Specifications Mar 8 2024 - 506-21-105.pdf

DEPARTMENT OF VETERANS AFFAIRS

LIEUTENANT COLONEL CHARLES S. KETTLES

2215 FULLER ROAD

ANN ARBOR, MI 48105-2303

FACILITY INTERIOR SIGNAGE REPLACEMENT

VA Project No.: 506-21-105

100% BID DOCUMENTS

ADDENDUM #1

SPECIFICATIONS

Prepared By:

March 8, 2024

Lieutenant Colonel Charles S. Kettles VA Medical Center Facility Interior Signage Replacement

Project Number 506 21 105

03-01-22

TABLE OF CONTENTS

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

Section 00 01 10

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 05-20

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 11-21 01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 11-21 01 33 23 Shop Drawings, Product Data, and Samples 06-21 01 35 26 Safety Requirements 11-21 01 42 19 Reference Standards 11-20 01 45 00 Quality Control 02-21 01 58 16 Temporary Interior Signage 07-15 01 74 19 Construction Waste Management 11-21 01 81 13 Sustainable Construction Requirements 10-17

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17 02 82 11 Traditional Asbestos Abatement 01-21 02 82 13.19 Asbestos Floor Tile and Mastic Abatement 01-21 02 83 33.13 Lead-Based Paint Removal and Disposal 01-21

DIVISION 03 – CONCRETE – NOT USED

DIVISION 04 – MASONRY – NOT USED

DIVISION 05 – METALS

05 50 00 Metal Fabrications 08-18

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 84 00 Firestopping 01-21 07 92 00 Joint Sealants 10-17

DIVISION 08 – OPENINGS – NOT USED

00 01 10-2

DIVISION 09 – FINISHES

09 22 16 Non-Structural Metal Framing 06-18 09 29 00 Gypsum Board 04-20 09 51 00 Acoustical Ceilings 12-18 09 65 13 Resilient Base and Accessories 01-21 09 91 00 Painting 01-21

DIVISION 10 – SPECIALTIES

10 14 00 Signage 01-21 10 26 00 Wall and Door Protection 01-21

DIVISION 11 – EQUIPMENT – NOT USED

DIVISION 12 – FURNISHINGS – NOT USED

DIVISION 13 - SPECIAL CONSTRUCTION – NOT USED

DIVISION 14– CONVEYING EQUIPEMENT – NOT USED

DIVISION 21- FIRE SUPPRESSION

21 13 13 Wet-pipe Sprinkler Systems 11-16

DIVISION 22 – PLUMBING – NOT USED

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)- NOT USED

DIVISION 25 – INTEGRATED AUTOMATION – NOT USED

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 26 Grounding and Bonding for Electrical Systems 01-17 26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 05 36 Wireways for Radiology Equipment 01-18 26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS – NOT USED

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 13 Conductors and Cables for Electronic Safety and

