ATTACHMENT G_PAST PERFORMANCE QUESTIONNAIRE_NX EQ TEE SCANNING SYSTEMS.docx
DOCX document 35 KB Posted
- Solicitation number
- 36C10X27R0011
About this file
This is a Past Performance Questionnaire form for the NX EQ Transesophageal Echocardiography (TEE) Scanning Systems solicitation issued by the Department of Veterans Affairs Strategic Acquisition Center Frederick under solicitation number 36C10X27R0011. The document serves as a template for prospective contractors to provide information regarding their relevant past performance experience on similar projects and contracts.
The questionnaire is designed to evaluate contractor capability and experience in delivering TEE scanning systems or comparable medical equipment and services. Respondents are required to document their past performance on projects of similar scope, complexity, and technical requirements, including details such as contract values, performance timelines, customer references, and demonstrated quality of work. This evaluation criterion allows the government to assess the offeror's ability to successfully execute the requirements of the NX EQ TEE scanning systems procurement and is a standard component of the competitive evaluation process for commercial items under FAR 12.2.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| ATTACHMENT E_REPORTING TOOL_NX EQ TEE SCANNING SYSTEMS.xlsx | XLSX spreadsheet | |
| S02 36C10X27R0011 Combined Synopsis Solicitation.docx | DOCX document | |
| ATTACHMENT B_CONTRACT ADMINISTRATION_NX EQ TEE SCANNING SYSTEMS.docx | DOCX document | |
| ATTACHMENT F_PAST PERFORMANCE REFERENCE_NX EQ TEE SCANNING SYSTEMS.docx | DOCX document | |
| ATTACHMENT J_CERTIFICATION OF RECALL OR SAFETY ISSUES_NX EQ TEE SCANNING SYSTEMS.docx | DOCX document | |
| ATTACHMENT C_CONTRACT CLAUSES_NX EQ TEE SCANNING SYSTEMS.docx | DOCX document | |
| ATTACHMENT D_SOLICITATION PROVISIONS_NX EQ TEE SCANNING SYSTEMS.docx | DOCX document | |
| ATTACHMENT H_RFQ QUESTIONS_NX EQ TEE SCANNING SYSTEMS.xlsx | XLSX spreadsheet | |
| ATTACHMENT A_PRICE COST SCHEDULE_NX EQ TEE SCANNING SYSTEMS.xlsx | XLSX spreadsheet |
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment G Past Performance Questionnaire
SOLICITATION NO.: 36C10X27R0011
DESCRIPTION: NX EQ TEE SCANNING SYSTEMS – Brand Name Philips Healthcare EPIQ CVx® or Equal
Offerors: Please Send Each Reference Cited in Submitted Proposal (Maximum of Five References from Past Three Years)
DEPARTMENT OF VETERANS AFFAIRS (VA)
ENTERPRISE PROCUREMENT OFFICE (EPO)
PAST PERFORMANCE QUESTIONNAIRE
TO: Courtney Chattman and Jessica Smith E-MAIL: Courtney.Chattman@va.gov and Jessica.Smith32@va.gov
VA EPO is currently in the process of awarding a contract for the solicitation described above. The offeror identified below has provided your organization’s name as a reference under the contract described below:
Offeror Name:
(Insert Offeror’s Name Here)
| Contract Number: |
| (Insert Applicable Contract Number Here) |
Please rate the offeror in each of the categories on this questionnaire. See “Rating Guidelines” section for detailed description of categories and ratings. There is room for comments where you deem remarks would be helpful to our evaluation (see ‘Comment from Reference’ under “Offeror Evaluation.” Please note that the past performance evaluators for this solicitation may contact you for further details in making a fair assessment of this offeror’s past performance. Thank you for your organization’s assistance in fairly evaluating offeror proposals for this solicitation.
Please E-mail Questionnaire to: Courtney.Chattman@va.gov and Jessica.Smith32@va.gov by December 15, 2026, at 10:00 AM CT.
| Name of Reference: |
| (Reference Complete These Sections) |
Title of Reference:
Phone Number:
E-Mail Address:
Name of Organization:
Contract Period of Performance (Month/Day/Year Begin and End):
Total Contract Value (Base and All Option Years):
Options Exercised on Contract (Yes/No)?
Brief Description of Services/Commodity Provided by Offeror:
Show Cause Order Issued on Contract (Yes/No)?
Stop Work Order Issued on Contract (Yes/No)?
Termination for Convenience, Cause, or Default Issued on Contract (Yes/No)?
