 BC or higher rating.

One - shovel, round point #0 lady or equal.

One - ax, 2 pounds or over, 26-inch minimum length, or one pulaski.

One - water container (at least 1-gallon capacity), not required with stationary equipment.

(3) Spark Arresters. Each internal combustion engine shall be provided with a spark arrester or spark arresting device approved by the Forest Service. Exceptions where the Forest Service may approve mufflers, or other equipment in lieu of spark arresters qualified and rated under Forest Service Standard 5100-1a are: (a) small multiposition engines, such as chain saws, shall meet Society of Automotive Engineers J335b standards; (b) passenger-carrying vehicles and light trucks may have baffle-type mufflers with tail pipe; (c) heavy-duty trucks may have a vertical stack exhaust system and muffler, provided the exhaust stack extends above the cab of the vehicle. An exhaust-driven turbocharger is considered to be a satisfactory spark arrester. Internal combustion engine exhaust systems, arresters, and other devices must be properly installed and maintained.

(4) Powersaws. For each powersaw used in connection with this contract, the following will be provided:

One - shovel, round point #0 lady or equal. Shovel must be immediately available for use.

One - Fire extinguisher, containing not less than 8 ounces of extinguisher fluid, or a dry chemical powder-type of not less than 1-pound capacity. The extinguisher must be immediately accessible to the saw operator at all times.

Any fueling or refueling of a powersaw shall only be done in an area which has first been cleared or is free of all material capable of carrying fire; powersaw shall be moved at least 10 feet from place of fueling before starting.

(5) Blasting. Fuse or prima cord shall not be used unless authorized in writing by the COR with special precautions stated.

(6) Smoking. Smoking shall not be permitted within the contract area except on surfaced or dirt roads, at landings, within closed vehicles, in camps, or at other posted places, and shall never be allowed while working or traveling on foot.

(7) Storage of Petroleum and Other Highly Flammable Products. Gasoline, oil, grease, or other highly flammable material will be stored either in a separate building used exclusively for such storage, or at a site where all combustible debris and vegetation is cleared away within a radius of 25 feet. Fire extinguishers and/or sand barrels may be required at such locations specified by the Forest Service when unusually hazardous conditions exist.

(8) Debris Burning and Warming Fires. Burning permits will be required for all debris burning fires. Lunch and warming fires may be allowed in fireproofed areas during periods of low fire danger if and as specified in the fire plan. Such fires must not be left burning unattended.

(9) Precautions for Stoves. Stovepipes on all temporary buildings, trailers, and tents using wood burning stoves, will be equipped with roof jacks and serviceable spark arresters of mesh with openings no larger than 5/8 inch.

All stovepipes, inside and out, will not be closer than 2 feet from any wood or other flammable material or 1 foot if the combustible material is protected by a metal or asbestos shield.

(10) Welding. Welding or use of cutting torches will be permitted only in areas that have been cleared or are free of all material capable of carrying fire. Flammable debris and vegetation must be removed from within a minimum of 10 feet radius of all welding and cutting torch operations. A shovel and a 5-gallon standard backpack water container (filled) with handpump attached, shall be immediately available for use in the event of a fire start.

(11) Fire Plan. Prior to initiating work on the contract area, during the closed fire season period, a fire prevention and suppression plan will usually be prepared. The Contractor and the Forest Service will jointly prepare this plan. Such plan shall include a detailed list of men and equipment at the Contractor's disposal for implementing the plan. The fire plan shall also specify additional measures and/or special requirements, such as Hoot Owl restrictions, necessary during periods of critical fire weather conditions.

When Hoot Owl restrictions are invoked, the Forest Service may curtail or shut down all or portions of a Contractor's operations. The following requirements may be imposed:

(i) All high fire risk operations could be terminated at 1300 local time.

(ii) All burning could be stopped, including debris burning fires.

