8-2411.1 Gallatin 2 CD-B BID.pdf

CVR-B

cover sheet

31 july 2025 drawing no.project directory

No. Date Issue Notes gallatin school renovations city mission living stones

155 n gallatin ave uniontown pa 15401

155 n gallatin ave uniontown pa 15401 renovations phase 2

© copyright 2025 lee CALISTI architecture+design all rights reserved this drawing is an instrument of service and is not to be reproduced or used without prior expressed written consent of lee CALISTI architecture+design.

leecalisti.com

24 cypress avenue greensburg pa 15601

724 832 7030 lee@leecalisti.comlee CALISTI architecture+design

2411.1project no.

THESE DRAWINGS AND THE INCLUDED SPECIFICATIONS ARE PART OF A COMPLETE SET OF DOCUMENTS. THE BREAKDOWN OF DRAWINGS AND SPECIFICATIONS INTO INDIVIDUAL SHEETS AND SECTIONS SHALL NOT DETERMINE THE RESPONSIBILITY FOR THE WORK OF INDIVIDUAL CONTRACTORS. ALL CONTRACTORS (GENERAL CONTRACTOR, SUB-CONTRACTORS, TRADESPERSONS) MUST REVIEW ALL PARTS OF THE DRAWINGS AND SPECIFICATIONS TO CONFIRM THE FULL SCOPE OF WORK.

SUB-CONTRACTORS ARE RESPONSIBLE FOR THEIR RESPECTIVE SCOPES OF WORK REGARDLESS OF WHICH PAGE OF THIS SET THE WORK MAY APPEAR. THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DISTRIBUTING FULL SETS OF DRAWINGS TO ALL THE SUB-CONTRACTORS.

THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DETERMINING THE LIMIT OR EXTENT OF THE WORK OF INDIVIDUAL TRADES AND SHALL FULLY

COORDINATE ALL THEIR ACTIVITY AND INFORM THE SUB-CONTRACTORS.

LEE CALISTI RA - 014425-X

RE

GISTERED ARCHITECT

PENNSYLVANIA

Issued for BID7/31/2025A north architect lee CALISTI architecture+design lee calisti, aia

24 cypress avenue greensburg, pa 15601

724.832.7030 lee@leecalisti.com project directory owner city mission living stones irmi gaut

155 north gallatin avenue uniontown, pa 15401

724.439.0201 igaut@citymissionfayette.org leecalisti.com citymissionfayette.org

GENERAL BUILDING OPERATION NOTES

1.

2.

3.

4.

5.

THE OWNER IS CURRENTLY OCCUPYING THE BUILDING AND WILL CONTINUE TO DO SO

THROUGHOUT THE RENOVATIONS. BASED ON GC’S CONSTRUCTION SCHEDULE, THE

OWNER WILL GRANT ACCESS TO INDIVIDUAL APARTMENTS SO THAT THE GC CAN

COMPLETE THE RENOVATIONS TO THAT AREA. SUBMIT AN INITIAL CONSTRUCTION

SCHEDULE ALONG WITH THEIR PROJECT BID.

NO UNUSUAL, INVASIVE, OR EXCEPTIONALLY NOISY WORK OR CONSTRUCTION

OPERATIONS ARE PERMITTED BETWEEN THE HOURS OF 9:00 AM AND 4:00 PM.

COORDINATE ALL NECESSARY INSTALLATIONS AND PROCESSES THAT EMIT LOUD

NOISE OUTSIDE OF THIS TIME FRAME. COORDINATE ANY SPECIAL CIRCUMSTANCES

WITH LANDLORD/OWNER.

TAKE MEASURES NOT TO INCONVENIENCE ANY RESIDENT OR NORMAL OCCUPANTS.

PERMIT OCCUPANTS PRIORITY IN USING ELEVATORS, STAIRS AND ACCESS IN AND

OUT OF BUILDING.

THIS IS A NON-SMOKING BUILDING AND NON-SMOKING SITE. NO SMOKING IS

PERMITTED ANYWHERE ON THE PROPERTY.

DUMPSTER - COORDINATE PLACEMENT OF DUMPSTER WITH THE OWNER IN FIELD.

drawing list

Dwg No Dwg Name 1 Dwg Name 2 Issue No Latest

Issue Date

ARCHITECTURAL

CVR-B cover sheet project directory A 31 july 2025

C2 survey reference only A 31 july 2025

A003 specifications divisions 06 - 09 A 31 july 2025

A201 floor plans key plans for reference A 31 july 2025

A300 elevations masonry restoration A 31 july 2025

A400 window details A 31 july 2025 gallatin school - phase 2 renovations - project B

SITE

THIS PROJECT IS FINANCED IN PART BY A GRANT FROM THE REDEVELOPMENT ASSISTANCE CAPITAL PROGRAM (RACP IN COOPERATION WITH THE CITY OF UNIONTOWN, REDEVELOPMENT AUTHORITY, AND IS SUBJECT TO ALL RELATED RACP REGULATIONS. THE PENNSYLVANIA PREVAILING WAGE ACT WILL APPLY TO THIS CONTRACT. THE CONTRACT DOCUMENTS CONTAIN REQUIREMENTS ADDRESSING LABOR WAGE RATES, LABOR STANDARDS, NONDISCRIMINATION IN HIRING PRACTICES, GOALS FOR MINORITY AND FEMALE PARTICIPATION, MBE AND WBE PARTICIPATION, PARTICIPATION BY SECTION 3 RESIDENTS AND BUSINESSES, PROHIBITION ON EMPLOYING

ILLEGAL ALIENS, AND RELATED MATTERS.

ALL CONTRACTORS AND SUBCONTRACTORS WORKING ON THIS PROJECT WILL BE REQUIRED TO COMPLY WITH THE PENNSYLVANIA HUMAN RELATIONS ACT (NO. 222, PA), THE STEEL PRODUCTS PROCUREMENT ACT, THE TRADE PRACTICES ACT, AND THE AMERICANS WITH DISABILITIES ACT. THEY MUST MEET GUIDELINES AND PRACTICES ESTABLISHED BY THE REDEVELOPMENT AUTHORITY AND CITY MISSION AND ALL OTHER APPROPRIATE REGULATIONS, INCLUDING: 1) EXECUTIVE ORDER 11246, 2) SECTION 3 OF THE HOUSING AND COMMUNITY DEVELOPMENT ACT OF 1968, AS AMENDED. BIDDERS SHALL CERTIFY THAT THEY ARE NOT DEBARRED FROM

PARTICIPATING IN STATE-FUNDED CONTRACTS.

THE REDEVELOPMENT AUTHORITY AND THE CITY MISSION DO NOT DISCRIMINATE REGARDING RACE, COLOR, RELIGION, SEX, ANCESTRY, MARITAL STATUS, DISABILITY OR THE USE OF A GUIDE OR SUPPORT ANIMAL BECAUSE OF PHYSICAL HANDICAP, OR AGE, IN THE PROVISION, ADMISSION, EMPLOYMENT, SEXUAL ORIENTATION, NATIONAL ORIGIN, GENDER IDENTITY OR EXPRESSION, FAMILY RESPONSIBILITY OR FAMILIAL STATUS.

https://www.leecalisti.com/ https://www.citymissionfayette.org

C2 survey

31 july 2025 drawing no.reference only

No. Date Issue Notes gallatin school renovations city mission living stones

155 n gallatin ave uniontown pa 15401

155 n gallatin ave uniontown pa 15401 renovations phase 2

© copyright 2025 lee CALISTI architecture+design all rights reserved this drawing is an instrument of service and is not to be reproduced or used without prior expressed written consent of lee CALISTI architecture+design.

leecalisti.com

24 cypress avenue greensburg pa 15601

724 832 7030 lee@leecalisti.comlee CALISTI architecture+design

2411.1project no.

THESE DRAWINGS AND THE INCLUDED SPECIFICATIONS ARE PART OF A COMPLETE SET OF DOCUMENTS. THE BREAKDOWN OF DRAWINGS AND SPECIFICATIONS INTO INDIVIDUAL SHEETS AND SECTIONS SHALL NOT DETERMINE THE RESPONSIBILITY FOR THE WORK OF INDIVIDUAL CONTRACTORS. ALL CONTRACTORS (GENERAL CONTRACTOR, SUB-CONTRACTORS, TRADESPERSONS) MUST REVIEW ALL PARTS OF THE DRAWINGS AND SPECIFICATIONS TO CONFIRM THE FULL SCOPE OF WORK.

SUB-CONTRACTORS ARE RESPONSIBLE FOR THEIR RESPECTIVE SCOPES OF WORK REGARDLESS OF WHICH PAGE OF THIS SET THE WORK MAY APPEAR. THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DISTRIBUTING FULL SETS OF DRAWINGS TO ALL THE SUB-CONTRACTORS.

THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DETERMINING THE LIMIT OR EXTENT OF THE WORK OF INDIVIDUAL TRADES AND SHALL FULLY

COORDINATE ALL THEIR ACTIVITY AND INFORM THE SUB-CONTRACTORS.

LEE CALISTI RA - 014425-X

RE

GISTERED ARCHITECT

PENNSYLVANIA

Issued for BID7/31/2025A

X X

XXX

XX

CO

NC

. W

AL

K

CR

OW

A

VE

NU

E

(B

IT

UM

IN

OU

S)

X

X X

X X

NO

RT

H

GA

LL

AT

IN

A

VE

NU

E (B

IT

UM

IN

OU

S)

MILLVIEW STREET

(BITUMINOUS)

N65° 21' 45"W 90.00'90.00'

N24° 37' 06"E

76.29'

S65° 21' 45"E 90.00'

N2 4°

8'

5"

E

.8

6'

S65° 23' 52"E 118.80'

N2 4°

8'

5"

E

.0

6'

75.39' S65° 21' 45"E

73.00'

S24° 37' 06"W

107.92'

S2 4°

7'

6"

W

.2

9'

N2 4°

7'

6"

E

.2 9'

N65° 21' 45"W 73.00'

N65° 21' 45"W 83.43' N24º 37' 06"E

107.95'

LOT 3

CITY MISSION PLAN OF LOTS

6,866 SQ. FT.

0.16 ACRE

P.B. 109 PG. 15

LOT 4

CITY MISSION PLAN OF LOTS

6,866 SQ. FT.

0.16 ACRE

P.B. 109 PG. 15

LOT 2

CITY MISSION PLAN OF LOTS

8,809 SQ. FT.

0.20 ACRE

P.B. 109 PG. 15

LOT 1

CITY MISSION PLAN OF LOTS

7,878 SQ. FT.

