36C25819B0032-001.docx

Section I

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C25819B0032 X 644-19-1-2362-0001 644-17-003 Department of Veterans Affairs NCO22-Gilbert Network Contracting 3601 S. 6th Avenue Tucson

AZ

85723 Department of Veterans Affairs Souther Arizona VA Healthcare System 3601 S. 6th Avenue Tucson

AZ

85723 Christina KellyTaylor 520.629.4618 Award is subject to the availability of funds.

Project Title: Renovate PCT/PMRS Clinic Backfill Project 644-17-003 Phoenix VA Healthcare System (PVAHCS), Phoenix, Arizona

In accordance with VAAR 836.204, Disclosed Magnitude of Construction Cost is between $1,000,000.00 and 2,000,000.00

Technical specifications and drawings describing the work to be performed are listed in Section C of this Solicitation and are incorporated herein by reference.

This requirement is 100% set aside for SDVOSB.

Applicable NAICS code and Size Standard for this Acquisition is 236220 / $36.5M This requirement is 100% set aside for SDVOSB Sole Source.

See Sched X X 52.211-10 X 11:30am (AZT) 08-28-2019 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

Department of Veterans Affairs NCO22-Gilbert Network Contracting 3601 S. 6th Avenue Tucson

AZ

85723 This is accomplished through the Tungsten Network located at:

http://www.fsc.va.gov/einvoice.asp This is mandatory and the sole method for submitting invoices.

John Kamerer

Table of Contents

SECTION B - SUPPLIES OR SERVICES AND PRICE/COSTS

Bid Schedule

BID ITEM 1

Construction to complete Project 644-17-003, Renovate PCT/PMRS Clinic Backfill.

The Remodel PCT project includes creating a new Emergency Power Electrical Closet, and tripling the size of the Normal Power Electrical Closet. The electrical work needed is thought to be the most complex portion of this project due to there being 3 adjacent clinics powered by circuits out of this PCT’s electrical closet in the center of the work area. The PCT electrical closet will have all the existing power panels removed and new breaker panels installed. The active circuits will need to be migrated over after clinical hours in a way that allows the VA’s active users in adjacent spaces to continue their patient appointments. The performance period for this contract is 275 Calendar Days. The General Contractor will have a site superintendent present at all times there is active construction work in progress on this project on the VA Phoenix Campus.

BID ITEM 1 LUMP SUM: $________________

Section B THE SPECIFICATIONS AND DRAWINGS CONTAIN DETAILED DESCRIPTION OF THE BID ITEM. IN THE EVENT OF A DISCREPANCY, THE SPECIFICATIONS WILL OVERRULE THE DRAWINGS Page 1 of Page 1 of

SECTION C - DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

See attached document: P07 Wage Determination 7.11.19.

See attached document: S02 Phoenix PMRS Corrected Final - Bid Set.

See attached document: S02 644-17-003 SOW_Final.

See attached document: S02 644-17-003 Revised Specifications June 2019.

See attached document: S02 644-17-003 Clarifications Drawing Set - Amended June2019 02.

See attached document: P01 VA provided PCT Materials List 8June2018.

See attached document: Attachment 7 Sample Cost and Price Breakdown Template.

[For this Solicitation, there are NO clauses in this Section] Section C

Page 1 of Page 1 of

SECTION E - INSPECTION AND ACCEPTANCE

Section E

Page 1 of Page 1 of

SECTION F - DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than See Sched days after receipt of award. The time stated for completion shall include final cleanup of the premises.

Section F (End of Clause) Page 1 of Page 1 of

SECTION G - CONTRACT ADMINISTRATION DATA

[For this Solicitation, there are NO clauses in this Section] Section G

Page 1 of Page 1 of

SECTION H - SPECIAL CONTRACT REQUIREMENTS

[For this Solicitation, there are NO clauses in this Section]

Section H

Page 1 of

PART II - CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

I.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

(End of Clause)

I.2 52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

(End of Clause)

17. N/A!!

I.3 52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

(a) The Government authorizes and consents to all use and manufacture, in performing this contract or any subcontract at any tier, of any invention described in and covered by a United States patent—

(1) Embodied in the structure or composition of any article the delivery of which is accepted by the Government under this contract; or

(2) Used in machinery, tools, or methods whose use necessarily results from compliance by the Contractor or a subcontractor with (i) specifications or written provisions forming a part of this contract or (ii) specific written instructions given by the Contracting Officer directing the manner of performance. The entire liability to the Government for infringement of a United States patent shall be determined solely by the provisions of the indemnity clause, if any, included in this contract or any subcontract hereunder (including any lower-tier subcontract), and the Government assumes liability for all other infringement to the extent of the authorization and consent hereinabove granted.

(b) The Contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts that are expected to exceed the simplified acquisition threshold. However, omission of this clause from any subcontract, including those at or below the simplified acquisition threshold, does not affect this authorization and consent.

(End of Clause) I.4 52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT COPYRIGHT INFRINGEMENT (DEC 2007)

(a) The Contractor shall report to the Contracting Officer, promptly and in reasonable written detail, each notice or claim of patent or copyright infringement based on the performance of this contract of which the Contractor has knowledge.

(b) In the event of any claim or suit against the Government on account of any alleged patent or copyright infringement arising out of the performance of this contract or out of the use of any supplies furnished or work or services performed under this contract, the Contractor shall furnish to the Government, when requested by the Contracting Officer, all evidence and information in the Contractor's possession pertaining to such claim or suit. Such evidence and information shall be furnished at the expense of the Government except where the Contractor has agreed to indemnify the Government.

(c) The Contractor shall include the substance of this clause, including this paragraph (c), in all subcontracts that are expected to exceed the simplified acquisition threshold.

(End of Clause)

I.5 SUPPLEMENTAL INSURANCE REQUIREMENTS

In accordance with FAR 28.307-2 and FAR 52.228-5, the following minimum coverage shall apply to this contract:

(a) Workers' compensation and employers liability: Contractors are required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a Contractor's commercial operations that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 is required, except in States with exclusive or monopolistic funds that do not permit workers' compensation to be written by private carriers.

(b) General Liability: per occurrences.

(c) Automobile liability: per person; per occurrence and property damage.

(d) The successful bidder must present to the Contracting Officer, prior to award, evidence of general liability insurance without any exclusionary clauses for asbestos that would void the general liability coverage.

(End of Clause)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, firms submitting offers or quotes are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for Thursday, August 2, 2019 at 09:00 AM (AZT)

(c) Participants will meet at the NMVAHCS campus in Albuquerque, New Mexico

(d) Contact Christina KellyTaylor by email at christina.kellytaylor@va.gov or email Gary Zettl at Gary.Zettl@va.gov for additional information on this site visit.

I.6 VAAR 852.252-70 SOLICITATION PROVISIONS OR CLAUSES INCORPORATED BY REFERENCE (JAN 2008) The following provisions or clauses incorporated by reference in this solicitation must be completed by the offeror or prospective contractor and submitted with the quotation or offer. Copies of these provisions or clauses are available on the Internet at the Web sites provided in the provision at FAR 52.252-1, Solicitation Provisions Incorporated by Reference, or the clause at FAR 52.252-2, Clauses Incorporated by Reference. Copies may also be obtained from the contracting officer.

[Contracting officer shall list all FAR and 48 CFR Chapter 8 (VAAR) provisions and clauses incorporated by reference that must be completed by the offeror or prospective contractor and submitted with the quotation or offer.] (End of Provision)