Food Services Solicitation.doc

Pine Ridge Food Services Requirement

AG-82A7-S-10-0021

02/08/2010

03/10/2010

U S D A Forest Service

FORMCHECKBOX

UNRESTRICTED OR X FORMCHECKBOX

SET ASIDE: 100 % FOR

SMALL BUSINESS FORMCHECKBOX

EMERGING SMALL

BUSINESS

HUBZONE SMALL

NAICS: 722310 BUSINESS

SERVICE-DISABLED VETERAN- FORMCHECKBOX

8(A)

SIZE STANDARD: $20.5 million OWNED SMALL BUSINESS

11. DELIVERY FOR FOB DESTINATION UNLESS BLOCK IS MARKED

FORMCHECKBOX

SEE SCHEDULE

13a. THIS CONTRACT IS A RATED ORDER UNDER DPAS (15 CFR 700) 13b. RATING

14. METHOD OF SOLICITATION

FORMCHECKBOX

RFQ FORMCHECKBOX

IFB FORMCHECKBOX

RFP

15. DELIVER TO CODE

USDA Forest Service Pine Ridge Job Corps Center

15710 HWY 385

Chadron, NE 69337

16. ADMINISTERED BY CODE

See Block 9

17a. CONTRACTOR/ CODE FACILITY

OFFEROR CODE

18a. PAYMENT WILL BE MADE BY CODE

USDA Rural Development

Centralized Servicing Center 4300 Goodfellow Blvd (FC-233) Bldg 105E

FORMCHECKBOX

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN 18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

FORMCHECKBOX

SEE ADDENDUM

*CCR valid until___________________ *Read INSTRUCTIONS FOR PREPARATIONS OF PROPOSALS and follow all instructions.

ALL INFORMATION REQUESTED ABOVE MUST BE SUBMITTED TO BE CONSIDERED TO BE RESPONSIVE TO THIS RFP.

25. ACCOUNTING AND APPROPRIATION DATA

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

FORMCHECKBOX

ARE NOT ATTACHED

FORMCHECKBOX

ARE NOT ATTACHED

29. AWARD OF CONTRACT: REF. OFFER

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS: ____________________

AUTHORIZED FOR LOCAL REPRODUCTION

STANDARD FORM 1449 (REV.3/2005)

PREVIOUS EDITION IS NOT USABLE

Prescribed by GSA ‑ FAR (48 CFR) 53.212

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

FORMCHECKBOX

RECEIVED

FORMCHECKBOX

INSPECTED

FORMCHECKBOX

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ________________________________________

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32f. TELPHONE NUMBER OF AUTHORZED GOVERNMENT REPRESENTATIVE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