0.18 ACRE

P.B. 109 PG. 15

N/F

CITY MISSION

TAX ID: 38-01-0087

RB. 2920 P. 806

8.28%

979.2 X

ALLEY

SS

EX

. B

LO

CK

W

AL

L

EX ASPHALT WEDGE CURB

CO

NC

. W

AL

K

0.129 acres 38-01-0087

187 N GALLATIN AVE

140'0" N 64°00'00" W

'0

N

°0

0'

E

140'0" S 64°00'00" E

'0

S

°0

0'

W

140'0" N 64°00'00" W

PHASE 3

MISSION PLACE BLDG. 3

FF = 978.70'

974.00

973.50

975.06

973.28

975.70

975.07

973.03 971.66

972.72

972.78

978.51

978.53

978.16 978.34

978.68

978.91

977.75 977.07

977.84

978.14

979.09978.51

985.45 983.48

979.33

978.76

984.27

987.49

982.84

988.81 988.00

984.63

984.35 985.52

985.56

984.61

980.88

979.44

979.94

980.34

981.32

985.15

980.79

979.52

980.76

TOP OF WALL

EL.=978.66

9 SPACES

9 SPACES

9 SPACES

9 SPACES

8 SPACES

DO

UB

LE

Y

EL

LO

W L

IN

E

R I

GH

T-

OF

-W

AY

EX BITUMINOUS PARKING LOT

NORTH GALLATIN AVENUE

(BITUMINOUS)

LOT 2

CITY MISSION PLAN OF LOTS

6,866 SQ. FT. / 0.16 ACRE

P.B. 109 PG. 15

CITY MISSION LIVING STONES, INC

TAX ID: 38-01-0326-01

P.B. 109 PG. 15

ALLEY

N/F

KOVAL RENTALS

TAX ID: 38-01-0082

RB. 3353 P. 1648

N/F

INDUSTRIAL REALTY, INC.

TAX ID: 38-04-0296

RB. 1323 P. 241

CONC. WALK

CONC. WALK

EX CONC. WALK

MB

EX ASPHALT DRIVE

EDGE OF EX.

BITUMINOUS

PAVEMENT

EDGE OF BITUMINOUS EX.

PAVEMENT

EDGE OF BITUMINOUS EX.

PAVEMENT

EX

. B

LO

CK

W

AL

L

FF ELEV: 992.86

(OUTSIDE)

N/F

CITY MISSION LIVING STONES, INC.

TAX ID: 38-01-0326

RB. 3482 P. 522

AREA: 9406 SQ. FT.; 0.22 ACRES

EX. BLOCK

WALL

EX

. W

AL

L

WALL CONTINUES IN

SOUTHERLY DIRECTION

OH ELEC

OH ELEC

OH ELEC

OH

E

LE

C

OH

E

LE

C

OH

E

LE

C

OH ELEC

XFMRUE

UE

UE

UE

UE UE UE UE UE

UE

UE

UE

UE UE UE UE

GLM

GA

S

GA

S

GA

S

GA

S

GA

S

GA

S

GA

S

GAS

GAS

GAS

GA

S

COLUM

BIA GAS 4" P-LP

CO

LU

M

BI

A

GA

S 6"

P -L

P

CO

LU

M

BI

A

GA

S

P-

LP

5+

LF

o f 1

2" V

CP

.7

4%

SAN

SA

N

EX 6" SDR35 AT 1/8"/ft (1.0%)

CO

COS

S

CO

4" PVC

8" CLAY 8"

C

LA

Y

8" C

LA

Y

EX. SAN MH

TOP 984.14

INV 975.94 (12" CLAY)

INV 975.94 (12" CLAY)

INV 975.84 (12" CLAY)

EX. SAN MH

TOP 989.69

INV 983.69

NE

W 6"

SD

R3

5 A T 1

/8"

/FT

(M

IN)

SE

E C

IVI

L

EX. SAN MH

TOP 972.57

INV. IN: 962.67 (8" CLAY)

INV. IN: 965.57 (8" CLAY)

INV. IN: 969.37 (4" PVC-DROP)

INV. OUT: 962.57 (8" CLAY)

CORE DRILL NEW PIPE

PENETRATION AND INSTALL

PIPE & SEAL (SEE CIVIL)

EX. SAN MH

TOP 973.01

INV. OUT:

965.31

EX. CLEANOUT

4" PVC IN WALL

EL. 972.09

EX. SAN MH

TOP 973.01

INV. OUT:

965.31

EX. INLET

STM

STM

STM

STM

ST

M

ST

M

ST

M

STM

EX. INLET

ST

M

STM

ST

M

LEVEL SPREADER

6" SCH40 ROOF DRAIN 1/8"/ft (MIN)

6" S

CH

R

OO

F

DR

AI

N

1/ 8"

/F T

(M

IN

20LF OF PERF. 15" PVC

INV.=973.5

ROUTE ROOF DRAINS TO LEVEL SPREADER

EX. 8" CPP

INV OUT 984.21

EX. 15" SLCPP

INV OUT 983.14

W W

W

W

W W

WV

WV

W V

WV

W V

W W

W W

W

W

W

EX

W

AT

ER

V

AU

LT

EX MANIF.

W W

W

W W

W W

W

W W

W W W W W W

PA AM

ERICAN W

ATER

W

W

W W W

EXTEND EXISTING WATER

SERVICE TO BLDG 3

CONNECT NEW WATER

SERVICE LINE TO EXISTING

WATER LINE AT THIS

LOCATION

EX ASPHALT WEDGE CURB

OH ELEC OH ELEC

118.82' N64° 11' 46"W

EX ASPHALT DRIVE

MISSION PLACE BLDG. 1

FF: 987.3

MISSION PLACE BLDG. 2

FF: 990.5

CONDUIT

CONDUIT

OH

E

LE

C

N65° 21' 45"W 90.00'90.00'

WV

WV

GALLATIN SCHOOL

CITY MISSION PLAN OF LOTS

41,708 SQ. FT.

0.96 ACRE

P.B. 109 PG. 15

RI

GH

T-

OF

-W

AY

EXISTING

TRANSFORMER

BU

S

ST

OP

SH

ED

EX.CONC. WALK

EX GENERATOR

SURVEY EX - GALLATIN SCHOOL

Scale: 1/16" = 1'-0"

C2

PROJECT SITE

PROTECT ALL EXISTING SITE FEATURES DURING

CONSTRUCTION. ALL DAMAGE CAUSED DUE TO THIS

CONSTRUCTION SHALL BE REPLACED TO MATCH

ORIGINAL CONDITION BY THIS CONTRACTOR.

GENERAL SITE NOTES

A.

B.

C.

ALL SURVEY INFORMATION IS BASED ON A SURVEY TITLED "UNIONTOWN CITY MISSION, OVERALL EXISTING CONDITIONS PLAN" CITY OF UNIONTOWN, FAYETTE COUNTY, PA, DATED 03/25/2025 BY HARSHMAN CE GROUP LLC, 100 COURSON HILL ROAD, WASHINGTON PA 15301 (724) 503-4125, PROJECT NO. 23.032.01 / DRAWING NO 23.032-C01 (SHEET NUMBER 2 OF 9)

PLAT IS ZONED C-1 LOCAL BUSINESS DISTRICT / BUILDING SETBACKS (PER VARIANCE) - REFER TO

APPROVED LAND DEVELOPMENT PLAN - AVAILABLE UPON REQUEST

FIELD VERIFY ALL PERTINENT SITE FEATURES IS RECOMMENDED. CONFIRM ALL TOPOGRAPHIC BENCH

MARKS WITH SURVEYOR IN FIELD AND NOTIFY ARCHITECT IMMEDIATELY OF ANY AND ALL

DISCREPANCIES.

A003 specifications

31 july 2025 drawing no.divisions 06 - 09

No. Date Issue Notes gallatin school renovations city mission living stones

155 n gallatin ave uniontown pa 15401

155 n gallatin ave uniontown pa 15401 renovations phase 2

© copyright 2025 lee CALISTI architecture+design all rights reserved this drawing is an instrument of service and is not to be reproduced or used without prior expressed written consent of lee CALISTI architecture+design.

leecalisti.com

24 cypress avenue greensburg pa 15601

724 832 7030 lee@leecalisti.comlee CALISTI architecture+design

2411.1project no.

THESE DRAWINGS AND THE INCLUDED SPECIFICATIONS ARE PART OF A COMPLETE SET OF DOCUMENTS. THE BREAKDOWN OF DRAWINGS AND SPECIFICATIONS INTO INDIVIDUAL SHEETS AND SECTIONS SHALL NOT DETERMINE THE RESPONSIBILITY FOR THE WORK OF INDIVIDUAL CONTRACTORS. ALL CONTRACTORS (GENERAL CONTRACTOR, SUB-CONTRACTORS, TRADESPERSONS) MUST REVIEW ALL PARTS OF THE DRAWINGS AND SPECIFICATIONS TO CONFIRM THE FULL SCOPE OF WORK.

SUB-CONTRACTORS ARE RESPONSIBLE FOR THEIR RESPECTIVE SCOPES OF WORK REGARDLESS OF WHICH PAGE OF THIS SET THE WORK MAY APPEAR. THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DISTRIBUTING FULL SETS OF DRAWINGS TO ALL THE SUB-CONTRACTORS.

THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DETERMINING THE LIMIT OR EXTENT OF THE WORK OF INDIVIDUAL TRADES AND SHALL FULLY

COORDINATE ALL THEIR ACTIVITY AND INFORM THE SUB-CONTRACTORS.

LEE CALISTI RA - 014425-X

RE

GISTERED ARCHITECT

PENNSYLVANIA

Issued for BID7/31/2025A

08251 - ALUMINUM CLAD WOOD WINDOWS

1.

2.

3.

4.

5.

6.

7.

8.

9.

10.

SECTION INCLUDES: ALUMINUM-CLAD WOOD SINGLE HUNG AND FIXED WINDOWS.

REFERENCES:

A. AMERICAN ARCHITECTURAL MANUFACTURERS ASSOCIATION (AAMA):

1).AAMA 2603 - VOLUNTARY SPECIFICATION, PERFORMANCE REQUIREMENTS AND TEST PROCEDURES

FOR PIGMENTED ORGANIC COATINGS ON ALUMINUM EXTRUSIONS AND PANELS.

2). AAMA 2605 - VOLUNTARY SPECIFICATION, PERFORMANCE REQUIREMENTS AND TEST PROCEDURES

FOR SUPERIOR PERFORMING ORGANIC COATINGS ON ALUMINUM EXTRUSIONS AND PANELS.

B. AMERICAN SOCIETY FOR TESTING AND MATERIALS (ASTM):

1). ASTM B 117 - OPERATING SALT SPRAY (FOG) APPARATUS.