(iii) Patrolman may be required for a period of 2 hours after high fire risk operations and 1 hour after end of work shift. The Contractor shall provide the patrolman unless the contract is for equipment rental, in which case the Government will provide the patrolman.

(12) Pump and Trailer. The Contractor shall provide at a location satisfactory to the Contracting Officer, a serviceable truck or trailer, equipped with a fire fighting tanker unit to be kept ready for instant use for suppressing forest fires. The unit shall consist of a tank of not less than 100-gallon capacity upon which shall be mounted a live hose reel or live hose basket with 250 feet of at least 3/4-inch I.D. heavy-duty rubber hose; a portable or power takeoff pump with discharge capacity of at least 10 gallons per minute at 150 P.S.I. pressure. Gear type pumps shall be provided with a bypass or pressure relief valve so that the hose nozzle may be shut while the pump is operating. Each tanker unit shall have a hose nozzle of the shut-off type, adjustable for straight stream, spray or fog, at least 12 feet of 1-inch suction hose with an intake screen, an additional 250 feet of 3/4-inch heavy-duty rubber hose or 1-inch cotton jacket rubber-lined or linen hose to be carried on the unit for use as needed. Tools, adapters, accessories and fuel necessary to operate the pump and truck or trailer shall be provided. If a trailer is used, a serviceable vehicle with the proper trailer tow hitch shall be located at a point satisfactory to the Contracting Officer. Where water is available, a supply sufficient for rapidly filling the water tank shall be provided at one or more accessible points along or adjacent to the main truck roads.

(13) Burning. Before starting any open burning, the Contractor shall comply with the following:

(i) Submit a burning plan, subject to approval by the Contracting Officer, designed to minimize the impact on air quality and to lessen any fire damage.

(ii) Obtain a burning permit from the District Ranger.

(iii) Use weather forecasts as far as possible in scheduling burning for more favorable dispersal of smoke.

(iv) Fuel shall be reasonably free of dirt and piled to facilitate rapid and complete combustion. Piles shall be tended during burning operations to maintain combustion and to eliminate unnecessary smudges. Piles shall be patrolled during off-work hours to avoid wildfires.

(v) Unless fire season controls dictate otherwise, burning shall be scheduled, as far as practicable, for the most favorable conditions during the burning period.

(vi) Under certain atmospheric conditions, smoke accumulations may become excessive and in these cases, the Regional Forester may, at his/her discretion, prohibit all open burning for definite periods within specific areas of the National Forest.

H- 2 - Loss, Damage, or Destruction

(a) Equipment furnished with operator. The Government shall not be liable for loss, damage, or destruction of equipment furnished under this contract except for such loss, damage, or destruction resulting from the negligent or wrongful act(s) of Government employee(s) while acting within the scope of their employment.

All claims arising under this clause will be submitted to the Contracting Officer.

H- 3 - Incidental Payment Items

The intent of the contract is to provide for the complete construction of the project described in the contract. Unless otherwise provided, the Contractor shall furnish all labor, materials, equipment, tools, transportation, and supplies and perform all work required to complete the project in accordance with drawings, specifications, and provisions of the contract. Payment for contract work will be made only for and under those pay items included in the Schedule of Items. All other work and materials will be considered as incidental to and included in the payment for items shown.

H- 4 - Conformity With Drawings and Specifications

Unless working tolerances are specified, all work performed and materials furnished shall be in reasonably close conformity with lines, grades, cross sections, dimensions, and material requirements shown on the drawings, indicated in the specifications, or designated on the ground. "Reasonably close conformity" is compliance with reasonable and customary manufacturing and construction tolerances.

H- 5 - Local Material Sources

(a) Designated Sources--Sources of local materials will be designated on the drawings. The Government assumes responsibility for the quality and quantity of material in the source. The Contractor shall determine the equipment and work required to produce the specified product.

The Contractor shall utilize all suitable material in the source. The designation of source will include the rights of the Contractor to use certain area(s) for plant site, stockpiles, and haul roads. Any Contractor royalty payment requirements will be stated below.