CORRECT FOR

|PARTIAL | |FINAL

FORMCHECKBOX

COMPLETE FORMCHECKBOX

PARTIAL FORMCHECKBOX

FINAL

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER

FOR PAYMENT

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

STANDARD FORM 1449 (REV.3/2005) BACK

Continuation of SF1449

Blocks 19 through 24

SCHEDULE OF ITEMS

PINE RIDGE JOB CORPS

FOOD SERVICES

ITEM SUPPLIES

QUANTITY

UNIT

UNIT

PRICE

AMOUNT

Base Period 07/01/10 – 06/30/11 Monday through Friday

A. Breakfast

48,400 ea

B. Lunch

48,400 ea

C. Dinner

48,400 ea

Saturday, Sunday, and Holidays

D. Brunch

22,400 ea

E. Supper

22,400 ea

F. Snack

22,400 ea

TOTAL

Option Period I 07/01/11 – 06/30/12 Monday through Friday

A. Breakfast

48,400 ea

B. Lunch

48,400 ea

C. Dinner

48,400 ea

Saturday, Sunday, and Holidays

D. Brunch

22,400 ea

E. Supper

22,400 ea

Option Period II 07/01/12 – 06/30/13 Monday through Friday

A. Breakfast

48,400 ea

B. Lunch

48,400 ea

C. Dinner

48,400 ea

Saturday, Sunday, and Holidays

D. Brunch

22,400 ea

E. Supper

22,400 ea

Option Period III 07/01/13– 06/30/14 Monday through Friday

A. Breakfast

48,400 ea

B. Lunch

48,400 ea

C. Dinner

48,400 ea

Saturday, Sunday, and Holidays

D. Brunch

22,400 ea

E. Supper

22,400 ea

Option Period IV 07/01/14 – 06/30/15 Monday through Friday

A. Breakfast

48,400 ea

B. Lunch

48,400 ea

C. Dinner

48,400 ea

Saturday, Sunday, and Holidays

D. Brunch

22,400 ea

E. Supper

22,400 ea

Grand Total - Base Period & Four Option Periods

Block 27: The full text of a clause or provision may be accessed electronically

Contract Clauses 52.204-9 Personal Identity Verification of Contractor Personnel (Sept 2007)

(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24 and Federal Information Processing Standards Publication (FIPS PUB) Number 201.

(b) The Contractor shall insert this clause in all subcontracts when the subcontractor is required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system.

(End of clause)

52.211-11 Liquidated Damages -- Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $1,500.00 per calendar day of total contract delay.

(b) If the Government terminates this contract in whole or in part under the Default -- Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default -- Fixed-Price Supply and Service clause in this contract.

(End of Clause)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of clause)

52.217-8 OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 30 DAYS before the end of the contract period.

(End of clause)

52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 15 DAYS; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 30 DAYS before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 5 years and 6 months, if options 52.217-8 and 52.217-9 are exercised.

(End of clause) 52.219-28 Post-Award Small Business Program Rerepresentation (Apr 2009)

(a) Definitions. As used in this clause—

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is “not dominant in its field of operation” when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts—

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure that they reflect the Contractor’s current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it o is, o is not a small business concern under NAICS Code ______________ assigned to contract number ______________.

[Contractor to sign and date and insert authorized signer’s name and title].

(End of clause)

52.228-5 Insurance—Work on a Government Installation (Jan 1997)

(a) The Contractor shall, at its own expense, provide and maintain during the entire performance of this contract, at least the kinds and minimum amounts of insurance required in the Schedule or elsewhere in the contract.

(b) Before commencing work under this contract, the Contractor shall notify the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government’s interest shall not be effective—

(1) For such period as the laws of the State in which this contract is to be performed prescribe; or

(2) Until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule or elsewhere in the contract. The Contractor shall maintain a copy of all subcontractors’ proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

(End of clause)

52.232-18 Availability of Funds (Apr 1984)

Funds are not presently available for this contract. The Government’s obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer.

(End of clause)

452.211-75 EFFECTIVE PERIOD OF THE CONTRACT (FEB 1988)

The effective period of this contract is from July 01, 2010 through June 30, 2015 (if all options are exercised).

(End of Clause)

452.215-73 POST AWARD CONFERENCE (NOV 1996)

A post award conference with the successful offeror is required. It will be scheduled within 15 days after the date of contract award. The conference will be held at a place to be determined later or telephonically.

(End of Clause)

452.224-70 CONFIDENTIALITY OF INFORMATION (FEB 1988)

(a) Confidential information, as used in this clause, means --

(1) information or data of a personal nature, proprietary about an individual, or (2) information or data submitted by or pertaining to an organization.

(b) In addition to the types of confidential information described in (a)(1) and (2) above, information which might require special consideration with regard to the timing of its disclosure may derive from studies or research, during which public disclosure of primarily invalidated findings could create an erroneous conclusion which might threaten public health or safety if acted upon.

(c) The Contracting Officer and the Contractor may, by mutual consent, identify elsewhere in this contract specific information and/or categories of information which the Government will furnish to the Contractor or that the Contractor is expected to generate which is confidential. Similarly, the contracting Officer and the Contractor may, by mutual consent, identify such confidential information from time to time during the performance of the contract. Failure to agree will be settled pursuant to the "Disputes" clause.