Security 10-18

DIVISION 31 – EARTHWORK – NOT USED

00 01 10-3

DIVISION 32 – EXTERIOR IMPROVEMENTS – NOT USED

DIVISION 33 – UTILITIES – NOT USED

DIVISION 34 – TRANSPORTATION – NOT USED

DIVISION 48 – Electrical Power Generation – NOT USED

05-01-20

LIST OF DRAWING SHEETS

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GENERAL

GI000 COVER SHEET

GI001 PROJECT SYMBOLS & ABBREVIATIONS

GI002 ICRA CLASS I & II

GI110 PHASING - BASEMENT OVERALL PLAN

GI111 PHASING - FIRST FLOOR OVERALL PLAN

GI112 PHASING - SECOND FLOOR OVERALL PLAN

GI113 PHASING - THIRD FLOOR OVERALL PLAN

GI114 PHASING - FOURTH FLOOR OVERALL PLAN

GI115 PHASING - FIFTH FLOOR OVERALL PLAN

GI116 PHASING - SIXTH FLOOR OVERALL PLAN

GI117 PHASING - SEVENTH FLOOR OVERALL PLAN

GI118 PHASING - EIGHTH FLOOR OVERALL PLAN

GI119 PHASING - NINTH FLOOR OVERALL PLAN

GI120 BASEMENT OVERALL PLAN

GI121 FIRST FLOOR OVERALL PLAN

GI122 SECOND FLOOR OVERALL PLAN

GI123 THIRD FLOOR OVERALL PLAN

GI124 FOURTH FLOOR OVERALL PLAN

GI125 FIFTH FLOOR OVERALL PLAN

GI126 SIXTH FLOOR OVERALL PLAN

GI127 SEVENTH FLOOR OVERALL PLAN

GI128 EIGHTH FLOOR OVERALL PLAN

GI129 NINTH FLOOR OVERALL PLAN

GI401 SAMPLE ICRA PLAN

ARCHITECTURE

AD400 DEMOLITION BASEMENT ENLARGED PLANS

AD401 DEMOLITION FIRST FLOOR ENLARGED PLANS

00 01 15 - 2

AD402 DEMOLITION SECOND FLOOR ENLARGED PLANS

AD403 DEMOLITION THIRD AND FOURTH FLOOR ENLARGED

PLANS

AD404 DEMOLITION FIFTH FLOOR ENLARGED PLANS

AD405 DEMOLITION SIXTH FLOOR ENLARGED PLANS

AD406 DEMOLITION SEVENTH FLOOR ENLARGED PLANS

AD407 DEMOLITION EIGHTH AND NINTH FLOOR ENLARGED

PLANS

AD408 DEMOLITION INTERIOR ELEVATIONS

AD409 DEMOLITION INTERIOR ELEVATIONS

AD410 DEMOLITION INTERIOR ELEVATIONS

AD411 DEMOLITION INTERIOR ELEVATIONS

AE400 BASEMENT ENLARGED PLANS

AE401 FIRST FLOOR ENLARGED PLANS

AE402 SECOND FLOOR ENLARGED PLANS

AE403 THIRD AND FOURTH FLOOR ENLARGED PLANS

AE405 FIFTH FLOOR ENLARGED PLANS

AE406 SIXTH FLOOR ENLARGED PLANS

AE407 SEVENTH FLOOR ENLARGED PLANS

AE409 EIGHTH AND NINTH FLOOR ENLARGED PLANS

AI400 INTERIOR ELEVATIONS

AI401 INTERIOR ELEVATIONS

AI402 INTERIOR ELEVATIONS

AI403 GARAGE ELEVATIONS

AI500 WALL SECTIONS & DETAILS

AI600 FINISH SCHEDULE

1W-AC140 BASEMENT SIGNAGE REFLECTED CEILING PLAN

1W-AC141 FIRST FLOOR SIGNAGE REFLECTED CEILING PLAN

1W-AC142 SECOND FLOOR SIGNAGE REFLECTED CEILING PLAN

1W-AC143 THIRD FLOOR SIGNAGE REFLECTED CEILING PLAN

1W-AC145 FIFTH FLOOR SIGNAGE REFLECTED CEILING PLAN

1W-AC146 SIXTH FLOOR SIGNAGE REFLECTED CEILING PLAN

1W-AC147 SEVENTH FLOOR SIGNAGE REFLECTED CEILING PLAN

1W-AC148 EIGHTH FLOOR SIGNAGE REFLECTED CEILING PLAN

1W-AC149 NINTH FLOOR SIGNAGE REFLECTED CEILING PLAN

1E-AC140 BASEMENT REFLECTED CEILING PLAN

1E-AC141 FIRST FLOOR REFLECTED CEILING PLAN

