620-18-203.13AB.IFC.Submittal.210318.xlsx

XLSX spreadsheet 57 KB Posted Mar 7, 2022

Attached to: Y1DA--620-18-203 RENOVATE BUILDING 13AB at the Montrose VAMC
Solicitation number: 36C24222B0014
Issued by: Department of Veterans Affairs Veterans Health Administration Veterans Integrated Service Network 2

About this file

Written by GovTribe AI · Dec 27, 2023

This submittal register outlines product submittal requirements for the renovation of Building 13AB at the Montrose Veterans Affairs Medical Center. Key specifications covered in the document include project schedules, staff qualifications, asbestos abatement plans, material and equipment lists, waste disposal procedures, notification requirements, air monitoring procedures and laboratories, commissioning documentation, and closeout submittals. The document provides a comprehensive list of submittal types and timing to ensure all necessary documentation is provided for review and approval by project stakeholders.

View the file

Other files

File	Type	Posted
36C24222B0014 0005.docx	DOCX document	Mar 22, 2022
08-31-11 006.jpg	JPG image	Mar 21, 2022
Pillar Support Details.pdf	PDF	Mar 21, 2022
08-24-11 003.jpg	JPG image	Mar 21, 2022
36C24222B0014 0004.docx	DOCX document	Mar 21, 2022
Contractor Access.pdf	PDF	Mar 21, 2022
RFI response clarifications.pdf	PDF	Mar 11, 2022
RFI 61 Response 001-010.pdf	PDF	Mar 11, 2022
RFI 61 Response 011-020.pdf	PDF	Mar 11, 2022
RFI 61 Response 021-030.pdf	PDF	Mar 11, 2022
620-18-203.13AB.Addendum.3.Summery.22.03.04.pdf	PDF	Mar 7, 2022
36C24222B0014 0002.docx	DOCX document	Mar 7, 2022
Final J2207020 Building 13 Montrose NY GeoReport.pdf	PDF	Mar 7, 2022
2021-08-05 13AB Dwgs Addendum 2 - Pages 101-209.pdf	PDF	Feb 8, 2022
2021-08-05 13AB Dwgs Addendum 2 - pages 1-100.pdf	PDF	Feb 8, 2022
2021-08-05 13AB Specs Addendum 2 - Copy.pdf	PDF	Feb 8, 2022
36C24222B0014 0001.docx	DOCX document	Feb 8, 2022
36C24222B0014_1.docx	DOCX document	Feb 8, 2022
wage determination-12-3-2021.pdf	PDF	Feb 8, 2022

