RFQ 19FR6326Q0097- Kitchen renovation.pdf

Embassy of the United States of America

U.S. Embassy Paris

Date: July 20, 2026

Dear Prospective Offeror:

Subject: Request for Quotes 19FR6326Q0097

Enclosed is a Request for Quotes (RFQ) for the renovation of a kitchen in one UGS Building. If you would like to submit a quotation, follow the instructions in Section J of the solicitation, complete the required portions of the attached document, and submit it to the address shown on the Standard Form that follows this letter.

The U.S. Government intends to award a contract/purchase order to the responsible company submitting an acceptable offer at the lowest price. We intend to award a contract/purchase order based on initial proposals, without holding discussions, although we may hold discussions with companies in the competitive range if there is a need to do so.

Quotations are due by Thursday August 20, 2026 at 14:00. No quotations will be accepted after this time.

Quotations must be in English and incomplete quotations will not be accepted.

Your quotation must be submitted electronically to Pariscontracting@state.gov . It is important to make sure the submission is made in specific size and format; in MS-Word 2007/2010 or MS-Excel 2007/2010 or Adobe Acrobat

(pdf) file format. The file size must not exceed 30MB. If the file size should exceed the 30MB, the submission must be made in separate files and attached to separate emails with less than 30MB each.

In order for a quotation to be considered, you must also complete and submit the following:

1. SF-1442

2. Section A, Pricing

3. Section L Representations and Certifications

4. Additional information as required in Section J

5. Proof of SAM Registration

Offerors shall be registered in the SAM (System for Award Management) database at https://www.sam.gov prior to submittal of their offer/proposal as prescribed under FAR 4.1102. Failure to be registered at time of proposal submission may deem the offeror’s proposal to be considered non-responsible and no further consideration will be given. Therefore, offerors are highly encouraged to register immediately if they are interested in submitting a response to this requirement.

Sincerely, Craig N. Deatrick

Contracting Officer mailto:Pariscontracting@state.gov https://www.sam.gov/

1 | P a g e 3 1

RFQ 19FR6326Q0097- Kitchen Renovation

TABLE OF CONTENTS

SF-1442 COVER SHEET

A. PRICING

B. STATEMENT OF WORK

C. PACKAGING AND MARKING

D. INSPECTION AND ACCEPTANCE

E. DELIVERIES AND PERFORMANCE

F. CONTRACT ADMINISTRATION DATA

G. SPECIAL TERMS AND CONDITIONS

H. CLAUSES

I. LIST OF ATTACHMENTS

Attachment 1: Statement of work

Attachment 2: Drawings

Attachment 3: Sample Letter of Bank Guaranty

Attachment 4: Breakdown of Price by Divisions of Specifications

J. INSTRUCTIONS ON HOW TO SUBMIT A QUOTATION

K. EVALUATION CRITERIA

L. REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS

2 | P a g e 3 1

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

19FR6326q0097

2. TYPE OF SOLICITATION

SEALED BID (IFB)

[x] NEGOTIATED (RFP)

3. DATE ISSUED

July 20, 2026

PAGE OF PAGES

2/ 31

IMPORTANT - The “offer” section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

5. REQUISITION/PURCHASE REQUEST NO.

PR16111096

6. PROJECT NO.

7. ISSUED BY CODE 8. ADDRESS OFFER TO

U.S EMBASSY PARIS

PROCUREMENT OFFICE

2 AVENUE GABRIEL

75008 PARIS - FRANCE

PROCUREMENT OFFICE

Pariscontracting@state.gov

9. FOR INFORMATION

CALL:

A. NAME

Anne HIBERT B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

0033 1 43 12 24 61

SOLICITATION

NOTE: In sealed bid solicitations “offer” and “offeror” mean “bid” and “bidder.”

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

Kitchen Renovation in one USG Building

11. The Contractor shall begin performance within 15 working days and complete it within 45 working days after receiving award, notice to proceed. This performance period is mandatory, negotiable. (See _______________.)

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If “YES,” indicate within how many calendar days after award in Item 12B.)

YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and ____ copies to perform the work required are due at the place specified in Item 8 by 14:00 local time on July 24, 2026. If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror’s name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 90 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

mailto:Pariscontracting@state.gov

3 | P a g e 3 1

SECTION A - PRICING

A. PRICE

The Contractor shall complete all work, including furnishing all labor, material, equipment, and services required under this purchase order for the following firm fixed price and within the time specified. This price shall include all labor, materials, all insurances, overhead and profit.

CLIN SERVICES QUANTITY UNIT

UNIT

PRICE IN

EUROS

EXCL.

VAT

TOTAL

PRICE IN

EUROS

EXCL. VAT

LOT 1- KITCHEN SUPPLY AND INSTALLATION

Demolition and removal of existing, including disponible in the appropriate waste facility 1 All

0002 Site preparation and protection 1 All 0003 Kitchen back wall preparation 1 All 0004 Floor and Wall Tiling work 1 All 0005 Painting work 1 All

Supply and installation of the kitchen furniture as described in 1.5 - 1.6 and 1.7 of the scope of work 1 All

Supply and installation of an Integrated Refrigerator 2 Each

Supply and installation of Built-in microwave ovens 2 Each

0009 Plumbing and mechanical works 1 All

Electrical works as described in 1.10 and 1.11 of the scope of work 1 All

LOT 2 - GLAZED PARTITION, COFFEE BAR, AND SUPPORTING STRUCTURE

0011 Demolition work 1 All 0012 Supply and installation of a coffee bar 1 All

Supply and installation of an atelier-style glazed window 1 All

Total price in Euros VAT excluded

20% VAT

Total price in Euros VAT Included

A.1 VALUE ADDED TAX

The Contractor shall include VAT as a separate charge on the Invoice and as a separate line item in Section

B.

4 | P a g e 3 1

SECTION B - STATEMENT OF WORK

The character and scope of the work are set forth in the contract. The Contractor shall furnish and install all materials required by this contract.

In case of differences between small and large-scale drawings, the latter will govern. Where a portion of the work is drawn in detail and the remainder of the work is indicated in outline, the parts drawn in detail shall apply also to all other portions of the work.

5 | P a g e 3 1

SECTION C - PACKAGING AND MARKING

Mark materials delivered to the site as follows:

US EMBASSY PARIS

CONSULAR SECTION

4 AVENUE GABRIEL

75008 PARIS

6 | P a g e 3 1

SECTION D - INSPECTION AND ACCEPTANCE

The COR, or his/her authorized representatives, will inspect from time to time the services being performed and the supplies furnished to determine whether work is being performed in a satisfactory manner, and that all supplies are of acceptable quality and standards.

The Contractor shall be responsible for any countermeasures or corrective action, within the scope of this contract, which may be required by the Contracting Officer as a result of such inspection.

D.1 SUBSTANTIAL COMPLETION

(a) "Substantial Completion" means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the

Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

(1) do not interfere with the intended occupancy or utilization of the work, and

(2) can be completed or corrected within the time period required for final completion.

(b) The "date of substantial completion" means the date determined by the Contracting Officer or authorized Government representative as of which substantial completion of the work has been achieved.

Use and Possession upon Substantial Completion - The Government shall have the right to take possession of and use the work upon substantial completion. Upon notice by the Contractor that the work is substantially complete (a Request for Substantial Completion) and an inspection by the Contracting

Officer or an authorized Government representative (including any required tests), the Contracting Officer shall furnish the Contractor a Certificate of Substantial Completion. The certificate will be accompanied by a Schedule of Defects listing items of work remaining to be performed, completed, or corrected before final completion and acceptance. Failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The Government's possession or use upon substantial completion shall not be deemed an acceptance of any work under the contract.

D.2 FINAL COMPLETION AND ACCEPTANCE

D.2.1 "Final completion and acceptance" means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

D.2.2 The "date of final completion and acceptance" means the date determined by the Contracting

Officer when final completion of the work has been achieved, as indicated by written notice to the

Contractor.