2). ASTM C 1036 - FLAT GLASS.

3). ASTM C 1048 - HEAT-TREATED FLAT GLASS KIND HS, KIND FT COATED AND UNCOATED GLASS.

4). ASTM D 1149 - RUBBER DETERIORATION SURFACE OZONE CRACKING IN A CHAMBER.

5). ASTM D 2803 - FILIFORM CORROSION RESISTANCE OF ORGANIC COATINGS ON METAL.

6). ASTM D 3656 - INSECT SCREENING AND LOUVER CLOTH WOVEN FROM VINYL-COATED GLASS

YARNS.

7). ASTM D 4060 - ABRASION RESISTANCE OF ORGANIC COATINGS BY THE TABER ABRASER.

8). ASTM E 283 - RATE OF AIR LEAKAGE THROUGH EXTERIOR WINDOWS, CURTAIN WALLS AND DOORS

UNDER SPECIFIED PRESSURE DIFFERENCE ACROSS THE SPECIMEN.

9). ASTM E 330 - STRUCTURAL PERFORMANCE OF EXTERIOR WINDOWS, CURTAIN WALLS AND DOORS

BY UNIFORM STATIC AIR PRESSURE DIFFERENCE.

10). ASTM E 547 - WATER PENETRATION OF EXTERIOR WINDOWS, CURTAIN WALLS AND DOORS BY

CYCLIC STATIC AIR PRESSURE DIFFERENTIAL.

C. WINDOW AND DOOR MANUFACTURERS ASSOCIATION (WDMA):

1). AAMA/WDMA/CSA 101/I.S.2/A440 NORTH AMERICAN FENESTRATION STANDARD/SPECIFICATION FOR

WINDOWS, DOORS AND SKYLIGHTS

2). WDMA I.S.4 - INDUSTRY SPECIFICATION FOR PRESERVATIVE TREATMENT FOR MILLWORK.

PERFORMANCE REQUIREMENTS:

A. WINDOWS SHALL BE HALLMARK CERTIFIED TO A RATING OF H-CW30 CW50 SPECIFICATIONS IN ACCORDANCE WITH ANSI/AAMA/WDMA 101/I.S.2/A440-08 OR ANSI/AAMA/WDMA 101/I.S.2/A440-11.

B. WINDOW UNIT AIR LEAKAGE, ASTM E 283, 1.57 PSF (25 MPH): 0.05 CFM PER SQUARE FOOT OF

FRAME OR LESS.

C. WINDOW UNIT WATER PENETRATION: NO WATER PENETRATION THROUGH WINDOW UNIT WHEN

TESTED IN ACCORDANCE WITH ASTM E 547, UNDER STATIC PRESSURE OF 7.5 PSF (52 MPH) AFTER 4 CYCLES OF 5 MINUTES EACH, WITH WATER BEING APPLIED AT A RATE OF 5 GALLONS PER HOUR PER

SQUARE FOOT.

SUBMITTALS:

A. COMPLY WITH DIVISION 01 REQUIREMENTS.

B. PRODUCT DATA: SUBMIT MANUFACTURER'S PRODUCT DATA, INCLUDING INSTALLATION

INSTRUCTIONS.

C. SHOP DRAWINGS: SUBMIT MANUFACTURER'S SHOP DRAWINGS, INDICATING DIMENSIONS,

CONSTRUCTION, COMPONENT CONNECTIONS AND LOCATIONS, ANCHORAGE METHODS AND

LOCATIONS, HARDWARE LOCATIONS, AND INSTALLATION DETAILS.

D. SAMPLES: SUBMIT SAMPLES (2 MINIMUM) OF WINDOW COLOR OF FINISH.

E. WARRANTY: SUBMIT MANUFACTURER'S STANDARD WARRANTY.

QUALITY ASSURANCE: MOCKUP:

A. PROVIDE (IN PLACE) APPROVED MOCKUP SHALL REPRESENT MINIMUM QUALITY REQUIRED FOR

THE WORK.

B. APPROVED MOCKUP SHALL REMAIN IN PLACE WITHIN THE WORK

DELIVERY, STORAGE, AND HANDLING:

A. DELIVERY: DELIVER MATERIALS TO SITE UNDAMAGED IN MANUFACTURER'S OR SALES BRANCH'S

ORIGINAL, UNOPENED CONTAINERS AND PACKAGING, WITH LABELS CLEARLY IDENTIFYING

MANUFACTURER AND PRODUCT NAME. INCLUDE INSTALLATION INSTRUCTIONS.

B. STORAGE: STORE MATERIALS IN AN UPRIGHT POSITION, OFF GROUND, UNDER COVER, AND

PROTECTED FROM WEATHER, DIRECT SUNLIGHT, AND CONSTRUCTION ACTIVITIES.

C. HANDLING: PROTECT MATERIALS AND FINISH DURING HANDLING AND INSTALLATION TO PREVENT

DAMAGE.

PRODUCTS / MANUFACTURER: PELLA CORPORATION - ALL ORDERS MUST GO THROUGH RICK FUNK, COMMERCIAL SEGMENT MANAGER, PELLA WINDOW AND DOOR CO., 230 THORN HILL RD., WARRENDALE, PA 15086, MOBILE: (412) 874-6036, PROFESSIONAL.PELLA.COM

ALUMINUM-CLAD WOOD SINGLE-HUNG WINDOWS: PELLA RESERVE TRADITIONAL

FACTORY-ASSEMBLED ALUMINUM-CLAD WOOD SINGLE-HUNG WINDOWS. SASH SHALL TILT TO THE

INTERIOR WITHOUT REMOVAL FOR CLEANING.

A. FRAME:

1). SELECT SOFTWOOD, WATER-REPELLENT, PRESERVATIVE-TREATED WITH ENDURAGUARD IN

ACCORDANCE WITH WDMA I.S.-4. ENDURAGUARD INCLUDES WATER-REPELLENCY, THREE ACTIVE

FUNGICIDES AND AN INSECTICIDE APPLIED TO THE FRAME.

2). INTERIOR EXPOSED SURFACES: CLEAR PINE [PRE-FINISHED] WITH NO VISIBLE FASTENER HOLES.

3). EXTERIOR SURFACES: CLAD WITH ALUMINUM.

B. OVERALL FRAME DEPTH: 5 INCHES (127 MM).

C. SASH:

1). SELECT SOFTWOOD, WATER WATER-REPELLENT, PRESERVATIVE-TREATED WITH ENDURAGUARD IN ACCORDANCE WITH WDMA I.S.-4. ENDURAGUARD INCLUDES WATER-REPELLENCY, THREE ACTIVE

FUNGICIDES AND AN INSECTICIDE APPLIED TO THE SASH.

2). INTERIOR EXPOSED SURFACES: CLEAR PINE [PRE-FINISHED] WITH NO VISIBLE FASTENER HOLES.

3). EXTERIOR SURFACES: CLAD WITH ALUMINUM, LAP-JOINTED AT CORNERS.

D. CORNERS: MORTISED AND TENONED, GLUED AND SECURED WITH METAL FASTENERS.

4). OPERABLE SASH TILT TO INTERIOR FOR CLEANING OR REMOVAL.

5). EXTRUDED ACRYLONITILE BUTADIENE STYPRENE GLAZING FLANGE. FLANGE IS LOCATED ON TOP

OF WOOD SASH MEMBERS AND UNDER EXTERIOR ALUMINUM CLADDING.

6). SASH THICKNESS: 1-3/4 INCHES

D. WEATHER STRIPPING:

1). FOAM WITH 3-MIL VINYL SKIN AT FRAME HEAD AND AT LOWER SASH BOTTOM RAIL.

2). THERMAL-PLASTIC ELASTOMER WITH SLIP-COATING SET INTO UPPER SASH FOR TIGHT CONTACT

AT CHECKRAIL.

3). SECONDARY POLYVINYL CHLORIDE (PVC) LEAF-TYPE WEATHER STRIP ON BOTTOM SASH AT SILL.

ALUMINUM-CLAD WOOD FIXED-FRAME WINDOWS: PELLA FACTORY-ASSEMBLED, ALUMINUM-CLAD

WOOD, FIXED-FRAME WINDOWS.

A. FRAME:

1). SELECT WOODS, WATER-REPELLENT, PRESERVATIVE-TREATED WITH ENDURAGUARD® IN

ACCORDANCE WITH WDMA I.S.-4. ENDURAGUARD INCLUDES WATER-REPELLENCY, THREE ACTIVE

FUNGICIDES AND AN INSECTICIDE APPLIED TO THE FRAME.

2). INTERIOR EXPOSED SURFACES: CLEAR PINE [PRE-FINISHED] WITH NO VISIBLE FASTENER HOLES.

3). EXTERIOR SURFACES: CLAD WITH ALUMINUM.

4). ASSEMBLED WITH SCREWS.

B. OVERALL FRAME DEPTH: 5 INCHES (127 MM).

GLAZING:

A. FLOAT GLASS: ASTM C 1036, QUALITY 1. TEMPERED GLASS: ASTM C 1048, WHERE REQUIRED BY

2018 IBC AT ALL HAZARD AREAS. REVIEW WITH ARCHITECT IN FIELD.

B. TYPE: SILICONE-GLAZED 11/16-INCH DUAL-SEAL, ANNEALED [TEMPERED WHERE REQUIRED BY CODE REVIEW LOCATIONS IN FIELD WITH ARCHITECT] INSULATING GLASS, MULTI-LAYER, ADVANCE

LOW-E COATED WITH ARGON

11.

12.

13.

14.

15.

16.

17.

18.

19.

20.

OPTIONS:

A. HUNG INSECT SCREENS: STANDARD

1). HALF-SIZE BLACK VINYL-COATED 18/18 MESH FIBERGLASS SCREEN CLOTH COMPLYING WITH THE

PERFORMANCE REQUIREMENTS OF SMA 1201, SET IN A STANDARD ROLL-FORM ALUMINUM FRAME

FITTED TO OUTSIDE OF WINDOW, SUPPLIED COMPLETE WITH ALL NECESSARY HARDWARE

2). FULL SCREEN SPREADER BAR PLACED ON UNITS > 37" WIDTH OR > 65" HEIGHT.

3).SCREEN FRAME FINISH IS STANDARD SCREEN: BAKED ENAMEL, COLOR TO MATCH WINDOW

CLADDING.

B. INSECT SCREENS: DOUBLE-HUNG HIDDEN SCREEN (SEE BID ALTERNATE)

1). COMPLIANCE: ASTM D 3656 AND SMA 1201.

2). SCREEN CLOTH: BLACK VINYL-COATED FIBERGLASS, 18/18 MESH.

