36C24619R0025-0002000.docx

5. PROJECT NUMBER (if applicable)

CODE

7. ADMINISTERED BY

2. AMENDMENT/MODIFICATION NUMBER

CODE

6. ISSUED BY

8. NAME AND ADDRESS OF CONTRACTOR

4. REQUISITION/PURCHASE REQ. NUMBER

3. EFFECTIVE DATE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED

PAGE OF PAGES

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED

BPA NO.

1. CONTRACT ID CODE

FACILITY CODE

CODE

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

E. IMPORTANT:

is extended,

(a) By completing Items 8 and 15, and returning __________ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY is not extended.

12. ACCOUNTING AND APPROPRIATION DATA

(REV. 11/2016)

is required to sign this document and return ___________ copies to the issuing office.

is not, A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

15C. DATE SIGNED

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER

Contractor

16C. DATE SIGNED

14. DESCRIPTION OF AMENDMENT/MODIFICATION

16B. UNITED STATES OF AMERICA

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER

16A. NAME AND TITLE OF CONTRACTING OFFICER

15B. CONTRACTOR/OFFEROR

STANDARD FORM 30

PREVIOUS EDITION NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.243 (Type or print) (Type or print) (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

(Number, street, county, State and ZIP Code) (If other than Item 6) (Specify type of modification and authority) (such as changes in paying office, appropriation date, etc.)

(If required)

(SEE ITEM 11)

(SEE ITEM 13)

(X)

CHECK

ONE

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

(Signature of person authorized to sign) (Signature of Contracting Officer) 558-318 Department of Veterans Affairs Network Contracting Office 6 ATTN: Billie Kindschuh 3518 Westgate Drive Durham

NC

27705 Department of Veterans Affairs Network Contracting Office 6 ATTN: Billie Kindschuh 3518 Westgate Drive Durham

NC

27707 To all Offerors/Bidders

36C24619R0025 06-10-2019

X X X

3:00 PM EDT 23 August 2019 X This solicitation is hereby amended. See the following pages for Request For Information responses and any other corrections or revisions to this solicitation.

The purpose if this amendment is to:

A. Extend the closing date for proposals from 9 August 2019 to 3:00PM EDT 23 August 2019.

B. Provide a corrected Exhibit A – Past Performance Questionnaire Request Letter correcting the point of contact on page 5 from Mark S. Harville at mark.harville@va.gov or @ (804)675-5841 to Billie Kindschuh at billie.kindschuh@va.gov or at 919-354-9340.

C. Provide clarification for Sub-Factor 4 – Construction Schedule Item 2 Minimum Standard of Acceptability. A question was presented regarding the similarity of Sub-Factor 4 to Sub-Factor 2 – Corporate Experience. There are similarities in the requested information. However, for Sub-Factor 4 – Construction Schedule, Item 2. e. note the requirement is to identify any and all delays in the schedule and how those delays were mitigated. This Sub-Factor 4 is designed to allow the Government to understand your firm’s ability to maintain the construction schedule and when there are delays or issues to understand how your firm addressed those delays or issues. If the progress of the project was delayed the number of days of delay should be included in the description of projects submitted to meet this sub-factor.

See attached document: S02 Exhibit A - Past Performance Questionnaire 02.