When materials are subject to weight measurement, the weight/volume relationship used for determination of designed quantities will be shown on the Drawings.

Should the designated source, due to causes beyond the control of the Contractor, contain insufficient suitable material, the Government will provide another source with an equitable adjustment in accordance with the Differing Site Conditions and Changes clauses.

(a) Contractor-Furnished Sources--When the material sources are not designated as provided above or the Contractor elects not to use designated sources, the Contractor shall be responsible for providing the specified product with no adjustment in contract price, unless weight/volume relationship differences between designated source material and Contractor-furnished source material result in financial disadvantage to the Government. Quality testing shall be the responsibility of the Contractor. Test results shall be furnished to the Contracting Officer.

H- 6 - Samples, Tests, Cited Specifications

Reference made in the contract to specifications, standards, or test methods adopted by AASHTO, ASTM, GSA, or other recognized National technical associations, shall mean specifications, standards, or test methods (including interim or tentative issues) which are in effect on the date of the solicitation.

H-7 - Prework Conference Prior to commencement of work, the Contracting Officer will arrange a meeting with the Contractor to discuss the contract terms and work performance requirements. Also at this meeting such things as work progress schedule and fire prevention and suppression plans shall be developed and established in writing.

H- 8- 52.204-11 American Recovery and Reinvestment Act--Reporting Requirements. (MAR 2009)

(a) Definitions. As used in this clause--

"Contract," as defined in FAR 2.101, means a mutually binding legal relationship obligating the seller to furnish the supplies or services (including construction) and the buyer to pay for them. It includes all types of commitments that obligate the Government to an expenditure of appropriated funds and that, except as otherwise authorized, are in writing. In addition to bilateral instruments, contracts include (but are not limited to) awards and notices of awards; job orders or task letters issued under basic ordering agreements; letter contracts; orders, such as purchase orders, under which the contract becomes effective by written acceptance or performance; and bilateral contract modifications. Contracts do not include grants and cooperative agreements covered by 31 U.S.C. 6301, et seq. For discussion of various types of contracts, see FAR Part 16.

"First-tier subcontract" means a subcontract awarded directly by a Federal Government prime contractor whose contract is funded by the Recovery Act.

"Jobs created" means an estimate of those new positions created and filled, or previously existing unfilled positions that are filled, as a result of funding by the American Recovery and Reinvestment Act of 2009 (Recovery Act). This definition covers only prime contractor positions established in the United States and outlying areas (see definition in FAR 2.101). The number shall be expressed as "full-time equivalent" (FTE), calculated cumulatively as all hours worked divided by the total number of hours in a full-time schedule, as defined by the contractor. For instance, two full-time employees and one part-time employee working half days would be reported as 2.5 FTE in each calendar quarter.

"Jobs retained" means an estimate of those previously existing filled positions that are retained as a result of funding by the American Recovery and Reinvestment Act of 2009 (Recovery Act). This definition covers only prime contractor positions established in the United States and outlying areas (see definition in FAR 2.101). The number shall be expressed as "full-time equivalent" (FTE), calculated cumulatively as all hours worked divided by the total number of hours in a full-time schedule, as defined by the contractor. For instance, two full-time employees and one part-time employee working half days would be reported as 2.5 FTE in each calendar quarter.

"Total compensation" means the cash and noncash dollar value earned by the executive during the contractor's past fiscal year of the following (for more information see 17 CFR 229.402(c)(2)):

(1) Salary and bonus.

(2) Awards of stock, stock options, and stock appreciation rights. Use the dollar amount recognized for financial statement reporting purposes with respect to the fiscal year in accordance with the Statement of Financial Accounting Standards No. 123 (Revised 2004) (FAS 123R), Shared Based Payments.

(3) Earnings for services under non-equity incentive plans. Does not include group life, health, hospitalization or medical reimbursement plans that do not discriminate in favor of executives, and are available generally to all salaried employees.