Show all 19

On GovTribe

Work with this file

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

VisiSpecs Submittal Register

SecNum	SecName	ParNum	Submittal	Type	Detail
01 32 16.15	Project Schedules (Small Projects - Design-Bid-Build)	1.5.A.	THE COMPLETE PROJECT SCHEDULE SUBMITTAL
Within 45 calendar days after receipt of Notice to Proceed, the Contractor shall submit for the Contracting Officer's review; three blue line copies of the interim schedule on sheets of paper 765 x 1070 mm (30 x 42 inches) and an electronic file in the previously approved CPM schedule program. The submittal shall also include three copies of a computer-produced activity/event ID schedule showing project duration; phase completion dates; and other data, including event cost. Each activity/event on the computer-produced schedule shall contain as a minimum, but not limited to, activity/event ID, activity/event description, duration, budget amount, early start date, early finish date, late start date, late finish date and total float. Work activity/event relationships shall be restricted to finish-to-start or start-to-start without lead or lag constraints. Activity/event date constraints, not required by the contract, will not be accepted unless submitted to and approved by the Contracting Officer. The contractor shall make a separate written detailed request to the Contracting Officer identifying these date constraints and secure the Contracting Officer’s written approval before incorporating them into the network diagram. The Contracting Officer’s separate approval of the Project Schedule shall not excuse the contractor of this requirement. Logic events (non-work) will be permitted where necessary to reflect proper logic among work events, but must have zero duration. The complete working schedule shall reflect the Contractor's approach to scheduling the complete project. The final Project Schedule in its original form shall contain no contract changes or delays which may have been incurred during the final network diagram development period and shall reflect the entire contract duration as defined in the bid documents. These changes/delays shall be entered at the first update after the final Project Schedule has been approved. The Contractor should provide their requests for time and supporting time extension analysis for contract time as a result of contract changes/delays, after this update, and in accordance with Article, ADJUSTMENT OF CONTRACT COMPLETION.
01 32 16.15	Project Schedules (Small Projects - Design-Bid-Build)	1.5.B.	THE COMPLETE PROJECT SCHEDULE SUBMITTAL
Within 30 calendar days after receipt of the complete project interim Project Schedule and the complete final Project Schedule, the Contracting Officer or his representative, will do one or both of the following
01 32 16.15	Project Schedules (Small Projects - Design-Bid-Build)	1.5.C.	THE COMPLETE PROJECT SCHEDULE SUBMITTAL
The approved baseline schedule and the computer-produced schedule(s) generated there from shall constitute the approved baseline schedule until subsequently revised in accordance with the requirements of this section.
01 32 16.15	Project Schedules (Small Projects - Design-Bid-Build)	1.5.D.	THE COMPLETE PROJECT SCHEDULE SUBMITTAL
The Complete Project Schedule shall contain approximately one work activities/events for each specification section. .
01 33 23	Shop Drawings, Product Data, and Samples	1.3.A.	SUBMITTAL REGISTER
The submittal register will list items of equipment and materials for which submittals are required by the specifications. This list may not be all inclusive and additional submittals may be required by the specifications. The Contractor is not relieved from supplying submittals required by the contract documents but which have been omitted from the submittal register.
01 33 23	Shop Drawings, Product Data, and Samples	1.3.B.	SUBMITTAL REGISTER
The submittal register will serve as a scheduling document for submittals and will be used to control submittal actions throughout the contract period.
01 33 23	Shop Drawings, Product Data, and Samples	1.3.C.	SUBMITTAL REGISTER
The VA will provide the initial submittal register in electronic format. Thereafter, the Contractor shall track all submittals by maintaining a complete list, including completion of all data columns, including dates on which submittals are received and returned by the VA.
01 33 23	Shop Drawings, Product Data, and Samples	1.3.D.	SUBMITTAL REGISTER
The Contractor shall update the submittal register as submittal actions occur and maintain the submittal register at the project site until final acceptance of all work by Contracting Officer.
01 33 23	Shop Drawings, Product Data, and Samples	1.3.E.	SUBMITTAL REGISTER
The Contractor shall submit formal monthly updates to the submittal register in electronic format. Each monthly update shall document actual submission and approval dates for each submittal.
01 33 23	Shop Drawings, Product Data, and Samples	1.4.A.	SUBMITTAL SCHEDULING
Submittals are to be scheduled, submitted, reviewed, and approved prior to the acquisition of the material or equipment.
01 33 23	Shop Drawings, Product Data, and Samples	1.4.B.	SUBMITTAL SCHEDULING
Coordinate scheduling, sequencing, preparing, and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow time for potential resubmittal.
01 33 23	Shop Drawings, Product Data, and Samples	1.4.C.	SUBMITTAL SCHEDULING
No delay costs or time extensions will be allowed for time lost in late submittals or resubmittals.
01 33 23	Shop Drawings, Product Data, and Samples	1.4.D.	SUBMITTAL SCHEDULING
All submittals are required to be approved prior to the start of the specified work activity.
01 33 23	Shop Drawings, Product Data, and Samples	1.5.A.	SUBMITTAL PREPARATION
Each submittal is to be complete and in sufficient detail to allow ready determination of compliance with contract requirements.
01 33 23	Shop Drawings, Product Data, and Samples	1.5.B.	SUBMITTAL PREPARATION
Collect required data for each specific material, product, unit of work, or system into a single submittal. Prominently mark choices, options, and portions applicable to the submittal. Partial submittals will not be accepted for expedition of construction effort. Submittal will be returned without review if incomplete.
01 33 23	Shop Drawings, Product Data, and Samples	1.5.C.	SUBMITTAL PREPARATION
If available product data is incomplete, provide Contractor-prepared documentation to supplement product data and satisfy submittal requirements.
01 33 23	Shop Drawings, Product Data, and Samples	1.5.D.	SUBMITTAL PREPARATION
All irrelevant or unnecessary data shall be removed from the submittal to facilitate accuracy and timely processing. Submittals that contain the excessive amount of irrelevant or unnecessary data will be returned with review.
01 33 23	Shop Drawings, Product Data, and Samples	1.5.E.	SUBMITTAL PREPARATION
Provide a transmittal form for each submittal with the following information
01 33 23	Shop Drawings, Product Data, and Samples	1.5.F.	SUBMITTAL PREPARATION
The Contractor is responsible for reviewing and certifying that all submittals are in compliance with contract requirements before submitting for VA review. Proposed deviations from the contract requirements are to be clearly identified. All deviations submitted must include a side by side comparison of item being proposed against item specified. Failure to point out deviations will result in the VA requiring removal and replacement of such work at the Contractor's expense.
01 33 23	Shop Drawings, Product Data, and Samples	1.5.G.	SUBMITTAL PREPARATION
Stamp, sign, and date each submittal transmittal form indicating action taken.