7 | P a g e 3 1

D.2.3 Final inspection and tests. The Contractor shall give the Contracting Officer at least five (5) days advance written notice of the date when the work will be fully completed and ready for final inspection and tests. Final inspection and tests will be started not later than the date specified in the notice unless the

Contracting Officer determines that the work is not ready for final inspection and so informs the

Contractor.

D.2.4 Final acceptance. If the Contracting Officer is satisfied that the work under the contract is complete (with the exception of continuing obligations), the Contracting Officer shall issue to the

Contractor a notice of final acceptance and make final payment upon:

• Satisfactory completion of all required tests,

• A final inspection that all items by the Contracting Officer listed in the Schedule of Defects have been completed or corrected and that the work is finally complete (subject to the discovery of defects after final completion), and

• Submittal by the Contractor of all documents and other items required upon completion of the work, including a final request for payment (Request for Final Acceptance).

8 | P a g e 3 1

SECTION E - DELIVERIES AND PERFORMANCE

52.211-12 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor shall pay liquidated damages to the Government in the amount of 250 € (two hundred and fifty) for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Default clause.

CONTRACTOR'S SUBMISSION OF CONSTRUCTION SCHEDULES

(a) The time for submission of the schedules referenced in FAR 52.236-15, "Schedules for

Construction Contracts", paragraph (a), is hereby modified to reflect the due date for submission as 10

(ten) calendar days after receipt of an executed contract".

(b) These schedules shall include the time by which shop drawings, product data, samples and other submittals required by the contract will be submitted for approval.

(c) The Contractor shall revise such schedules (1) to account for the actual progress of the work, (2) to reflect approved adjustments in the performance schedule, and (3) as required by the Contracting

Officer to achieve coordination with work by the Government and any separate contractors used by the

Government. The Contractor shall submit a schedule, which sequences work so as to minimize disruption at the job site.

(d) All deliverables shall be in the English language and any system of dimensions (English or metric) shown shall be consistent with that used in the contract. No extension of time shall be allowed due to delay by the Government in approving such deliverables if the Contractor has failed to act promptly and responsively in submitting its deliverables. The Contractor shall identify each deliverable as required by the contract.

(e) Acceptance of Schedule: When the Government has accepted any time schedule; it shall be binding upon the Contractor. The completion date is fixed and may be extended only by a written contract modification signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not:

(1) Extend the completion date or obligate the Government to do so,

(2) Constitute acceptance or approval of any delay, or

(3) Excuse the Contractor from or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

9 | P a g e 3 1

NOTICE OF DELAY

If the Contractor receives a notice of any change in the work, or if any other conditions arise which are likely to cause or are actually causing delays which the Contractor believes may result in late completion of the project, the Contractor shall notify the Contracting Officer. The Contractor’s notice shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule, or the completion date should be revised. The Contractor shall give such notice promptly, not more than ten (10) days after the first event giving rise to the delay or prospective delay. Only the Contracting Officer may revise the approved time schedule.

NOTICE TO PROCEED

(a) After receiving and accepting any bonds or evidence of insurance, the Contracting Officer will provide the Contractor a Notice to Proceed. The Contractor must then prosecute the work, commencing and completing performance not later than the time period established in the contract.

(b) It is possible that the Contracting Officer may elect to issue the Notice to Proceed before receipt and acceptance of any bonds or evidence of insurance. Issuance of a Notice to Proceed by the Government before receipt of the required bonds or insurance certificates or policies shall not be a waiver of the requirement to furnish these documents.

WORKING HOURS

All work shall be performed during working days, Monday through Friday- 9am through 5pm. Other hours, if requested by the Contractor, may be approved by the Contracting Officer's Representative (COR).

The Contractor shall give 24 hours in advance to COR who will consider any deviation from the hours identified above. Changes in work hours, initiated by the Contractor, will not be a cause for a price increase.