(4) Change in pension value. This is the change in present value of defined benefit and actuarial pension plans.

(5) Above-market earnings on deferred compensation which is not tax-qualified.

(6). Other compensation. For example, severance, termination payments, value of life insurance paid on behalf of the employee, perquisites or property if the value for the executive exceeds $10,000.

(b) This contract requires the contractor to provide products and/or services that are funded under the American Recovery and Reinvestment Act of 2009 (Recovery Act). Section 1512(c) of the Recovery Act requires each contractor to report on its use of Recovery Act funds under this contract. These reports will be made available to the public.

(c) Reports from contractors for all work funded, in whole or in part, by the Recovery Act, and for which an invoice is submitted prior to June 30, 2009, are due no later than July 10, 2009. Thereafter, reports shall be submitted no later than the 10th day after the end of each calendar quarter.

(d) The Contractor shall report the following information, using the online reporting tool available at http://www.FederalReporting.gov.

(1) The Government contract and order number, as applicable.

(2) The amount of Recovery Act funds invoiced by the contractor for the reporting period. A cumulative amount from all the reports submitted for this action will be maintained by the government's on-line reporting tool.

(3) A list of all significant services performed or supplies delivered, including construction, for which the contractor invoiced in this calendar quarter.

(4) Program or project title, if any.

(5) A description of the overall purpose and expected outcomes or results of the contract, including significant deliverables and, if appropriate, associated units of measure.

(6) An assessment of the contractor's progress towards the completion of the overall purpose and expected outcomes or results of the contract (i.e., not started, less than 50 percent completed, completed 50 percent or more, or fully completed). This covers the contract (or portion thereof) funded by the Recovery Act.

(7) A narrative description of the employment impact of work funded by the Recovery Act. This narrative should be cumulative for each calendar quarter and only address the impact on the contractor's workforce. At a minimum, the contractor shall provide--

(i) A brief description of the types of jobs created and jobs retained in the United States and outlying areas (see definition in FAR 2.101). This description may rely on job titles, broader labor categories, or the contractor's existing practice for describing jobs as long as the terms used are widely understood and describe the general nature of the work; and

(ii) An estimate of the number of jobs created and jobs retained by the prime contractor, in the United States and outlying areas. A job cannot be reported as both created and retained.

(8) Names and total compensation of each of the five most highly compensated officers of the Contractor for the calendar year in which the contract is awarded if--

(i) In the Contractor's preceding fiscal year, the Contractor received--

(A) 80 percent or more of its annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants) and cooperative agreements; and

(B) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants) and cooperative agreements; and

(ii) The public does not have access to information about the compensation of the senior executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986.

(9) For subcontracts valued at less than $25,000 or any subcontracts awarded to an individual, or subcontracts awarded to a subcontractor that in the previous tax year had gross income under $300,000, the Contractor shall only report the aggregate number of such first tier subcontracts awarded in the quarter and their aggregate total dollar amount.

(10) For any first-tier subcontract funded in whole or in part under the Recovery Act, that is over $25,000 and not subject to reporting under paragraph 9, the contractor shall require the subcontractor to provide the information described in (i), (ix), (x), and (xi) below to the contractor for the purposes of the quarterly report. The contractor shall advise the subcontractor that the information will be made available to the public as required by section 1512 of the Recovery Act. The contractor shall provide detailed information on these first-tier subcontracts as follows:

(i) Unique identifier (DUNS Number) for the subcontractor receiving the award and for the subcontractor's parent company, if the subcontractor has a parent company.

(ii) Name of the subcontractor.

(iii) Amount of the subcontract award.

(iv) Date of the subcontract award.

(v) The applicable North American Industry Classification System (NAICS) code.

(vi) Funding agency.

(vii) A description of the products or services (including construction) being provided under the subcontract, including the overall purpose and expected outcomes or results of the subcontract.