01 33 23	Shop Drawings, Product Data, and Samples	1.5.H.	SUBMITTAL PREPARATION
Stamp used by the Contractor on the submittal transmittal form to certify that the submittal meets contract requirements is to be similar to the following
01 33 23	Shop Drawings, Product Data, and Samples	1.6.A.	SUBMITTAL FORMAT AND TRANSMISSION
Provide submittals in electronic format, with the exception of material samples. Use PDF as the electronic format, unless otherwise specified or directed by the Contracting Officer.
01 33 23	Shop Drawings, Product Data, and Samples	1.6.B.	SUBMITTAL FORMAT AND TRANSMISSION
Compile the electronic submittal file as a single, complete document. Name the electronic submittal file specifically according to its contents.
01 33 23	Shop Drawings, Product Data, and Samples	1.6.C.	SUBMITTAL FORMAT AND TRANSMISSION
Electronic files must be of sufficient quality that all information is legible. Generate PDF files from original documents so that the text included in the PDF file is both searchable and can be copied. If documents are scanned, Optical Character Resolution (OCR) routines are required.
01 33 23	Shop Drawings, Product Data, and Samples	1.6.D.	SUBMITTAL FORMAT AND TRANSMISSION
E-mail electronic submittal documents smaller than 5MB in size to e-mail addresses as directed by the Contracting Officer.
01 33 23	Shop Drawings, Product Data, and Samples	1.6.E.	SUBMITTAL FORMAT AND TRANSMISSION
Provide electronic documents over 5MB through an electronic FTP file sharing system. Confirm that the electronic FTP file sharing system can be accessed from the VA computer network. The Contractor is responsible for setting up, providing, and maintaining the electronic FTP file sharing system for the construction contract period of performance.
01 33 23	Shop Drawings, Product Data, and Samples	1.6.F.	SUBMITTAL FORMAT AND TRANSMISSION
Provide hard copies of submittals when requested by the Contracting Officer. Up to 3 additional hard copies of any submittal may be requested at the discretion of the Contracting Officer, at no additional cost to the VA.
01 33 23	Shop Drawings, Product Data, and Samples	1.11.A.	VA REVIEW OF SUBMITTALS AND RFIS
The VA will review all submittals for compliance with the technical requirements of the contract documents. The Architect-Engineer for this project will assist the VA in reviewing all submittals and determining contractual compliance. Review will be only for conformance with the applicable codes, standards and contract requirements.
01 33 23	Shop Drawings, Product Data, and Samples	1.11.B.	VA REVIEW OF SUBMITTALS AND RFIS
Period of review for submittals begins when the VA COR receives submittal from the Contractor.
01 33 23	Shop Drawings, Product Data, and Samples	1.11.C.	VA REVIEW OF SUBMITTALS AND RFIS
Period of review for each resubmittal is the same as for initial submittal.
01 33 23	Shop Drawings, Product Data, and Samples	1.11.D.	VA REVIEW OF SUBMITTALS AND RFIS
VA review period is 15 working days for submittals.
01 33 23	Shop Drawings, Product Data, and Samples	1.11.E.	VA REVIEW OF SUBMITTALS AND RFIS
VA review period is 10 working days for RFIs.
01 33 23	Shop Drawings, Product Data, and Samples	1.11.F.	VA REVIEW OF SUBMITTALS AND RFIS
The VA will return submittals to the Contractor with the following notations
01 33 23	Shop Drawings, Product Data, and Samples	1.12.A.	APPROVED SUBMITTALS
The VA approval of submittals is not to be construed as a complete check, and indicates only that the general method of construction, materials, detailing, and other information are satisfactory.
01 33 23	Shop Drawings, Product Data, and Samples	1.12.B.	APPROVED SUBMITTALS
VA approval of a submittal does not relieve the Contractor of the responsibility for any error which may exist. The Contractor is responsible for fully complying with all contract requirements and the satisfactory construction of all work, including the need to check, confirm, and coordinate the work of all subcontractors for the project. Non-compliant material incorporated in the work will be removed and replaced at the Contractor’s expense.
01 33 23	Shop Drawings, Product Data, and Samples	1.12.C.	APPROVED SUBMITTALS
After submittals have been approved, no resubmittal for the purpose of substituting materials or equipment will be considered unless accompanied by an explanation of why a substitution is necessary.
01 33 23	Shop Drawings, Product Data, and Samples	1.12.D.	APPROVED SUBMITTALS
Retain a copy of all approved submittals at project site, including approved samples.
01 45 00	Quality Control	1.3.A.	SUBMITTALS
Government approval is required for all submittals. CQC inspection reports shall be submitted under this Specification section and follow the Applicable CQC Control Phase (Preparatory, Initial, or Follow-Up)	Applicable Specification section naming convention.
01 45 00	Quality Control	3.5.A.	SUBMITTALS AND DELIVERABLES:
Submittals have to comply with the requirements in Section 01 33 23 Shop Drawings, Product Data, and Samples. The CQC organization is responsible for certifying that all submittals and deliverables are in compliance with the contract requirements. When Section 01 91 00 General Commissioning Requirements is included in the contract, the submittals required by the section have to be coordinated with the Section 01 33 23 Shop Drawings, Product Data, and Samples to ensure adequate time is allowed for each type of submittal required.
01 57 19	Temporary Environmental Controls	1.4.A.	SUBMITTALS
In accordance with Section, 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES, furnish the following
01 57 19	Temporary Environmental Controls	1.4.B.	SUBMITTALS
Approval of the Contractor's Environmental Protection Plan will not relieve the Contractor of responsibility for adequate and continued control of pollutants and other environmental protection measures.
01 74 19	Construction Waste Management	1.5.A.	SUBMITTALS
In accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, and SAMPLES, furnish the following
01 74 19	Construction Waste Management	1.5.B.	SUBMITTALS
Prepare and submit to the Resident Engineer a written demolition debris management plan. The plan shall include, but not be limited to, the following information
01 74 19	Construction Waste Management	1.5.C.	SUBMITTALS
Designated Manager responsible for instructing personnel, supervising, documenting and administer over meetings relevant to the Waste Management Plan.
01 74 19	Construction Waste Management	1.5.D.	SUBMITTALS
Monthly summary of construction and demolition debris diversion and disposal, quantifying all materials generated at the work site and disposed of or diverted from disposal through recycling.
01 81 13	Sustainable Construction Requirements	1.5.A.	SUBMITTALS
All submittals to be provided by contractor to COR.
01 81 13	Sustainable Construction Requirements	1.5.B.	SUBMITTALS
Sustainability Action Plan
01 81 13	Sustainable Construction Requirements	1.5.C.	SUBMITTALS
Low Pollutant-Emitting Materials Tracking Spreadsheet	Within 30 days after Preconstruction Meeting provide a preliminary Low Pollutant-Emitting Materials Tracking Spreadsheet. The Low Pollutant-Emitting Materials Tracking Spreadsheet must be an electronic file and include all materials on Project in categories described under Low Pollutant-Emitting Materials in 01 81 13.
01 81 13	Sustainable Construction Requirements	1.5.D.	SUBMITTALS
Construction Indoor Air Quality (IAQ) Management Plan
01 81 13	Sustainable Construction Requirements	1.5.E.	SUBMITTALS
Product Submittals
01 81 13	Sustainable Construction Requirements	1.5.F.	SUBMITTALS
Sustainable Construction Progress Reports	Concurrent with each Application for Payment, submit a Sustainable Construction Progress Report to confirm adherence with Sustainability Action Plan.
