6973GH-20-R-00130.pdf

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

AC-20-03647

AAQ-721 LOGISTICS CENTER ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ0721-AFN

OKLAHOMA CITY OK 73125

Cilony Alejandro 405-954-7814 x

06/04/2020 44

PURCHASE REQUEST NO.

6973GH-20-R-00130

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Under $25,000.00

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

5 30 calendar days and complete it within ________________ ________________ calendar days after receiving

06/26/2020 x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

AAQ-721 LOGISTICS CENTER ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ721-AFN

OKLAHOMA CITY OK 73125

Cilony Alejandro

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 44

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

6973GH-20-R-00130

(A) (B) (C) (D) (E) (F)

Delivery: 30 Days After Notice to Proceed

Delivery Location Code: 26991BPF

March Air Reserve Base, CA

Moreno Valley, CA

FOB: Destination

00001 Concrete Sidewalks and Curbing

Electronic & IT: 03

Section A - Solicitation/Contract Form Clauses

Section B - Supplies or Services/Prices Section B - Schedule

The contractor shall furnish all labor, tools, materials, equipment, transportation, and supplies necessary to complete all work defined in the statement of work.

ITEM NO. DESCRIPTION UNIT

PRICE

0001 INSTALL CONCRETE WALKWAYS AT

THE MARCH AIR RESERVE BASE IN CALIFORNIA $________

PERIOD OF PERFORMANCE:

TO BE COMPLETED 30 DAYS AFTER NTP

FIRM FIXED-PRICE AMOUNT $ _________

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

C.1 STATEMENT OF WORK (SOW)

The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project set forth, in accordance with the attached technical specifications, drawings, and all other terms,conditions, and provisions as set forth herein.

Section D - Packaging and Marking

Section E - Inspection and Acceptance Clause List

E.1 INSPECTION

The Contracting Officer or his authorized representative may at all reasonable times inspect or otherwise evaluate the work being performed hereunder and the premises on which it is being performed.If any inspection or evaluation is made on the premises of the vendor or his subcontractor, the vendor shall provide and shall require his subcontractors to provide all reasonable facilities and assistance for the safety and convenience of the Government representatives in the performance of their duties. All inspections and evaluations shall be performed in such a manner as will not unduly delay the work.

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

Section F - Deliveries or Performance Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

Section G - Contract Administration Data

Clause List

H.1 PERMITS AND RESPONSIBILITIES

The Contractor shall secure and pay for all permits, licenses, special inspections, etc., required in the execution ofthe work, whether of a permanent or temporary nature.The Contractor shall secure and pay for all permits, licenses, special inspections, etc.., required in the execution of the work, whether of a permanent or temporary nature.

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

AC1227 RELEASE FORM (JAN 1997)

The contractor will be required to execute Contractor's Release Form DOT F 4220.4 (2-71) prior to final payment under the contract. (Note: A copy of Form DOT F 4220.4 (2-71) is attached hereto for information purposes.)

AC2916 PAYMENT PROCEDURES (JUL 1997)

(a) The contractor shall submit original invoices, including applications for installment payments, directly to:

The original to: 9-AMC-AMZ-FAA-APInvoices@faa.gov (Preferred) or mail to:

FAA, Mike Monroney Aeronautical Center

DOT/FAA AMK-311/314

P.O. Box 25710 Oklahoma City, OK 73125-4913

(b) Payment for work performed or items furnished under this contract is subject to approval by the Contracting Officer. The contractor shall submit 1 copy of all invoices, including applications for installment payments, to:

FAA, Mike Monroney Aeronautical Center Cilony.Alejandro@faa,gov 6500 South MacArthur Boulevard P.O. Box 25082 Oklahoma City, OK 73125

(c) Each invoice, including applications for installment payments, must reflect the contract number, delivery order number, and a description of the work, services, or items being invoiced.

mailto:Cilony.Alejandro@faa,gov

Section H - Special Contract Requirements Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2018)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