Rating Guidelines:
| Rating |
| Quality of Service |
| Cost Control |
| Timeliness of Performance |
| Business Relations |
| 1: Unsatisfactory |
| Offeror is not in compliance and has jeopardized achievement of contract objectives |
| Offeror is unable to manage costs effectively |
| Offeror delays have jeopardized performance |
| Responses to inquiries and issues are not effective |
| 2: Satisfactory |
| Minor inefficiencies and errors have been identified |
| Offeror is usually effective in managing costs |
| Offeror is usually effective in meeting milestones and delivery schedule |
| Responses to inquiries and issues is usually effective |
| 3: Excellent |
| Offeror is in compliance with contract requirements and delivers quality services |
| Offeror is effective in managing costs and submits proper invoices |
| Offeror is effective in meeting and exceeding milestones and delivery schedule |
| Responses to inquiries have been effective and/or exceeded expectations and established deadlines |
Offeror Evaluation:
| Rating (List Number Based on Rating Guidelines Above) |
| Category |
| Description |
| Quality of Service |
| In compliance with contract requirements, submits accurate reports/deliverables, has effective personnel, and has achieved/maintained technical excellence: |
Comment from Reference: _______________________
| Cost Control |
| Has achieved efficiencies in costs, managed costs effectively, and has submitted timely/accurate invoices with supporting documentation: |
| Timeliness of Performance |
| Has met milestones, is reliable, is responsive to technical direction, and has completed milestones on-time or ahead of schedule: |
| Business Relations |
| Has maintained effective management of contract, has exhibited reasonable/cooperative behavior, is responsive to contract requirements, is responsive to inquiries/issues, and is proactive about resolving problems: |
| |_| YES |_| NO |
| Overall Satisfaction |
| Would you (reference) choose to work with this offeror again? |
| Name of Reference: |
| (Reference Complete These Sections) |
Title of Reference:
Phone Number:
E-Mail Address:
Name of Organization:
Contract Period of Performance (Month/Day/Year Begin and End):
Total Contract Value (Base and All Option Years):
Options Exercised on Contract (Yes/No)?
Brief Description of Services/Commodity Provided by Offeror:
Show Cause Order Issued on Contract (Yes/No)?
Stop Work Order Issued on Contract (Yes/No)?
Termination for Convenience, Cause, or Default Issued on Contract (Yes/No)?
| Rating |
| Quality of Service |
| Cost Control |
| Timeliness of Performance |
| Business Relations |
| 1: Unsatisfactory |
| Offeror is not in compliance and has jeopardized achievement of contract objectives |
| Offeror is unable to manage costs effectively |
| Offeror delays have jeopardized performance |
| Responses to inquiries and issues are not effective |
| 2: Satisfactory |
| Minor inefficiencies and errors have been identified |
| Offeror is usually effective in managing costs |
| Offeror is usually effective in meeting milestones and delivery schedule |
| Responses to inquiries and issues is usually effective |
| 3: Excellent |
| Offeror is in compliance with contract requirements and delivers quality services |
| Offeror is effective in managing costs and submits proper invoices |
| Offeror is effective in meeting and exceeding milestones and delivery schedule |
| Responses to inquiries have been effective and/or exceeded expectations and established deadlines |
| Rating (List Number Based on Rating Guidelines Above) |
| Category |
| Description |
| Quality of Service |
| In compliance with contract requirements, submits accurate reports/deliverables, has effective personnel, and has achieved/maintained technical excellence: |
| Cost Control |
| Has achieved efficiencies in costs, managed costs effectively, and has submitted timely/accurate invoices with supporting documentation: |
| Timeliness of Performance |
| Has met milestones, is reliable, is responsive to technical direction, and has completed milestones on-time or ahead of schedule: |
| Business Relations |
| Has maintained effective management of contract, has exhibited reasonable/cooperative behavior, is responsive to contract requirements, is responsive to inquiries/issues, and is proactive about resolving problems: |
| |_| YES |_| NO |
| Overall Satisfaction |
| Would you (reference) choose to work with this offeror again? |
| Name of Reference: |
| (Reference Complete These Sections) |
Title of Reference:
Phone Number:
E-Mail Address:
Name of Organization:
Contract Period of Performance (Month/Day/Year Begin and End):
Total Contract Value (Base and All Option Years):
Options Exercised on Contract (Yes/No)?
Brief Description of Services/Commodity Provided by Offeror:
Show Cause Order Issued on Contract (Yes/No)?
Stop Work Order Issued on Contract (Yes/No)?
Termination for Convenience, Cause, or Default Issued on Contract (Yes/No)?
| Rating |
| Quality of Service |
| Cost Control |
| Timeliness of Performance |
| Business Relations |
| 1: Unsatisfactory |
| Offeror is not in compliance and has jeopardized achievement of contract objectives |
| Offeror is unable to manage costs effectively |
| Offeror delays have jeopardized performance |
| Responses to inquiries and issues are not effective |
| 2: Satisfactory |
| Minor inefficiencies and errors have been identified |
| Offeror is usually effective in managing costs |
| Offeror is usually effective in meeting milestones and delivery schedule |
| Responses to inquiries and issues is usually effective |
| 3: Excellent |
| Offeror is in compliance with contract requirements and delivers quality services |
| Offeror is effective in managing costs and submits proper invoices |
| Offeror is effective in meeting and exceeding milestones and delivery schedule |
| Responses to inquiries have been effective and/or exceeded expectations and established deadlines |
| Rating (List Number Based on Rating Guidelines Above) |
| Category |
| Description |
| Quality of Service |
| In compliance with contract requirements, submits accurate reports/deliverables, has effective personnel, and has achieved/maintained technical excellence: |
| Cost Control |
| Has achieved efficiencies in costs, managed costs effectively, and has submitted timely/accurate invoices with supporting documentation: |
| Timeliness of Performance |
| Has met milestones, is reliable, is responsive to technical direction, and has completed milestones on-time or ahead of schedule: |
| Business Relations |
| Has maintained effective management of contract, has exhibited reasonable/cooperative behavior, is responsive to contract requirements, is responsive to inquiries/issues, and is proactive about resolving problems: |
| |_| YES |_| NO |
| Overall Satisfaction |
| Would you (reference) choose to work with this offeror again? |
File details come from the government source that posted it. Updated .