00 01 15 - 3

1E-AC142 SECOND FLOOR REFLECTED CEILING PLAN

1E-AC143 THIRD FLOOR REFLECTED CEILING PLAN

1E-AC144 FOURTH FLOOR REFLECTED CEILING PLAN

1E-AC145 FIFTH FLOOR REFLECTED CEILING PLAN

1E-AC146 SIXTH FLOOR REFLECTED CEILING PLAN

1E-AC147 SEVENTH FLOOR REFLECTED CEILING PLAN

1E-AC148 EIGHTH FLOOR REFLECTED CEILING PLAN

28-AC140 REFLECTED CEILING PLANS

1W-AC440 BASEMENT ENLARGED REFLECTED CEILING PLAN

1W-AC441 FIRST FLOOR ENLARGED REFLECTED CEILING PLAN

1W-AC442 SECOND FLOOR ENLARGED REFLECTED CEILING PLAN

1W-AC443 THIRD FLOOR ENLARGED REFLECTED CEILING PLAN

1W-AC444 FIFTH AND SIXTH FLOOR ENLARGED REFLECTED

CEILING PLAN

1W-AC446 SEVENTH - NINTH FLOOR ENLARGED REFLECTED

CEILING PLAN

1E-AC440 BASEMENT ENLARGED REFLECTED CEILING PLAN

1E-AC441 FIRST FLOOR ENLARGED REFLECTED CEILING PLAN

1E-AC442 SECOND AND THIRD FLOOR ENLARGED REFLECTED

CEILING PLAN

1E-AC443 FOURTH AND FIFTH FLOOR ENLARGED REFLECTED

CEILING PLAN

1E-AC444 SIXTH AND SEVENTH FLOOR ENLARGED REFLECTED

CEILING PLAN

1E-AC445 EIGHTH FLOOR ENLARGED REFLECTED CEILING PLAN

28-AC440 ENLARGED REFLECTED CEILING PLANS

1W-AW100 BUILDING 1W - BASEMENT SIGNAGE PLAN

1W-AW101 BUILDING 1W - FIRST FLOOR SIGNAGE PLAN

1W-AW102 BUILDING 1W - SECOND FLOOR SIGNAGE PLAN

1W-AW103 BUILDING 1W - THIRD FLOOR SIGNAGE PLAN

1W-AW104 BUILDING 1W - FOURTH FLOOR SIGNAGE PLAN

1W-AW105 BUILDING 1W - FIFTH FLOOR SIGNAGE PLAN

1W-AW106 BUILDING 1W - SIXTH FLOOR SIGNAGE PLAN

1W-AW107 BUILDING 1W - SEVENTH FLOOR SIGNAGE PLAN

1W-AW108 BUILDING 1W - EIGHTH FLOOR SIGNAGE PLAN

1W-AW109 BUILDING 1W - NINTH FLOOR SIGNAGE PLAN

1E-AW100 BUILDING 1E - BASEMENT SIGNAGE PLAN

1E-AW101 BUILDING 1E - FIRST FLOOR SIGNAGE PLAN

00 01 15 - 4

1E-AW102 BUILDING 1E - SECOND FLOOR SIGNAGE PLAN

1E-AW103 BUILDING 1E - THIRD FLOOR SIGNAGE PLAN

1E-AW104 BUILDING 1E - FOURTH FLOOR SIGNAGE PLAN

1E-AW105 BUILDING 1E - FIFTH FLOOR SIGNAGE PLAN

1E-AW106 BUILDING 1E - SIXTH FLOOR SIGNAGE PLAN

1E-AW107 BUILDING 1E - SEVENTH FLOOR SIGNAGE PLAN

1E-AW108 BUILDING 1E - EIGHTH FLOOR SIGNAGE PLAN

28-AW100 BUILDING 28 - BASEMENT SIGNAGE PLAN

28-AW101 BUILDING 28 - FIRST FLOOR SIGNAGE PLAN

28-AW102 BUILDING 28 - SECOND FLOOR SIGNAGE PLAN

29-AW100 EAST PARKING STRUCTURE LEVEL AA-A - SIGNAGE

LOCATION PLAN

29-AW101 EAST PARKING STRUCTURE LEVEL BB-B - SIGNAGE

LOCATION PLAN

29-AW102 EAST PARKING STRUCTURE LEVEL 1 (LEVEL CC-C) -

SIGNAGE LOCATION PLAN

29-AW103 EAST PARKING STRUCTURE LEVEL 2 (LEVEL DD-D) -

SIGNAGE LOCATION PLAN

29-AW104 EAST PARKING STRUCTURE LEVEL 3 (LEVEL E) -

SIGNAGE LOCATION PLAN

AW200 INTERIOR STANDARD SIGN TYPES

AW201 INTERIOR SPECIALTY SIGN TYPES

AW202 EAST GARAGE STANDARD SIGN TYPES

AW203 EAST GARAGE SPECIALTY SIGN TYPES

