70Z08524RLREP1490 Attachment 8 Change Request Proposal Form.xls

Govt Est

Person

Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.

The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.

Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:

The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

See page 1 for info on need for contract extension.

Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.

The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.

Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:

The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.

The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.

Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:

The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of Part I. This is a request for proposal only. You are requested to provide a detailed price proposal within 3 calendar days from the date of issuance by the Contracting Officer or earlier. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached and a bilateral contract modification is executed between the Government and the Contractor.

The work described below is withing the scope fo the subject contract. All terms and conditions of the subject contract are applicable to this work request.

Provide all labor and materials to accomplish the following additional work. This work request is in response to the Contractor's CFR listed above:

The above work will require an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

The above work will require an extension of days beyond the current delivery date of ____.

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and of Provide all labor and materials to accomplish the following:

The above work will reuire an extension of ______ days beyond the current delivery date of __________.

FOR COAST GUARD USE ONLY

Operational Commander (___________________) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phoncon between _____________________ and _________________________ Of _________________________________________________________________ Remarks:

FOR COAST GUARD USE ONLY

Operational Commander ( ___ ) notified of potential delay and concures or acknowledges that potential schedule impact may result from this change.

Ref: Phonecon between and _______ of You are requested to provide a detailed price proposal for the work described below to the Contracting Officer within 3 calendar days (or earlier if requested) from the date of issuance. No obligation is created for the United States Government to award any work until an agreement on price and performance period is reached. Following agreement on price and performance period a bilateral contract modification is executed between the Government and the Contractor.

The work described below is within the scope of the subject contract. All terms and conditions of the subject contract are applicable to this work request.