Section_C_Div_01_-_Div_51.docx

Pasture Canyon Dam Modifications

Bureau of Indian Affairs Hopi Indian Reservation - Arizona

DESIGNER

U.S. Department of the Interior FINAL SPECIFICATIONS Bureau of Reclamation Technical Service Center Denver, Colorado FEBRUARY 2015

DESCRIPTION / SPECIFICATIONS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

Plan

DIVISION 02 - EXISTING CONDITIONS

Table of Contents 00 0110 - 1

DIVISION 03 - CONCRETE

DIVISION 05 - METALS

05 50 00 Metal Fabrications

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 92 00 Joint Sealants

DIVISION 08 - OPENINGS

08 31 20 Access Hatches

DIVISION 09 - FINISHES

DIVISION 26 - ELECTRICAL

DIVISION 31 - EARTHWORK

00 0110 - 2

DIVISION 33 - UTILITIES

33 11 13 HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe 33 46 36 Toe Drains

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

DIVISION 51 - INFORMATION AVAILABLE TO OFFERORS

DIVISION 52 - DRAWINGS

5200 00 Drawings

DIVISION 53 - GEOLOGIC INVESTIGATIONS AND RECORDS

00 0110 - 3

END OF CONTENTS

00 0110 - 4

SECTION 01 10 00

MOBILIZATION AND PREPARATORY WORK

schedule will be made as reflected herein. To the extent that this line item exceeds 5.0 percent of the total contract pricing, payment will be made as reflected in B.5.

paid for performance and payment bonds as required by the Performance and Payment Bond Requirements clause of this contract and for any insurance required as payable by the Government under this contract.

2. Except as provided in B.1, progress payments for mobilization and preparatory work shall not be considered a separate division of work for the purposes of progress payments and shall be subject to retainage before payment of the total amount for this contract line item.

3. When progress payments totaling 5 percent of the total original contract amount have been made by the Government for all other work accomplished under the contract, the Government shall pay the Contractor 50 percent of the mobilization and preparatory work contract line item amount or 5.5 percent of the total original contract amount, (whichever is lower), exclusive of any payment already made to the Contractor for performance and payment bond premiums and specified insurance under B.1.

4. When progress payments totaling 10 percent of the total original contract amount have been made by the Government for all other work accomplished under the contract and upon approval of the baseline schedule, the balance of the amount for the mobilization and preparatory work contract line item or 11 percent of the total original contract amount, (whichever is lower), shall be paid to the Contractor.

5. If the contract amount for mobilization and preparatory work exceeds the total of the payments allowed under B.3 and B.4 above, the balance shall be paid when the contract work is substantially complete as determined by the Contracting Officer.

Mobilization and Preparatory Work 01 1000 - 1

C. Termination for default: Should the Contractor be terminated for default as provided by the Default clause of this contract:

1. All facilities, plant, and equipment on the site shall be subject to the Government's right to take possession of and utilize such items for the purpose of completing the work;

2. The Contractor shall provide evidence of encumbrances, liens, or other security interests, to the Contracting Officer; and

3. Any encumbrance, lien, or other security interest on such facilities, plant, or equipment shall be subordinated to the Government's rights under the Default clause of this contract to utilize all facilities, plant, and equipment to complete the work under the contract.

(excludes temporary buildings - e.g. storage sheds, shops, offices) and utilities listed in the Temporary Utilities section of this contract;

initiation of meaningful work at the site where the contract does not otherwise provide for payment.

be deemed to be subject to the provisions of this paragraph unless the Contracting Officer specifically provides other written authorization for a particular item or items.

2. The Contractor shall be solely responsible for the adequacy, efficiency, use, protection, maintenance, repair, and preservation of facilities, plant, and equipment on site.

3. Facilities, plant, and equipment covered by this paragraph shall not be dismantled or removed from the site prior to completion of the work under the contract without written authorization of the Contracting Officer.

01 1000 - 2

PART 3 EXECUTION

Not Used.

END OF SECTION

01 1000 - 3

SECTION 01 11 00

SUMMARY OF WORK

Coconino County, Arizona.

along downstream slope of embankment. Cover filter with Zone 1 embankment.

H. Furnishment and installation of toe drain pipe surrounded by Zone 2 fine filter and Zone 3 coarse filter at downstream toe of embankment, and Zone 2 fine filter material in trench below new toe drain. Cover toe drain with Zone 1 embankment.