AW204 EAST GARAGE ADD ALTERNATE SIGN TYPES

AW401 FREEDOM BUILDING ELEVATIONS SUPERGRAPHIC LEVEL

ID

AW402 CENTRAL BUILDING ELEVATIONS SUPERGRAPHIC LEVEL

ID

AW403 LIBERTY BUILDING ELEVATIONS SUPERGRAPHIC LEVEL

ID

AW404 INDEPENDENCE BUILDING ELEVATIONS SUPERGRAPHIC

LEVEL ID

29-AW401 EAST PARKING STRUCTURE ELEVATOR LOBBIES -

SIGNAGE LOCATION PLAN

AW501 GARAGE SIGNAGE DETAILS

AW900 VA SIGNAGE RENDERINGS

FIRE PROTECTION

FX100 BASEMENT FIRE PROTECTION PLAN

00 01 15 - 5

FX101 FIRST FLOOR FIRE PROTECTION PLAN

FX102 SECOND FLOOR FIRE PROTECTION PLAN

FX103 THIRD FLOOR FIRE PROTECTION PLAN

FX104 FOURTH FLOOR FIRE PROTECTION PLAN

FX105 FIFTH FLOOR FIRE PROTECTION PLAN

FX106 SIXTH FLOOR FIRE PROTECTION PLAN

FX107 SEVENTH FLOOR FIRE PROTECTION PLAN

FX108 EIGHTH FLOOR FIRE PROTECTION PLAN

FX109 NINTH FLOOR FIRE PROTECTION PLAN

ELECTRICAL

E001 ELECTRICAL LEGEND

1W-E100 BASEMENT OVERALL PLAN

1W-E101 FIRST FLOOR OVERALL PLAN

1W-E102 SECOND FLOOR OVERALL PLAN

1W-E103 THIRD FLOOR OVERALL PLAN

1W-E105 FIFTH FLOOR OVERALL PLAN

1W-E106 SIXTH FLOOR OVERALL PLAN

1W-E107 SEVENTH FLOOR OVERALL PLAN

1W-E108 EIGHTH FLOOR OVERALL PLAN

1W-E109 NINTH FLOOR OVERALL PLAN

1E-E100 BASEMENT OVERALL PLAN

1E-E101 FIRST FLOOR OVERALL PLAN

1E-E102 SECOND FLOOR OVERALL PLAN

1E-E103 THIRD FLOOR OVERALL PLAN

1E-E104 FOURTH FLOOR OVERALL PLAN

1E-E105 FIFTH FLOOR OVERALL PLAN

1E-E106 SIXTH FLOOR OVERALL PLAN

1E-E107 SEVENTH FLOOR OVERALL PLAN

1E-E108 EIGHTH FLOOR OVERALL PLAN

28-E100 BASEMENT OVERALL PLAN

28-E101 FIRST FLOOR OVERALL PLAN

28-E102 SECOND FLOOR OVERALL PLAN

1W-ED400 BASEMENT AND FIRST FLOOR ENLARGED DEMOLITION

PLAN

1W-ED401 "SECOND, THIRD, AND FIFTH FLOOR ENLARGED

DEMOLITION PLAN"

00 01 15 - 6

1W-ED402 "SIXTH, SEVENTH, EIGHTH, AND NINTH FLOOR

ENLARGED DEMOLITION PLAN"

1E-ED400 BASEMENT AND FIRST FLOOR ENLARGED DEMOLITION

PLANS

1E-ED401 FIRST FLOOR ENLARGED DEMOLITION PLANS

1E-ED402 SECOND AND THIRD FLOOR ENLARGED DEMOLITION

PLANS

1E-ED403 FOURTH AND FIFTH FLOOR ENLARGED DEMOLITION

PLANS

1E-ED404 SIXTH AND SEVENTH FLOOR ENLARGED DEMOLITION

PLANS

1E-ED405 EIGHTH FLOOR ENLARGED DEMOLITION PLANS

28-ED400 "BASEMENT, FIRST, AND SECOND FLOOR ENLARGED

DEMOLITION PLANS"

1W-EP400 BASEMENT AND FIRST FLOOR ENLARGED PLAN

1W-EP401 SECOND FLOOR ENLARGED PLAN

1W-EP402 "THIRD, FIFTH, AND SIXTH FLOOR ENLARGED PLAN"

1W-EP403 "SEVENTH, EIGHTH, AND NINTH FLOOR ENLARGED

PLAN"

1E-EP400 BASEMENT AND FIRST FLOOR ENLARGED PLANS

1E-EP401 FIRST FLOOR ENLARGED PLANS

1E-EP402 SECOND AND THIRD FLOOR ENLARGED PLANS

1E-EP403 FOURTH AND FIFTH FLOOR ENLARGED PLANS

1E-EP404 SIXTH AND SEVENTH FLOOR ENLARGED PLANS

1E-EP405 EIGHTH FLOOR ENLARGED PLANS

28-EP400 "BASEMENT, FIRST, AND SECOND FLOOR ENLARGED

PLANS"

