Specifications 70Z08221BPMV16100.pdf

MAJOR MAINTENANCE AND

REPAIR STATION

AT

U.S. COAST GUARD STATION

FORT PIERCE

FLORIDA

PROJECT No. 10985275

NOVEMBER, 2020

FINAL SUBMITTAL

COMMANDING OFFICER, CIVIL ENGINEERING UNIT MIAMI

15608 S.W. 117TH AVENUE

MIAMI, FLORIDA

33177

TABLE OF CONTENTS

DIVISION 01 GENERAL REQUIREMENTS

Section 01 11 00 Summary of Work

Section 01 32 01.00 10 Progress Schedule

Section 01 33 00 Submittal Procedures

Appendix 01 33 00.A Submittal Register

Section 01 45 00.10 20 Quality Control for Minor Construction

Section 01 78 23 Operation & Maintenance Data

DIVISION 02 EXISTING CONDITIONS

Section 02 41 00 Demolition

DIVISION 03 CONCRETE

Section 03 30 00 Cast-in-Place Concrete

DIVISION 04-06 NOT USED

None

DIVISION 07 THERMAL AND MOISTURE PROTECTION

Section 07 21 16 Mineral Fiber Blanket Insulation

Section 07 27 36 Spray Foam Insulation

Section 07 54 23 Thermoplastic Polyolefin Roofing

DIVISION 08 NOT USED

DIVISION 09 FINISHES ____

Section 09 29 00 Gypsum Board

Section 09 65 00 Resilient Flooring

Section 09 67 23.13 Standard Resinous Flooring

Section 09 90 00 Paints and Coatings

Section 09 97 13.27 Exterior Coating of Steel Structures

DIVISION 10-12 NOT USED

DIVISION 13 SPECIAL CONSTRUCTION

Section 13 34 19 Metal Building Systems

DIVISION 14-22 NOT USED

Section 22 00 00 General Plumbing

DIVISION 23 HEATING, VENTILATING AND AIR CONDITIONING

Section 23 00 00 Air Supply, Distribution, Ventilation & Exhaust

DIVISION 24 – 25 RESERVED

DIVISION 26 ELECTRICAL

Section 26 00 00.00 20 Basic Electrical Materials and Methods

Section 26 05 00.00 40 Common Electrical

Section 26 05 19.10 10 Insulated Wire and Cable

Section 26 12 21 Single-Phase Pad Mounted Transformers

Section 26 24 16.00 40 Panelboards

Section 26 27 29 Marina Electrical Work

Section 26 51 00 Interior Lighting

Section 26 56 00 Exterior Lighting

DIVISION 27 – 30 NOT USED

DIVISION 31 EARTHWORK

Section 31 23 00.00 20 Excavation and Fill

DIVISION 32 EXTERIOR IMPROVEMENTS

Section 32 01 17.61 Sealing Cracks in Asphalt Paving

Section 32 12 17 Hit Mix Bituminous Pavement

Section 32 12 36.13 Asphaltic Seal and Fog Coats

Section 32 17 24.00 10 Pavement Markings

DIVISION 33 UTILITIES

Section 33 11 00 Water Utility Distribution Piping

Section 33 71 02 Underground Electrical Distribution

DIVISION 34-48 NOT USED

ENCLOSURES SURVEYS AND FORMS

Enclosure 1 Material Submittal Review Request Form

Enclosure 2 Asset Enrollment Form

Enclosure 3 Equipment Enrollment Form

Enclosure 4 USCG Approved Equipment Enrollment Catalogue

Enclosure 5 Sea Turtle Lighting Guideline

Enclosure 6 Migratory Bird Conservation Measures

ENCLOSURES REFERENCE DRAWINGS

Enclosure 7 Shop Building (102) Original Construction Drawings

Enclosure 8 Shop Building (102) Bathroom Remodel Construction Drawings

Enclosure 9 Cutter Office/Storage Bldg (106) Original Construction Drawings

-- End of Table of Contents --

USCG STATION FT. PIERCE 10985275

MAJOR MAINTENANCE & REPAIR STATION

SECTION 01 32 01.00 10

PROJECT SCHEDULE

PART 1 GENERAL

1.1 GENERAL

Prepare a Construction Progress Schedule in conformance with the section entitled Deliveries or Performance contained within the Construction Contract. Reflect all major milestones and events for the entire duration of the construction contract. Prepare the Construction Progress Schedule in a horizontal bar graph format referencing all of the construction contract work activities to a time scale. Divide and subdivide the project into a sufficient number of work activities that can accurately display the work sequence, activity duration interplay of activities, and dollar value of each activity in graphical form.

1.2 RESPONSBILITES

Execute the work within the time stated in the Construction Contract.