3). SET IN EXTERIOR MOUNTED ALUMINUM CHANNELS WITH RETRACTABLE SCREEN CLOTH.

4).FRAME COLOR: WHITE

HARDWARE: HUNG

A. BALANCES: COMPLY WITH AAMA 902 SPECIFICATION

1). BLOCK-AND-TACKLE BALANCES CONNECTED TO SELF-LOCKING SHOES WITH ZINC DIE CAST

TERMINALS CONCEALED WITHIN THE FRAME.

2). BALANCES ARE ATTACHED TO FRAME AND CONNECTED TO SASH WITH POLYESTER CORD.

B. LOCKING SYSTEM: WOCD HARDWARE ON TOP FLOOR WINDOWS

1). TWO-PIECE LOCKING SYSTEM WITH LOCK AND KEEPER STANDARD (CAM-ACTION)

2). ONE INSTALLED ON UNITS WITH FRAME WIDTH LESS THAN 37 INCHES, 2 LOCKS INSTALLED ON

UNITS WITH FRAME WIDTH OF 37 INCHES OR GREATER.

C. SASH LIFTS:

1). SASH LIFT FURNISHED FOR FIELD INSTALLATION.

2). ONE SASH LIFT ON UNITS WITH FRAME WIDTH LESS THAN 37 INCHES, 2 SASH LIFTS ON UNITS WITH

FRAME WIDTH OF 37 INCHES OR GREATER.

D. HARDWARE FINISH: BAKED ENAMEL WHITE

TOLERANCES: WINDOWS SHALL ACCOMMODATE THE FOLLOWING OPENING TOLERANCES:

A. VERTICAL DIMENSIONS BETWEEN HIGH AND LOW POINTS: PLUS 1/4 INCH, MINUS 0 INCH.

B. WIDTH DIMENSIONS: PLUS 1/4 INCH, MINUS 0 INCH.

C. BUILDING COLUMNS OR MASONRY OPENINGS: PLUS OR MINUS 1/4 INCH FROM PLUMB.

FINISH: EXTERIOR FINISH SYSTEM: PELLA ENDURACLAD.

A. EXTERIOR ALUMINUM SURFACES SHALL BE FINISHED WITH THE FOLLOWING MULTI-STAGE SYSTEM:

1). CLEAN AND ETCH ALUMINUM SURFACE OF OXIDES.

2). PRE-TREAT WITH CONVERSION COATING.

3). TOP COAT WITH BAKED-ON POLYESTER ENAMEL.

B. COLOR: TWO COLOR SYSTEM WINDOW UNIT COLOR A, WINDOW TRIM COLOR B

C. PERFORMANCE REQUIREMENTS: EXTERIOR ALUMINUM FINISHES SHALL MEET OR EXCEED ALL

PERFORMANCE REQUIREMENTS OF AAMA 2603 AND THE FOLLOWING PERFORMANCE REQUIREMENTS

OF AAMA 2605:

1). DRY FILM HARDNESS: EAGLE TURQUOISE PENCIL, H MINIMUM.

2). FILM ADHESION: 1 MM CROSSHATCH, DRY, WET, BOILING WATER.

3). IMPACT RESISTANCE: 1/10-INCH DISTORTION, NO FILM REMOVAL.

4). CHEMICAL RESISTANCE: 10 PERCENT MURIATIC ACID, 15 MINUTES. MORTAR PAT TEST, 24 HOURS.

5). DETERGENT RESISTANCE: 3 PERCENT AT 100 DEGREES F, 72 HOURS.

6). CORROSION RESISTANCE: ASTM G85-A5, 2000 HOURS. HUMIDITY, 3,000 HOURS. SALT SPRAY

EXCEEDS 3,000 HOURS.

D, INTERIOR FINISH: FACTORY FINISHED WITH 1 PRIME COAT AND 1 TOP COAT OF WHITE ACRYLIC

LATEX

INSTALLATION ACCESSORIES

A. FLASHING/SEALANT TAPE: PELLA SMARTFLASH.

1). ALUMINUM-FOIL-BACKED BUTYL WINDOW AND DOOR FLASHING TAPE.

2). MAXIMUM TOTAL THICKNESS: 0.013 INCH.

3). UV RESISTANT.

4). VERIFY SEALANT COMPATIBILITY WITH SEALANT MANUFACTURER.

B. INTERIOR PERIMETER BACKER ROD AND SEALANT: “PELLA WINDOW AND DOOR INSTALLATION SEALANT” OR EQUIVALENT HIGH QUALITY, MULTI-PURPOSE SEALANT AS SPECIFIED IN THE JOINT

SEALANT SECTION. REFER TO ARCHITECTURAL DETAILS AND FIELD CONDITIONS.

C. EXTERIOR PERIMETER SEALANT: “PELLA WINDOW AND DOOR INSTALLATION SEALANT” OR

EQUIVALENT HIGH QUALITY, MULTI-PURPOSE SEALANT AS SPECIFIED IN THE JOINT SEALANT SECTION.

SOURCE QUALITY CONTROL: FACTORY TESTING: FACTORY TEST INDIVIDUAL STANDARD OPERABLE WINDOWS FOR AIR INFILTRATION IN ACCORDANCE WITH ASTM E 283, TO ENSURE COMPLIANCE WITH

THIS SPECIFICATION.

EXECUTION / EXAMINATION: EXAMINE AREAS TO RECEIVE WINDOWS. NOTIFY ARCHITECT OF

CONDITIONS THAT WOULD ADVERSELY AFFECT INSTALLATION OR SUBSEQUENT USE. DO NOT

PROCEED WITH INSTALLATION UNTIL UNSATISFACTORY CONDITIONS ARE CORRECTED.

INSTALLATION

A. INSTALL WINDOWS IN ACCORDANCE WITH MANUFACTURER'S INSTRUCTIONS AND APPROVED SHOP

DRAWINGS.

B. INSTALL WINDOWS TO BE WEATHER-TIGHT AND FREELY OPERATING.

C. MAINTAIN ALIGNMENT WITH ADJACENT WORK.

D. SECURE ASSEMBLY TO FRAMED OPENINGS, PLUMB AND SQUARE, WITHOUT DISTORTION.

E. INTEGRATE WINDOW SYSTEM INSTALLATION WITH EXTERIOR WATER-RESISTANT BARRIER USING FLASHING/SEALANT TAPE. APPLY AND INTEGRATE FLASHING/SEALANT TAPE WITH WATER-RESISTANT

BARRIER USING WATERSHED PRINCIPLES IN ACCORDANCE WITH WINDOW MANUFACTURER'S

INSTRUCTIONS.

F. PLACE INTERIOR SEAL AROUND WINDOW PERIMETER TO MAINTAIN THE BUILDING THERMAL AND

AIR BARRIER CONTINUITY USING BACKER ROD AND SEALANT.

G. SEAL WINDOW TO EXTERIOR WALL CLADDING WITH SEALANT AND RELATED BACKING MATERIALS

AT PERIMETER OF ASSEMBLY.

H. LEAVE WINDOWS CLOSED AND LOCKED.

CLEANING:

A. CLEAN WINDOW FRAMES AND GLASS IN ACCORDANCE WITH DIVISION 1 REQUIREMENTS, OR AS

REQUIRED TO LEAVE NEAT, OWNER APPROVED CONDITION.

B. DO NOT USE HARSH CLEANING MATERIALS OR METHODS THAT WOULD DAMAGE FINISH.

C. REMOVE LABELS AND VISIBLE MARKINGS.

PROTECTION: PROTECT INSTALLED WINDOWS TO ENSURE THAT, EXCEPT FOR NORMAL WEATHERING, WINDOWS WILL BE WITHOUT DAMAGE OR DETERIORATION AT TIME OF SUBSTANTIAL COMPLETION.

01000 - GENERAL CONDITIONS

1.

2.

3.

4.

5.

6.

7.

8.

9.

10.

11.

12.

13.

14.

15.

16.

17.

18.

ALL REFERENCES TO RELEVANT PARTIES SHALL BE AS INDICATED:

ARCHITECT: LEE CALISTI ARCHITECTURE+DESIGN

OWNER: CITY MISSION LIVING STONES

IF ANY DISCREPANCY OR UNCERTAINTY ARISES AS TO THE RESPONSIBLE PARTY INVOLVED,

CONTACT THE ARCHITECT AND OWNER AND SEEK DIRECTION.

IMPORTANT - CALL BEFORE YOU DIG - PENNSYLVANIA ONE CALL SYSTEM, INC. CALL 3

BUSINESS DAYS BEFORE YOU DIG! 1-800-242-1776 OR 8-1-1.

THESE DRAWINGS AND THE SPECIFICATIONS ARE PART OF A COMPLETE SET OF

DOCUMENTS. THE BREAKDOWN OF DRAWINGS AND SPECIFICATIONS INTO INDIVIDUAL

SHEETS AND SECTIONS SHALL NOT DETERMINE THE RESPONSIBILITY FOR THE WORK OF

INDIVIDUAL CONTRACTORS.

ALL CONTRACTORS MUST REVIEW ALL PARTS OF THE DRAWINGS AND SPECIFICATIONS. THE

GENERAL CONTRACTOR SHALL BE SOLELY RESPONSIBLE FOR DETERMINING THE LIMIT OR

EXTENT OF THE WORK OF INDIVIDUAL TRADES AND SHALL FULLY COORDINATE ALL THEIR

ACTIVITY.

THE CONTRACTOR SHALL BE RESPONSIBLE FOR COMPLETELY CHECKING AND VERIFYING

ALL EXISTING CONDITIONS AFFECTING THEIR PERFORMANCE OF THE DESIGNATED WORK.

SHOULD THE CONTRACTOR ENCOUNTER A DISCREPANCY AFFECTING HIS PERFORMANCE,

THEY SHALL NOTIFY THE OWNER AND ARCHITECT IMMEDIATELY AND SEEK DIRECTION. DO

NOT PROCEED UNTIL THE DISCREPANCY IS RESOLVED.

ALL WORK SHALL BE IN ACCORDANCE WITH ALL KNOWN APPLICABLE CODES, RULES AND

REGULATIONS OF THE AGENCIES HAVING JURISDICTION. CONTRACTOR SHALL SECURE AND

PAY FOR ALL PERMITS, LICENSES, CERTIFICATES, INSPECTIONS, AND OTHER LEGAL FEES

REQUIRED, AND ALL APPLICABLE TAXES.