DELIVERABLES - The following items shall be delivered under this contract:

Description Quantity Deliver Date Deliver To

Section G. Securities/Insurance 1 10 days after award CO

Section E. Construction Schedule 1 10 days after award COR

Section G. Personnel Biographies 1 10 days after award COR

Section F. Payment Request 1

Last calendar day of each month COR

Section D. Request for Substantial Completion 1

15 days before inspection COR

Section D. Request for Final Acceptance 1

5 days before inspection COR

10 | P a g e 3 1

SECTION F – CONTRACT ADMINISTRATION DATA

652.242-70 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (AUG 1999)

(a) The Contracting Officer may designate in writing one or more Government employees, by name or position title, to take action for the Contracting Officer under this contract. Each designee shall be identified as a Contracting Officer’s Representative (COR). Such designation(s) shall specify the scope and limitations of the authority so delegated; provided, that the designee shall not change the terms or conditions of the contract, unless the COR is a warranted Contracting Officer, and this authority is delegated in the designation.

(b) The COR for this contract is the US Embassy Architect.

PAYMENT:

The Contractor's attention is directed to Section H, 52.232-5, "Payments Under Fixed-Price Construction

Contracts". The following elaborates on the information contained in that clause.

Requests for payment may be made no more frequently than monthly. Payment requests shall cover the value of labor and materials completed and in place, including a prorated portion of overhead and profit.

After receipt of the Contractor's request for payment, and on the basis of an inspection of the work, the

Contracting Officer shall make a determination as to the amount, which is then due. If the Contracting

Officer does not approve payment of the full amount applied for, less the retainage allowed by in 52.232-

5, the Contracting Officer shall advise the Contractor as to the reasons.

Under the authority of 52.232-27(a), the 14 day period identified in FAR 52.232-27(a)(1)(i)(A) is hereby changed to 30 days.

The Contractor shall address invoices to:

American Embassy Paris

A l’attention de : FMO VOUCHER / DBO

2, avenue Gabriel

75382 PARIS Cedex 08

Tél. : 01.43.12.22.22

The contractor shall submit invoices preferably by email to ParisFMCDBO1@state.gov

The Contractor shall show 20% Value Added Tax (VAT) as a separate item on invoices submitted for payment.

mailto:ParisFMCDBO1@state.gov

11 | P a g e 3 1

SECTION G - SPECIAL TERMS AND CONDITIONS

G.1.0 PERFORMANCE/PAYMENT PROTECTION - RESERVED

G.1.1 The Contractor shall provide the information required by the paragraph above within ten (10) calendar days after award. Failure to timely submit the required security may result in rescinding or termination of the contract by the Government. If the contract is terminated, the Contractor will be liable for those costs as described in FAR 52.249-10, Default (Fixed-Price Construction), which is included in this purchase order.

G.1.2 The bonds or alternate performance security shall guarantee the Contractor's execution and completion of the work within the contract time. This security shall also guarantee the correction of any defects after completion, the payment of all wages and other amounts payable by the Contractor under its subcontracts or for labor and materials, and the satisfaction or removal of any liens or encumbrances placed on the work.

G.1.3 The required securities shall remain in effect in the full amount required until final acceptance of the project by the Government. Upon final acceptance, the penal sum of the performance security shall be reduced to 10% of the contract price. The security shall remain in effect for one year after the date of final completion and acceptance, and the Contractor shall pay any premium required for the entire period of coverage.

G.2.0 INSURANCE - The Contractor is required by FAR 52.228-5, "Insurance - Work on a Government

Installation" to provide whatever insurance is legally necessary. The Contractor shall at its own expense provide and maintain during the entire performance period the following insurance amounts:

G.2.1 GENERAL LIABILITY (includes premises/operations, collapse hazard, products, completed operations, contractual, independent contractors, broad form property damage, personal injury):

(1) BODILY INJURY, ON OR OFF THE SITE, IN EUROS

Per Occurrence € 9,000,000.00

(2) PROPERTY DAMAGE, ON OR OFF THE SITE, IN EUROS

Per Occurrence € 9,000,000.00

G.2.2 The foregoing types and amounts of insurance are the minimums required. The Contractor shall obtain any other types of insurance required by local law or that are ordinarily or customarily obtained in the location of the work. The limit of such insurance shall be as provided by law or sufficient to meet normal and customary claims.