01 81 13	Sustainable Construction Requirements	1.5.G.	SUBMITTALS
Closeout Submittals	Within 14 days after Substantial Completion provide the following
01 91 00	General Commissioning Requirements	1.13.A.	SUBMITTALS
Preliminary Commissioning Plan Submittal	The Commissioning Agent has prepared a Preliminary Commissioning Plan based on the final Construction Documents. The Preliminary Commissioning Plan is included as an Appendix to this specification section. The Preliminary Commissioning Plan is provided for information only. It contains preliminary information about the following commissioning activities
01 91 00	General Commissioning Requirements	1.13.B.	SUBMITTALS
Final Commissioning Plan Submittal	Based on the Final Construction Documents and the Contractor’s project team, the Commissioning Agent will prepare the Final Commissioning Plan as described in this section. The Commissioning Agent will submit three hard copies and three sets of electronic files of Final Commissioning Plan. The Contractor shall review the Commissioning Plan and provide any comments to the VA. The Commissioning Agent will incorporate review comments into the Final Commissioning Plan as directed by the VA.
01 91 00	General Commissioning Requirements	1.13.C.	SUBMITTALS
Systems Functional Performance Test Procedure	The Commissioning Agent will submit preliminary Systems Functional Performance Test Procedures to the Contractor, and the VA for review and comment. The Contractor shall return review comments to the VA and the Commissioning Agent. The VA will also return review comments to the Commissioning Agent. The Commissioning Agent will incorporate review comments into the Final Systems Functional Test Procedures to be used in Systems Functional Performance Testing.
01 91 00	General Commissioning Requirements	1.13.D.	SUBMITTALS
Pre-Functional Checklists	The Commissioning Agent will submit Pre-Functional Checklists to be completed by the Contractor.
01 91 00	General Commissioning Requirements	1.13.E.	SUBMITTALS
Test and Inspection Reports	The Commissioning Agent will submit test and inspection reports to the VA with copies to the Contractor and the Architect/Engineer.
01 91 00	General Commissioning Requirements	1.13.F.	SUBMITTALS
Corrective Action Documents	The Commissioning Agent will submit corrective action documents to the VA Resident Engineer with copies to the Contractor and Architect.
01 91 00	General Commissioning Requirements	1.13.G.	SUBMITTALS
Preliminary Commissioning Report Submittal	The Commissioning Agent will submit three electronic copies of the preliminary commissioning report. One electronic copy, with review comments, will be returned to the Commissioning Agent for preparation of the final submittal.
01 91 00	General Commissioning Requirements	1.13.H.	SUBMITTALS
Final Commissioning Report Submittal	The Commissioning Agent will submit four sets of electronically formatted information of the final commissioning report to the VA. The final submittal will incorporate comments as directed by the VA.
01 91 00	General Commissioning Requirements	1.13.I.	SUBMITTALS
Data for Commissioning
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
Submit to the VA a minimum of 14 days prior to the pre-start meeting the following for review and approval. Meeting this requirement is a prerequisite for the pre-start meeting for this project
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
A.	Submit a detailed work schedule for the entire project reflecting contract documents and the phasing/schedule requirements from the CPM chart.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
B.	Submit a staff organization chart showing all personnel who will be working on the project and their capacity/function. Provide their qualifications, training, accreditations, and licenses, as appropriate. Provide a copy of the "Certificate of Worker's Acknowledgment" and the "Affidavit of Medical Surveillance and Respiratory Protection" for each person.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
C.	Submit Asbestos Hazard Abatement Plan developed specifically for this project, incorporating the requirements of the specifications, prepared, signed and dated by the CPIH/CIH.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
D.	Submit the specifics of the materials and equipment to be used for this project with manufacturer names, model numbers, performance characteristics, pictures/diagrams, and number available for the following
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
E.	Submit the name, location, and phone number of the approved landfill; proof/verification the landfill is approved for ACM disposal; the landfill's requirements for ACM waste; the type of vehicle to be used for transportation; and name, address, phone number, and permit number of waste transporter, if used. Proof of asbestos training for transportation personnel shall be provided.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
F.	Submit required notifications and arrangements made with regulatory agencies having regulatory jurisdiction and the specific contingency/emergency arrangements made with local health, fire, ambulance, hospital authorities and any other notifications/arrangements.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
G.	Submit the name, location and verification of the laboratory and/or personnel to be used for analysis of air and/or bulk samples. Personal air monitoring must be done in accordance with OSHA 29 CFR 1926.1101(f) and Appendix A. And area or clearance air monitoring in accordance with EPA AHERA protocols.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
H.	Submit qualifications verification	Submit the following evidence of qualifications. Make sure that all references are current and verifiable by providing current phone numbers and documentation.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
I.	Submit information on personnel	Provide a resume; address each item completely; copies of certificates, accreditations, and licenses. Submit an affidavit signed by the CPIH/CIH stating that all personnel submitted below have medical records in accordance with OSHA 29 CFR 1926.1101(m) and 29 CFR 1910.20 and that the company has implemented a medical surveillance program and written respiratory protection program and maintains recordkeeping in accordance with the above regulations. Submit the phone number and doctor/clinic/hospital used for medical evaluations.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
J.	Submit copies of State license for asbestos abatement; copy of insurance policy, including exclusions with a letter from agent stating in plain language the coverage provided and the fact that asbestos abatement activities are covered by the policy; copy of AHAP(s) incorporating the requirements of this specification; information on who provides your training, how often; who provides medical surveillance, how often; who performs and how is personal air monitoring of abatement workers conducted; a list of references of independent laboratories/IH's familiar with your air monitoring and Asbestos Hazard Abatement Plans; copies of monitoring results of the five referenced projects listed and analytical method(s) used.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
K.	Rented equipment must be decontaminated prior to returning to the rental agency.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS
L.	Submit, before the start of work, the manufacturer's technical data for all types of encapsulants, all SDS, and application instructions.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.1 PRE-START MEETING SUBMITTALS