LEE CALISTI ARCHITECTURE+DESIGN EXPRESSLY RESERVES ITS COMMON LAW COPYRIGHT

AND OTHER RIGHTS IN THESE PLANS. THESE PLANS ARE NOT TO BE REPRODUCED,

CHANGED OR MANIPULATED IN ANY FORM OR MANNER WHATSOEVER NOR ARE THEY TO BE

ASSIGNED TO ANY THIRD PARTY WITHOUT PERMISSION AND CONSENT OF LEE CALISTI

ARCHITECTURE+DESIGN.

THE ARCHITECT ACCEPTS NO RESPONSIBILITY FOR ANY CHANGES IN DESIGN PLANS

UNLESS WRITTEN CONSENT IS GIVEN BY THE ARCHITECT. THE CONTRACTOR AND/OR

OWNER WILL BE HELD RESPONSIBLE FOR ANY FIELD MODIFICATIONS MADE WITHOUT THE

WRITTEN CONSENT OF THE ARCHITECT AND NECESSARY APPROVALS BY PERMITTING

AGENCIES.

CONTRACTOR IS SOLELY RESPONSIBLE FOR THE CONSTRUCTION MEANS AND METHODS

INCLUDING WORKMANSHIP. IT IS IMPLIED [AND REQUIRED] THAT INDICATED WORK, WHICH IS

NOT FULLY SPECIFIED [IN DETAIL] SHALL COMPLY WITH APPLICABLE RECOGNIZED

STANDARDS OF THE CONSTRUCTION INDUSTRY, FOR THE INTENDED USE OF THE WORK.

THE SCOPE OF WORK OUTLINED IN THESE DRAWINGS IS BASED ON PROGRAM DATA

PROVIDED BY THE OWNER. WHILE THESE ARE IN GENERAL ACCORDANCE WITH THE LAYOUT

OF THE BUILDING, BASED ON PRELIMINARY FIELD VERIFICATIONS, CERTAIN ELEMENTS ON

THE DRAWINGS MAY VARY IN SIZE AND/OR PLACEMENT FROM THE CONDITIONS ACTUALLY

PRESENT. HOWEVER, THE CONTRACTOR SHALL FULLY AQUAINT THEMSELVES WITH THE

WORK AREAS AND VERIFY ALL DIMENSIONS AND CONDITIONS IN THE FIELD NECESSARY TO

THE PREPARATION OF BIDS. THE CONTRACTOR WILL MAKE PROVISIONS IN THEIR

PROPOSALS TO ACCOUNT FOR THE COST OF ANY VARIANCES IN QUANTITY OR POSITION

WITHOUT ANY ADDITIONAL EXPENSE TO THE OWNER.

SUBSTITUTIONS: BIDDING AND CONTRACTOR AWARD

A. THE BASE BID PROPOSED BY THE CONTRACTOR IS STRICTLY AND EXCLUSIVELY FOR THE

WORK AS PER THE CONTRACT DOCUMENTS.

B. ANY SUBSTITUTIONS MUST BE SUBMITTED WITH COST AND SUPPORT DATA FOR

APPROVAL DURING THE BID PERIOD

C. THE OWNER’S AND ARCHITECT'S DECISION OF APPROVAL OR DISAPPROVAL OF A

PROPOSED SUBSTITUTION SHALL BE FINAL.

D. NO SUBSTITUTION SHALL BE ACCEPTED WITHOUT A SUBSTANTIAL CREDIT GIVEN BACK TO

THE OWNER.

DO NOT SCALE FROM THE DRAWINGS. ALL DIMENSIONS LISTED IN THESE DRAWINGS ARE

BASED ON FIELD DIMENSIONS, THE CONTRACTOR SHALL BE RESPONSIBLE FOR

COMPLETELY CHECKING AND FIELD VERIFYING ALL EXISTING CONDITIONS AND DIMENSIONS

AFFECTING THEIR PERFORMANCE OF THE DESIGNATED WORK. SHOULD THE CONTRACTOR

ENCOUNTER A DISCREPANCY AFFECTING HIS PERFORMANCE, HE SHALL NOTIFY THE

OWNER AND ARCHITECT IMMEDIATELY AND SEEK DIRECTION. DO NOT PROCEED UNTIL THE

DISCREPANCY IS RESOLVED BY THE OWNER AND ARCHITECT.

ALL MATERIALS SHALL BE INSTALLED IN STRICT ACCORDANCE WITH THE MANUFACTURER'S

INSTRUCTIONS. MATERIALS UNLESS OTHERWISE NOTED, TO BE IN NEW AND PERFECT

CONDITION WHEN INSTALLED AND PROTECTED UNTIL ACCEPTED.

PROVIDE SOLID WOOD BLOCKING WITHIN WALL CONSTRUCTION AS REQUIRED FOR SECURE

ANCHORAGE OF CASEWORK, EQUIPMENT, ETC. COORDINATE ALL LOCATIONS WITH OWNER

AND OWNER'S EQUIPMENT SUPPLIER.

NO CUTTING, BLOW TORCHES, OR OPEN FLAME TOOLS ARE PERMITTED IN THE WORK AREAS

WITHOUT THE EXPRESS PRIOR APPROVAL OF THE ARCHITECT AND OWNER. IF USE IS

PERMITTED, AN EXTINGUISHER MUST BE PROVIDED AND PLACED IN IMMEDIATE PROXIMITY

TO THE WORK. ALL CUTTING WORK SHALL BE COMPLETED AND INSPECTED BY THE

CONTRACTOR'S SUPERVISING PERSONNEL AT LEAST ONE HOUR BEFORE THE WORK AREA

IS VACATED FOR THE DAY.

USE THE MEANS NECESSARY TO PREVENT DUST FROM BECOMING A NUISANCE TO THE

PUBLIC, THE ADJACENT PROPERTIES OR TO NEIGHBORING AREAS OF THE SITE.

REMOVE EXISTING ELEMENTS SHOWN DOTTED OR NOTED FOR REMOVAL. REMOVE ALL

STRAY PIPES, FENCING, EQUIPMENT, OR PAVEMENT. NOT REQUIRED TO CONTINUE TO

SERVICE ANY PART OF THIS SITE AS REQUIRED TO SUIT THE NEW CONFIGURATION AND

FUNCTION OF THIS FACILITY.

NOTIFY THE OWNER'S REPRESENTATIVE IN ADVANCE REGARDING ANY REQUIRED UTILITY

SHUT-DOWNS AFFECTING OTHER AREAS OF THE SITE OUTSIDE OF THE CONTRACT LIMITS.

ARRANGE AND PAY FOR DISCONNECTING, REMOVING AND CAPPING UTILITY SERVICES

WITHIN AREAS OF DEMOLITION OR SITE WORK. DISCONNECT AND STUB OFF. NOTIFY THE

AFFECTED UTILITY COMPANY AND BUILDING MANAGER IN ADVANCE AND OBTAIN APPROVAL

BEFORE STARTING THE WORK. PLACE MARKERS TO INDICATE LOCATION OF

DISCONNECTED SERVICES. IDENTIFY SERVICE LINES AND CAPPING LOCATIONS ON

PROJECT RECORD DOCUMENTS. SHUT OFF, CAP, ABANDON OR OTHERWISE PROTECT

EXISTING UTILITY LINES WHERE AFFECTED BY DEMOLITION OPERATIONS IN ACCORDANCE

WITH GOOD PRACTICE, CODES, OR WITH THE REQUIREMENTS OF THE AGENCY OR UTILITY

HAVING JURISDICTION.

MISCELLANEOUS DEFINITIONS:

A. THE TERM "PRODUCT" INCLUDES MATERIALS, SYSTEMS, AND EQUIPMENT.

B. THE TERM "FURNISH" INDICATES OBTAINING AND DELIVERING A PRODUCT TO THE SITE,

FOR INSTALLATION BY OTHERS.

C. THE TERM "INSTALL" INDICATES SETTING IN PLACE, CONNECTING, TESTING AND PLACING

IN FULL OPERATING CONDITION MATERIALS, WHICH ARE FURNISHED BY OTHERS.

D.THE TERM "PROVIDE" INDICATES FURNISHING AND INSTALLING MATERIALS.

E. THE TERM "BUILDING CODE," AND THE TERM "CODE," REFER TO REGULATIONS OF

GOVERNMENTAL AGENCIES HAVING JURISDICTION.

F. THE TERMS "APPROVED," "REQUIRED," AND "AS DIRECTED," INDICATE THE WORK OR

MATERIALS THAT MAY BE APPROVED, REQUIRED, OR DIRECTED BY THE ARCHITECT ACTING

AS THE AGENT OF THE OWNER.

G. THE TERM "SIMILAR" IS USED IN ITS GENERAL SENSE, AND DOES NOT NECESSARILY

INDICATE IDENTICAL.

H. THE TERMS "SHOWN," "INDICATED," "DETAILED," "NOTED," "SCHEDULED," AND TERMS OF

SIMILAR IMPORT, REFER TO REQUIREMENTS CONTAINED IN THE CONTRACT DOCUMENTS.

01030 - ALTERNATES

1.

2.

PROVIDE ALTERNATIVE BID PROPOSALS AS DESCRIBED IN THIS SECTION AND/OR AS ARE

INDICATED ON THE DRAWINGS.

PROCEDURES:

A. PROVIDE ALTERNATIVE BIDS TO BE ADDED TO OR DEDUCTED FROM THE AMOUNT OF THE

BASE BID IF THE CORRESPONDING CHANGE IN SCOPE IS ACCEPTED BY THE OWNER.

B. INCLUDE WITHIN THE ALTERNATIVE BID PRICES ALL COSTS, INCLUDING PROVIDING ALL

MATERIALS, INSTALLATION, AND FEES TO COMPLETE THE INTENDED WORK.

C. SHOW THE PROPOSED ALTERNATIVE AMOUNTS OPPOSITE THEIR PROPER DESCRIPTION

ON THE BID FORM.

01152 - APPLICATION FOR PAYMENT

1.

2.

3.

4.

5.

6.

7.

8.

COMPLY WITH PROCEDURES DESCRIBED IN THIS SECTION WHEN APPLYING FOR PROGRESS

PAYMENT AND FINAL PAYMENT UNDER THE CONTRACT.

SUBMIT APPLICATION OF PAYMENT ON AIA DOCUMENT G702, LATEST VERSION, WITH G703

CONTINUATION SHEET.

ELECTRONIC SUBMISSION (PDF) TO THE ARCHITECT OF THE ORIGINAL DOCUMENT IS

PERMISSABLE.

THE ARCHITECT'S APPROVAL OF APPLICATIONS FOR PROGRESS PAYMENT AND FINAL

PAYMENT MAY BE CONTINGENT UPON THE ARCHITECT'S APPROVAL OF STATUS OF PROJECT

RECORD DOCUMENTS AS DESCRIBED IN SECTION 01000 OF THESE SPECIFICATIONS.