- - - E N D - - -

11-01-21

GENERAL REQUIREMENTS

01 00 00 -1

SECTION 01 00 00

GENERAL

1.1 SAFETY REQUIREMENTS

A. Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for the replacement of interior signage to improve and modernize wayfinding for our Veterans, visitors, and staff as they navigate the facilities. Areas of focus include buildings 1E, 1W, 28, and East Parking garage structure. The project replaces wayfinding signage addressing digital signage, room numbering, associated architectural improvements affected by signage replacement and affected infrastructure systems such as lighting, re-locations of fire alarms and fire sprinklers as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the Medical Center Contracting Officer Representative (COR).

C. Offices of FFE, Inc., as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the

Government without affirmations by Contracting Officer

Representative.

D. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

01 00 00 -2

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, BASE BID: Work includes general construction, alterations, removal and replacement of existing wall/ceiling mounted signage, digital directories, relocation and/or replacement of ceilings mounted light fixtures, relocation of fire sprinklers as needed, repair/replacement of ceiling grids, relocation of wall mounted door operators, removal and replacement of wall finishes, wall protection and certain other items affected by proposed signage throughout the campus. The contractor shall hire a Siemens control system integrator for the

Building Automation System to update their systems graphics and references to new areas or room names and numbers modified by this project.

B. ALTERNATE NO.1: BASE BID except delete all scope associated with

Building 29 parking garage.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at

Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

01 00 00 -3

2. Before starting work the General Contractor shall give one week’s notice to the COR so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the COR. Patients and staff are not to be photographed at any time.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the

COR.

C. Document Control:

1. Before starting any work, the General Contractor/Sub

Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or

“Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the COR upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of the COR.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the

VA.

01 00 00 -4

6. Notify COR and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an

Engineering Document Management Software (EDMS).

Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the EDMS system.

“Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

D. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted

24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of permits shall be issued for General

Contractor and its employees for parking in designated areas only. Contractor to coordinate with VA Medical CenterCOR.

1.6 OPERATIONS AND STORAGE AREAS (FAR 52.236-10)

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the COR and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the Contractor at its

01 00 00 -5 expense upon completion of the work. With the written consent of theCOR, the buildings and utilities may be abandoned and need not be removed.

C. The Contractor shall, under regulations prescribed by the COR, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the COR.

When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as determined by the COR.

E. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by

Department of Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to

Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's

01 00 00 -6 materials and equipment will be permitted subject to fire and safety requirements.

F. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

All such actions shall be coordinated with the COR or Utility

Company involved:

1. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

G. Phasing:

1. The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur. It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

2. To ensure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the

Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such phasing dates to ensure

01 00 00 -7 accomplishment of this work in successive phases mutually agreeable to COR and Contractor.

H. Building(s) No.(s) 1E, 1W, 28 and East Parking Garage will be occupied during performance of work.

1. Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical

Centers operations will not be hindered. Contractor shall permit access to Department of Veterans Affairs personnel and patients through other construction areas which serve as routes of access to such affected areas and equipment. These routes whether access or egress shall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc. to facilitate patient and staff access. Coordinate alteration work in areas occupied by

Department of Veterans Affairs so that Medical Center operations will continue during the construction period.

I. Utilities Services: Maintain existing utility services for

Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR.

Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or

01 00 00 -8 equipment shall not commence without a detailed work plan, the

Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, and 27 05 11

REQUIREMENTS FOR COMMUNICATIONS INSTALLATIONS for additional requirements.

2. Contractor shall submit a request to interrupt any such services to the COR, in writing, 7 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical

Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

J. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, shall be removed back to their source. Those which are indicated to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or

01 00 00 -9 plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

K. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

L. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF

ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, to the COR. This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Shall note any discrepancies between drawings and existing conditions at site.

3. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by

Contractor with new items in accordance with specifications which will be furnished by Government. Provided the contract work is changed by reason of this subparagraph B, the contract will be

01 00 00 -10 modified accordingly, under provisions of clause entitled

"DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR

52.243-4).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by

Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of Contractor to restore damage caused by Contractor's workers in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Temporary protection against damage for portions of existing structures where work is to be done, materials handled and equipment moved and/or relocated.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by

COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

01 00 00 -11

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

a) Copies of the following listed CFR titles may be obtained from the Government Printing Office:

40 CFR 261 ...... Identification and Listing of Hazardous

Waste

40 CFR 262 ...... Standards Applicable to Generators of

Hazardous Waste

40 CFR 263 ...... Standards Applicable to Transporters of

Hazardous Waste

40 CFR 761 ...... PCB Manufacturing, Processing, Distribution in Commerce, and use Prohibitions

49 CFR 172 ...... Hazardous Material tables and Hazardous

Material Communications Regulations

49 CFR 173 ...... Shippers - General Requirements for

Shipments and Packaging

49 CRR 173 ...... Subpart A General

49 CFR 173 ...... Subpart B Preparation of Hazardous Material for Transportation

49 CFR 173 ...... Subpart J Other Regulated Material;

Definitions and Preparation

TSCA ............ Compliance Program Policy Nos. 6-PCB-6 and

6-PCB-7

1.9 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and

01 00 00 -12 do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems

(including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES" (FAR 52.243-4) and "DIFFERING SITE CONDITIONS"

(FAR 52.236-2).

1.10 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

01 00 00 -13

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.11 WARRANTY MANAGEMENT

A. Warranty Management Plan: Develop a warranty management plan which contains information relevant to FAR 52.246-21 Warranty of

Construction in at least 30 days before the planned pre-warranty conference, submit four setsof the warranty management plan.

Include within the warranty management plan all required actions and documents to assure that the Government receives all warranties to which it is entitled. The plan must be in narrative form and contain sufficient detail to render it suitable for use by future maintenance and repair personnel, whether tradesman, or of engineering background, not necessarily familiar with this contract. The term “status” as indicated below must include due date and whether item has been submitted or was approved.

Warranty information made available during the construction phase must be submitted to the COR for approval prior to each monthly invoice for payment. Assemble approved information in a binder and turn over to the Government upon acceptance of the work. The construction warranty period will begin on the date of the project acceptance and continue for the product warranty period.

A joint 4 month and 9 month warranty inspection will be conducted, measured from time of acceptance, by the Contactor and the Contracting Officer. Include in the warranty management plan, but not limited to, the following:

1. Roles and responsibilities of all personnel associated with the warranty process, including points of contact and telephone numbers within the company of the Contractor, subcontractors, manufacturers or suppliers involved.

01 00 00 -14

2. Furnish with each warranty the name, address and telephone number of each of the guarantor’s representatives nearest project location.

3. Listing and status of delivery of all Certificates of Warranty for extended warranty items, to include roofs, HVAC balancing, pumps, motors, transformers and for all commissioned systems such as fire protection and alarm systems, sprinkler systems and lightning protection systems, etc.

4. A list for each warranted equipment item, feature of construction or system indicating:

a. Name of item.

b. Model and serial numbers.

c. Location where installed.

d. Name and phone numbers of manufacturers and suppliers.

e. Name and phone numbers of manufacturers or suppliers.

f. Names, addresses and phone numbers of sources of spare parts.

g. Warranties and terms of warranty. Include one-year overall warranty of construction, including the starting date of warranty of construction. Items which have extended warranties must be indicated with separate warranty expiration dates.

h. Starting point and duration of warranty period.

i. Summary of maintenance procedures required to continue the warranty in force.

j. Cross-reference to specific pertinent Operation and Maintenance manuals.

k. Organizations, names and phone numbers of persons to call for warranty service.

l. Typical response time and repair time expected for various warranted equipment.

5. The plans for attendance at the 4 and 9-month post construction warranty inspections conducted by the government.

01 00 00 -15

6. Procedure and status of tagging of all equipment covered by extended warranties.

7. Copies of instructions to be posted near selected pieces of equipment where operation is critical for warranty and/or safety reasons.

B. Performance & Payment Bonds: The Performance & Payment Bonds must remain effective throughout the construction period.

1. In the event the Contractor fails to commence and diligently pursue any construction warranty work required, the

Contracting Officer will have the work performed by others, and after completion of the work, will charge the remaining construction warranty funds of expenses incurred by the

Government while performing the work, including, but not limited to administrative expenses.