(viii) Subcontract number (the contract number assigned by the prime contractor).

(ix) Subcontractor's physical address including street address, city, state, and country. Also include the nine-digit zip code and congressional district if applicable.

(x) Subcontract primary performance location including street address, city, state, and country. Also include the nine-digit zip code and congressional district if applicable.

(xi) Names and total compensation of each of the subcontractor's five most highly compensated officers, for the calendar year in which the subcontract is awarded if--

(A) In the subcontractor's preceding fiscal year, the subcontractor received--

(l) 80 percent or more of its annual gross revenues in Federal contracts (and subcontracts), loans, grants (and subgrants), and cooperative agreements; and

(2) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants), and cooperative agreements; and

(B) The public does not have access to information about the compensation of the senior executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986.

H – 9 Whistleblower Protections Under The American Recovery And Reinvestment Act of 2009 (Mar 2009)

(a) The Contractor shall post notice of employees rights and remedies for whistleblower protections provided under section 1553 of the American Recovery and Reinvestment Act of 2009 (Pub. L. 111-5).

(a) The Contractor shall include the substance of this clause including this paragraph (b) in all subcontracts.

(End of Clause)

H – 10 SEC. 1553. PROTECTING STATE AND LOCAL GOVERNMENT AND CONTRACTOR

WHISTLEBLOWERS.

(a) PROHIBITION OF REPRISALS.—An employee of any non-Federal employer receiving covered funds may not be discharged, demoted, or otherwise discriminated against as a reprisal for disclosing, including a disclosure made in the ordinary course of an employee’s duties, to the Board, an inspector general, the Comptroller General, a member of Congress, a State or Federal regulatory or law enforcement agency, a person with supervisory authority over the employee (or such other person working for the employer who has the authority to investigate, discover, or terminate misconduct), a court or grand jury, the head of a Federal agency, or their representatives, information that the employee reasonably believes is evidence of—

(1) gross mismanagement of an agency contract or grant relating to covered funds;

(2) a gross waste of covered funds;

(3) a substantial and specific danger to public health or safety related to the implementation or use of covered funds;

(4) an abuse of authority related to the implementation or use of covered funds; or

(5) a violation of law, rule, or regulation related to an agency contract (including the competition for or negotiation of a contract) or grant, awarded or issued relating to covered funds.

(b) INVESTIGATION OF COMPLAINTS.—

(1) IN GENERAL.—A person who believes that the person has been subjected to a reprisal prohibited by subsection (a) may submit a complaint regarding the reprisal to the appropriate inspector general. Except as provided under paragraph (3), unless the inspector general determines that the complaint is frivolous, does not relate to covered funds, or another Federal or State judicial or administrative proceeding has previously been invoked to resolve such complaint, the inspector general shall investigate the complaint and, upon completion of such investigation, submit a report of the findings of the investigation to the person, the person’s employer, the head of the appropriate agency, and the Board.

(2) TIME LIMITATIONS FOR ACTIONS.—

(A) IN GENERAL.—Except as provided under subparagraph (B), the inspector general shall, not later than 180 days after receiving a complaint under paragraph (1)— H. R. 1—184

(i) make a determination that the complaint is frivolous, does not relate to covered funds, or another Federal or State judicial or administrative proceeding has previously been invoked to resolve such complaint; or

(ii) submit a report under paragraph (1).

(B) EXTENSIONS.—

(i) VOLUNTARY EXTENSION AGREED TO BETWEEN INSPECTOR GENERAL AND COMPLAINANT.—If the inspector general is unable to complete an investigation under this section in time to submit a report within the 180-day period specified under subparagraph (A) and the person submitting the complaint agrees to an extension of time, the inspector general shall submit a report under paragraph (1) within such additional period of time as shall be agreed upon between the inspector general and the person submitting the complaint.