(d) If it is established that information to be utilized under this contract is subject to the Privacy Act, the Contractor will follow the rules and procedures of disclosure set forth in the Privacy Act of 1974, 5 U.S.C. 552a, and implementing regulations and policies, with respect to systems of records determined to be subject to the Privacy Act.

(e) Confidential information, as defined in (a)(1) and (2) above, shall not be disclosed without the prior written consent of the individual, institution or organization.

(f) Written advance notice of at least 45 days will be provided to the Contracting Officer of the Contractor's intent to release findings of studies or research, which have the possibility of adverse effects on the public or the Federal agency, as described in (b) above. If the Contracting Officer does not pose any objections in writing within the 45 day period, the contractor may proceed with disclosure. Disagreements not resolved by the Contractor and Contracting Officer will be settled pursuant to the "Disputes" clause.

(g) Whenever the Contractor is uncertain with regard to the proper handling of material under the contract, or if the material in question is subject to the Privacy Act or is confidential information subject to the provisions of this clause, the Contractor shall obtain a written determination from the Contracting Officer prior to any release, disclosure, dissemination, or publication.

(h) The provisions of paragraph (e) of this clause shall not apply when the information is subject to conflicting or overlapping provisions in other Federal, State or local laws.

(End of Clause)

452.228-71 INSURANCE COVERAGE (NOV 1996)

Pursuant to FAR clause 52.228-5, Insurance-Work on a Government Installation, the Contractor will be required to present evidence to show, as a minimum, the amounts of insurance coverage indicated below:

(a) Workers Compensation and Employer's Liability. The Contractor is required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a Contractor's commercial operations that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 shall be required, except in States with exclusive or monopolistic funds that do not permit worker's compensation to be written by private carriers.

(b) General Liability. The Contractor shall have bodily injury liability insurance coverage written on a comprehensive form of policy of at least $500,000 per occurrence

(c) Automobile Liability. The Contractor shall have automobile liability insurance written on a comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and 500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage or loss.

(d) Aircraft Public and Passenger Liability. When aircraft are used in connection with performing the contract, the Contractor shall have aircraft public and passenger liability insurance. Coverage shall be at least $200,000 per person and $500,000 per occurrence for bodily injury, other than passenger injury. Coverage for passenger injury shall be at least $200,000 multiplied by the number of seats or passengers, whichever is greater.

(End of Clause)

452.237-70 LOSS, DAMAGE, DESTRUCTION OR REPAIR (FEB 1988)

(a) For equipment furnished under this contract without operator, the Government will assume liability for any loss, damage or destruction of such equipment, not to exceed a total of $2,500.00 except that no reimbursement will be made for loss, damage or destruction due to (1) ordinary wear or tear, (2) mechanical failure, or (3) the fault or negligence of the Contractor or the Contractor's agents or employees.

(b) For equipment furnished under this contract with operator, the Government shall not be liable for any loss, damage or destruction of such equipment, except for loss, damage or destruction resulting from the negligent or wrongful act(s) of Government employee(s) while acting within the scope of their employment.

(c) All repairs to equipment furnished under this contract shall be made by the Contractor and reimbursement, if any, shall be determined in accordance with (a) or (b) above. Repairs shall be made promptly and equipment returned to use within 48 hours. In lieu of repairing equipment, the Contractor may furnish similar replacement equipment within the time specified. The Contractor may authorize the Government to make repairs upon the request of theContracting Officer. In such case, the Contractor will be billed for labor and parts costs.

(End of Clause)

452.237-74 KEY PERSONNEL (FEB 1988)

(a) The Contractor shall assign to this contract the following key personnel: Food Services Manager

(b) During the first ninety (90) days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 90-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. The contract will be modified to reflect any approved changes of key personnel.