2. In the event sufficient funds are not available to cover the construction warranty work performed by the Government at the contractor’s expenses, the COR will have the right to recoup expenses from the bonding company.

3. Following oral or written notification of required construction warranty repair work, the Contractor shall respond in a timely manner. Written verification will follow oral instructions. Failure to respond will be cause for the

COR to proceed against the Contractor.

C. Pre-Warranty Conference: Prior to contract completion, and at a time designated by the COR, the Contractor shall meet with the

COR to develop a mutual understanding with respect to the requirements of this section. Communication procedures for

Contractor notification of construction warranty defects, priorities with respect to the type of defect, reasonable time required for Contractor response, and other details deemed necessary by the COR for the execution of the construction warranty will be established/ reviewed at this meeting. In connection with these requirements and at the time of the

01 00 00 -16

Contractor’s quality control completion inspection, furnish the name, telephone number and address of a licensed and bonded company which is authorized to initiate and pursue construction warranty work action on behalf of the Contractor. This point of contract will be located within the local service area of the warranted construction, be continuously available and be responsive to Government inquiry on warranty work action and status. This requirement does not relieve the Contractor of any of its responsibilities in conjunction with other portions of this provision.

D. Contractor’s Response to Construction Warranty Service

Requirements:

E. Following oral or written notification by the COR, the Contractor shall respond to construction warranty service requirements in accordance with the “Construction Warranty Service Priority List” and the three categories of priorities listed below. Submit a report on any warranty item that has been repaired during the warranty period. Include within the report the cause of the problem, date reported, corrective action taken, and when the repair was completed. If the Contractor does not perform the construction warranty within the timeframe specified, the

Government will perform the work and back charge the construction warranty payment item established.

1. First Priority Code 1. Perform onsite inspection to evaluate situation, and determine course of action within 4 hours, initiate work within 6 hours and work continuously to completion or relief.

2. Second Priority Code 2. Perform onsite inspection to evaluate situation, and determine course of action within 8 hours, initiate work within 24 hours and work continuously to completion or relief.

3. Third Priority Code 3. All other work to be initiated within 3 work days and work continuously to completion or relief.

01 00 00 -17

4. The “Construction Warranty Service Priority List” is as follows:

a) Code 1-Life Safety Systems Fire suppression systems.

Fire alarm system(s).

b) Code 1-Air Conditioning Systems Air conditioning leak in part of the building, if causing damage.

Air conditioning system not cooling properly.

c) Code 1 Doors

Overhead doors not operational, causing a security, fire or safety problem.

1) Interior, exterior personnel doors or hardware, not functioning properly, causing security, fire or safety problem.

d) Code 3-Doors Overhead doors not operational.

Interior/exterior personnel doors or hardware not functioning properly.

e) Code 1-Electrical Power failure (entire area or any building operational after 1600 hours).

Security lights.

Smoke detectors.

f) Code 2-Electrical Power failure (no power to a room or part of building).

Receptacle and lights not operational (in a room or part of building).

g) Code 3-Electrical Exterior lights not operational.

h) Code 1-Gas Leaks and pipeline breaks.

i) Code 1-Heat

01 00 00 -18

Power failure affecting heat.

j) Code 1-Plumbing

Hot water heater failure.

2) Leaking water supply pipes

k) Code 2-Plumbing Flush valves not operating properly Fixture drain, supply line or any water pipe leaking.

Toilet leaking at base.

l) Code 3- Plumbing Leaky faucets.

m) Code 3-Interior Floors damaged.

Paint chipping or peeling.

Casework damaged.

n) Code 1-Roof Leaks Damage to property is occurring.

o) Code 2-Water (Exterior) No water to facility.

p) Code 2-Water (Hot) No hot water in portion of building listed.

q) Code 3 All work not listed above.

F. Warranty Tags: At the time of installation, tag each warranted item with a durable, oil and water-resistant tag approved by the

COR. Attach each tag with a copper wire and spray with a silicone waterproof coating. Also submit two record copies of the warranty tags showing the layout and design. The date of acceptance and the QC signature must remain blank until the project is accepted for beneficial occupancy. Show the following information on the tag.