(ii) EXTENSION GRANTED BY INSPECTOR GENERAL.— If the inspector general is unable to complete an investigation under this section in time to submit a report within the 180-day period specified under subparagraph (A), the inspector general may extend the period for not more than 180 days without agreeing with the person submitting the complaint to such extension, provided that the inspector general provides a written explanation (subject to the authority to exclude information under paragraph (4)(C)) for the decision, which shall be provided to both the person submitting the complaint and the non-Federal employer.

(iii) SEMI-ANNUAL REPORT ON EXTENSIONS.—The inspector general shall include in semi-annual reports to Congress a list of those investigations for which the inspector general received an extension.

(3) DISCRETION NOT TO INVESTIGATE COMPLAINTS.—

(A) IN GENERAL.—The inspector general may decide not to conduct or continue an investigation under this section upon providing to the person submitting the complaint and the non-Federal employer a written explanation (subject to the authority to exclude information under paragraph (4)(C)) for such decision.

(B) ASSUMPTION OF RIGHTS TO CIVIL REMEDY.—Upon receipt of an explanation of a decision not to conduct or continue an investigation under subparagraph (A), the person submitting a complaint shall immediately assume the right to a civil remedy under subsection (c)(3) as if the 210-day period specified under such subsection has already passed.

(C) SEMI-ANNUAL REPORT.—The inspector general shall include in semi-annual reports to Congress a list of those investigations the inspector general decided not to conduct or continue under this paragraph.

(4) ACCESS TO INVESTIGATIVE FILE OF INSPECTOR GENERAL.—

(A) IN GENERAL.—The person alleging a reprisal under this section shall have access to the investigation file of H. R. 1—185 the appropriate inspector general in accordance with section 552a of title 5, United States Code (commonly referred to as the ‘‘Privacy Act’’). The investigation of the inspector general shall be deemed closed for purposes of disclosure under such section when an employee files an appeal to an agency head or a court of competent jurisdiction.

(B) CIVIL ACTION.—In the event the person alleging the reprisal brings suit under subsection (c)(3), the person alleging the reprisal and the non-Federal employer shall have access to the investigative file of the inspector general in accordance with the Privacy Act.

(C) EXCEPTION.—The inspector general may exclude from disclosure—

(i) information protected from disclosure by a provision of law; and

(ii) any additional information the inspector general determines disclosure of which would impede a continuing investigation, provided that such information is disclosed once such disclosure would no longer impede such investigation, unless the inspector general determines that disclosure of law enforcement techniques, procedures, or information could reasonably be expected to risk circumvention of the law or disclose the identity of a confidential source.

(5) PRIVACY OF INFORMATION.—An inspector general investigating an alleged reprisal under this section may not respond to any inquiry or disclose any information from or about any person alleging such reprisal, except in accordance with the provisions of section 552a of title 5, United States Code, or as required by any other applicable Federal law.

(c) REMEDY AND ENFORCEMENT AUTHORITY.—

(1) BURDEN OF PROOF.—

(A) DISCLOSURE AS CONTRIBUTING FACTOR IN

REPRISAL.—

(i) IN GENERAL.—A person alleging a reprisal under this section shall be deemed to have affirmatively established the occurrence of the reprisal if the person demonstrates that a disclosure described in subsection

(a) was a contributing factor in the reprisal.

(ii) USE OF CIRCUMSTANTIAL EVIDENCE.—A disclosure may be demonstrated as a contributing factor in a reprisal for purposes of this paragraph by circumstantial evidence, including—

(I) evidence that the official undertaking the reprisal knew of the disclosure; or (II) evidence that the reprisal occurred within a period of time after the disclosure such that a reasonable person could conclude that the disclosure was a contributing factor in the reprisal.

(B) OPPORTUNITY FOR REBUTTAL.—The head of an agency may not find the occurrence of a reprisal with respect to a reprisal that is affirmatively established under subparagraph (A) if the non-Federal employer demonstrates by clear and convincing evidence that the non- Federal employer would have taken the action constituting the reprisal in the absence of the disclosure.