1.3 SUBMITTALS

Submit a preliminary single draft schedule copy of the Construction Progress Schedule prior to the Pre-Construction Conference. The preliminary single draft copy shall reflect time periods but will not show dates of Notice to Proceed (NTP) and completion. By having the draft schedule at the pre-construction conference, the Contracting Officer and Contractor can discuss any apparent inconsistencies or omission, and approval can be expedited.

Once a NTP date has been established, submit a minimum of (3) copies of the final Construction Progress Schedule including Schedule of Values no later than (5) calendar days after receiving the NTP. The final Construction Progress Schedule shall reflect all dates.

Submit updated Construction Progress Schedule every month along with the Request for Payment.

PART 2 PRODUCTS

2.1 PROGRESS SCHEDULE

Construction Progress Schedule shall have project name, location, contract number and company name. The final Construction Progress Schedule, with the NTP and Construction Contract completion date filled in, shall be signed.

At the left side of the Construction Progress Schedule form, list the following in columns.

a. Activity Number and Description - At a minimum, break down the project into enough activities to reflect work discipline(s). If enough detail is given on the progress schedule, then the activity breakdown may be done at the Contracting Officer's discretion. Unit price items shall be listed as individual activities, and not grouped together with the base bid items. If the project encompasses work on more than one real property asset (RPUID), work activities are to be broken down by each asset or RPUID. Activities can be of various origins (i.e. by specification section, by logical sequence of work, by breakdown used for bid estimates, etc.) Additional activities important to the progress of the Construction Contract but conducted by others - such as testing conducted by agencies not related to the Contractor or the delivery of Contractor Installed Government Furnished Equipment, interruption of existing utilities - may be considered for addition to the Progress Schedule by the Contractor, or added by the Contracting Officer at the Contracting Officer’s discretion.

b. Specification Section Reference - This is optional. Use only if the breakdown of activities directly correlates with the specification sections.

c. The Activities Percentage (i.e. 50%) or Weight (i.e. 5) of the entire contract based on Dollar Value - the cumulative percentage should add up to 100 percent.

d. Estimated Value of the Activity - Profit and overhead should be distributed throughout activities or listed as a separate line item and distributed over the entire length of the project. The total values should add to the Contract Amount.

Establish the time schedule across the top of the sheet for the entire project duration. Divide the project into months, weeks, or days depending on the length of the project and an appropriate time scale.

Lay out a bar graph opposite each activity, corresponding to the schedule start date and extended for the scheduled duration of the activity. Indicate the percentage of the activity, which you intend to complete each week above or below each bar.

2.2 SPECIAL PROGRESS CHART TIME EVENTS AND ACTIVITIES

In addition to the minimum time events and activities required to be demonstrated on the Progress Chart as indicated herein, indicate and schedule the Hold Point Construction Inspections along with the Special Progress Chart Time Events and Activities listed in Section 01 11 00, “Summary of Work”, paragraphs 1.10.3 and 1.10.3.1, respectively.

PART 3 EXECUTION

3.1 UPDATING SCHEDULE

Update and submit Construction Progress Schedule every month with progress payment showing actual progress. Updated Construction Progress Schedule shall include the original information and an updated actual progress curve using a broken line.

3.2 DELAYS

Notify the Contracting Officer, in writing, within 3 calendar days if there is reason to believe that the delivery of any material or equipment, the shortage of qualified labor, delays caused by others, or the occurrence of any other difficulty may cause delay in executing the Work as scheduled.

3.3 PROGRESS CHART

A sample Construction Progress Schedule chart is shown on the following page. This should only be used as a guide. The Sample Chart displays the "basic type" of information, which should be included in the submitted progress schedules, but is not limited to the indicated activities, such as Submittals, Manuals, Test and Balance, etc.

-- End of Section --

SECTION 01 33 00

SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.1 SUBMITTALS REQUIRED

Items to be submitted are specified in each applicable Section of this specification and listed in the submittal register. Submittals shall be approved before procurement, fabrication, or delivery of items to the job site. Submittals shall include the manufacturer's name, trade name, catalog model or number, nameplate data, size, layout dimensions, capacity, project specification and paragraph reference, applicable Federal, Military, industry and technical society publication references, and other information necessary to establish contract compliance of each item that the Contractor proposes to furnish. Indicate the description of what is being submitted on the submittal cover sheet.

1.2 TIMING OF SUBMITTALS

1.2.1 General

Submit submittals in sufficient time and in such sequence to avoid delays in the Work. Except for voluminous submittals, numerous submittals submitted on or about the same time, and submittals for very complex items, submittals will be reviewed by the Contracting Officer’s Representative (COR) and returned to the Contractor electronically within 10 working days after receipt. Large submittals shall be submitted electronically via CD to prevent overloading government servers. Commence submittal procedures upon receiving the Notice to Proceed.

1.2.2 Commencing the Submittal Process

Commence the shop drawing submittal process upon award of project. Special attention shall be given to the long lead items to avoid delays in the Work.