Warranty Tags

Type of product/material

01 00 00 -19

Warranty Tags

Model number

Serial number

Contract number

Warranty period from/to

Inspector’s signature

Construction Contractor

Address

Telephone number

Warranty Contact

Address

Telephone number

Warranty response time priority code

1.12 TEMPORARY USE OF EXISTING ELEVATORS

A. Use of existing elevators for handling building materials and

Contractor's personnel will be permitted subject to following provisions:

1. Contractor makes all arrangements with the COR for use of elevators.

2. Contractor covers and provides maximum protection of following elevator components:

a) Entrance jambs, heads soffits and threshold plates.

b) Entrance columns, canopy, return panels and inside surfaces of car enclosure walls.

c) Finish flooring.

3. Government will accept hoisting ropes of elevator and rope of each speed governor if they are worn under normal operation.

However, if these ropes are damaged by action of foreign matter such as sand, lime, grit, stones, etc., during temporary use, they shall be removed and replaced by new hoisting ropes at the contractors expense.

01 00 00 -20

4. If brake lining of elevators are excessively worn or damaged during temporary use, they shall be removed and replaced by new brake lining at the contractors expense.

5. All parts of main controller, starter, relay panel, selector, etc., worn or damaged during temporary use shall be removed and replaced with new parts at the contractors expense, if recommended by elevator inspector after elevator is released by Contractor.

6. Place elevator in condition equal, less normal wear, to that existing at time it was placed in service of Contractor as approved by Contracting Officer.

1.13 TEMPORARY TOILETS

A. Provide where directed, (for use of all Contractor's workers) ample temporary sanitary toilet accommodations with suitable sewer and water connections; or, when approved by COR, provide suitable dry closets where directed. Keep such places clean and free from flies and all connections and appliances connected therewith are to be removed prior to completion of contract, and premises left perfectly clean.

1. *Contractor may have for use of Contractor's workers, such toilet accommodations as may be assigned to Contractor by

Medical Center. Contractor shall keep such places clean and be responsible for any damage done thereto by Contractor's workers. Failure to maintain satisfactory condition in toilets will deprive Contractor of the privilege to use such toilets.

1.14 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the Government. The Contractor shall carefully conserve any utilities furnished without charge.

01 00 00 -21

B. The Contractor, at Contractor's expense and in a workmanlike manner, in compliance with code and as satisfactory to the COR, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of electricity used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia and repair restore the infrastructure as required.

C. Contractor shall install meters at Contractor's expense and furnish the Medical Center a monthly record of the Contractor's usage of electricity as hereinafter specified.

1.15 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals (hard copies and electronic) and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

B. Manuals: Maintenance and operating manuals and one compact disc

(four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidental with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include "exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for

01 00 00 -22 each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed training to assigned Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment.

All such training will be at the job site. These requirements are more specifically detailed in the various technical sections.

Instructions for different items of equipment that are component parts of a complete system, shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed. This is to assure proper instruction in the operation of inter-related systems. All instruction periods shall be at such times as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough coverage.

The contractor shall submit a course outline with associated material to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the contractual requirements. The Department of

Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in the opinion of the

COR, does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.16 RELOCATED ITEMS

A. Contractor shall disconnect, dismantle as necessary, remove and reinstall in new location, all existing equipment and items indicated or otherwise shown to be relocated by the Contractor.

01 00 00 -23

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR.

C. Provide all mechanical and electrical service connections, fittings, fastenings and any other materials necessary for assembly and installation of relocated equipment; and leave such equipment in proper operating condition.

D. All service lines such as noted above for relocated equipment shall be in place at point of relocation ready for use before any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

01 32 16.15 - 1

SECTION 01 32 16.15

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officer's Representative (COR).

B. The Contractor's representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements of this specification section.

C. The Contractor’s representative shall have the option of developing the project schedule within their organization or to engage the services of an outside consultant. If an outside scheduling consultant is utilized, Section 1.3 of this specification will apply.

1.3 CONTRACTOR'S CONSULTANT:

A. The Contractor shall submit a qualification proposal to the COR, within

10 days of bid acceptance. The qualification proposal shall include:

1. The name and address of the proposed consultant.

2. Information to show that the proposed consultant has the qualifications to meet the requirements specified in the preceding paragraph.

3. A representative sample of prior construction projects, which the proposed consultant has performed complete project scheduling services. These representative samples shall be of similar size and scope.

(SMALL PROJECTS – DESIGN/BID/BUILD)

01 32 16.15 - 2

B. The Contracting…