A04_SOW_SPECS-2021-22-04.pdf

100% Construction Documents Submission PMIS Nos. 216560 | GWWO Project No. 19031 March 2, 2020

UPPER DELAWARE SCENIC & RECREATIONAL

RIVER

ROOF REPLACEMENT OF THE CORWIN HOUSE

GWWO, INC.

800 Wyman Park Drive, Suite 300

Baltimore, MD 21211 www.gwwoinc.com

© 2019 GWWO, Inc.

UPDE - 216560 01 11 00 - 1

091015 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1.2 Work covered by the Contract Documents.

1.3 Work under other contracts.

1.4 Contractor use of premises.

1.5 Public use of site.

1.6 Occupancy requirements for buildings.

1.7 Historic site and building

1.8 Conduct of operations

1.9 Work restrictions

1.10 Archeological protection

1.11 Special construction

1.12 Soils investigation

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: The Corwin House is located at 2995 NY 97, Pond Eddy, New York 12770. It is part of the Upper Delaware Scenic and Recreational River.

B. The work consists of the following:

1. The work consists of the replacement of wood shake roof, EPDM roof, wood siding, door, gutter and downspouts and flashings at the Corwin House.

C. Project will be constructed under a single prime contract.

1.3 WORK UNDER OTHER CONTRACTS

A. General: Cooperate fully with separate contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate the Work of this Contract with work performed under separate contracts.

1.4 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of the site for construction operations. Limit use of premises to areas within the Contract limits indicated. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine constructions operations to the Corwin House. Out buildings including the Barn are not to be used for any purposes.

UPDE - 216560 01 11 00 - 2

2. Limit of area of disturbance will be provided by COR at preconstruction meeting.

B. Storage of Materials: Coordinate storage of materials with NPS UPDE project manager.

C. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with

Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

D. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to

Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

E. Construction Camp: Establishment of a camp within the park will not be permitted.

F. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.5 PUBLIC USE OF SITE

A. The building will be closed to the public during construction.

1.6 OCCUPANCY REQUIRMENTS FOR BUILIDINGS

A. Existing Buildings

1. Full Government Occupancy: Government will occupy buildings that will be under construction during the entire contract period. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform the Work so as not to interfere with Government's day-to-day operations. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from the CO.

UPDE - 216560 01 11 00 - 3

b. Maintain existing building in a weather tight condition throughout construction period. Repair damage caused by construction operations. Protect building and its occupants during construction period.

1.7 HISTORIC SITE AND BUILDING

A. The Contractor shall note the historical significance of the site and building at which the Work will be performed. Because of the historical nature of the site, certain aspects of the Work may not be executed with the materials and/or methods commonplace in the modern construction industry. It is incumbent upon the Contractor to furnish mechanics who can and will execute first-class workmanship in the materials and methods specified, and who will take the necessary precautions to protect the elements of this historical structure.

As of December 2019, per a management the decision, the Corwin Farm will now be called Cowen

Farm. It was discovered during the research for the Corwin Farm Historic Structures Report that it was a Cowen family, not a Corwin family that owned and developed the property in the 1800s during the operation of the Delaware and Hudson Canal. This property is eligible for listing on the National

Register of Historic Places.

1. See Division 01 section “HISTORIC PRESERVATION TREATMENT PROCEDURES” for further requirements.

1.8 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests 2 days in advance of the work to the

Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.9 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of

7:00 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend Hours: Permitted on a case-by-case basis as approved by the Contracting Officer with at least 2 days advance written notice.

2. Early Morning Hours: Permitted on a case-by-case basis as approved by the Contracting

Officer with at least 2 days advance written notice.

3. Hours for noisy activity will be allowed during normal business hours of 7:00 a.m. to 5:00 p.m., Monday through Friday, except when otherwise indicated

B. Existing Utilities

UPDE - 216560 01 11 00 - 4

1. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

2. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than 2 days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

3. Hours for Utility Shutdowns: Utility shutdowns shall only take place during regular business hours. Maximum utility shutdown shall not exceed four (4) hours.

D. Nonsmoking Building: Smoking is not permitted. The Historic Preservation Treatment Plan

Specification prohibits smoking by personnel performing work on or near the historic structure.

1.10 ARCHEOLOGIAL PROTECTION

A. Contractor is advised that there may be archeological remains in the area surrounding the site.

Artifacts, structural features, domestic and/or archaeological objects of nature, historic or prehistoric, above or sub-surface, found within the Project Area or otherwise on the premises, are and shall remain the property of the Government.

1. Contractor shall minimize disturbance of soil throughout the performance of the Work.

B. If archeological resources are discovered, Contractor shall stop work immediately and report the discover to the Government. Should this occur, Contractor shall relocate work activities to non-sensitive areas.