AC1231 NOTIFICATION REQUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS

REMOVED/DISTURBED (JAN 1997)

(a) Prior to any planned and/or scheduled disturbance of friable asbestos material, mainly CAFCO ceilings, the contractor shall present a written plan to the Contracting Officer. The plan shall include, but not be limited to, location, type facility, size of area to be disturbed or removed, method of containment to be used, disposal procedures, clean-up procedures, number of employees involved, protective clothing/equipment to be used, the date and time removal/disturbance is planned and any other information requested by the Contracting Officer. The contractor shall not proceed with any removal or disturbance of friable asbestos material without written approval from the Contracting Officer.

(b) If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-1 EXCLUSION FROM FUTURE AGENCY CONTRACTS (JUL 2018)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JUL 2018)

3.2.2.3-42 DIFFERING SITE CONDITIONS (JUL 2004)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (JUL 2004)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-48 OTHER CONTRACTS (MAR 2009)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-62 PRECONSTRUCTION CONFERENCE (JUL 2004)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2019)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2019)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2019)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (OCT

2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD MANAGEMENT

(JUL 2018)

3.3.2-1 FAA COST PRINCIPLES (OCT 2019)

3.4.1-7 NOTICE TO PROCEED (OCT 2019)

3.4.1-8 PATENT INFRINGEMENT BOND REQUIREMENTS (OCT 2019)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2019)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT 1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (JUL 2019)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JAN

2009)

3.5-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS (JAN 2009)

3.5-23 RIGHTS TO PROPOSAL DATA (TECHNICAL) (JAN 2009)

3.6.1-1 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (OCT 2019)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED, AND

SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS CONCERNS (OCT 2019)

3.6.1-4 SMALL, SMALL DISADVANTAGED, WOMEN-OWNED AND SERVICE-DISABLED VETERAN

OWNED SMALL BUSINESS SUBCONTRACTING PLAN (JUL 2019)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (JUL 2019)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (OCT 2019)

3.6.2-9 EQUAL OPPORTUNITY (OCT 2018)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (OCT 2018) - ALTERNATE I (JAN 2012)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (OCT 2018)

3.6.2-18 DAVIS BACON ACT (OCT 2018)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (JUL 2017)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2017)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (JAN 2019)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (JAN 2019)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (JAN 2019)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (OCT 2018)

3.6.2-39 TRAFFICKING IN PERSONS (APR 2019)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (JAN 2020)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (JAN 2020)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-22 CONSTRUCTION WASTE MANAGEMENT (JAN 2020)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (JAN 2020)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.4-4 BUY AMERICAN ACT - CONSTRUCTION MATERIALS UNDER NORTH AMERICAN FREE

TRADE AGREEMENT (APR 2020)

3.6.4-5 BUY AMERICAN - STEEL AND MANUFACTURED PRODUCTS (JUL 2010)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.4-23 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (OCT 2019)

3.6.5-1 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN OWNED ECONOMIC

ENTERPRISES (MAR 2009)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 1996)

3.10.1-16 CHANGES AND CHANGED CONDITIONS (APR 1996)

3.10.1-20 WARRANTY-CONSTRUCTION (JUL 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.3-2 GOVERNMENT PROPERTY - BASIC CLAUSE (APR 2019)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV 1997)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT 1996)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.2.2.3-41 PERFORMING WORK (JUL 2004)

The Contractor (you) must perform, using your own organization, work equivalent to at least 15 percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if you request a reduction and the CO determines that it would be to the Government's advantage to do so.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 5 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 30. The time allowed for completion must include final cleanup of the premises.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004) -

ALTERNATE I (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 5 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 30. The time allowed for completion must include final cleanup of the premises.