PRIOR TO START OF CONSTRUCTION, SECURE THE ARCHITECT'S APPROVAL OF THE

SCHEDULE OF VALUES REQUIRED TO BE SUBMITTED UNDER THE GENERAL CONDITIONS,

DURING PROGRESS OF THE WORK, MODIFY THE SCHEDULE OF VALUES AS APPROVED BY

THE ARCHITECT TO REFLECT CHANGES IN THE CONTRACT SUM DUE TO CHANGE ORDER OR

OTHER MODIFICATIONS OF THE CONTRACT.

BASE REQUESTS FOR PAYMENT ON THE APPROVED SCHEDULE OF VALUES AS APPROVED

BY THE ARCHITECT.

SIGN AND NOTARIZE THE APPLICATION AND CERTIFICATE FOR PAYMENT.

01610 - SUBSTITUTIONS

1.

2.

3.

4.

5.

6.

SUBSTITUTIONS - PRIOR TO RECEIPT OF BID - ARE SPECIFIED IN THE INSTRUCTIONS TO

BIDDERS AND ON THE BID FORM.

AVAILABILITY OF SPECIFIED ITEMS:

A. VERIFY PRIOR TO SUBMITTAL THAT SPECIFIED ITEMS WILL BE AVAILABLE IN TIME FOR

INSTALLATION DURING ORDERLY AND TIMELY PROGRESS OF THE WORK. IF ITEMS

SPECIFIED WILL NOT BE SO AVAILABLE, NOTIFY THE ARCHITECT IMMEDIATELY.

B. SUBCONTRACTORS AND SUPPLIERS SHALL MAKE ALL REQUESTS FOR APPROVAL

THROUGH THE CONTRACTOR.

C. CONTRACTOR SHALL ARRANGE FOR THE ORDERING OF MATERIALS (AFTER APPROVED

SUBMITTALS) IN SUCH A MANNER TO AVOID KNOWN DELAYS - EVEN IF IT REQUIRES

ORDERING EARLIER THAN CUSTOMARY.

SUBSTITUTION PROCEDURE AFTER AWARD OF CONTRACT:

REQUESTS PROPOSED BY THE CONTRACTOR AFTER THE AWARD OF THE CONTRACT AND

METHODS OF CONSTRUCTION REQUIRED BY THE CONTRACT DOCUMENTS WILL BE

CONSIDERED BY THE ARCHITECT ONLY UNDER ONE OF THE FOLLOWING CONDITIONS:

A. WHEN SPECIFIED PRODUCT IS NOT AVAILABLE OR NO LONGER MANUFACTURED.

B. WHEN A GUARANTEE OF PERFORMANCE IS REQUIRED AND, IN THE JUDGMENT OF THE

CONTRACTOR, SPECIFIED PRODUCT OR PROCESS WILL NOT PRODUCE THE DESIRED

RESULTS, AND WHERE THE CONTRACTOR CERTIFIES THAT THE PROPOSED SUBSTITUTION

PROVIDES THE REQUIRED WARRANTY.

C. THE SPECIFIED PRODUCT OR METHOD OF CONSTRUCTION CANNOT RECEIVE NECESSARY

APPROVAL BY A GOVERNING AUTHORITY, AND THE REQUESTED SUBSTITUTION CAN BE

APPROVED.

D. THE SPECIFIED PRODUCT OR METHOD OF CONSTRUCTION CANNOT BE PROVIDED IN A

MANNER THAT IS COMPATIBLE WITH OTHER MATERIALS, AND WHERE THE CONTRACTOR

CERTIFIES THAT THE SUBSTITUTION WILL OVERCOME THE INCOMPATIBILITY.

ACCOMPANY REQUEST FOR SUBSTITUTION WITH SUCH DRAWINGS, SPECIFICATIONS,

SAMPLES, MANUFACTURER'S LITERATURE, PERFORMANCE DATA, AND OTHER INFORMATION

NECESSARY TO DESCRIBE AND EVALUATE THE PROPOSED SUBSTITUTION AND COMPARE IT

TO THE SPECIFIED PRODUCT COMPLETELY.

THE BURDEN OF PROOF SHALL BE ON THE CONTRACTOR.

AGREEMENT TO MAKE SUBSTITUTION SHALL NOT RELIEVE CONTRACTOR, SUBCONTRACTOR,

MANUFACTURER, FABRICATOR, OR SUPPLIER FROM RESPONSIBILITY FOR ANY DEFICIENCY

THAT MAY EXIST IN THE SUBSTITUTED PRODUCT, OR FOR ANY DEPARTURES OR DEVIATIONS

FROM THE REQUIREMENTS OF THE CONTRACT DOCUMENTS AS MODIFIED BY SUCH

CHANGE. CONTRACTOR SHALL BE DEEMED TO WARRANT BY HIS REQUEST THAT THE

PROPOSED SUBSTITUTE PRODUCT WILL SATISFY ALL STANDARDS AND REQUIREMENTS

SATISFIED BY THE ORIGINALLY SPECIFIED PRODUCT, AND THAT AGREEMENT TO THE

CHANGE SHALL NOT BE DEEMED TO MODIFY CONTRACT DOCUMENTS WITH RESPECT

THERETO.

IF ANY SUBSTITUTION WILL AFFECT A CORRELATED FUNCTION, ADJACENT CONSTRUCTION,

OR THE WORK OF OTHER TRADES OR CONTRACTORS, NECESSARY CHANGES AND

MODIFICATIONS TO AFFECTED WORK SHALL BE CONSIDERED AS AN ESSENTIAL PART OF

THE PROPOSED SUBSTITUTION, TO BE ACCOMPLISHED BY CONTRACTOR AT HIS EXPENSE.

SUBMIT, FOR APPROVAL, FIELD DRAWINGS SHOWING NECESSARY CHANGES OR

MODIFICATIONS TO BE AFFECTED INCLUDING THOSE WHICH REQUIRE STRUCTURAL

CHANGES, BUILDING CHANGES, OR EQUIPMENT CHANGES

01300 - ADMINSTRATIVE REQUIREMENTS

1.

2.

3.

4.

5.

6.

7.

8.

9.

10.

11.

12.

13.

CONTRACTOR USE OF THE PREMISES: BEFORE BEGINNING WORK, SECURE APPROVAL FROM

OWNER (OR THE CITY) AREAS PERMITTED FOR THE FOLLOWING:

A. SITE ACCESS AND PERSONNEL PARKING, MATERIAL STORAGE AND DUMPSTERS

B. LOCATION OF CRANES, HOISTS AND CHUTES

C. LOCATION OF TEMPORARY SANITARY FACILITIES AND UTILITY HOOKUPS

SEE GENERAL SITE AND BUILDING OPERATION NOTES ON THE COVER SHEET

INSURANCE: BEFORE COMMENCING ANY WORK, PROVIDE TO THE OWNER SATISFACTORY

EVIDENCE OF COVERAGE IN THE AMOUNTS SPECIFIED, OR IN THE ABSENCE OF SPECIFIED

REQUIREMENTS, AMOUNTS SUITABLE FOR THE PROJECT FOR:

A. BUILDER'S RISK INSURANCE

B. WORKMAN'S COMPENSATION INSURANCE

FROM THE DATE THAT WORK COMMENCES UNTIL COMPLETION AND ACCEPTANCE OF WORK,

ASSUME FULL RESPONSIBILITY FOR MAINTAINING THE AFFECTED BUILDING SECURE AND WEATHER

TIGHT AFTER CONSTRUCTION HAS PROCEEDED TO ENCLOSE AND SECURE THE BUILDING.

THE CONTRACTOR SHALL PROVIDE AND MAINTAIN SAFEGUARDS AS REQUIRED TO PREVENT INJURY

TO THE WORKMEN, OWNER, ARCHITECT, VISITORS, AND DELIVERY PERSONNEL. MAINTAIN

PROTECTED INGRESS AND EGRESS TO THE SITE AT ALL TIMES. ERECT SUCH BARRIERS TO

PROTECT THE PUBLIC AND NOT CREATE AN “ATTRACTIVE NUISANCE”. ALL OSHA AND OTHER

SAFETY REQUIREMENTS SHALL BE THE SOLE RESPONSIBILITY OF THE G.C.

THE CONTRACTOR SHALL PROVIDE AN EXPERIENCED, JOB SUPERINTENDENT WHO WILL OVERSEE

CONSTRUCTION.

MATERIAL HANDLING - G.C. MUST PROVIDE -

A. A SAFE, CLIMATE CONTROLLED BUILDING AND SUBFLOOR FOR ALL SPACES

B. A SECURE STORAGE AREA THAT IS MAINTAINED PERMANENTLY OR TEMPORARILY AT AMBIENT

TEMPERATURE AND HUMIDITY PER MATERIAL MANUFACTURERS

C. A PROTECTED INSTALLATION AREA PER MANUFACTURER'S SPECFICATIONS

INTENT, PURPOSE, AND INTERPRETATION OF DRAWINGS AND SPECIFICATIONS:

A. IN THE CASE OF AN ERROR OR INCONSISTENCY, SPECIFICATIONS SHALL TAKE PRECEDENCE

OVER DRAWINGS. FIGURED DIMENSIONS SUPERSEDE SCALED ONES.

B. CONTRACTOR, ARCHITECT OR OWNER SHALL TAKE NO ADVANTAGE OF, AND SHALL PROMPTLY

CALL TO THE ARCHITECT'S ATTENTION TO ANY ERROR, OMISSION OR INCONSISTENCY IN/OR

BETWEEN THE DRAWINGS AND SPECIFICATIONS.

PRE-CONSTRUCTION CONFERENCE: PRIOR TO COMMENCEMENT OF THE WORK, REPRESENTATIVES

OF THE ARCHITECT AND OWNER WILL MEET WITH THE CONTRACTOR, HIS SUPERINTENDENT OR

FOREMAN WHO WILL BE ENGAGED FULL TIME ON THE PROJECT WITH SUBCONTRACTORS, TO

REVIEW THE ADMINISTRATIVE REQUIREMENTS, MATERIALS AND PROCEDURES TO BE FOLLOWED IN

PERFORMING THE WORK.

PROGRESS (JOB OR OAC) MEETINGS: THE CONTRACTOR AND ANY SUBCONTRACTORS, MATERIAL

SUPPLIERS, OR VENDORS WHOSE PRESENCE IS NECESSARY OR REQUESTED MUST ATTEND

MEETINGS (REFERRED TO AS PROGRESS OR JOB MEETINGS) WHEN CALLED BY THE ARCHITECT,

CONTRACTOR OR OWNER AT DESIGNATED INTERVALS FOR THE PURPOSE OF DISCUSSING THE

EXECUTION OF THE WORK. EACH OF SUCH MEETINGS WILL BE HELD AT THE SITE OR A TIME AND

PLACE AGREED TO BY THE ARCHITECT, OWNER AND THE CONTRACTOR OR THEIR

REPRESENTATIVES.