C. The Contractor shall plan, schedule, and execute the work to prevent stoppages due to discovery of archeological resources in one area from stopping all work at the construction site.

1.11 SPECIAL CONSTRUCTION REQUIREMENTS

A. Project Website: A project website administered by the NPS will be used for purposes of managing communication and documents during the construction stage.

1. See Section 01 31 00 “Project Management and Coordination” for requirements on using the Project Website.

B. The government and the public may occupy the public parking area and the orchard area at any time.

The house and the barn will be used by government employees during construction. Government employees will need daily access through the kitchen door. The barn doors and the road to the river must remain clear of obstructions at all times.

1.12 SOILS INVESTIGATION REPORT

A. A soils investigation report is required before and after all paint scrapping to test for lead.

UPDE - 216560 01 11 00 - 5

B. A copy of the report is available to all plan holders with this package.

C. If conflicts occur between the report and drawings or specifications, the drawings and specifications govern.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

UPDE - 216560 UNIT PRICES

01 22 00 - 1

SECTION 01 22 00 - UNIT PRICES

PART 1 GENERAL

1.1 SECTION INCLUDES

A. List of unit prices, for use in preparing Bids.

B. Measurement and payment criteria applicable to Work performed under a unit price payment method.

1.2 COSTS INCLUDED

A. Unit Prices included on the Bid Form shall include full compensation for all required labor, products, tools, equipment, plant, transportation, services and incidentals; erection, application or installation of an item of the Work; overhead and profit.

1.3 UNIT QUANTITIES SPECIFIED

A. Quantities indicated in the Bid Form are for bidding and contract purposes only. Quantities and measurements of actual Work will determine the payment amount.

1.4 MEASUREMENT OF QUANTITIES

A. Take all measurements and compute quantities. Measurements and quantities will be verified by COR.

B. Owner reserves the right to reject Contractor's measurement of work-in-place that involves use of established unit prices and to have this work measured, at Owner's expense, by an independent surveyor acceptable to Contractor. All quantities to be reviewed with the COR prior to performing work.

C. List of Unit Prices: A schedule of unit prices is attached as a separate document. Specification

Sections referenced in the schedule contain requirements for materials described under each unit price.

D. Assist by providing necessary equipment, workers, and survey personnel as required.

1.5 PAYMENT

A. Payment for Work governed by unit prices will be made on the basis of the actual measurements and quantities of Work that is incorporated in or made necessary by the Work and accepted by the COR, multiplied by the unit price.

UPDE - 216560 UNIT PRICES

01 22 00 - 2

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

END OF SECTION

UPDE - 21650 UNIT PRICES

01 22 00A

Instruction: The schedule below shall be submitted as an attachment to the Contract Price Schedule. The line item totals on this sheet should be incorporated into the total prices listed on the Contract Price

Schedule. Actual quantities may be greater or less than the estimated quantity below. Where actual quantities differ, the unit price listed below will be used to adjust the contract accordingly.

SCHEDULE OF UNIT PRICES

UNIT TITLE SPEC SECTION UNIT OF UNIT ESTIMATED TOTAL

PRICE MEASURE PRICE QUANTITY

NO. FOR

BIDDING

PURPOSES

ROOF

1 Roof Sheathing 06 10 00 Square Foot $ / 64 sq. ft. $ Replacement Rough Carpentry sq. ft.

SECTION TOTAL $

END OF SCHEDULE

UPDE - 216560 01 26 01 - 1

031414 CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

UPDE - 216560 01 26 01 - 2

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating

General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums , such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

UPDE - 216560 01 26 01 - 3

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General

Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that they are included in the hourly rate shown, or contractor is not requesting reimbursement.

Contractor may utilize the government provided Contractor Estimate Form, or their http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank http://www.nps.gov/dscw/publicforms.htm#ct

UPDE - 216560 01 26 01 - 4

own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. Requests for extensions of contract time as a result of this change must be justified with a Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction

Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the

Contractor waiving the right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

5. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work.

Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

UPDE - 216560 01 26 01 - 5

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals.

Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the

US Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

Utilize the Profit Calculator to generate the allowable maximum rate for Profit on self-performed work.

Insert the result below where indicated by the red X.XX%. Work collaboratively with the COR to produce the draft Profit Calculator for Design Development (DD) submission. Denver Service Center Contracting

Services division will approve the final number. Submit completed Profit Calculator with the DD submission.

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………10%

Profit………………X.XX%

2. Total aggregate limit of markup (OH&P) for contractor and subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

3. If contractors form a partnership, than the partnership may only receive home office overhead and profit in the same amount as an individual contractor (refer to par 1.3,E,1 above). It is the responsibility of the partners to decide on the division of revenue.

http://www.nps.gov/dscw/publicforms.htm#dt

UPDE - 216560 01 26 01 - 6

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, the overhead and profit mark-ups are required on the net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 012601

UPDE - 216560 01 27 00 - 1

082714 DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 0001: Base Bid

1. This item consists of all work for the roof construction, roof coverings, exterior walls, exterior doors. Included in this item is the exterior painting of all repaired in-kind and/or new work.