(d) The completion date assumes that the successful offeror will receive the notice to proceed by 15. The CO will extend the completion date by the number of calendar days after the above date that you receive the notice to proceed, except to the extent that the delay in issuing the notice to proceed results from your failure to execute the contract and give the required performance and payment bonds to FAA within the time specified.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (JUL 2018)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, https://www.vip.vetbiz.gov.

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor must provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) change the name in the SAM database;

(B) comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor must not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees must be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.6.2-2 CONVICT LABOR (APR 1996)

The Contractor agrees not to employ any person undergoing sentence of imprisonment in performing this contract except as provided by 18 U.S.C. 4082(c)(2) and Executive Order 11755.

(End of clause)

3.6.2-41 EMPLOYMENT ELIGIBILITY VERIFICATION (OCT 2019)

(a) Definitions:

"Employee assigned to the contract" means an employee who was hired after November 6, 1986, who is directly performing work, in the United States, under a contract that is required to include the Employment Eligibility Verification clause. An employee is not considered to be directly performing work under a contract if the employee-

(1) Normally performs support work, such as indirect or overhead functions; and

(2) Does not perform any substantial duties applicable to the contract.

"Subcontract" means any contract entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.

"Subcontractor" means any supplier, distributor, vendor, or firm that furnishes supplies or services to or for a prime Contractor or another subcontractor.

"United States", as defined in 8 U.S.C. 1101(a)(38), except as otherwise specifically provided (in this statute) means the 50 States, the District of Columbia, Puerto Rico, Guam, the U.S. Virgin Islands, and the Commonwealth of the Northern Mariana Islands.

(b) Enrollment and verification requirements.

(1) If the Contractor is not enrolled as a Federal Contractor in Department of Homeland Security's Employment Eligibility Verification system ("E-Verify") at time of contract award, the Contractor must--

(i) Enroll. Enroll as a Federal Contractor in the E-Verify program within 30 calendar days of contract award;

(ii) Verify all new employees. Within 90 calendar days of enrollment in the E-Verify program, begin to use E-Verify to initiate verification of employment eligibility of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); and

(iii) Verify employees assigned to the contract. For each employee assigned to the contract, initiate verification within 90 calendar days after date of enrollment or within 30 calendar days of the employee's assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).

(2) If the Contractor is enrolled as a Federal Contractor in E-Verify at time of contract award, the Contractor must use E-Verify to initiate verification of employment eligibility of--

(i) All new employees.

(A) Enrolled 90 calendar days or more.

The Contractor must initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); or

(B) Enrolled less than 90 calendar days. Within 90 calendar days after enrollment as a Federal Contractor in E-verify, the Contractor must initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); or

(ii) Employees assigned to the contract. For each employee assigned to the contract, the Contractor must initiate verification within 90 calendar days after date of contract award or within 30 calendar days after assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).

(3) If the Contractor is an institution of higher education (as defined at 20 U.S.C. 1001(a)); a State or local government or the government of a Federally recognized Indian tribe; or a surety performing under a takeover agreement entered into with a Federal agency pursuant to a performance bond, the Contractor may choose to verify only employees assigned to the contract, whether existing employees or new hires. The Contractor must follow the applicable verification requirements at (b)(1) or (b)(2), respectively, except that any requirement for verification of new employees applies only to new employees assigned to the contract.

(4) Option to verify employment eligibility of all employees. The Contractor may elect to verify all existing employees hired after November 6, 1986, rather than just those employees assigned to the contract. The Contractor must initiate verification for each existing employee working in the United States who was hired after November 6, 1986, within 180 calendar days of--

(i) Enrollment in the E-Verify program; or

(ii) Notification to E-Verify Operations of the Contractor's decision to exercise this option, using the contact information provided in the E-Verify program Memorandum of Understanding (MOU).

(5) The Contractor must comply, for the period of performance of this contract, with the requirements of the E- Verify program MOU.