02 82 13.13	Glovebag Asbestos Abatement	.	2.5.2 SUBMITTALS DURING ABATEMENT
A.	The Competent Person shall maintain and submit a daily log at the regulated area documenting the dates and times of the following	purpose, attendees and summary of meetings; all personnel entering/exiting the regulated area; document and discuss the resolution of unusual events such as barrier breeching, equipment failures, emergencies, and any cause for stopping work; representative air monitoring and results/TWAs/ELs. Submit this information daily to the VPIH/CIH.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.2 SUBMITTALS DURING ABATEMENT
B.	The CPIH/CIH shall document and maintain the inspection and approval of the regulated area preparation prior to start of work and daily during work.
02 82 13.13	Glovebag Asbestos Abatement	.	2.5.3 SUBMITTALS AT COMPLETION OF ABATEMENT
The CPIH/CIH shall submit a project report consisting of the daily log book requirements and documentation of events during the abatement project including Waste Shipment Records signed by the landfill's agent. It will also include information on the containment and transportation of waste from the containment with applicable Chain of Custody forms. The report shall include a certificate of completion, signed and dated by the CPIH/CIH, in accordance with Attachment #1. All clearance and perimeter area samples must be submitted. The VA Representative will retain the abatement report after completion of the project and provide copies of the abatement report to VAMC Office of Engineer and the Safety Office.
02 83 33.13	Lead-Based Pain Removal and Disposal	1.6.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
02 83 33.13	Lead-Based Pain Removal and Disposal	1.6.B.	SUBMITTALS
Manufacturer's Literature and Data
02 83 33.13	Lead-Based Pain Removal and Disposal	1.6.C.	SUBMITTALS
Test Reports	Submit testing laboratory reports.
02 83 33.13	Lead-Based Pain Removal and Disposal	1.6.D.	SUBMITTALS
Certificates	Certify completed training.
02 83 33.13	Lead-Based Pain Removal and Disposal	1.6.E.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
02 83 33.13	Lead-Based Pain Removal and Disposal	1.6.F.	SUBMITTALS
Record Documents
03 30 00	Cast-In-Place Concrete	1.6.A.	SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, and SAMPLES.
03 30 00	Cast-In-Place Concrete	1.6.B.	SUBMITTALS:
Shop Drawings	Reinforcing steel
03 30 00	Cast-In-Place Concrete	1.6.C.	SUBMITTALS:
Mill Test Reports
03 30 00	Cast-In-Place Concrete	1.6.D.	SUBMITTALS:
Manufacturer's Certificates
03 30 00	Cast-In-Place Concrete	1.6.E.	SUBMITTALS:
Testing Agency for Concrete Mix Design	Approval request including qualifications of principals and technicians and evidence of active participation in program of Cement and Concrete Reference Laboratory (CCRL) of National Institute of Standards and Technology and copy of report of latest CCRL, Inspection of Laboratory.
03 30 00	Cast-In-Place Concrete	1.6.F.	SUBMITTALS:
Test Report for Concrete Mix Designs	Trial mixes including water�cement ratio curves, concrete mix ingredients, and admixtures.
03 30 00	Cast-In-Place Concrete	1.6.G.	SUBMITTALS:
Shoring and Reshoring Sequence	Submit for approval a shoring and reshoring sequence for flat slab/flat plate portions, prepared by a registered Professional Engineer. As a minimum, include timing of form stripping, reshoring, number of floors to be re-shored and timing of re-shore removal to serve as an initial outline of procedures subject to modification as construction progresses. Submit revisions to sequence, whether initiated by Resident Engineer (see FORMWORK) or Contractor.
03 30 00	Cast-In-Place Concrete	1.6.H.	SUBMITTALS:
Test reports on splitting tensile strength (Fct) of lightweight concrete.
04 01 00	Maintenance of Masonry	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
04 01 00	Maintenance of Masonry	1.4.B.	SUBMITTALS
Manufacturer's Literature and Data
04 01 00	Maintenance of Masonry	1.4.C.	SUBMITTALS
Samples
04 01 00	Maintenance of Masonry	1.4.D.	SUBMITTALS
Test reports
04 05 13	Masonry Mortaring	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
04 05 13	Masonry Mortaring	1.4.B.	SUBMITTALS
Manufacturer's Literature and Data
04 05 13	Masonry Mortaring	1.4.C.	SUBMITTALS
Test Reports	Certify each product complies with specifications.
04 05 13	Masonry Mortaring	1.4.D.	SUBMITTALS
Certificates	Certify each product complies with specifications.
04 05 13	Masonry Mortaring	1.4.E.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
04 05 16	Masonry Grouting	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
04 05 16	Masonry Grouting	1.4.B.	SUBMITTALS
Manufacturer's Literature and Data
04 05 16	Masonry Grouting	1.4.C.	SUBMITTALS
Sustainable Construction Submittals
04 05 16	Masonry Grouting	1.4.D.	SUBMITTALS
Test Reports	Certify each product complies with specifications.
04 05 16	Masonry Grouting	1.4.E.	SUBMITTALS
Certificates	Certify each product complies with specifications.
04 20 00	Unit Masonry	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
04 20 00	Unit Masonry	1.4.B.	SUBMITTALS
Submittal Drawings
04 20 00	Unit Masonry	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
04 20 00	Unit Masonry	1.4.D.	SUBMITTALS
Samples
04 20 00	Unit Masonry	1.4.E.	SUBMITTALS
Sustainable Construction Submittals
04 20 00	Unit Masonry	1.4.F.	SUBMITTALS
Test reports	Certify products comply with specifications.
04 20 00	Unit Masonry	1.4.G.	SUBMITTALS
Certificates	Certify products comply with specifications.
04 20 00	Unit Masonry	1.4.H.	SUBMITTALS
Delegated Design Drawings and Calculations	Signed and sealed by responsible design professional.
04 72 00	Cast Stone Masonry	1.3.A.	SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
04 72 00	Cast Stone Masonry	1.3.B.	SUBMITTALS
Samples
04 72 00	Cast Stone Masonry	1.3.C.	SUBMITTALS
C.	Shop Drawings
04 72 00	Cast Stone Masonry	1.3.D.	SUBMITTALS
Certificates	Test results indicating that the cast stone meets specification requirements and proof of plant certification.
04 72 00	Cast Stone Masonry	1.3.E.	SUBMITTALS