1.2.3 Preparation of Electronic Submittals

Prepare electronic submittals from one division complete and submit together and at the same time – piecemeal submittals from within each division are not acceptable and will be returned without review at the discretion of the Contracting Officer’. In addition, submittals whose layouts and design are dependent on the Work included in other divisions (example: shop drawing submittal indicating a new mechanical utility building whose construction, size, layout and orientation depends on the type, manufacturer and size of the mechanical and electrical equipment contained within) shall also be returned without review at the discretion of the Contracting Officer if all related submittals from other applicable divisions are not submitted simultaneously. Except for voluminous submittals, numerous submittals submitted on or about the same time, and submittals for very complex items, submittals will be reviewed by the Contracting Officer and returned to the Contractor within 10 working days after receipt by the Contracting Officer.

1.2.4 Long-Lead Items

Comply with the requirements specified in the Letter of Award. Submit a list of long lead items within 5 calendar days of Award. This list shall identify items such as, but not limited to materials, fabrication and delivery of items to the job site. Prepare submittals and submit those items in sufficient time to avoid delays.

1.3 DEFINITION

Contractor shall review individual specification sections for submittal requirements and applicable publications relating to submittals. Typical submittal types and numbers of each required are as follows:

1.3.1 Preconstruction Submittals (1 electronic copy each)

Submit all preconstruction submittals for approval within 10 calendar days after the Notice of Award date. All preconstruction submittals shall be approved prior to the start of any work on-site.

The preconstruction submittals shall include:

a. Progress schedule.

b. Schedule of Values.

c. Long lead items.

d. Personnel list for security access.

e. Safety Plan.

f. Demolition Plan.

1.3.2 Shop Drawings (1 electronic copy each)

Shop drawings shall show types, sizes, accessories, elevations, floor plans, sectional views, installation details, elementary diagrams, wiring diagrams, details of equipment and equipment spaces identifying and indicating proposed location, layout and arrangement of items of equipment, control panels, accessories, piping, ductwork, and other items that must be shown to ensure a coordinated installation. Wiring diagrams shall identify circuit terminals and shall indicate the internal wiring for each item of equipment and the interconnection between the items. Drawings shall also indicate adequate clearance for operation, maintenance and replacement of operating equipment devices. If any equipment is disapproved, the drawings shall be revised to show acceptable equipment and be resubmitted. Shop Drawings shall be a minimum of 8–1/2 inches by 11 inches in size using a 1/4" = 1'-0" scale size for ductwork and piping layout outside mechanical rooms, and a 1/2" = 1'-0" scale size for plan views and cross section views of each mechanical room.

1.3.3 Product Data (1 electronic copy each)

Submittals for each manufactured item shall be manufacturer's descriptive literature of cataloged products, equipment drawings, diagrams, performance and characteristic curves and catalog cuts. Submit complete descriptive data for each type of material. Clearly mark data to indicate the type of material the Contractor intends to provide.

1.3.4 Test Reports (1 electronic copy each)

Before delivery of materials and equipment or completion of the Work where indicated, certified copies of all test reports specified in the individual sections shall be submitted for approval.

1.3.5 Samples (2 each)

Submit color (not black and white) printed data or actual pieces of the items where specified in the individual specification sections. The contract prices will not be adjusted due to the Contracting Officer's selection of any color, texture, or pattern submitted.

1.3.6 Colors (1 electronic copy each)

Unless otherwise noted in Contract Documents color selection will be made by the COR.

1.3.7 Certificates of Compliance (1 electronic copy each)

Submit certification from the manufacturer attesting that materials and equipment to be furnished for this project conform and comply to the requirements of this specification and of the referenced publications. Pre-printed certifications will not be acceptable; certifications shall be in the original. The certification shall not contain statements that could be interpreted to imply that the product does not meet all requirements specified, such as "as good as"; "achieve the same end use and results as materials formulated in accordance with the referenced publications"; "equal or exceed the service and performance of the specified materials". The certification shall simply state that the product conforms to the requirements specified.

1.3.8 Standards of Compliance (1 electronic copy each)

When materials or equipment must conform to the standards of organizations such as the American National Standards Institute (ANSI), American Society for Testing and Materials (ASTM), National Electrical Manufacturers Association (NEMA), and Underwriters Laboratories (UL), proof of such conformance shall be submitted to the Contracting Officer for approval. If an organization uses a label or listing to indicate compliance with a particular standard, label or listing, the Contractor shall submit a certificate from an independent testing organization, which is competent to perform acceptable tests and is approved by the Contracting Officer. The certificate shall state that the item has been tested in accordance with the specified organization's test methods and that the item conforms to the specified organization's standard. For materials and equipment whose compliance with organizational standards or specifications is not regulated by an organization using its own listing or label as proof of compliance, a Certificate of Compliance from the manufacturer shall be submitted for approval. The certificate shall identify the manufacturer, the product and the referenced standard and shall simply state that the manufacturer certifies that the product conforms to all requirements of the project specification and of the referenced standards listed.