(i) The Department of Homeland Security (DHS) or the Social Security Administration (SSA) may terminate the Contractor's MOU and deny access to the E-Verify system in accordance with the terms of the MOU. In such case, the Contractor will be referred to a suspension or debarment official by the terminating agency.

(ii) During the period between termination of the MOU and a decision by the suspension or debarment official whether to suspend or debar, the Contractor is excused from its obligations under paragraph (b) of this clause. If the Contractor is suspended or debarred as a result of the MOU termination, the contractor is not eligible to participate in E-Verify during the period of its suspension or debarment. If the suspension or debarment official determines not to suspend or debar the Contractor, then the Contractor must reenroll in E-Verify.

(c) Web site. Information on registration for and use of the E-Verify program can be obtained via the Internet at the Department of Homeland Security Web site: http://www.dhs.gov/E-Verify.

(d) Individuals previously verified. The Contractor is not required by this clause to perform additional employment verification using E-Verify for any employee--

(1) Whose employment eligibility was previously verified by the Contractor through the E-Verify program;

(2) Who has been granted and holds an active U.S. Government security clearance for access to confidential, secret, or top secret information in accordance with the National Industrial Security Program Operating Manual; or

(3) Who has undergone a completed background investigation and been issued credentials pursuant to Homeland Security Presidential Directive (HSPD)-12, Policy for a Common Identification Standard for Federal Employees and Contractors.

(e) Subcontracts. The Contractor must include the requirements of this clause, including this paragraph (e) (appropriately modified for identification of the parties), in each subcontract that is for Noncommercial services or construction with a value greater than $3,000 and includes work that is performed inside of the United States.

(End of Clause)

3.6.3-12 ASBESTOS - FREE CONSTRUCTION (APR 2017)

(a) In performing this contract, the Contractor must not use asbestos or asbestos-containing building materials during construction, renovation, and/or modernization of this facility.

(b) The Contractor must provide to the Contracting Officer (CO) a signed statement prior to final acceptance indicating that no asbestos or asbestos-containing building materials were used during construction, renovation, and/or modernization of this facility. The Contractor's certification under this clause is considered to be a material requirement of the contract and the FAA may withhold payment pending submittal and receipt of an acceptable certification.

(c) The FAA retains the right to conduct sampling of contractor building materials used during construction, renovation, and/or modernization of this facility to verify that they are asbestos-free. If asbestos-containing material is found, the Contractor must bear the expense of the sampling conducted by the FAA, remove and replace the asbestos-containing material and decontaminate the site of asbestos contamination caused by the Contractor at no additional cost to the Government. In addition, the Contractor must bear the expense of all testing (bulk sampling and air sampling conducted by the contactor and the FAA) to determine that the asbestos removal and site decontamination are satisfactorily completed. The Contractor must follow all applicable federal, state, and local asbestos regulatory requirements as well as applicable FAA Orders with respect to asbestos abatement when the Contractor is required to remove asbestos materials they have installed.

(End of clause)

3.10.1-19 MODIFICATION COST PROPOSAL - PRICE BREAKDOWN (CONSTRUCTION) (JUL 1996)

(a) The contractor, in connection with any proposal it makes for a contract modification, shall furnish a price breakdown, itemized as required by the Contracting Officer. The breakdown shall be in enough detail to permit an analysis of all material, labor, equipment, subcontract, and overhead costs, as well as profit, and shall cover all work involved in the modification, whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by similar price breakdowns from those subcontractors.

(b) In addition, if the proposal includes a time extension, a justification thereof shall also be furnished.

Notwithstanding any other provisions of this contract, it is mutually understood that the time extension for changes in the work will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of work. The contract completion dates will be extended only for those specific elements so delayed and the remaining contract completion dates for all other portions of the work will not be altered.

(c) The proposal, together with the price breakdown and time extension justification, shall be furnished by the date specified by the Contracting Officer.