I. Replacement of low-voltage electrical distribution equipment associated with the outlet works slide gate hydraulic power unit and gate controls, (HPU), including combination starters, conduit system, grounding system, conductors and cables, and associated electrical equipment.

otherwise stated.

Summary of Work 01 1100 - 1

C. Where specifications are written in streamlined form, the words “shall be” are included by inference where a colon (:) is used within the sentence or phrase.

Regulations (FAR), the definition of the word or term shall be in accordance with FAR sections in effect at the time the solicitation was issued.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

Summary of Work 01 1100 - 2

SECTION 01 14 10

USE OF SITE

Equipment and Vehicles to Prevent the Spread of Invasive Species (Technical memorandum No. 86-68220-07-05) 2012 Edition Available online at:

http://www.usbr.gov/mussels/prevention

to the following:

1) Buildings and service areas including offices, shops, warehouses, storage areas, fuel and oil storage areas, and fabrication yards.

compressor station.

(such as trees, shrubs, and grass), and other landscape features on or adjacent to the jobsite, which are not to be removed and which do not

Use of Site 01 1410 - 1 interfere with the work required under this contract. Include methods to mark work area limits, protect disturbed areas, and prevent erosion.

c. Describe methods to protect, and repair if damaged, existing improvements and utilities at or near the jobsite.

d. Describe methods for removing temporary structures and facilities, cleanup, and rehabilitating site after completion of construction activities.

e. Describe methods for preventing spread of invasive species in the project area during construction.

1) Herbicides, application techniques, and applicator will be approved by the Hopi Environmental Protection Office.

2. Submit revised drawings of changes in use of Government land made during design and erection stages or after use of Government land is in operation.

necessary arrangements associated with use of private land.

C. Location, construction, operation, maintenance, and removal of construction facilities on Tribal land will be subject to approval of the COR.

D. Do not interfere with work of other contractors or the Tribe in vicinity, or with reservations made by the Tribe for use of such land.

E. Housing for construction personnel will not be permitted on Government land, except housing for guards or watchmen as may be approved by the COR.

01 1410 - 2

4. Power: Provide electrical power for lighting, computer operation, fax machine, refrigerator, water cooler, and at least 3 additional duplex outlets.

and other organic material to prevent introduction of noxious weeds, and invasive plant and animal species.

2. Contractor cleaning procedures shall result in equipment being cleaned as well or better than the procedures described in Cleaning Manual.

3. COR will inspect construction equipment following procedures described in USBR Cleaning Manual before allowing the equipment onsite.

4. Contractor to obtain approval from COR on removal and prevention plans for possible invasive species within the project area.

vehicular traffic when no longer required.

C. After completion of work, regrade and scarify Tribal land used for construction purposes and not required for completed installation so that surfaces blend with natural terrain and are in a condition that will facilitate revegetation, provide proper drainage, and prevent erosion.

01 1410 - 3

SECTION 01 29 00

THE HOPI TRIBE BUSINESS LICENSE APPLICATION

CONSTRUCTION PROJECTS

Projects.

C. RSN 01 29 00-2, Copy of All Subcontractors Hopi Business License for Construction Projects.

obtaining a business license including payment of applicable fees and compliance with applicable Hopi Tribal Employment Rights and Hopi Environmental Protection requirements for the license.

1. Obtain current information regarding applicable fees and contacts from the Hopi Tribe Office of Revenue Commission, P.O. Box 123, Kykotsmovi, AZ 86039, or by telephone: 928-734-3172.

B. The Contractor shall ensure that each Subcontractor obtains appropriate business license in connection with the work.

C. Hopi Tribe Business License applies to work being performed within the boundaries of the Hopi Reservation.

amount for Prime and Subs. The following table lists the fees as of January 1, 2015.

The Hopi Tribe Business License Application - Construction Projects 01 2900 - 1

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

The Hopi Tribe Business License Application - Construction Projects 01 2900 - 2

SECTION 01 29 10

THE HOPI TRIBE EMPLOYMENT RIGHTS

appropriate percentage of total contract amount shown below.

b. Price shall include only the amount to be paid to the Hopi Tribe for the fee and shall be due prior to commencement of work.

Prior to Commencement of Work.

the Interior” and “Indian Preference Program - Department of the Interior,” the Contractor shall comply with the Hopi Labor Code.