1.3.9 Manufacturer's Instructions (1 electronic copy each)

Where installation procedures or any part hereof, are required to be in accordance with the recommendations of the manufacturer of the material being installed, printed copies of these recommendations shall be furnished to the Contracting Officer prior to installation. Installation of the item will not be allowed to proceed until the installation recommendations are received. Failure to furnish these recommendations can be cause for rejection of the material. With this submittal, explicitly identify in writing any differences between manufacturer's installation instructions and the requirements specified herein.

1.3.10 Operation and Maintenance Manuals (1 paper copy to ensure completeness, then 3 hard copies plus 3 electronic copies on DVD media)

Compile an Operation and Maintenance Manual section for each item of equipment. The Operation and Maintenance Manuals shall form a part of the Record Documents - refer to section 01 11 00, “Summary of Work”, for additional requirements. Furnish the complete manuals bound in hardback binders. Provide one complete manual prior to the time that equipment tests are performed for review and approval. Provide the final manuals including the electronic copies (in PDF format) incorporating all review comments prior to Contract completion. Provide the following inscription on the cover of each manual and each electronic DVD copy:

OPERATION AND MAINTENANCE MANUAL

Project Name

Project Number Name of Prime Contractor

Contract Number

Page 1: Provide the first (cover) page of the manual with the following:

OPERATION AND MAINTENANCE MANUAL

Project Name Project Number

Contract Number

General (Prime) Contractor: Name, address, telephone number.

Sub-Contractor: Name, address, telephone number (for each sub-contractor).

Major Equipment Vendor/Supplier: Name, address and telephone number for each local representative for each item of equipment.

Page 2: Table of Contents

Assemble the remaining portions of the manual to conform and coordinate with the Table of Contents. Each section shall have a tab sheet placed before the data or instructions covering the subject and shall match the order presented in the Table of Contents. The instructions shall be legible and easily read, with large sheets of drawings folded in as required. Each section shall include, as a minimum:

a. A complete description of the system, wiring and control diagrams with data to explain detailed operation and control of each item of equipment;

b. A control sequence describing start-up, operation and shut-down instructions;

c. Installation instructions;

d. Maintenance instructions;

e. Lubrication schedule including type, grade, temperature range, and frequency;

f. Safety precautions, diagrams, and illustrations;

g. Operating instructions;

h. Test procedures;

i. Performance data;

j. Completed and approved certified Test and Balance report;

k. Parts list. The parts lists for equipment shall indicate the sources of supply, recommended spare parts, and the service organization, which is reasonably convenient to the project site. The manual shall be complete in all respects for equipment, controls, accessories, and associated appurtenances provided;

l. Training lesson plans;

m. Training(s) letter to Contracting Officer.

1.3.11 Operating Instructions (1 electronic copy each plus 1 for lamination of new standby generator if Option Item 1 is accepted))

Furnish manufacturer's Operating Instructions for each principal mechanical and electrical component or item, for use by operating personnel. A copy shall be provided in each of the Operations and Maintenance manuals as indicated above. The Option Item 1 generator copy shall be laminated between thermoplastic sheets and affixed where directed by COR adjacent to the equipment or system. Laminated operating instructions shall not face direct sunlight and shall be secured to prevent easy removal or peeling. The operating instructions shall include wiring diagrams, control diagrams, and control sequences for each principal item of equipment. The instructions shall describe the functions of the equipment, its most economical operation, start-up and shutdown procedures, procedures to follow in the event of failure, normal maintenance practices, and caution and warning notices.

1.3.12 Training Instructions (hard copies for the attendees and 1 electronic copy each)

Prior to conducting any training instructions, furnish a lesson plan and the qualifications of the trainer for each training session specified under each individual technical specification section. Each lesson plan shall be prepared on 8-1/2” x 11” paper and include, as a minimum:

a. Project title, name of contractor and/or subcontractors responsible for each training lesson including address and telephone number;

b. The name and qualifications of the proposed trainer including the trainer’s resume, work history and/or relationship with the service provided, certifications and trainer history;

c. A complete description of the system/equipment/component to be instructed;

d. Training schedule including all topics listed in the order of proposed presentation, breaks, demonstrations – all presented within a maximum (or multiple) 8 hour day(s);

e. General technical description of each topic to be presented including wiring and control diagrams, operation and control of each item of equipment, demonstration of control sequences describing normal and emergency operations, recommended maintenance cycles, lubrication schedule, safety precautions.

Provide 1 hard copy bound lesson plan for each of the attendees specified in section 01 11 00, paragraph 1.29. Submit an electronic copy of the Training plan including accepted comments and the recorded instruction (if specified in section 01 11 00, paragraph 1.29) after completion of the Training Instruction.

PART 2 - PRODUCTS

Not used.