Submit manufacturers test results of cast stone previously made by manufacturer.
04 72 00	Cast Stone Masonry	1.3.F.	SUBMITTALS
Laboratory Data	Description of testing laboratories facilities and qualifications of its principals and key personnel.
04 72 00	Cast Stone Masonry	1.3.G.	SUBMITTALS
List of jobs furnished by the manufacturer, which were similar in scope and at least three (3) years of age.
05 12 00	Structural Steel Framing	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
05 12 00	Structural Steel Framing	1.4.B.	SUBMITTALS
Submittal Drawings
05 12 00	Structural Steel Framing	1.4.C.	SUBMITTALS
Sustainable Construction Submittals
05 12 00	Structural Steel Framing	1.4.D.	SUBMITTALS
Test Reports	Certify products comply with specifications.
05 12 00	Structural Steel Framing	1.4.E.	SUBMITTALS
Certificates	Certify each product complies with specifications.
05 12 00	Structural Steel Framing	1.4.F.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
05 12 00	Structural Steel Framing	1.4.G.	SUBMITTALS
Delegated Design Drawings and Calculations	Signed and sealed by responsible Architect/Engineer.
05 12 00	Structural Steel Framing	1.4.H.	SUBMITTALS
Record Surveys	Signed and sealed by responsible surveyor or engineer.
05 31 00	Steel Decking	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
05 31 00	Steel Decking	1.4.B.	SUBMITTALS
Submittal Drawings
05 31 00	Steel Decking	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
05 31 00	Steel Decking	1.4.D.	SUBMITTALS
Sustainable Construction Submittals
05 31 00	Steel Decking	1.4.E.	SUBMITTALS
Certificates	Certify each product complies with specifications.
05 31 00	Steel Decking	1.4.F.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
05 31 00	Steel Decking	1.4.G.	SUBMITTALS
Insurance Certification	Assist the Government in preparation and submittal of roof installation acceptance certification as may be necessary in connection with fire and extended coverage insurance.
05 50 00	Metal Fabrications	1.3.A.	SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
05 50 00	Metal Fabrications	1.3.B.	SUBMITTALS
Manufacturer's Literature and Data
05 50 00	Metal Fabrications	1.3.C.	SUBMITTALS
Shop Drawings
05 50 00	Metal Fabrications	1.3.D.	SUBMITTALS
Manufacturer's Certificates
05 50 00	Metal Fabrications	1.3.E.	SUBMITTALS
Design Calculations for specified live loads including dead loads.
05 50 00	Metal Fabrications	1.3.F.	SUBMITTALS
Furnish setting drawings and instructions for installation of anchors to be preset into concrete and masonry work, and for the positioning of items having anchors to be built into concrete or masonry construction.
05 51 00	Metal Stairs	1.3.A.	SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
05 51 00	Metal Stairs	1.3.B.	SUBMITTALS:
Sustainable Design Submittals, as described below
05 51 00	Metal Stairs	1.3.C.	SUBMITTALS:
Shop Drawings	Show design, fabrication details, installation, connections, material, and size of members.
05 51 00	Metal Stairs	1.3.D.	SUBMITTALS:
Fabrication qualifications.
05 51 00	Metal Stairs	1.3.E.	SUBMITTALS:
Installer qualifications.
05 51 00	Metal Stairs	1.3.F.	SUBMITTALS:
Calculations.
05 51 00	Metal Stairs	1.3.G.	SUBMITTALS:
Welding qualifications.
06 10 00	Rough Carpentry	1.3.A.	1.3 SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
06 10 00	Rough Carpentry	1.3.B.	1.3 SUBMITTALS:
Sustainable Design Submittals, as described below
06 10 00	Rough Carpentry	1.3.C.	1.3 SUBMITTALS:
Shop Drawings showing framing connection details, fasteners, connections and dimensions.
06 10 00	Rough Carpentry	1.3.D.	1.3 SUBMITTALS:
Manufacturer’s Literature and Data
06 10 00	Rough Carpentry	1.3.E.	1.3 SUBMITTALS:
Manufacturer’s certificate for unmarked lumber.
07 01 50.19	Preparation for Re-Roofing	1.5.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 01 50.19	Preparation for Re-Roofing	1.5.B.	SUBMITTALS
Submittal Drawings
07 01 50.19	Preparation for Re-Roofing	1.5.C.	SUBMITTALS
Manufacturer's Literature and Data
07 01 50.19	Preparation for Re-Roofing	1.5.D.	SUBMITTALS
Photographs	Document existing conditions potentially affected by roofing operations before work begins.
07 01 50.19	Preparation for Re-Roofing	1.5.E.	SUBMITTALS
Field Inspection Reports
07 01 50.19	Preparation for Re-Roofing	1.5.F.	SUBMITTALS
Infrared Roof Moisture Survey Report.
07 08 00	Facility Exterior Closure Commissioning	1.6.A.	SUBMITTALS
The commissioning process requires review of selected Submittals that pertain to the systems to be commissioned. The Commissioning Agent will provide a list of submittals that will be reviewed by the Commissioning Agent. This list will be reviewed and approved by the VA prior to forwarding to the Contractor. Refer to Section 01 33 23 SHOP DRAWINGS, PRODUCT DATA, and SAMPLES for further details.
07 08 00	Facility Exterior Closure Commissioning	1.6.B.	SUBMITTALS
The commissioning process requires Submittal review simultaneously with engineering review. Specific submittal requirements related to the commissioning process are specified in Section 01 91 00 GENERAL COMMISSIONING REQUIREMENTS.
07 13 00	Sheet Waterproofing	1.3.A.	SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 13 00	Sheet Waterproofing	1.3.B.	SUBMITTALS
Manufacturer's Literature and Data
07 13 00	Sheet Waterproofing	1.3.C.	SUBMITTALS
Certificates
07 13 00	Sheet Waterproofing	1.3.D.	SUBMITTALS
Samples
07 13 52	Modified Bituminous Sheet Waterproofing	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 13 52	Modified Bituminous Sheet Waterproofing	1.4.B.	SUBMITTALS
Submittal Drawings
07 13 52	Modified Bituminous Sheet Waterproofing	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
07 13 52	Modified Bituminous Sheet Waterproofing	1.4.D.	SUBMITTALS
Samples
07 13 52	Modified Bituminous Sheet Waterproofing	1.4.E.	SUBMITTALS
Test reports	Certify products comply with specifications.
07 13 52	Modified Bituminous Sheet Waterproofing	1.4.F.	SUBMITTALS
Certificates	Certify products comply with specifications.
07 13 52	Modified Bituminous Sheet Waterproofing	1.4.G.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