B. As part of the business licensing process the Contractor is required to submit a compliance plan to the Hopi Tribal Employments Rights Office indicating arrangements to fulfill the requirements of the Hopi Labor Code.

1. Contractor shall be responsible for contacting the Office of Revenue Commission and complying with Hopi Environmental Protection requirements to obtain the license.

2. Contractor shall ensure that each Subcontractor provides an acceptable compliance plan to the Tribe in connection with the work.

3. Contractor shall obtain current information regarding the Hopi Labor Code and licensing contacts from the Hopi Tribal Employment Rights Office, P.O. Box 123, Kykotsmovi, AZ 86039, or by telephone: 928-734-3162.

The Hopi Tribe Employment Rights 01 2910 - 1

C. Contractor shall also be responsible for paying, to the appropriate authorities, all applicable Tribal Employment Rights Ordinance (TERO) fees and taxes.

1. As of January 1, 2015, the employment rights fee was 1/2 of 1 percent, (0.5 percent) of the total contract price, (excluding amounts bid for tribal fees or employment fees).

a. This fee is separate from and in addition to the fees required for The Hopi Tribe Business License Fee for Construction Projects discussed in Section 01 29 00 - The Hopi Tribe Business License Application - Construction Projects.

b. Copies of the Hopi Labor Code and other information on current fees which are applicable to this contract can be obtained from the Hopi Tribal Employment Rights Office, P.O. Box 123, Kykotsmovi, AZ 86039, or by telephone: 928-734-3162.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

The Hopi Tribe Employment Rights 01 2910 - 2

SECTION 01 29 20

THE HOPI TRIBE ENVIRONMENTAL PROTECTION OFFICE -

ENVIRONMENTAL PROTECTION PLAN

Tribe’s Environmental Protection Office as a condition of obtaining a business license.

B. Contractor shall ensure that each Subcontractor obtains appropriate business license and amends the EPP as necessary in connection with the work.

C. The requirement for a Hopi Tribe Business License process and EPP applies to work being performed within the boundaries of the Hopi Reservation.

D. The Contractor shall obtain current information the Hopi Tribe Environmental Protection Office, P.O. Box 123, Kykotsmovi, AZ 86039, or by telephone: 928-734-3632.

E. The Contractor may obtain a copy of the Environmental Assessment (EA) for the project from Reclamation.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

The Hopi Tribe Environmental Protection Office - Environmental Protection Plan 01 2920 - 1

The Hopi Tribe Environmental Protection Office - Environmental Protection Plan 01 2920 - 2

SECTION 01 32 10

CONSTRUCTION PROGRAM

schedule A for mobilization and preparatory work.

2. Updating and Using Construction Program: Include as an element of Contractor’s overhead.

Manual, 2004

project where activities are arranged based on activity relationships and network calculations determine when activities can be performed and the critical path of the project.

B. Project Calendar: Cross reference of numerical work days with calendar days. The project calendar serves as the basis for the day/date conversion and assigns work days and non-workdays.

C. Resources: Equipment, labor or crews, materials, subcontractors, fabricators, manufacturers, and consultants.

D. Out of Sequence Work: An activity that starts before its predecessor activities are completed.

P6 Project Manager.

2. Furnish schedule and database files on CD-ROM disc.

Construction Program 01 3210 - 1

3. Upon request, provide information and data used to develop and maintain the Construction Program to the CO.

caused the "behind schedule" condition and provide proposed course of action to complete the project within the specified delivery time.

2) List of Contractor-initiated changes to current schedule stating reason for action taken and unresolved issues relating to the Construction Program. Government reserves the right to reject Contractor-initiated changes to current schedule which negatively impact Government action which was initiated on the basis of current schedule.

evaluate, and report accomplishment of work.

B. Failure to include any element of the work will not release Contractor from completing all required work under the contract.

01 3210 - 2

5. Define construction activities to a level of detail resulting in their durations being no greater than 25 workdays.

include actual start dates, percent completes, or actual finish dates.

Contractor shall take steps necessary to improve progress, including those that may be required by the CO.

1. The CO may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting officer deems necessary to demonstrate how the approved rate of progress will be regained.

2. Costs for actions required to improve progress will be the responsibility of the Contractor.

showing effects of modification or delay on the progress schedule if a time extension is being requested.