PART 3 - EXECUTION

Provide the submittals listed in the attached Appendix 01 33 00.A in the format and quantities specified herein.

-- End of Section --

APPENDIX 01 33 00.A

SCHEDULE OF MATERIAL SUBMITTALS

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

10985275

CONTRACT NUMBER

SPECIFICATION

PARAGRAPH NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R E D

S U B M I S S I O N

D A T

B M I T T A L

N U M B

R

S U B M T T A L

N

M B

T E

O

C

N T R A C T I

G

T E

T O

P R O J E

M

N A G

DATE CONTRACTOR

NOTIFIED

REMARKS

S H O P

D R A W I N

P

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

F

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

I

S T R U C T I O

N U F A C T U R E R

W

R R A N

Y

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

H

M M E N

S A P P R O V

N A L

A P P R O V

Division 01

01 11 00 – P 1.1.2 a.

Ground Penetrating Radar Survey

X

01 11 00 – P 1.1.2 b.

Lead Based Paint and Asbestos Containing Materials Survey

X

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

01 11 00 – P

1.12.2.3 Submit

written evidence to demonstrate the hazardous waste treatment, storage, or disposal facility (TSD) is approved for lead disposal by the EPA, State or local regulatory agencies. Submit one copy of the completed hazardous waste manifest, signed and dated by the initial transporter in accordance with 40 CFR 262. Provide a certificate that the waste was accepted by the disposal facility.

X

01 11 00 – P 1.12.8 Landfill disposal receipts and/or manifests

X

01 11 00 – P 1.13.3 Safety Plan

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

01 11 00 – P 1.13.4.1 Safety Data Sheets

X

01 11 00 – P 1.24 Personnel List

X

01 11 00 – P 1.25 Final Record Drawings

X

01 11 00 – P 1.26 Written request for Final Inspection

X

01 11 00 – P 1.29 Training Lesson Plan;

Trainer Qualifications

X

01 11 00 – P 1.29 Letter listing all personnel attending training and training subject, date, time, and location

X

01 32 01.00 10 – P 1.3 Preliminary draft Construction Progress Schedule

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

01 32 01.00 10 – P 1.3 Final Construction Progress Schedule

X

01 32 01.00 10 – P 1.3 Updated Construction Progress Schedule every month

X

01 32 01.00 10 – P 1.3 Schedule of Values

X

01 33 00 – P 1.2.4 Long Lead Items

X

01 33 00 – P 1.3.10 Operation and Maintenance Manual

X

01 33 00 – P 1.3.11 Operating Instructions

X

01 33 00 – P 1.3.12 Training Instructions

X

01 45 00.10 20 – P1.2 QC Plan

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

01 45 00.10 20 – P1.2 QC Manager Certification of As- Built Drawing(s) accuracy

X

01 78 23 – P 1.2 Facilities Preventive Maintenance Program

(FPMP)

X

01 78 23 – P 1.2 Draft O&M Manuals;

Corrected O&M Manuals; Final O&M Manuals

X

Division 02

02 41 00 – P 1.3 Operator’s Qualifications

X

02 41 00 – P 1.3 Demolition Plan

X

02 41 00 – P1.3 Notification of Demolition and Renovation Forms

X

02 41 00 – P1.3 Proposed demolition and removal procedures

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

02 41 00 – P1.3 Accident Prevention Program

X

02 41 00 – P1.3 Site Safety and Health Plan

X

Division 03

03 33 00 – P 1.3 Reinforcing Fibers

X

03 33 00 – P 1.3 Local/Regional Materials

X

03 33 00 – P 1.3 Concrete Mix Design

X

03 33 00 – Par 1.3 Safety Data Sheets

X

03 33 00 – Par 1.3 Forest Stewardship Council (FSC) Certification

X

03 33 00 – Par 1.3 Field Testing Technician and Testing Agency

X

03 33 00 – Par 1.3 Manufacturer’s Instructions

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

03 33 00 – P 1.3 Liquid Chemical Floor Hardeners and Sealers

X

03 33 00 – P 1.3 Joint Sealants

X

Division 04 - 06

Not Applicable.

Division 07

07 21 16 – P 1.2 Blanket Insulation

X

07 21 16 – P 1.2 Recycled Content for Insulation Materials

X

07 21 16 – P 1.2 Sill Sealer Insulation

X

07 21 16 – P 1.2 Accessories

X

07 21 16 – P 1.2 Indoor Air Quality for Insulation Materials

X

07 21 16 – P 1.2 Indoor Air Quality for Adhesives

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

07 21 16 – P 1.2 Manufacturer's Instructions

X

07 21 16 – P 1.2 Insulation

X

07 27 36 – P 1.3 Qualification of Manufacturer

X X

07 27 36 – P 1.3 Qualification of Installer

X X

07 27 36 – P 1.3 Quality Control Plan

X

07 27 36 – P 1.3 Safety Plan

X

07 27 36 – P 1.3 Fire Prevention Plan

X

07 27 36 – P 1.3 Respirator Plan

X

07 27 36 – P 1.3 Spray Foam Air Barrier System

X

07 27 36 – P 1.3 Closed Cell SPF

X X

07 27 36 – P 1.3 Primers, Adhesives, and Mastics

X X

07 27 36 – P 1.3 Sealants

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

07 27 36 – P 1.3 Safety Data Sheets

X

07 27 36 – P 1.3 Thermal Barrier Materials

X

07 27 36 – P 1.3 Accessories

X

07 27 36 – P 1.3 Recycled Content for Closed Cell Spray Foam Air Barrier;