(End of clause)

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within 5 calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

3.10.2-1 SUBCONTRACTS (FIXED-PRICE CONTRACTS) (JAN 2019)

(a) Consent to subcontract in this clause applies to subcontracts resulting from unpriced modifications to this contract if required as indicated under (b) or (c) below.

(b) Subcontract, as used in this clause, includes but is not limited to purchase orders, and changes and modifications to purchase orders. The Contractor must notify the Contracting Officer reasonably in advance of entering into any subcontract if the Contractor does not have an approved purchasing system and if the subcontract:

(1) Is proposed to exceed $150,000; or

(2) Is one of a number of subcontracts with a single subcontractor, under this contract, for the same or related supplies or services, that in the aggregate are expected to exceed $150,000.

(c) If the contractor has an approved purchasing system, the contractor nevertheless must obtain the Contracting Officer's written consent before placing the following subcontracts:

[Fillin subcontract] [Fillin subcontract] [Fillin subcontract]

(d) The advance notification required by paragraphs (b) and (c) above must include-

(1) A description of the supplies or services to be subcontracted;

(2) Identification of the type of subcontract to be used;

(3) Identification of the proposed subcontractor and an explanation of why and how the proposed subcontractor was selected, including the competition obtained;

(4) The proposed subcontract price and the Contractor's cost or price analysis;

(5) The subcontractor's current, complete, and accurate cost or pricing data and Certificate of Current Cost or Pricing Data, if required by other contract provisions;

(6) The subcontractor's Disclosure Statement or Certificate relating to Cost Accounting Standards when such data are required by other provisions of this contract; and

(7) A negotiation memorandum reflecting-

(i) The principal elements of the subcontract price negotiations;

(ii) The most significant considerations controlling establishment of initial or revised prices;

(iii) The reason cost or pricing data were or were not required;

(iv) The extent, if any, to which the Contractor did not rely on the subcontractor's cost or pricing data in determining the price objective and in negotiating the final price;

(v) The extent, if any, to which it was recognized in the negotiation that the subcontractor's cost or pricing data were not accurate, complete, or current; the action taken by the Contractor and subcontractor; and the effect of any such defective data on the total price negotiated;

(vi) The reasons for any significant difference between the Contractor's price objective and the price negotiated; and

(vii) A complete explanation of the incentive fee or profit plan when incentives are used. The explanation must identify each critical performance element, management decisions used to quantify each incentive element, reasons for the incentives, and a summary of all trade-off possibilities considered.

(e) The Contractor must obtain the Contracting Officer's written consent before placing any subcontract for which advance notification is required under paragraph (b) above. However, the Contracting Officer may ratify in writing any such subcontract. Ratification will constitute the consent of the Contracting Officer.

(f) Even if the Contractor's purchasing system has been approved, the Contractor must obtain the Contracting Officer's written consent before placing subcontracts identified below:

(g) Unless the consent or approval specifically provides otherwise, neither consent by the Contracting Officer to any subcontract nor approval of the Contractor's purchasing system will constitute a determination:

(1) of the acceptability of any subcontract terms or conditions,

(2) of the acceptability of any subcontract price or of any amount paid under any subcontract, or

(3) to relieve the Contractor of any responsibility for performing this contract.

(h) No subcontract placed under this contract will provide for payment on a cost-plus-a-percentage-of-cost basis.

(i) The Government reserves the right to review the Contractor's purchasing system.

(End of clause)

3.13-16 RECORDS MANAGEMENT (JAN 2020)

(a) Definitions.

Federal record as defined in 44 U.S.C. § 3301, means all recorded information, regardless of form or characteristics, made or received by a Federal agency under Federal law or in connection with the transaction of public business and preserved or appropriate for preservation by that agency or its legitimate successor as evidence of the organization, functions, policies, decisions, procedures, operations, or other activities of the United States Government or because of the informational value of data in them. The term Federal record:

(1) Includes all FAA records.

(2) Does not include personal materials.