CONSTRUCTION SCHEDULE:

A. WITHIN TEN (10) DAYS OF THE CONTRACT SIGNING THE G.C. SHALL PREPARE A CONSTRUCTION

SCHEDULE FOR THE OWNER'S REVIEW.

B. THE CONTRACTOR AND ALL SUBCONTRACTORS, SUPPLIERS, AND MANUFACTURERS SHALL

SCHEDULE THE WORK TO CONFORM TO THE CONSTRUCTION SCHEDULE.

C. SUBMIT REVISIONS TO THE SCHEDULE AS CONSTRUCTION PROCEEDS NOTING MAJOR

DIFFERENCES TO THE SCHEDULE.

D. A DELAY TO SUBMIT A SCHEDULE AS STATED COULD DELAY THE RELEASE OF PAYMENT(S).

SUBMITTALS: SUBMIT THE FOLLOWING:

A. PRODUCT DATA: SUBMIT ENTIRE CATALOG OR BROCHURE, NOT JUST A SINGLE CUT-SHEET.

INDICATE THE EXACT PRODUCT TO BE USED.

B. SAMPLES: WHEN REQUESTED, SAMPLES SHALL BE THE PRECISE ARTICLE PROPOSED TO BE

FURNISHED.

C. SHOP DRAWINGS: UNLESS OTHERWISE DIRECTED, MAKE ALL SHOP DRAWINGS ACCURATELY TO A SCALE SUFFICIENTLY LARGE TO SHOW ALL PERTINENT FEATURES INCLUDING CONNECTIONS TO THE WORK. SUBMIT ELECTRONICALLY IN PDF FORMAT NO PAPER COPIES. EACH SUBMITTAL MUST

BE NUMBERED CONSECUTIVELY WITH THE GENERAL CONTRACTOR'S LETTERHEAD/TRANSMITTAL.

THE ARCHITECT WILL MARK UP ONE (1) SET AND RETURN COPIES ELECTRONICALLY TO THE

CONTRACTOR.

D. COLORS:

1). WHERE COLORS ARE NOT SPECIFICALLY DESCRIBED IN THE CONTRACT DOCUMENTS AND A

CHOICE OF COLOR OR PATTERNS IS AVAILABLE IN A PRODUCT, SUBMIT ACCURATE COLOR AND/OR

PATTERN CHARTS FOR ARCHITECT'S REVIEW.

2). INCLUDE RELATIVE COSTS OF COLORS AND PATTERNS IF THEY VARY.

E. MANUALS, CONTENTS: MANUALS SHALL CONTAIN AT LEAST THE FOLLOWING ITEMS:

1). COMPLETE MANUFACTURERS' INSTRUCTIONS REGARDING MAINTENANCE OF EQUIPMENT,

PRODUCTS, ETC.

2). COMPLETE NOMENCLATURE OF ALL REPLACEABLE PARTS, THEIR PART NUMBERS, AND NAME

AND ADDRESS OF NEAREST VENDOR.

3). COPY OF ALL GUARANTEES AND WARRANTEES ISSUED.

CHANGES TO THE WORK: (CHANGE ORDER REQUESTS AND CHANGE ORDERS)

A. CONTRACTORS SHALL NOT CONSTRUE ANY CORRESPONDENCE OR VERBAL COMMUNICATIONS

WITH OR BY THE ARCHITECT, OR HIS REPRESENTATIVE AS AUTHORIZATION FOR "EXTRA"

CONSTRUCTION PAYMENT. SUBMIT IN WRITING TO THE ARCHITECT ALL CHANGE ORDER REQUESTS

(C.O.R.) FOR ADDITIONS TO THIS CONTRACT FOR CONSIDERATION BY THE OWNER'S

REPRESENTATIVE. WORK PERFORMED WITHOUT WRITTEN APPROVAL OF THE OWNER AND

ARCHITECT WILL BE AT THE CONTRACTOR'S SOLE RESPONSIBILITY.

B. PROCESSING CHANGES INITIATED BY THE OWNER - SHOULD THE OWNER CONTEMPLATE MAKING A CHANGE IN THE WORK OR A CHANGE IN THE CONTRACT TIME OF COMPLETION, THE ARCHITECT WILL ISSUE EITHER THE ARCHITECT'S SUPPLEMENTAL INSTRUCTIONS OR A PROPOSAL REQUEST

TO THE CONTRACTOR. THE SUPPLEMENTAL INSTRUCTIONS AND PROPOSALS WILL DESCRIBE THE

CONTEMPLATED CHANGE, AND WILL CARRY ONE OF THE FOLLOWING INSTRUCTIONS TO THE

CONTRACTOR:

1) MAKE THE DESCRIBED CHANGE IN THE WORK AT NO CHANGE IN THE CONTRACT SUM AND NO

CHANGE IN THE CONTRACT TIME OF COMPLETION; (SUPPLEMENTAL INSTRUCTION ONLY)

2) MAKE THE DESCRIBED CHANGE IN THE WORK, CREDIT OR COST FOR WHICH WILL BE EVALUATED

BY THE ARCHITECT AND OWNER (PROPOSAL REQUEST)

3) PROMPTLY ADVISE THE ARCHITECT AS TO CREDIT OR COST PROPOSED FOR THE DESCRIBED

CHANGE. THIS IS NOT AN AUTHORIZATION TO PROCEED WITH THE CHANGE. (PROPOSAL REQUEST)

4) NO CHANGES WILL BE ACCEPTED WITHOUT THE ARCHITECT'S AND OWNER'S APPROVAL OF THE

CONTRACTOR'S REQUEST FOR CHANGE ORDER (RFCO).

C. PROCESSING CHANGES INITIATED BY THE CONTRACTOR - SHOULD THE CONTRACTOR DISCOVER

A DISCREPANCY AMONG THE CONTRACT DOCUMENTS, A CONCEALED CONDITIONS, OR OTHER

CAUSE FOR SUGGESTING A CHANGE IN THE WORK, A CHANGE IN THE CONTRACT SUM, OR A

CHANGE IN THE CONTRACT TIME OF COMPLETION, THEY SHALL NOTIFY THE ARCHITECT AS

REQUIRED BY PERTINENT PROVISIONS OF THE CONTRACT DOCUMENTS. NO CLAIMS FOR EXTRA

TIME OR WORK SHALL BE HONORED WITH OUT A WRITTEN CHANGE ORDER, APPROVED BY THE

OWNER AND THE ARCHITECT, PRIOR TO THE EXECUTION OF THE SAID CLAIM. UPON AGREEMENT BY

THE ARCHITECT THAT THERE IS REASONABLE CAUSE TO CONSIDER THE CONTRACTOR'S

PROPOSED CHANGE, THE ARCHITECT WILL RECOMMEND TO THE OWNER APPROVAL OF THE

REQUEST FOR CHANGE ORDER, PROMPTING A FORMAL CHANGE ORDER ISSUED TO ALL PARTIES

FOR SIGNATURE.

D. PROCESSING CHANGE ORDERS

1) CHANGE ORDERS WILL BE DATED AND WILL BE NUMBERED IN SEQUENCE.

2) THE CHANGE ORDER WILL DESCRIBE THE CHANGE OR CHANGES (BASED ON APPROVED CHANGE ORDER REQUESTS), WILL REFER TO THE PROPOSAL OR PROPOSALS INVOLVED (C.O.R.), AND WILL

BE SIGNED BY THE CONTRACTOR, OWNER AND THE ARCHITECT.

GUARANTEE:

A. CONTRACTOR SHALL SUBMIT A LETTER TO THE OWNER GUARANTEEING THE WORK IN ITS

14.

15.

16.

17.

18.

19.

20.

21.

ENTIRETY FOR A PERIOD OF ONE (1) YEAR, UNLESS SPECIFICALLY STATED ELSEWHERE IN THE

PROJECT MANUAL TO BE IN EXCESS OF ONE YEAR.

B. THE STARTING DATE OF THE GUARANTEE SHALL BEGIN AT ISSUANCE OF FINAL PAYMENT AT THE

PROJECT COMPLETION, UNLESS AN INDIVIDUAL PRODUCT MANUFACTURER'S OR SERVICE

GUARANTEE BEGINS UPON INSTALLATION, DATES OF EACH TO BE NOTED AND GIVEN TO THE

OWNER UPON PROJECT COMPLETION.

DOCUMENTATION, CERTIFICATES AND INSPECTIONS:

A. THE CONTRACTOR SHALL MAINTAIN A SET OF CONSTRUCTION DOCUMENTS AT THE SITE AND

RECORD ALL CHANGES NEATLY IN RED (ANALOG OR DIGITAL). THIS SET SHALL BE TURNED OVER

TO THE OWNER FOR HIS RECORDS.

B. ALL CITY OR COUNTY APPROVED DOCUMENTS, INSPECTIONS, AND CERTIFICATES SHALL BE

APPLIED FOR AND OBTAINED BY THE CONTRACTOR, PAID FOR BY THE CONTRACTOR UNLESS

OTHERWISE PROVIDED FOR BY THE OWNER. THIS INCLUDES BUT IS NOT NECESSARILY LIMITED TO THE FOLLOWING: CITY OR COUNTY APPROVED DRAWINGS, BUILDING PERMIT, REQUIRED UTILITY OR MEP/FP PERMITS, OCCUPANCY PERMIT, ELECTRICAL AND PLUMBING INSPECTION CERTIFICATES, AND ALL OTHER PERMITS AND INSPECTIONS REQUIRED BY THE LOCAL COUNTY AND THE STATE.

C. DELEGATE THE RESPONSIBILITY FOR MAINTENANCE OF RECORD DOCUMENTS TO A DRAFTSMAN, EMPLOYED OR CONTRACTED BY THE CONTRACTOR, AS APPROVED BY THE ARCHITECT.

D. THOROUGHLY COORDINATE CHANGES WITHIN THE RECORD DOCUMENTS, MAKING ADEQUATE

AND PROPER ENTRIES ON EACH PAGE OF SPECIFICATIONS AND EACH SHEET OF DRAWINGS AND

OTHER DOCUMENTS WHERE SUCH ENTRY IS REQUIRED TO SHOW THE CHANGE PROPERLY.

E. ACCURACY OF RECORDS SHALL BE SUCH THAT FUTURE SEARCH FOR ITEMS SHOWN IN THE

CONTRACT DOCUMENTS MAY RELY REASONABLY ON INFORMATION OBTAINED FROM THE

APPROVED PROJECT RECORD DOCUMENTS.

