3-Kos952935D_25-09_Contract_Doc_DD.pdf

Kos952935D Nutrient Reduction Wetland Project DOCUMENT DD

Bid No. 25-09 CONSTRUCTION CONTRACT

DD-1

State of Iowa

Iowa Department of Agriculture and Land Stewardship

DIVISION OF SOIL CONSERVATION AND WATER QUALITY

THIS AGREEMENT, made this ______ day of _____________, 20____, by and between the State of

Iowa, acting through:

Division of Soil Conservation and Water Quality hereinafter called the DIVISION, and

(Name of Company)

(Address)

(City, State, Zip) hereinafter called the CONTRACTOR.

WITNESSETH: that the DIVISION agrees to pay the CONTRACTOR the contract price provided herein for the fulfillment of the work and performance of the covenants set forth herein, and the CONTRACTOR agrees to commence and complete the project described as follows:

Nutrient Reduction Wetland Project Construction Contract

Section 35, Township 95 North, Range 29 West, Kossuth County, Iowa

Project ID: Kos952935D

Bid No. 25-09 for the sum of _______________________ _____/100 Dollars ($_____________.__) and all extra work in connection therewith as modified by approved Change Orders and Amendments, all in accordance with the terms and conditions herein contained; and to furnish at the CONTRACTOR’S own proper cost and expense, all materials, equipment, supervision, labor, insurance, and other accessories and services necessary to construct and complete, in a workmanlike manner, ready for continuous operation, the above-mentioned project. The work shall be performed in accordance with the requirements and provisions of the following documents, all of which are made a part hereof and collectively evidence and constitute the contract:

1. Notice-to-Bidders (Document AA)

2. Instructions to Bidders (Document BB)

3. Proposal and Schedule of Prices (Document CC)

4. This Instrument – Construction Contract (Document DD)

5. General Conditions (Document FF)

6. Special Conditions (Document GG)

7. Approved Change Orders (Document HH)

8. Approved Construction Contract Amendments (Document II)

9. Construction Specifications

10. Drawings, Sheet Numbers C001-C401

11. Notice-of-Award (Document LL)

12. Construction Progress Schedule (Document JJ)

13. Notice-to-Proceed (Document MM)

14. Performance Bond (Document NN)

15. Addenda (when applicable)

The CONTRACTOR shall complete the Construction Progress Schedule (Document JJ) form provided within fourteen (14) days of the date that the Notice-of-Award is received. Should there be any reason why the Construction Progress Schedule

Kos952935D Nutrient Reduction Wetland Project DOCUMENT DD

Bid No. 25-09 CONSTRUCTION CONTRACT

DD-2

needs adjustment, those changes may be made by mutual agreement between the DIVISION and the CONTRACTOR as set forth in Paragraph 3-21 of Document FF. The Notice-to-Proceed will be issued within five (5) days of the execution of

Contract, provided that the Construction Progress Schedule is approved by Division.

The CONTRACTOR shall schedule and attend a Preconstruction Conference with the DIVISION and the ENGINEER. The

Preconstruction Conference shall be held within seven (7) days prior to the Construction Start Date specified in the accepted

Construction Progress Schedule, or earlier by mutual agreement. No work may commence on site prior to the Preconstruction

Conference. If the CONTRACTOR plans to adjust the Construction Start Date, this shall be communicated to the DIVISION as soon as possible to allow scheduling of the Preconstruction Conference.

The CONTRACTOR hereby agrees to complete the work within the contract period, or to pay liquidated damages. All work except for seeding must be completed by June 15, 2026, and the seeding must be completed by June 30, 2026.

It is understood that the CONTRACTOR consents to the jurisdiction of the courts of Iowa to hear, determine and render judgments as to any controversy arising hereunder, and that this contract shall be governed by, and construed according to the laws of the State of Iowa.

IN WITNESS WHEREOF, the parties hereto have executed this Agreement, in the day and year first aforementioned.

FOR THE DIVISION FOR THE CONTRACTOR

Grant D. Menke, Deputy Secretary

(Date)

(Company Representative)

(Date)

(Name of Company)

(Address of Company)

(City, State, Zip Code)

Seal if by a corporation

Identification Number

Soc. Sec. No. ____________________________________ or

Fed. ID No. _____________________________________

Iowa Division of Labor

Public Registration No. ___________________________

END OF DOCUMENT DD