X

07 27 36 – P 1.3 Spray Foam Air Barrier Field Mockup

X

07 27 36 – P 1.3 Field Peel Adhesion Test

X

07 27 36 – P 1.3 Thermographic Test

X

07 27 36 – P 1.3 Primers

X

07 27 36 – P 1.3 Fire-Ratings of Thermal Barrier Materials

X

07 27 36 – P 1.3 Flame Spread and Smoke Developed Index Ratings of SPF Products

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

07 27 36 – P 1.3 Site Inspections Reports

X

07 27 36 – P 1.3 Indoor Air Quality for Spray Foam Air Barrier

X

07 27 36 – P 1.3 Procedures

X

07 27 36 – P 1.3 Substrate Preparation

X

07 27 36 – P 1.3 Thermal Barrier

X

07 27 36 – P 1.3 Ignition Barrier

X

07 27 36 – P 1.3 Core Samples

X

07 27 36 – P 1.3 Daily Work Record

X

07 27 36 – P 1.3 Visual Inspection and Thermal Scanning

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

07 54 23 – P 1.3 Roof Plan Drawing to include: Detail drawings; boundaries of enhanced perimeter;

attachments of roof system components;

perimeter, corner, and infield fasteners

X

07 54 23 – P 1.3 TPO Roofing membrane

X

07 54 23 – P 1.3 Bonding adhesive

X

07 54 23 – P 1.3 Flashing

X X

07 54 23 – P 1.3 Membrane fasteners and plates

X

07 54 23 – P 1.3 Roof insulation

X

07 54 23 – P 1.3 Roof cover board

X

07 54 23 – P 1.3 Wall and Curb accessories

X

07 54 23 – P 1.3 Penetration Accessories

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

07 54 23 – P 1.3 Wind uplift resistance

X X

07 54 23 – P 1.3 Qualification of manufacturer

X

07 54 23 – P 1.3 Qualifications of applicator

X

07 54 23 – P 1.3 Fire resistance classification

X

07 54 23 – P 1.3 Sample warranty

X

07 54 23 – P 1.3 application

X

07 54 23 – P 1.3 Application Method;

including pattern and frequency of mechanical attachments required in the field of roof, corners, and perimeters to provide for the specified wind resistance Membrane Flashing

X

07 54 23 – P 1.3 Fasteners

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

07 54 23 – P 1.3 Pre-Manufactured Accessories

X

07 54 23 – P 1.3 Warranty

X

07 54 23 – P 1.3 Information card

X

07 54 23 – P 1.3 Instructions to Government Personnel

X

07 54 23 – P 1.3 Roofing system manufacturer’s maintenance instructions

X

Division 08

Not Applicable.

Division 09

09 29 00 – P1.2 Cementitious Backer Units

X

09 29 00 – P1.2 Water-Resistant Gypsum Board

X

09 29 00 – P1.2 Accessories

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 29 00 – P1.2 Each type of gypsum board and backer units

X

09 29 00 – P1.2 VOC content of joint compound

X

09 29 00 – P1.2 Asbestos Free Materials

X

09 29 00 – P1.2 Indoor Air Quality for Gypsum Board

X

09 29 00 – P1.2 Indoor Air Quality for Non-aerosol Adhesives

X

09 29 00 – P1.2 Indoor Air Quality for Aerosol Adhesives

X

09 29 00 – P1.2 Safety Data Sheets

X

09 29 00 – P1.2 Manufacturer Maintenance Instructions

X

09 65 00 – P1.2.1 Seaming Plan

X X X

09 65 00 – P1.2.1 Coving Details

X X X

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 65 00 – P1.2.2 Colors for flooring and applicable Accessories

X X

09 65 00 – P1.2.3 Adhesives

X X

09 65 00 – P1.2.3 Moisture Mitigation Systems

X X

09 65 00 – P1.2.3 Primers

X X

09 65 00 – P1.2.3 Patching/Leveling Compounds

X X

09 65 00 – P1.2.3 Floor Finishes (polishes) and cleaning agents

X X

09 65 00 – P1.2.3 Flooring Products

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 65 00 – P1.2.4 Operation and maintenance data for installed products;

include methods for maintaining installed products, and precautions against cleaning materials and methods detrimental to finishes and performance