F. MAKE ENTRIES WITHIN 24 HOURS AFTER RECEIPT OF INFORMATION THAT THE CHANGE HAS

OCCURRED.

G. THE PURPOSE OF THE FINAL PROJECT RECORD DOCUMENTS IS TO PROVIDE FACTUAL

INFORMATION REGARDING ALL ASPECTS OF THE WORK, BOTH CONCEALED AND VISIBLE, TO

ENABLE FUTURE MODIFICATION OF THE WORK TO PROCEED WITHOUT LENGTHY AND EXPENSIVE

SITE MEASUREMENT, INVESTIGATION, AND EXAMINATION.

PROJECT CLOSE OUT

A. FINAL CLEANING: THE G.C. SHALL MAINTAIN A CLEAN SITE DURING CONSTRUCTION. THE G.C.

SHALL THOROUGHLY CLEAN THE INTERIOR OF THE BUILDING, WAX ALL VCT FLOORS, CLEAN ALL

OTHER FLOORING, VACUUM ALL CARPET, CLEAN ALL PLUMBING FIXTURES, REMOVE ALL DUST

FROM CABINETS ETC., SO THE UNITS ARE MOVE-IN' READY. BROOM CLEAN ALONE IS NOT

ACCEPTABLE. ALL WINDOWS AND MIRRORS SHALL BE CLEANED.

B. IT IS REQUIRED AND ASSUMED THAT ALL TRADES WILL HAVE ALL OF THEIR RESPECTIVE

SYSTEMS FULLY TESTED, OPERATIONAL AND RECEIVE WHATEVER PERMITS AND APPROVALS

REQUIRED BY UTILITIES AND AUTHORITIES HAVING JURISDICTION WHICH IN TURN WILL BE

PROVIDED TO OWNER'S REPRESENTATIVE.

C. DEMONSTRATE TO THE OWNER'S REPRESENTATIVE HOW TO OPERATE ALL BUILDING FUNCTIONS

AND EQUIPMENT. PROVIDE ALL EQUIPMENT MAINTENANCE MANUALS, GUARANTEES AND

WARRANTIES.

SUBSTANTIAL COMPLETION:

A. WHEN THE CONTRACTOR HAS DETERMINED THE PROJECT IS COMPLETE TO THE POINT WHERE

THE OWNER CAN OCCUPY IT AND IT HAS RECEIVED A CERTIFICATE OF OCCUPANCY BY THE LOCAL

MUNICIPALITY, THEY SHALL REQUEST THE ARCHITECT PREPARE A PUNCH LIST.

B. WITHIN A REASONABLE TIME AFTER RECEIPT OF THE LIST, THE ARCHITECT WILL INSPECT TO

DETERMINE STATUS OF COMPLETION.

C. SHOULD THE ARCHITECT DETERMINE THAT THE WORK IS NOT SUBSTANTIALLY COMPLETE,THE

ARCHITECT PROMPTLY WILL SO NOTIFY THE CONTRACTOR, IN WRITING, GIVING THE REASONS

THEREFORE

D. THE CONTRACTOR SHALL REMEDY THE DEFICIENCIES AND NOTIFY THE ARCHITECT WHEN READY

FOR REINSPECTION.

E. THE ARCHITECT WILL REINSPECT THE WORK AND WHEN THE ARCHITECT CONCURS THAT THE

WORK IS SUBSTANTIALLY COMPLETE, THE ARCHITECT WILL PREPARE A "CERTIFICATE OF

SUBSTANTIAL COMPLETION" ON AIA FORM G704, ACCOMPANIED BY THE CONTRACTOR'S LIST OF

ITEMS TO BE COMPLETED OR CORRECTED, AS VERIFIED BY THE ARCHITECT.

F. THE ARCHITECT WILL SUBMIT THE CERTIFICATE TO THE OWNER AND TO THE CONTRACTOR FOR THEIR WRITTEN ACCEPTANCE OF THE RESPONSIBILITIES ASSIGNED TO THEM IN THE CERTIFICATE.

CLOSEOUT SUBMITTALS: INCLUDE, BUT ARE NOT NECESSARILY LIMITED TO:

A. PROJECT RECORD DOCUMENTS DESCRIBED IN SECTION 01000

B. OPERATION AND MAINTENANCE DATA FOR ITEMS SO LISTED IN PERTINENT OTHER SECTIONS OF

THESE SPECIFICATIONS, AND FOR OTHER ITEMS WHEN SO DIRECTED BY THE ARCHITEC

C. WARRANTIES AND BONDS

D. SPARE PARTS AND MATERIALS ATTIC OR EXTRA STOCK;

F. EVIDENCE OF COMPLIANCE WITH REQUIREMENTS OF GOVERNMENTAL AGENCIES HAVING

JURISDICTION INCLUDING, BUT NOT NECESSARILY LIMITED TO:

1) CERTIFICATES OF INSPECTION;

2) CERTIFICATES OF OCCUPANCY

G. CERTIFICATES OF INSURANCE FOR PRODUCTS AND COMPLETED OPERATIONS;

H. EVIDENCE OF PAYMENT AND RELEASE OF LIENS;

I. LIST OF SUBCONTRACTORS, SERVICE ORGANIZATIONS, AND PRINCIPAL VENDORS, INCLUDING

NAMES, ADDRESSES, AND TELEPHONE NUMBERS WHERE THEY CAN BE REACHED FOR EMERGENCY

SERVICE.

FINAL COMPLETION:

A. CONTRACT SHALL VERIFY THAT THE WORK IS COMPLETE INCLUDING ALL ELEMENTS ON THE

PUNCH LIST

B. THE CONTRACTOR SHALL CERTIFY THAT THE CONTRACT DOCUMENTS HAVE BEEN REVIEWED,

WORK HAS BEEN INSPECTED BY LOCAL MUNICIPAL CODE INSPECTION AGENCIES FOR COMPLIANCE

WITH THE CONTRACT DOCUMENTS, EQUIPMENT AND SYSTEMS HAVE BEEN TESTED AS REQUIRED,

AND ARE OPERATIONAL, WORK IS COMPLETED AND READY FOR FINAL INSPECTION.

C. THE ARCHITECT WILL MAKE AN INSPECTION TO VERIFY STATUS OF COMPLETION.

D. SHOULD THE ARCHITECT DETERMINE THAT THE WORK IS INCOMPLETE OR DEFECTIVE:

1) THE ARCHITECT PROMPTLY WILL SO NOTIFY THE CONTRACTOR, IN WRITING, LISTING THE

INCOMPLETE OR DEFECTIVE WORK.

2) REMEDY THE DEFICIENCIES PROMPTLY, AND NOTIFY THE ARCHITECT WHEN READY FOR

REINSPECTION.

3) WHEN THE ARCHITECT DETERMINES THAT THE WORK IS ACCEPTABLE UNDER THE CONTRACT

DOCUMENTS, HE WILL REQUEST THE CONTRACTOR TO MAKE CLOSEOUT SUBMITTALS.

FINAL ADJUSTMENT OF ACCOUNTS:

A. SUBMIT A FINAL STATEMENT OF ACCOUNTING TO THE ARCHITECT, SHOWING ALL ADJUSTMENTS

TO THE CONTRACT SUM.

B. IF SO REQUIRED, THE ARCHITECT WILL PREPARE A FINAL CHANGE ORDER SHOWING

ADJUSTMENTS TO THE CONTRACT SUM WHICH WERE NOT MADE PREVIOUSLY BY CHANGE ORDERS.

OPERATING AND MAINTENANCE

A. IN PREPARING DATA REQUIRED BY THIS SECTION, USE ONLY PERSONNEL WHO ARE

THOROUGHLY TRAINED AND EXPERIENCED IN OPERATION AND MAINTENANCE OF THE DESCRIBED

ITEMS, COMPLETELY FAMILIAR WITH THE REQUIREMENTS OF THIS SECTION, AND SKILLED IN

TECHNICAL WRITING TO THE EXTENT NEEDED FOR COMMUNICATING THE ESSENTIAL DATA.

B. PROVIDE ALL OPERATION, MAINTENANCE AND WARRANTY INFORMATION IN A CATALOGED

DIGITALLY (UNLESS REQUESTED BY THE OWNER).

C. THE ARCHITECT SHALL, UPON ACCEPTANCE OF THIS DOCUMENT, FORWARD DIGITAL LINKS TO

THE OWNER FOR THEIR USE.

INSTRUCTION AND TRAINING: INSTRUCT THE OWNER'S PERSONNEL IN PROPER OPERATION AND

MAINTENANCE OF SYSTEMS, EQUIPMENT, AND SIMILAR ITEMS WHICH WERE PROVIDED AS PART OF

THE WORK.

A201 floor plans key plans

31 july 2025 drawing no.for reference

No. Date Issue Notes gallatin school renovations city mission living stones

155 n gallatin ave uniontown pa 15401

155 n gallatin ave uniontown pa 15401 renovations phase 2

© copyright 2025 lee CALISTI architecture+design all rights reserved this drawing is an instrument of service and is not to be reproduced or used without prior expressed written consent of lee CALISTI architecture+design.

leecalisti.com

24 cypress avenue greensburg pa 15601

724 832 7030 lee@leecalisti.comlee CALISTI architecture+design

2411.1project no.

THESE DRAWINGS AND THE INCLUDED SPECIFICATIONS ARE PART OF A COMPLETE SET OF DOCUMENTS. THE BREAKDOWN OF DRAWINGS AND SPECIFICATIONS INTO INDIVIDUAL SHEETS AND SECTIONS SHALL NOT DETERMINE THE RESPONSIBILITY FOR THE WORK OF INDIVIDUAL CONTRACTORS. ALL CONTRACTORS (GENERAL CONTRACTOR, SUB-CONTRACTORS, TRADESPERSONS) MUST REVIEW ALL PARTS OF THE DRAWINGS AND SPECIFICATIONS TO CONFIRM THE FULL SCOPE OF WORK.

SUB-CONTRACTORS ARE RESPONSIBLE FOR THEIR RESPECTIVE SCOPES OF WORK REGARDLESS OF WHICH PAGE OF THIS SET THE WORK MAY APPEAR. THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DISTRIBUTING FULL SETS OF DRAWINGS TO ALL THE SUB-CONTRACTORS.

THE GENERAL CONTRACTOR SHALL BE RESPONSIBLE FOR DETERMINING THE LIMIT OR EXTENT OF THE WORK OF INDIVIDUAL TRADES AND SHALL FULLY

COORDINATE ALL THEIR ACTIVITY AND INFORM THE SUB-CONTRACTORS.

LEE CALISTI RA…