2. Time extensions for performance will be considered only to the extent that the Contractor’s current scheduled milestone dates exceed the contract milestone dates.

H. Float or slack is not for the exclusive use by or benefit of either the Government or Contractor.

determination by the CO that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the specified time.

01 3210 - 3

B. CO may terminate the Contractor’s right to proceed with the work, or separable part of it, in accordance with default terms of this contract.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

01 3210 - 4

SECTION 01 33 00

SUBMITTALS

work.

Format

Version 5

complete submittal.

clause at FAR 52.236-21, Specifications and Drawings for Construction.

does not comply with the contract. Contractor shall correct mistakes or deficiencies in rejected Informational submittals and resubmit.

Submittals 01 3300 - 1

c. Informational submittals are considered to be “shop drawings” within terms of clause at FAR 52.236-21, Specifications and Drawings for Construction, except that approval by Government is not required.

elsewhere in these specifications, requirements included elsewhere take precedence.

be neat.

cut sheets.

highlighter).

d. Strike through items that do not apply.

01 3300 - 2

professional.

2. Manufacturer’s certifications: Signed by authorized representative of manufacturer.

equipment.

d. As-built drawings, photographs, and test records or reports if required by the specifications.

“set” of samples.

number and title.

01 3300 - 3

will be returned for resubmission.

B. Submit complete sets of required materials for each RSN as specified in “Submittals required” column in Table 01 33 00A - List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submit number of sets specified in “No. of sets to be sent to:” columns in Table 01 33 00A - List of Submittals.

otherwise directed.

code is the same.

unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return mailing postmark date.

01 3300 - 4

work affected by excess review time.

a. Time extension will be to the extent that excess review time caused delay to the contract completion date.

b. The time extension will not exceed the time used in excess of the specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of two or more separate submittals or resubmittals will be counted only once in extending the contract completion date.

2. No time extension will be allowed if Contractor fails to make complete approval submittals in sequence and within time periods specified.

approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR 52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

either approved, approved subject to identified changes, or not approved.

drawings, documentation, and technical data have been approved.

2. Informational Submittals: Government will acknowledge Informational submittals.

a. Informational submittals will not be returned when they comply with specifications.

b. Informational submittals that do not comply with specifications may be returned for resubmittal or additional information may be requested.

01 3300 - 5

Pasture Canyon Dam Modification, 2600 N. Central Avenue, Phoenix, AZ 85004.

*The Contractor shall provide the Contracting Officer a copy of all correspondence and related documents, pertaining to this contract that is addressed to a representative of the Government. This does not pertain to the Submittal Requirements as they are outlined herein.

2. COR: Bureau of Indian Affairs, Western Region Office, Contracting Officer Representative - Pasture Canyon Dam Modification, 2600 N. Central Avenue, Phoenix, AZ 85004.

B. Send original transmittal letter with appropriate number of sets to COR at office listed, as shown in “Responsible Code” column in Table 01 33 00A - List of Submittals.

C. Submittals required by the specifications, but not listed in Table 01 33 00A - List of Submittals:

project. The use of this system will be organized by the Government at no cost to the Contractor and will be the preferred method for receiving and reviewing submittals.

2. If the Contractor elects to utilize the electronic submittal and review system for a submittal required by the Specifications, the Contractor does not need to perform Sub-Article B of this Section, and will submit set electronically for Article1.05.C.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

01 3300 - 6

Table 01 33 00A. - List of Submittals

* Submittal types: A - Action, I - Informational ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

01 1410-1

01 2900-1

01 2900-2

01 2910-1

01 2910-2

01 2910-3

01 2920-1

01 2920-2

Clause or Section Title

The Hopi Tribe Business License Application- Construction Projects The Hopi Tribe Business License Application- Construction Projects The Hopi Tribe Employment Rights

The Hopi Tribe Employment Rights The Hopi Tribe Employment Rights The Hopi Tribe Environmental Protection Office - Environmental Protection Plan