H. R. 1—186

(2) AGENCY ACTION.—Not later than 30 days after receiving an inspector general report under subsection (b), the head of the agency concerned shall determine whether there is sufficient basis to conclude that the non-Federal employer has subjected the complainant to a reprisal prohibited by subsection

(a) and shall either issue an order denying relief in whole or in part or shall take 1 or more of the following actions:

(A) Order the employer to take affirmative action to abate the reprisal.

(B) Order the employer to reinstate the person to the position that the person held before the reprisal, together with the compensation (including back pay), compensatory damages, employment benefits, and other terms and conditions of employment that would apply to the person in that position if the reprisal had not been taken.

(C) Order the employer to pay the complainant an amount equal to the aggregate amount of all costs and expenses (including attorneys’ fees and expert witnesses’ fees) that were reasonably incurred by the complainant for, or in connection with, bringing the complaint regarding the reprisal, as determined by the head of the agency or a court of competent jurisdiction.

(3) CIVIL ACTION.—If the head of an agency issues an order denying relief in whole or in part under paragraph (1), has not issued an order within 210 days after the submission of a complaint under subsection (b), or in the case of an extension of time under subsection (b)(2)(B)(i), within 30 days after the expiration of the extension of time, or decides under subsection (b)(3) not to investigate or to discontinue an investigation, and there is no showing that such delay or decision is due to the bad faith of the complainant, the complainant shall be deemed to have exhausted all administrative remedies with respect to the complaint, and the complainant may bring a de novo action at law or equity against the employer to seek compensatory damages and other relief available under this section in the appropriate district court of the United States, which shall have jurisdiction over such an action without regard to the amount in controversy. Such an action shall, at the request of either party to the action, be tried by the court with a jury.

(4) JUDICIAL ENFORCEMENT OF ORDER.—Whenever a person fails to comply with an order issued under paragraph (2), the head of the agency shall file an action for enforcement of such order in the United States district court for a district in which the reprisal was found to have occurred. In any action brought under this paragraph, the court may grant appropriate relief, including injunctive relief, compensatory and exemplary damages, and attorneys fees and costs.

(5) JUDICIAL REVIEW.—Any person adversely affected or aggrieved by an order issued under paragraph (2) may obtain review of the order’s conformance with this subsection, and any regulations issued to carry out this section, in the United States court of appeals for a circuit in which the reprisal is alleged in the order to have occurred. No petition seeking such review may be filed more than 60 days after issuance of the order by the head of the agency. Review shall conform to chapter 7 of title 5, United States Code.

H. R. 1—187

(d) NONENFORCEABILITY OF CERTAIN PROVISIONS WAIVING

RIGHTS AND REMEDIES OR REQUIRING ARBITRATION OF DISPUTES.—

(1) WAIVER OF RIGHTS AND REMEDIES.—Except as provided under paragraph (3), the rights and remedies provided for in this section may not be waived by any agreement, policy, form, or condition of employment, including by any predispute arbitration agreement.

(2) PREDISPUTE ARBITRATION AGREEMENTS.—Except as provided under paragraph (3), no predispute arbitration agreement shall be valid or enforceable if it requires arbitration of a dispute arising under this section.

(3) EXCEPTION FOR COLLECTIVE BARGAINING AGREEMENTS.—

Notwithstanding paragraphs (1) and (2), an arbitration provision in a collective bargaining agreement shall be enforceable as to disputes arising under the collective bargaining agreement.

(e) REQUIREMENT TO POST NOTICE OF RIGHTS AND REMEDIES.— Any employer receiving covered funds shall post notice of the rights and remedies provided under this section.

(f) RULES OF CONSTRUCTION.—

(1) NO IMPLIED AUTHORITY TO RETALIATE FOR NON-PROTECTED

DISCLOSURES.—Nothing in this section may be construed to authorize the discharge of, demotion of, or discrimination against an employee for a disclosure other than a disclosure protected by subsection (a) or to modify or derogate from a right or remedy otherwise available to the employee.