07 21 13	Thermal Insulation	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 21 13	Thermal Insulation	1.4.B.	SUBMITTALS
Submittal Drawings
07 21 13	Thermal Insulation	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
07 21 13	Thermal Insulation	1.4.D.	SUBMITTALS
Sustainable Construction Submittals
07 22 00	Roof and Deck Insulation	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 22 00	Roof and Deck Insulation	1.4.B.	SUBMITTALS
Submittal Drawings
07 22 00	Roof and Deck Insulation	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
07 22 00	Roof and Deck Insulation	1.4.D.	SUBMITTALS
Samples
07 22 00	Roof and Deck Insulation	1.4.E.	SUBMITTALS
Sustainable Construction Submittals
07 22 00	Roof and Deck Insulation	1.4.F.	SUBMITTALS
Qualifications	Substantiate qualifications meet specifications.
07 27 27	Fluid-Applied Membrane Air Barrier, Vapor Retarding	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 27 27	Fluid-Applied Membrane Air Barrier, Vapor Retarding	1.4.B.	SUBMITTALS
Manufacturer's Literature and Data
07 27 27	Fluid-Applied Membrane Air Barrier, Vapor Retarding	1.4.C.	SUBMITTALS
Sustainable Construction Submittals
07 27 27	Fluid-Applied Membrane Air Barrier, Vapor Retarding	1.4.D.	SUBMITTALS
Test reports
07 27 27	Fluid-Applied Membrane Air Barrier, Vapor Retarding	1.4.E.	SUBMITTALS
Certificates	Certify each product complies with specifications.
07 27 27	Fluid-Applied Membrane Air Barrier, Vapor Retarding	1.4.F.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
07 27 27	Fluid-Applied Membrane Air Barrier, Vapor Retarding	1.4.G.	SUBMITTALS
Installation Audit
07 31 13	Asphalt Shingles	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 31 13	Asphalt Shingles	1.4.B.	SUBMITTALS
Manufacturer's Literature and Data
07 31 13	Asphalt Shingles	1.4.C.	SUBMITTALS
Samples
07 31 13	Asphalt Shingles	1.4.D.	SUBMITTALS
Sustainable Construction Submittals
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.B.	SUBMITTALS
Submittal Drawings
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.C.	SUBMITTALS
Manufacturer's Literature and Data
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.D.	SUBMITTALS
Samples
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.E.	SUBMITTALS
Sustainable Construction Submittals
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.F.	SUBMITTALS
Certificates	Certify products comply with specifications.
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.G.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.H.	SUBMITTALS
Field quality control reports.
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.I.	SUBMITTALS
Temporary protection plan. Include list of proposed temporary materials.
07 54 23	Thermoplastic Polyolefin (TPO) Roofing	1.5.J.	SUBMITTALS
Operation and Maintenance Data
07 60 00	Flashing and Sheet Metal	1.5.A.	SUBMITTALS
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 60 00	Flashing and Sheet Metal	1.5.B.	SUBMITTALS
Shop Drawings	For all specified items, including
07 60 00	Flashing and Sheet Metal	1.5.C.	SUBMITTALS
Manufacturer's Literature and Data	For all specified items, including
07 60 00	Flashing and Sheet Metal	1.5.D.	SUBMITTALS
Certificates	Indicating compliance with specified finishing requirements, from applicator and contractor.
07 71 00	Roof Specialties	1.5.A.	SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 71 00	Roof Specialties	1.5.B.	SUBMITTALS:
Sustainable Design Submittals, as described below
07 71 00	Roof Specialties	1.5.C.	SUBMITTALS:
Samples	Representative sample panel of color-anodized aluminum not less than 101 x 101 mm (4 x 4 inches), except extrusions are to be of a width not less than section to be used. Submit sample that shows coating with integral color and texture. Include manufacturer's identifying label.
07 71 00	Roof Specialties	1.5.D.	SUBMITTALS:
Shop Drawings	Each item specified showing design, details of construction, installation and fastenings.
07 71 00	Roof Specialties	1.5.E.	SUBMITTALS:
Manufacturer's Literature and Data	Each item specified.
07 71 00	Roof Specialties	1.5.F.	SUBMITTALS:
Certificates	Stating that aluminum has been given specified thickness of anodizing.
07 72 00	Roof Accessories	1.4.A.	SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 72 00	Roof Accessories	1.4.B.	SUBMITTALS:
Sustainable Design Submittals, as described below
07 72 00	Roof Accessories	1.4.C.	SUBMITTALS:
Samples	Submit representative sample panel of color anodized aluminum not less than 101 x 101 mm (4 x 4 inches). For extrusions, submit width not less than section to be installed. Show coating with integral color and texture and include manufacturer's identifying label.
07 72 00	Roof Accessories	1.4.D.	SUBMITTALS:
Shop Drawings	Each item specified showing design, details of construction, installation and fastenings.
07 72 00	Roof Accessories	1.4.E.	SUBMITTALS:
Manufacturer's Literature and Data	Each item specified.
07 72 00	Roof Accessories	1.4.F.	SUBMITTALS:
Certificates	Stating that aluminum has been given specified thickness of anodizing.
07 81 00	Applied Fireproofing	1.3.A.	SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 81 00	Applied Fireproofing	1.3.B.	SUBMITTALS:
Sustainable Design Submittals, as described below
07 81 00	Applied Fireproofing	1.3.C.	SUBMITTALS:
Installer qualifications.
07 81 00	Applied Fireproofing	1.3.D.	SUBMITTALS:
Testing laboratory accreditations.
07 81 00	Applied Fireproofing	1.3.E.	SUBMITTALS:
Manufacturer's Literature and Data
07 81 00	Applied Fireproofing	1.3.F.	SUBMITTALS:
Certificates
07 81 00	Applied Fireproofing	1.3.G.	SUBMITTALS:
Miscellaneous
07 84 00	Firestopping	1.3.A.	SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 84 00	Firestopping	1.3.B.	SUBMITTALS:
Sustainable Design Submittals, as described below
07 84 00	Firestopping	1.3.C.	SUBMITTALS:
Installer qualifications.
07 84 00	Firestopping	1.3.D.	SUBMITTALS:
Inspector qualifications.
07 84 00	Firestopping	1.3.E.	SUBMITTALS:
Manufacturers literature, data, and installation instructions for types of firestopping and smoke stopping used.
07 84 00	Firestopping	1.3.F.	SUBMITTALS:
List of FM, UL, or WH classification number of systems installed.