The Hopi Tribe Environmental Protection Office - Environmental Protection Plan

Respon-

Business License for Construction Projects

Business License for Construction Projects

Rights Fees to the Hopi Tribe Prior to the Commencement of Work

Rights Compliance Plan

Rights Compliance Plan

Approval

Protection Plan for Approval

No. of sets to be sent to: **

CO COR

0 3

0 2

0 2

0 2

0 2

0 2

0 2

0 2

01 3300 - 7

01 32 10-1

01 32 10-2

01 35 10-1

01 35 10-2

01 35 20-1

01 35 20-2

01 35 22-1

01 35 22-2 01 35 30-1

Clause or Section Title Construction Program

Construction Program

Safety Data Sheets

Safety and Health

Safety and Health

First Aid

Contractor’s Onsite Safety Personnel

Respon-

code Baseline Schedule: Within 21 days after A COR receipt of Notice to

1. Blackline prints Proceed

2. Reports

3. Data on CD or DVD ( 1 copy per submittal set) Updated Schedule: With monthly A COR requests for progress

1. Blackline prints payments

2. Reports

3. Data on CD or DVD (1 copy per submittal set)

delivery of hazardous material

delivery of hazardous material not previously listed Safety Program Submitted and A COR accepted before commencing work.

See section 3 of

RSHS

paragraph 3 of

RSHS

start of operations

No. of sets to be sent to: **

CO COR

0 6

0 4

0 3

0 3

0 3

0 3

0 3

01 3300 - 8

01 35 30-2

01 46 20-1

01 55 20-1

01 57 20-1

01 57 30-1

01 57 30-2

01 57 50-1

01 57 90-1

01 71 20-1

01 71 20-2

01 71 20-3

01 71 20-4 or Section Title Contractor’s Onsite Safety Personnel Testing Laboratory Services

Traffic Control

Environmental Controls

Water Pollution Control Water Pollution Control

Tree and Plant Protection

Preservation of Historical and Archeological Data Surveying

Respon-

code

start of construction

before start of operations Traffic Control Plan At least 36 days A COR before affecting public traffic.

construction work

construction work

(SPCC) Plan Protection Plan At least 28 days A COR before starting on site construction work

site construction work Surveying Plan At least 36 days A COR before beginning survey work Resume At least 36 days A COR before beginning survey work; At Least 36 days before personnel change

survey work

No. of sets to be sent to: **

CO COR

0 3

0 4

0 4

0 3

0 4

0 4

0 4

0 4

0 4

0 4

0 4

0 4

01 3300 - 9

01 7120-5

01 7120-6

01 7120-7

01 7400-1

01 7400-2

01 7400-3

01 7400-4

01 7830-1

02 2130-1

02 4107-1

02 8220-1

02 8220-2 or Section

Cleaning and Waste Management Cleaning and Waste Management Cleaning and Waste Management

Cleaning and Waste Management Project Record Documents Benchmarks

Removal and Disposal of Existing Features Removal and Disposal of Asbestos Containing Materials Removal and Disposal of Asbestos Containing Materials

Respon-

requests

requests

Records

disposal

environmental assessment

construction work

construction work

No. of sets to be sent to: **

CO COR

0 4

0 4

0 4

0 3

0 3

0 3

0 3

0 4

0 4

0 4

0 3

0 3

01 3300 - 10

02 8220-3

02 8220-4

03 1512-1

03 1512-2

03 1512-3

03 1512-4

03 1517-1

03 1517-2

03 1517-3

03 2000-1 or Section Title Removal and Disposal of Asbestos Containing Materials Removal and Disposal of Asbestos Containing Materials

PVC

Waterstop

Hydrophilic Strip Waterstop

Hydrophilic Strip Waterstop

Hydrophilic Strip Waterstop

Concrete Reinforcement

Respon-

related site construction work

and Certificate of Disposal

Purchase Orders At least 28 days A COR before starting related site construction work Samples At least 28 days A COR before starting related site construction work Certifications At least 28 days I COR before starting related site construction work Instructions At least 28 days I COR before starting related site construction work Product Data At least 28 days A COR before starting related site construction work Certification At least 28 days I COR before starting related site construction work Instructions At least 28 days I COR before starting related site construction work

related site construction work

No. of sets to be sent to: **

CO COR

0 3

0 4

0 4

0 2

0 2

0 2

0 4

0 2

0 2

0 6

01 3300 - 11

03 3000-1

03 3000-2

03 3000-3

03 3000-4

03 3752-1

03 3755-1

07 9200-1

07 9200-2

07 9200-3

09 9620-1

09 9620-2

09 9620-3

Clause or Section Title Cast-In-Place Concrete

Slush Grout

Dental

Joint Sealants

Coatings

Coatings

Coatings

Respon-

site construction work

site construction work

site construction work Certifications At least 28 days I COR before starting related site construction Mix Design At least 28 days A COR before starting on site construction work Mix Design At least 28 days A COR before starting on site construction work

work Certification At least 28 days I COR before starting related construction work Instructions At least 28 days I COR before starting related construction work Approval Data At least 28 days A COR prior to application Final Approval Data At least 28 days I COR prior to application Documentation At least 28 days I COR prior to application