(2) RELATIONSHIP TO STATE LAWS.—Nothing in this section may be construed to preempt, preclude, or limit the protections provided for public or private employees under State whistleblower laws.

(g) DEFINITIONS.—In this section:

(1) ABUSE OF AUTHORITY.—The term ‘‘abuse of authority’’ means an arbitrary and capricious exercise of authority by a contracting official or employee that adversely affects the rights of any person, or that results in personal gain or advantage to the official or employee or to preferred other persons.

(2) COVERED FUNDS.—The term ‘‘covered funds’’ means any contract, grant, or other payment received by any non-Federal employer if—

(A) the Federal Government provides any portion of the money or property that is provided, requested, or demanded; and

(B) at least some of the funds are appropriated or otherwise made available by this Act.

(3) EMPLOYEE.—The term ‘‘employee’’—

(A) except as provided under subparagraph (B), means an individual performing services on behalf of an employer;

and

(B) does not include any Federal employee or member of the uniformed services (as that term is defined in section 101(a)(5) of title 10, United States Code).

(4) NON-FEDERAL EMPLOYER.—The term ‘‘non-Federal employer’’—

(A) means any employer—

(i) with respect to covered funds—

(I) the contractor, subcontractor, grantee, or recipient, as the case may be, if the contractor, H. R. 1—188 subcontractor, grantee, or recipient is an employer;

and (II) any professional membership organization, certification or other professional body, any agent or licensee of the Federal government, or any person acting directly or indirectly in the interest of an employer receiving covered funds; or

(ii) with respect to covered funds received by a State or local government, the State or local government receiving the funds and any contractor or subcontractor of the State or local government; and

(B) does not mean any department, agency, or other entity of the Federal Government.

(5) STATE OR LOCAL GOVERNMENT.—The term ‘‘State or local government’’ means—

(A) the government of each of the several States, the District of Columbia, the Commonwealth of Puerto Rico, Guam, American Samoa, the Virgin Islands, the Commonwealth of the Northern Mariana Islands, or any other territory or possession of the United States; or

(B) the government of any political subdivision of a government listed in subparagraph (A).

//Section End//

H-11 - 52.225-21 Required Use of American Iron, Steel, and Other Manufactured Goods--Buy American Act--Construction Materials. (MAR 2009)

(a) Definitions. As used in this clause--

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

"Domestic construction material" means--

(1) An unmanufactured construction material mined or produced in the United States; or

(2) A construction material manufactured in the United States.

"Foreign construction material" means a construction material other than a domestic construction material.

"Manufactured construction material" means any construction material that is not unmanufactured construction material.

"Steel" means an alloy that includes at least 50 percent iron, between .02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

"Unmanufactured construction material" means raw material brought to the construction site for incorporation into the building or work that has not been--

(1) Processed into a specific form and shape; or

(2) Combined with other raw material to create a material that has different properties than the properties of the individual raw materials.

(b) Domestic preference. (1) This clause implements--

(i) Section 1605 of the American Recovery and Reinvestment Act of 2009 (Recovery Act) (Pub. L. 111-5), by requiring, unless an exception applies, that all iron, steel, and other manufactured goods used as construction material in the project are produced in the United States; and

(ii) The Buy American Act (41 U.S.C. 10a-10d) by providing a preference for unmanufactured domestic construction material.

(2) The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraph (b)(3) and (b)(4) of this clause.

(3) This requirement does not apply to the construction material or components listed by the Government as follows:

NONE

(4) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(3) of this clause if the Government determines that--

(i) The cost of domestic construction material would be unreasonable.

(A) The cost of domestic iron, steel, or other manufactured goods used as construction material is unreasonable when the cumulative cost of such material will increase the cost of the contract by more than 25 percent;

(B) The cost of unmanufactured construction material is unreasonable when the cost of such material exceeds the cost of foreign material by…