X

09 65 00 – P1.2.4 Warranty documents specified

X

09 67 23.13 – P 1.3 Installation Drawings

X

09 67 23.13 – P 1.3 Manufacturer's Data sheets on product to be used, including:

Preparation instructions and recommendations;

storage and handling requirements and recommendations; and installation methods

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 67 23.13 – P 1.3 Verification Samples: For each finish product specified, submit 1 sample 12 by 12 inches in size in color, chip size and variation, and matrix color, representing actual product scheduled;

Min. 4 by 4 inch sample showing Specified Glaze Coat

X

09 67 23.13 – P 1.3 Listing of Product Installations

X

09 67 23.13 – P 1.3 Referenced Standards Certificates

X

09 67 23.13 – P 1.3 Manufacturer’s Flooring System cleaning and maintenance recommendations

X

09 67 23.13 – P 1.3 Warranty

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 90 00 – P 1.2 Piping Identification

X

09 90 00 – P 1.2 Coatings

X X

09 90 00 – P 1.2 Sealants

X

09 90 00 – P 1.2 Color

X

09 90 00 – P 1.2 Applicator’s Qualifications

X

09 90 00 – P 1.2 Indoor Air Quality for Paints and Primers

X

09 90 00 – P 1.2 Indoor Air Quality for Consolidated Latex Paints

X

09 90 00 – P 1.2 Application Instructions

X

09 90 00 – P 1.2 Mixing

X

09 90 00 – P 1.2 Manufacturer’s Safety Data Sheets

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 90 00 – P 1.2 Preprinted cleaning and maintenance instructions for all coating systems

X

09 90 00 – P 1.2 Coatings

X

09 97 13.27 – P 1.3 LBM Testing Results

X

09 97 13.27 – P 1.3 Containment System

X

09 97 13.27 – P 1.3 Recyclable Encapsulated Abrasive Media

X X X X

09 97 13.27 – P 1.3 Recyclable Encapsulated Abrasive Media Safety Plan

X

09 97 13.27 – P 1.3 Joint Sealant Qualification Test Reports

X

09 97 13.27 – P 1.3 Coatings Qualification Test Reports

X

09 97 13.27 – P 1.3 Coating Sample Test Reports

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 97 13.27 – P 1.3 Inspection Report Forms

X

09 97 13.27 – P 1.3 Daily Inspection Reports

X

09 97 13.27 – P 1.3 Contract Errors, Omissions, and Other Discrepancies

X

09 97 13.27 – P 1.3 Corrective Action Procedures

X

09 97 13.27 – P 1.3 Coating Work Plan

X

09 97 13.27 – P 1.3 Qualifications of Certified Protective Coating Specialist

(PCS)

X

09 97 13.27 – P 1.3 Qualifications of Individuals Performing Recyclable Encapsulated Media Blasting

X

09 97 13.27 – P 1.3 Qualifications of QC Specialist Coating Inspector

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 97 13.27 – P 1.3 Qualifications of Coating Contractors

X

09 97 13.27 – P 1.3 Joint Sealant Materials

X X

09 97 13.27 – P 1.3 Coating Materials

X

09 97 13.27 – P 1.3 Coating System Component Compatibility

X

09 97 13.27 – P 1.3 Coating System

X

09 97 13.27 – P 1.3 Recyclable Encapsulated Abrasive Media Manufacturer’s approved list of application equipment to be used on this project

X

09 97 13.27 – P 1.3 Recyclable Encapsulated Abrasive Media Shipping Handling and Storage

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

09 97 13.27 – P 1.3 Recycling or Disposal of Used Abrasive

X

09 97 13.27 – P 1.3 Inspection Logbook

Division 10 - 12

Not Applicable.