No. of sets to be sent to: **

CO COR

0 6

0 6

0 6

0 6

0 6

0 6

0 4

0 4

0 4

0 4

0 4

0 4

01 3300 - 12

09 9623-1

09 9623-2

09 9623-3

26 05 10-1

26 3523-1

31 03 10-1

31 03 23-1

31 03 33-1

31 2318-1

31 2318-2 or Section Title Graffiti Resistant Coatings for Concrete and Masonry Graffiti Resistant Coatings for Concrete and Masonry Graffiti Resistant Coatings for Concrete and Masonry Conductors and Cables Manual Transfer Switch- Generator Power Inlet Diversion and Care of Flows During Construction

Cofferdam

Removal of Water From Excavation

Excavation of Reservoir Sediments

Excavation of Reservoir Sediments

Respon-

prior to application

Final Approval Data At least 28 days I COR

Documentation At least 28 days I COR

Approval Data Within 60 days after A COR Notice to proceed Approval Data Within 60 days after A COR Notice to proceed

any work on the diversion and care of the stream Approval Plans Within 60 days after A COR Notice to proceed

site construction work

work

Reservoir Sediments #1 Plan

No. of sets to be sent to: **

CO COR

0 4

0 4

0 4

0 6

0 6

0 6

0 6

0 6

0 8

0 8

01 3300 - 13

31 2318-3

31 2318-4

31 2321-1

31 2370-1

31 2410-1

31 2412-1

31 2413-1

31 2414-1

31 2510-1

31 2510-2 or Section Title Excavation of Reservoir Sediments

Excavation of Reservoir Sediments

Excavation of Existing Embankment and Spillway Controlled Low Strength Material

(CLSM)

Embankment Construction, General

Zone 2, Fine Filter

Zone 3, Coarse Filter

Zone 4, Crest and Downstream Face Protection Erosion

Erosion

Respon-

Reservoir Sediments #2 Plan

Reservoir Sediments #3 Plan Excavation Plan At least 28 days A COR before starting on site construction work Approval Data At least 28 days A COR before starting on site construction work

any work on the diversion and care of the stream

embankment

any work on the embankment

any work on the embankment

site construction work Straw Certification At least 28 days A COR before starting on site construction work

No. of sets to be sent to: **

CO COR

0 8

0 8

0 6

0 6

0 6

0 6

0 6

0 6

0 4

0 4

01 3300 - 14

313232-1

313232-2

313232-3

313700-1

31 3700-2

33 1113-1

33 1113-2 or Section

Geotextile

Riprap and Bedding

Riprap and Bedding

HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe

Respon-

related on site construction work Samples At least 28 days I COR before starting related on site construction work Protection Method At least 28 days I COR before starting related on site construction work

work

related construction work

Procedures

Work Plans, and Fusion Procedures

No. of sets to be sent to: **

CO COR

0 4

0 2

0 4

0 4

0 4

0 6

0 6

01 3300 - 15

33 1113-3

33 1113-4

33 1113-5

33 1113-6

33 1113-7 or Section Title HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe HDPE Pipes for Outlet Works, Air Vent, Drainage, Hydraulic Lines, and Irrigation Turnout Pipe

Respon-

Fusion Procedures

construction work

construction work

No. of sets to be sent to: **

CO COR

0 6

0 4

0 4

0 4

0 4

01 3300 - 16

334636-1

334636-2

334636 -3

33 4636-4

33 4636-5

33 4636-6

35 2182-1

35 2182-2

35 2182-3

35 2215-1

35 2215-2

35 2312-1

352312 -2 or Section

Toe Drains

Steel Pipe

Cast-Iron Hydraulic Slide Gate Cast-Iron Hydraulic Slide Gate Valves and Equipment

Valves and Equipment

Respon-

before starting related on site construction work Certifications At least 28 days A COR before starting related on site construction work Samples At least 28 days A COR before starting related on site construction work Survey Reports Within 14 days after I COR0 construction is completed