(End of Clause)

452.237-75 RESTRICTIONS AGAINST DISCLOSURE (FEB 1988)

(a) The Contractor agrees, in the performance of this contract, to keep all information contained in source documents or other media furnished by the Government in the strictest confidence. The Contractor also agrees not to publish or otherwise divulge such information in whole or in part in any manner or form, or to authorize or permit others to do so, taking such reasonable measures as are necessary to restrict access to such information while in the Contractor's possession, to those employees needing such information to perform the work provided herein, i.e., on a "need to know" basis. The Contractor agrees to immediately notify in writing, the Contracting Officer, named herein, in the event that the Contractor determines or has reason to suspect a breach of this requirement.

(b) The Contractor agrees not to disclose any information concerning the work under this contract to any persons or individual unless prior written approval is obtained from the Contracting Officer. The Contractor agrees to insert the substance of this clause in any consultant agreement or subcontract hereunder.

(End of Clause)

452.246-70 INSPECTION AND ACCEPTANCE (FEB 1988)

(a) The Contracting Officer or the Contracting Officer's duly authorized representative will inspect and accept the supplies and/or services to be provided under this contract.

(b) Inspection and acceptance will be performed at each individual center by the Center Director or his designee.

(End of clause)

52.212- 4 Contract Terms and Conditions -- Commercial Items (Mar 2009)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights --

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to the Contract Disputes Act of 1978, as amended (41 U.S.C. 601-613). Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include --

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, contract line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer—Central Contractor Registration, or 52.232-34, Payment by Electronic Funds Transfer—Other Than Central Contractor Registration), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt Payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected contract line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in Section 611 of the Contract Disputes Act of 1978 (Public Law 95-563), which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period at fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. 3701, et seq., Contract Work Hours and Safety Standards Act; 41 U.S.C. 51-58, Anti-Kickback Act of 1986; 41 U.S.C. 265 and 10 U.S.C. 2409 relating to whistleblower protections; Section 1553 of the American Recovery and Reinvestment Act of 2009 relating to whistleblower protections for contracts funded under that Act; 49 U.S.C. 40118, Fly American; and 41 U.S.C. 423 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, and Compliance with Laws Unique to Government Contracts paragraphs of this clause.

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments.

(9) The specification.

(t) Central Contractor Registration (CCR).

(1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the CCR database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the CCR database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the CCR database to ensure it is current, accurate and complete. Updating information in the CCR does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(2)

(i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to:

(A) Change the name in the CCR database;

(B) Comply with the requirements of Subpart 42.12 of the FAR;

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the CCR information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the CCR record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the CCR database. Information provided to the Contractor’s CCR record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of payment” paragraph of the EFT clause of this contract.

(4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the Internet at http://www.ccr.gov or by calling 1-888-227-2423, or 269-961-5757.

(End of Clause)

52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (Feb 2010)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)).

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer shall check as appropriate.] _x_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sep 2006), with Alternate I (Oct 1995)(41 U.S.C. 253g and 10 U.S.C. 2402).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Dec 2008) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Mar 2009) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

___ (4) 52.204-11, American Recovery and Reinvestment Act—Reporting Requirements (Mar 2009) (Pub. L. 111-5).

_x_ (5) 52.219-3, Notice of Total HUBZone Set-Aside (Jan 1999)(15 U.S.C. 657a).

___ (6) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jul 2005) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

___ (7) [Reserved]

___ (8) (i) 52.219-6, Notice of Total Small Business Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-6.

___ (iii) Alternate II (Mar 2004) of 52.219-6.

___ (9) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003)(15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

_x_ (10) 52.219-8, Utilization of Small Business Concerns (May 2004) (15 U.S.C. 637(d)(2) and (3)).

_x_ (11) (i) 52.219-9, Small Business Subcontracting Plan (Apr 2008)(15 U.S.C. 637 (d)(4).)

___ (ii) Alternate I (Oct 2001) of 52.219-9.

_x_ (iii) Alternate II (Oct 2001) of 52.219-9.