2. Measurement for payment will be percentage complete of line item per scheduled value.

3. Payment will be made at the contract lump sum price.

B. Contract Line Item No. 0002: Bid Option 1

1. This item consists of all work for the installation of stainless-steel gutters and downspouts.

2. Measurement for payment will be percentage complete of line item per scheduled value.

3. Payment will be made at the contract lump sum price.

END OF SECTION 01 27 00

UPDE - 216560 01 31 00 - 1

091015 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on

Project including, but not limited to, the following:

1.2 Definitions

1.3 Construction Coordination.

1.4 Submittals

1.5 Requests for Information (RFIs).

1.6 Project meetings.

1.7 Environmental Coordination.

Permits

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 DEFINITIONS

A. Agency with Jurisdiction

B. Construction Permits – Contractor Provided

C. Government Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

http://www.nps.gov/dscw/definitionsdc_a.htm#awj http://www.nps.gov/dscw/definitionsdc_c.htm#cpcp http://www.nps.gov/dscw/definitionsdc_g.htm#gfperm

UPDE - 216560 01 31 00 - 2

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Pre-installation conferences.

8. Project closeout activities.

1.4 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the

Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

10. Temporary Storm Water Pollution Prevention Plan (SWPP or UPPP).

11. Indoor Air Quality (IAQ) Management Plan.

12. Historic Preservation Treatment Plan.

13. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit.

b. The Agency(ies) with Jurisdiction issuing the permit.

c. Information required from the Government to complete the permit application.

B. All items listed must be provided to the Contracting Officer before the Pre-Construction

Conference is held. If all of these documents have not been received one week prior to the

UPDE - 216560 01 31 00 - 3

scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to Proceed will not be issued, and the Contracting Officer will consider other contractual remedies. Work shall not commence until written Notice to Proceed has been issued.

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the

Contract Documents, Contractor shall prepare and submit an RFI utilizing the form provided by the COR. RFI’s should be submitted through email to the email address provided at the preconstruction metting.

1. COR will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. RFI Form: Complete the RFI Form provided as follows:

1. Enter the general information at the top of the form.

2. Under the “Action” section at the bottom of the form, select “Question” then select “CMR” in the drop-down of the “Send to” box.

3. Enter the details of the question and attach related documents.

4. Select “Submit Form” at the bottom of the page.

D. Contracting Officer’s Action: COR will review each RFI, determine action required, and respond. COR will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

UPDE - 216560 01 31 00 - 4

d. Requests for coordination information already indicated in the Contract Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the

Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.6 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. Acceptance/rejection of work.

17. Progress meetings.

18. Submittal procedures.

19. NPS Final Accessibility Inspection.

20. Environmental requirements.

21. Permit requirements.

22. As-constructed drawings/operation and maintenance (O&M) manuals.

23. Saturday, Sunday, holiday and night work.

24. Reference materials.

25. Value engineering.

B. Progress Meetings: The Contracting Officer will schedule weekly meetings with the Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings. All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

UPDE - 216560 01 31 00 - 5

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise CO of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Review of mockups.

i. Possible conflicts.

j. Compatibility requirements.

k. Time schedules.

l. Weather limitations.

m. Manufacturer's written instructions.

n. Warranty requirements.

o. Compatibility of materials.

p. Acceptability of substrates.

q. Temporary facilities and controls.

r. Space and access limitations.

s. Regulations of agency(ies) with jurisdiction.

t. Testing and inspecting requirements.

u. Installation procedures.

v. Coordination with other work.

w. Required performance results.

x. Protection of adjacent work.

UPDE - 216560 01 31 00 - 6

y. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the Work and reconvene the conference at earliest feasible date.

1.7 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate an on-site party responsible for overseeing the

Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to those of this project; must be familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of the Waste Management Plan(WMP).

c. Implementation of the Indoor Air Quality (IAQ) Management Plan.

d. Implementation of the Storm Water Pollution Prevention Plan(SWPPP).

e. Present an overview of environmental issues and summarize site specific procedures relating to management plans at the Preconstruction conference.

f. Training for Contractor personnel in accordance with their position requirements.

g. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. 01 40 00 - Quality Requirements.

2. 01 42 00 – Reference Standards

3. 01 74 19 - Construction Waste Management.

C. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on the project site. Training shall include the following:

1. Overview of environmental issues related to the building industry.

2. Overview of environmental issues related to the Project.

3. Review of site specific procedures and management plans:

a. Construction Waste Management.

4. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Contractor 40 CFR employee training records upon request of Contracting Officer.

UPDE - 216560 01 31 00 - 7

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

UPDE - 216560 01 32 16 - 1

031414 CONSTRUCTION SCHEDULE

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1.2 Definitions

1.3 Submittals

1.4 Quality assurance

1.5 Coordination

2.1 Schedule of Values

2.2 Construction Schedule Requirements.

3.1 Construction Schedule Updates.

3.2 Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The Construction

Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the

Contractor but is jointly owned.

UPDE - 216560 01 32 16 - 2

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

B. Construction Baseline Schedule: After contract award and before the Pre-Construction conference, submit 3 paper copies of baseline schedule, large enough to show entire schedule for entire construction period.

C. CPM Reports: Concurrent with CPM schedule, submit 3 paper copies of each of the following computer-generated reports. Format for each activity in reports shall contain activity number, activity description, resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity Report: List of all activities sorted by activity number and then early start date, or actual start date if known.

2. Logic Report: List of predecessor and successor tasks for all activities, sorted in ascending order by activity number and then early start date, or actual start date if known.

3. Total Float Report: List of all activities sorted in ascending order of total float.

D. Construction Schedule Updates: On or before the 7th day preceding the progress payment request date, submit estimates of the percent completion of each schedule activity and necessary supporting data. Provide two paper copies.

E. Construction Schedule Revisions and Time Impact Analysis: For each Construction Schedule revision submit 3 paper copies of a Time Impact Analysis. Each Time Impact Analysis shall include a Fragmentary Network (Fragnet), incorporated into the currently accepted Construction

Schedule, demonstrating how the Contractor proposes to incorporate a modification, change, delay, or Contractor request.

1.4 QUALITY ASSURANCE

A. The Contractor shall meet with the Contracting Officer on the day of the preconstruction conference to go over the following:

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Discuss constraints

UPDE - 216560 01 32 16 - 3

4. Review delivery dates for Government-furnished products.

5. Review schedule for work of separate Government contracts.

6. Review time required for review of submittals and re-submittals.

7. Review requirements for tests and inspections by independent testing and inspecting agencies.

8. Review time required for completion and startup procedures.

9. Review time required for obtaining and activating permits.

10. Review and finalize list of construction activities to be included in schedule.

11. Review baseline schedule comments, resolve issues and progress on incorporating them

12. Review procedures for updating schedule.

13. Discuss reporting requirements and establish a protocol for naming and transmitting electronic schedules.

B. Contractor's Schedule Representative: Before or at the preconstruction conference, designate an authorized representative to be responsible for the preparation and maintenance of the

Construction Schedule. A resume outlining the qualifications of the Scheduler shall be submitted to the Contracting Officer for acceptance. The Scheduler shall have prepared and maintained at least 5 previous schedules of similar size and complexity similar to this Contract, demonstrating proficiency in the use of scheduling software. The authorized representative will be responsible for preparing the Baseline Schedule, all required updates, revisions, Time Impact Analyses, and preparation of reports.

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing the Construction Baseline Schedule, ensure that the Subcontractor’s work at all tiers, as well as the prime Contractor’s work, is included and coordinated.

2. Secure time commitments for performing critical elements of the Work from parties involved.

3. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

PART 2 - PRODUCTS

2.1 SCHEDULE OF VALUES

A. Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. Include mobilization, general condition costs, overhead and profit in the total dollar

UPDE - 216560 01 32 16 - 4

value of unit price items and in the component work activities for each lump-sum item. Do not include mobilization, general condition costs, overhead or profit as a separate item.

B. Do not break down unit price items. Use only the contract price for unit price items.

C. The total cost of all items shall equal the contract price. The Schedule of Values will form the basis for progress payments.

D. An acceptable Schedule of Values shall be agreed upon by the Contractor and Contracting Officer before the first progress payment is processed.

2.2 CONSTRUCTION SCHEDULE REQUIREMENTS

A. Construction Baseline Schedule: Prepare Construction Baseline Schedule using a computerized, resource-loaded, time-scaled CPM network analysis diagram for the Work.

1. Develop and finalize Construction Baseline Schedule so it can be accepted for use no later than 30 days after date established for the Notice of Award.

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing all work within applicable completion dates, regardless of Governments acceptance of the schedule.

2. Establish procedures for monitoring and updating Construction Baseline Schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

B. Construction Baseline Schedule Preparation: Prepare a list of all activities required to complete the Work. Using the preliminary CPM network diagram, prepare a skeleton network to identify probable critical paths.

1. Activities: Indicate the estimated duration, sequence requirements, and relationship of each activity in relation to other activities.

2. Critical Path Activities: Identify critical path…