Division 13

13 34 19 – P 1.5 Manufacturer’s Qualifications

X

13 34 19 – P 1.5 Detail Drawings

X

13 34 19 – P 1.5 Erection Plan

X

13 34 19 – P 1.5 Manufacturer’s Catalogue Data

X

13 34 19 – P 1.5 Fasteners

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

13 34 19 – P 1.5 Metal Closure Strips 10 inches long of each type

X

Manufacturer's Color Charts and Chips, 4 by 4 inches

X

13 34 19 – P 1.5 Manufacturer’s Descriptive and Technical Literature

X

13 34 19 – P 1.5 Manufacturer’s Building and Design Analysis

X

13 34 19 – P 1.5 Test Reports

X

13 34 19 – P 1.5 Coatings and Base Metals

X

13 34 19 – P 1.5 Factory Color Finish Performance Requirements

X

13 34 19 – P 1.5 System Components

X

13 34 19 – P 1.5 Coil Stock Certification

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

13 34 19 – P 1.5 Galvanizing Repair Paint

X

13 34 19 – P 1.5 Enamel Repair Paint

X

13 34 19 – P 1.5 Qualification of Manufacturer

X

13 34 19 – P 1.5 Qualification of Erector

X

13 34 19 – P 1.5 Installation of Roof and Wall Panels

X

13 34 19 – P 1.5 Shipping, Handling and Storage

X

13 34 19 – P 1.5 Manufacturer’s Warranty

X

13 34 19 – P 1.5 Contractor’s Warranty for Installation

Division 14 - 21

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

Division 22

22 00 00 P 1.2 Piping and joining materials

X

22 00 00 – P 1.2 Valves, Thermostatic Mixing valves

X X

22 00 00 – P 1.2 Plumbing Fixtures

X X

22 00 00 – P 1.2 List of Installed fixtures with manufacturer, model, and flow rate

X

22 00 00 – P 1.2 Flush Tank Water Closet

X

22 00 00 – P 1.2 Wall Hung Lavatories

X

22 00 00 - P 1.2 Floor drains

X X

22 00 00 - P 1.2 Shower Faucets

X X

22 00 00 - P 1.2 Instantaneous Water Heater

X X

22 00 00 - P 1.2 Copper tubing

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

22 00 00 - P 1.2 Welding

X

22 00 00 - P 1.2 Operational Test, flushing and disinfection

Division 23

23 00 00 – P 1.3 Ductwork

X

23 00 00 – P 1.3 Duct Connectors

X

23 00 00 – P 1.3 Manual Balancing Dampers

X X

23 00 00 – P 1.3 Registers and Grilles

X

23 00 00 – P 1.3 Ceiling Exhaust Fans

X X

23 00 00 – P 1.3 Ductless split system

X X

23 00 00 – P 1.3 Damper Acceptance Test

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

23 00 00 – P 1.3 Independent TAB Agency and Personnel Qualifications

X

23 00 00 – P 1.3 Instrument Calibration

X X X

23 00 00 – P 1.6.4.6 Final DALT Report by

TAB

X X

23 00 00 – P 3.11 Equipment Operation and Maintenance Manuals

X

23 00 00 – P2.10.8 Sheet Metal duct with Internal Lining insulation

X X

23 00 00 – P2.10.10 Diffusers

Division 24 - 25

Division 26

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

26 12 21 – P 1.2 Pad-mounted transformer

X X X X

26 12 21 – P 1.2 Acceptance Checks and Tests

X

26 12 21 – P 1.2 Transformer efficiencies

X

26 12 21 – P 1.2 Transformer test schedule

X

26 12 21 – P 1.2 Transformer, data package

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

26 20 00 – P 1.3.1 Identify the feeder’s path of the existing Ant Maintenance Shed Electrical Subpanel (S04) to be demolished. Also, the start points of the feeder, (supply panel, bar, switchgear, and breaker and/or disconnect switch) and the grounding system of the existing Ant Maintenance Shed Electrical Subpanel (S04) to be replaced.

X

26 20 00 – P 1.3.2 Panelboards X

26 20 00 – P 1.3.2 & P 1.3.3 Transformers

X X

26 20 00 – P 1.3.2 Cable Trays

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

26 20 00 – P 1.3.2 & P 1.3.3 Load Centers

X X

26 20 00 – P 1.3.3 Receptacles

X

26 20 00 – P 1.3.3 Circuit Breakers

X

26 20 00 – P 1.3.3 Switches

X

26 20 00 – P 1.3.3 Enclosed Circuit Breakers

X

26 20 00 – P 1.3.3 CATV Outlets

26 20 00 – P 1.3.4 600-volt Wiring Test

X

26 20 00 – P 1.3.4 Grounding System Test

X

26 20 00 – P 1.3.4 Transformer Tests

X

26 20 00 – P 1.3.4 Ground-fault Receptacle Test

X

26 20 00 – P 1.3.4 Arc-fault Receptacle Test

X

26 20 00 – P 1.3.5 Fuses

PROJECT TITLE

USCG STATION FT. PIERCE MAJOR MAINTENANCE & REPAIR STATION

PROJECT NUMBER

SUBMITTAL

DESCRIPTION

SUBMITTAL TYPES REQUIRED

R E Q U I R

B M I S S I O N

D A

B M I T T A L

N U M B

S U B M T T

M B

T E

N T R A C T I

T E

T O

P R O J E

N A G

REMARKS

S H O P

D R A W I N

O D U C T

D A

S T

R E P O R

M P L

R T I F I C A T E S

M P L I A N

A N D A R D S

M P L I A N

N U F A C T U R E R

S T R U C T I O

N U F A C T U R E R

R R A N

E R A T I O N

A

I N T E N A N C E

D A

H

P R O V

P R O V E D

W I

M M E N

S A P P R O V

N A L

A P P R O V

26 20 00 – P 1.3.6 Transformer Factory Tests

X

26 24 16.00 40 – P 1.2 Panelboards

X

26 24 16.00…