___ (12) 52.219-14, Limitations on Subcontracting (Dec 1996)(15 U.S.C. 637(a)(14)).

_x_ (13) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999)(15 U.S.C. 637(d)(4)(F)(i)).

___ (14) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008)(10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer).

___ (ii) Alternate I (June 2003) of 52.219-23.

___ (15) 52.219-25, Small Disadvantaged Business Participation Program—Disadvantaged Status and Reporting (Apr 2008)(Pub. L. 103-355, section 7102, and 10 U.S.C. 2323).

___ (16) 52.219-26, Small Disadvantaged Business Participation Program—Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323).

___ (17) 52.219-27, Notice of Total Service-Disabled Veteran-Owned Small Business Set-Aside (May 2004) (15 U.S.C. 657 f).

_x_ (18) 52.219-28, Post Award Small Business Program Rerepresentation (Apr 2009) (15 U.S.C. 632(a)(2)).

_x_ (19) 52.222-3, Convict Labor (June 2003)(E.O. 11755).

___ (20) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Aug 2009) (E.O. 13126).

_x_ (21) 52.222-21, Prohibition of Segregated Facilities (Feb 1999).

_x_ (22) 52.222-26, Equal Opportunity (Mar 2007)(E.O. 11246).

_x_ (23) 52.222-35, Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Sep 2006)(38 U.S.C. 4212).

_x_ (24) 52.222-36, Affirmative Action for Workers with Disabilities (Jun 1998)(29 U.S.C. 793).

_x_ (25) 52.222-37, Employment Reports on Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Sep 2006)(38 U.S.C. 4212).

___ (26) 52.222-54, Employment Eligibility Verification (Jan 2009). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

___ (27) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008)(42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (28) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

_x_ (29) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423).

___ (ii) Alternate I (Dec 2007) of 52.223-16.

_x_ (30) 52.225-1, Buy American Act--Supplies (Feb 2009)(41 U.S.C. 10a-10d).

___ (31) (i) 52.225-3, Buy American Act –Free Trade Agreements – Israeli Trade Act (Jun 2009) (41 U.S.C. 10a-10d, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, Pub. L. 108-77, 108-78, 108-286, 108-301, 109-53, 109-169, 109-283, and 110-138).

___ (ii) Alternate I (Jan 2004) of 52.225-3.

___ (iii) Alternate II (Jan 2004) of 52.225-3.

___ (32) 52.225-5, Trade Agreements (Aug 2009) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_x_ (33) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

___ (34) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

___ (35) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

___ (36) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)).

___ (37) 52.232.30, Installment Payments for Commercial Items (Oct 1995)(41 U.S.C. 255(f), 10 U.S.C. 2307(f)).

_x_ (38) 52.232-33, Payment by Electronic Funds Transfer—Central Contractor Registration (Oct. 2003)(31 U.S.C. 3332).

___ (39) 52.232-34, Payment by Electronic Funds Transfer—Other Than Central Contractor Registration (Feb 2010)(31 U.S.C. 3332).

___ (40) 52.232-36, Payment by Third Party (May 1999)(31 U.S.C. 3332).

_x_ (41) 52.239-1, Privacy or Security Safeguards (Aug 1996)(5 U.S.C. 552a).

___ (42) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006)(46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).

___ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

_x_ (1) 52.222-41, Service Contract Act of 1965 (Nov 2007)(41 U.S.C. 351, et seq.).

_x_ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 1989)(29 U.S.C. 206 and 41 U.S.C. 351, et seq.).

_x_ (3) 52.222-43, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Multiple Year and Option Contracts) (Sep 2009) (29 U.S.C.206 and 41 U.S.C. 351, et seq.).

___ (4) 52.222-44, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Sep 2009)(29 U.S.C. 206 and 41 U.S.C. 351, et seq.).

___ (5) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.).

___ (6) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.).

_x_ (7) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247).

_x_ (8) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008)(31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this…