07 84 00	Firestopping	1.3.G.	SUBMITTALS:
Certified laboratory test reports for ASTM E814 tests for systems not listed by FM, UL, or WH proposed for use.
07 84 00	Firestopping	1.3.H.	SUBMITTALS:
Submit certificates from manufacturer attesting that firestopping materials comply with the specified requirements.
07 92 00	Joint Sealants	1.5.A.	SUBMITTALS:
Submit in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 92 00	Joint Sealants	1.5.B.	SUBMITTALS:
Sustainable Design Submittals, as described below
07 92 00	Joint Sealants	1.5.C.	SUBMITTALS:
C. Installer qualifications.
07 92 00	Joint Sealants	1.5.D.	SUBMITTALS:
Contractor certification.
07 92 00	Joint Sealants	1.5.E.	SUBMITTALS:
Manufacturer's installation instructions for each product used.
07 92 00	Joint Sealants	1.5.F.	SUBMITTALS:
Cured samples of exposed sealants for each color.
07 92 00	Joint Sealants	1.5.G.	SUBMITTALS:
Manufacturer's Literature and Data
07 92 00	Joint Sealants	1.5.H.	SUBMITTALS:
Manufacturer warranty.
07 95 13	Expansion Joint Cover Assemblies	1.5.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
07 95 13	Expansion Joint Cover Assemblies	1.5.B.	SUBMITTALS
Submittal Drawings
07 95 13	Expansion Joint Cover Assemblies	1.5.C.	SUBMITTALS
Manufacturer's Literature and Data
07 95 13	Expansion Joint Cover Assemblies	1.5.D.	SUBMITTALS
Samples	Submit 300 mm (12 inch) long samples.
07 95 13	Expansion Joint Cover Assemblies	1.5.E.	SUBMITTALS
Sustainable Construction Submittals
07 95 13	Expansion Joint Cover Assemblies	1.5.F.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
07 95 13	Expansion Joint Cover Assemblies	1.5.G.	SUBMITTALS
Certificates	Indicate products comply with specifications.
07 95 13	Expansion Joint Cover Assemblies	1.5.H.	SUBMITTALS
Operation and Maintenance Data
08 11 13	Hollow Metal Doors and Frames	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
08 11 13	Hollow Metal Doors and Frames	1.4.B.	SUBMITTALS
Submittal Drawings
08 11 13	Hollow Metal Doors and Frames	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
08 11 13	Hollow Metal Doors and Frames	1.4.D.	SUBMITTALS
Sustainable Construction Submittals
08 11 13	Hollow Metal Doors and Frames	1.4.E.	SUBMITTALS
Test reports	Certify each product complies with specifications.
08 11 13	Hollow Metal Doors and Frames	1.4.F.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
08 14 00	Interior Wood Doors	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
08 14 00	Interior Wood Doors	1.4.B.	SUBMITTALS
Submittal Drawings
08 14 00	Interior Wood Doors	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
08 14 00	Interior Wood Doors	1.4.D.	SUBMITTALS
Samples
08 14 00	Interior Wood Doors	1.4.E.	SUBMITTALS
Sustainable Construction Submittals
08 14 00	Interior Wood Doors	1.4.F.	SUBMITTALS
Test Reports	Indicate each product complies with specifications.
08 14 00	Interior Wood Doors	1.4.G.	SUBMITTALS
Operation and Maintenance Data
08 17 10	Integrated Door Assemblies	1.5.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
08 17 10	Integrated Door Assemblies	1.5.B.	SUBMITTALS
Submittal Drawings
08 17 10	Integrated Door Assemblies	1.5.C.	SUBMITTALS
Manufacturer's Literature and Data
08 17 10	Integrated Door Assemblies	1.5.D.	SUBMITTALS
Sustainable Construction Submittals
08 17 10	Integrated Door Assemblies	1.5.E.	SUBMITTALS
Certificates	Indicate integrated door assemblies comply with specifications.
08 17 10	Integrated Door Assemblies	1.5.F.	SUBMITTALS
Qualifications	Substantiate qualifications comply with specifications.
08 17 10	Integrated Door Assemblies	1.5.G.	SUBMITTALS
Operation and Maintenance Data
08 31 13	Access Doors and Frames	1.4.A.	SUBMITTALS
Submittal Procedures	Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
08 31 13	Access Doors and Frames	1.4.B.	SUBMITTALS
Submittal Drawings
08 31 13	Access Doors and Frames	1.4.C.	SUBMITTALS
Manufacturer's Literature and Data
08 31 13	Access Doors and Frames	1.4.D.	SUBMITTALS
Sustainable Construction Submittals
08 36 16.13	High Performance Barn (Sliding) Door	1.3.A.	SUBMITTALS
Comply with Section 01 33 23 – SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES
08 36 16.13	High Performance Barn (Sliding) Door	1.3.B.	SUBMITTALS
Product Data	Submit manufacturer’s product data, including installation instructions.
08 36 16.13	High Performance Barn (Sliding) Door	1.3.C.	SUBMITTALS
Shop Drawings	Submit manufacturer’s shop drawings, including plans, elevations, sections, and details, indicating dimensions, tolerances, materials, components, hardware, finish, options, and accessories. Shop Drawings to show required blocking by others.
08 36 16.13	High Performance Barn (Sliding) Door	1.3.D.	SUBMITTALS
Samples	Submit manufacturer’s samples of the following sliding door components
08 36 16.13	High Performance Barn (Sliding) Door	1.3.E.	SUBMITTALS
Manufacturer’s Certification	Submit manufacturer’s certification that materials comply with specified requirements and are suitable for intended application.
08 36 16.13	High Performance Barn (Sliding) Door	1.3.F.	SUBMITTALS
Warranty Documentation	Submit manufacturer’s standard warranty.
08 36 16.13	High Performance Barn (Sliding) Door	1.3.G.	SUBMITTALS
Test Reports	Submit acoustical reports or UL1784 as applicable.
08 51 13	Aluminum Windows	1.5.A.	SUBMITTAL
Submit according to Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES.
08 51 13	Aluminum Windows	1.5.B.	SUBMITTAL
Submittal Drawings
08 51 13	Aluminum Windows	1.5.C.	SUBMITTAL
Manufacturer's Literature and Data
08 51 13	Aluminum Windows	1.5.D.	SUBMITTAL
Sustainable Construction Submittals
08 51 13	Aluminum Windows	1.5.E.	SUBMITTAL
Samples
08 51 13	Aluminum Windows	1.5.F.	SUBMITTAL
Test reports	Indicate each product complies with specifications.
08 51 13	Aluminum Windows	1.5.G.	SUBMITTAL
Certificates	Indicate each product complies with requirements (window characteristics may be on window schedule or other drawings).
08 71 00	Door Hardware	1.6.A.	SUBMITTALS

This is the start of the file's text. The full file is on GovTribe.

File details come from the government source that posted it. Updated Mar 7, 2022.