(3) Applies to records created, received, or maintained by Contractors pursuant to a FAA contract.

(4) May include deliverables and documentation associated with deliverables.

(b) Requirements.

(1) Compliance. The contractor must comply with all applicable records management laws and regulations, as well as National Archives and Records Administration (NARA) records policies, including but not limited to the Federal Records Act (44 U.S.C. chapters 21, 29, 31, 33), NARA regulations at 36 CFR Chapter XII Subchapter B, and those policies associated with the safeguarding of records covered by Privacy Act of 1974 (5 U.S.C. 552a), to the extent that the Privacy Act applies to any records maintained by the Contractor. These policies include the preservation of all Federal records, regardless of form or characteristics, mode of transmission, or state of completion.

(2) Applicability. All data created for Government use and delivered to, or falling under, the legal control of the Government, are Federal records subject to the provisions of 44 U.S.C. chapters 21, 29, 31, and 33. Such Federal records must be managed and scheduled for disposition only as permitted by the Federal Records Act, relevant statute or regulation, and FAA Order 1350.14 "Records Management" at https://www.faa.gov/documentLibrary/media/Order/FAA_1350.14B.pdf.

(3) Records maintenance. While in Contractor's custody, the Contractor is responsible for preventing the alienation or unauthorized destruction of FAA records, including all forms of mutilation. Records may not be removed from the legal custody of FAA or destroyed except in accordance with the provisions of the agency records schedules and with the written concurrence of the FAA Agency Records Officer (ARO) (or the ARO's designate) and Contracting Officer, as appropriate. Willful and unlawful destruction, damage or alienation of Federal records is subject to the fines and penalties imposed by 18 U.S.C. 2701. In the event of any unlawful or accidental removal, defacing, alteration, or destruction of records, the Contractor must report the event to the Contracting Officer in accordance with 36 CFR 1230, Unlawful or Accidental Removal, Defacing, Alteration, or Destruction of Records, for reporting to NARA by FAA Records Management. Electronic records and associated metadata must be accompanied by sufficient technical documentation to permit understanding and use of the records and data.

(4) Unauthorized disclosure. The Contractor must notify the Contracting Officer within 2 (two) hours of discovery of any inadvertent or unauthorized disclosures of information, data, documentary materials, records or equipment.

Disclosure of non-public information is limited to authorized personnel with a need-to-know as described in the contract. The Contractor must ensure that the appropriate personnel, administrative, technical, and physical safeguards are established to ensure the security and confidentiality of this information, data, documentary material, records and/or equipment is properly protected. The Contractor must not remove material from Government facilities or systems, or facilities or systems operated or maintained on the Government's behalf, without the express written permission of the FAA ARO (or the ARO's designate) and the Contracting Officer. Destruction of records is expressly prohibited unless in accordance with the contract.

(c) Records management contracts - where the contractor is required to design, develop, and/or operate a system of records, the following additional requirements apply:

During the contract, the FAA ARO (or ARO's designate) has the right to inspect where the records are stored (digitally or paper records) in order to ensure they are properly protected from the elements and/or loss. This inspection must be coordinated through the Contracting Officer or the Contracting Officer's Representative. The contractor must be provided 30 calendar days' notice of such inspections. This clause may be tailored to provide for a different notice period. Additional details regarding such inspections consistent with this clause may be specified in the Statement of Work.

For contracts where the contractor is responsible for managing FAA records, when the records are no longer required or at the completion of the contract, the records must be returned to FAA control. Items returned to the FAA must be hand carried, mailed, or securely electronically transmitted to the Contracting Officer or address indicated in the contract.

(d) Non-public information. The Contractor must not create or maintain any records containing any non-public FAA information that are not specifically tied to or authorized by the contract.

(e) Ownership. Consistent with all applicable data rights clauses in this contract, the FAA is the sole owner of the rights to all data and records produced as part of this contract. All deliverables under the contract are the property of the U.S.