G.2.3 The Contractor agrees that the Government shall not be responsible for personal injuries or for damages to any property of the Contractor, its officers, agents, servants, and employees, or any other person, arising from and incident to the Contractor's performance of this contract.

12 | P a g e 3 1

The Contractor shall hold harmless and indemnify the Government from any and all claims arising therefrom, except in the instance of gross negligence on the part of the Government.

G.2.4 The Contractor shall obtain adequate insurance for damage to, or theft of, materials and equipment in insurance coverage for loose transit to the site or in storage on or off the site.

G.2.5 The general liability policy required of the Contractor shall name "the United States of America, acting by and through the Department of State", as an additional insured with respect to operations performed under this contract.

G.3.0 DOCUMENT DESCRIPTIONS

G.3.1 Supplemental documents: The Contracting Officer shall furnish from time to time such detailed drawings and other information as is considered necessary, in the opinion of the Contracting

Officer, to interpret, clarify, supplement, or correct inconsistencies, errors or omissions in the Contract documents, or to describe minor changes in the work not involving an increase in the contract price or extension of the contract time. The Contractor shall comply with the requirements of the supplemental documents, and unless prompt objection is made by the Contractor within 20 days, their issuance shall not provide for any claim for an increase in the Contract price or an extension of contract time.

G.3.1.1.Record documents. The Contractor shall maintain at the project site:

(1) a current marked set of Contract drawings and specifications indicating all interpretations and clarification, contract modifications, change orders, or any other departure from the contract requirements approved by the Contracting Officer; and,

(2) a complete set of record shop drawings, product data, samples and other submittals as approved by the Contracting Officer.

G.3.1.2 . "As-Built" Documents: After final completion of the work, but before final acceptance thereof, the Contractor shall provide:

(1) a complete set of "as-built" drawings, based upon the record set of drawings, marked to show the details of construction as actually accomplished; and,

(2) record shop drawings and other submittals, in the number and form as required by the specifications.

G.4.0 LAWS AND REGULATIONS

The Contractor shall, without additional expense to the Government, be responsible for complying with all laws, codes, ordinances, and regulations applicable to the performance of the work, including those of the host country, and with the lawful orders of any governmental authority having jurisdiction. Host country authorities may not enter the construction site without the permission of the Contracting Officer.

13 | P a g e 3 1

Unless otherwise directed by the Contracting Officer, the Contractor shall comply with the more stringent of the requirements of such laws, regulations, and orders and of the contract. In the event of a conflict between the contract and such laws, regulations and orders, the Contractor shall promptly advise the

Contracting Officer of the conflict and of the Contractor's proposed course of action for resolution by the

Contracting Officer.

G.4.1 The Contractor shall comply with all local labor laws, regulations, customs, and practices pertaining to labor, safety, and similar matters, to the extent that such compliance is not inconsistent with the requirements of this contract.

G.4.2 The Contractor shall give written assurance to the Contracting Officer that all subcontractors and others performing work on or for the project have obtained all requisite licenses and permits.

G.4.3 The Contractor shall submit proper documentation and evidence satisfactory to the Contracting

Officer of compliance with this clause.

G.5.0 CONSTRUCTION PERSONNEL - The Contractor shall maintain discipline at the site and at all times take all reasonable precautions to prevent any unlawful, riotous, or disorderly conduct by or among those employed at the site. The Contractor shall ensure the preservation of peace and protection of persons and property in the neighborhood of the project against such action. The Contracting Officer may require, in writing that the Contractor remove from the work any employee that the Contracting Officer deems incompetent, careless, insubordinate or otherwise objectionable, or whose continued employment on the project is deemed by the Contracting Officer to be contrary to the Government's interests.

G.5.1 If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately give notice, including all relevant information, to the Contracting Officer.

G.5.2 After award, the Contractor has ten (10) calendar days to submit to the Contracting Officer a list of workers and supervisors assigned to this project for the Government to conduct all necessary security checks. It is anticipated that security checks will take 5 (five) working days to perform. For each individual, the list shall include:

Full Name

Identification number

Failure to provide any of the above information may be considered grounds for rejection and/or resubmittal of the application. Once the Government has completed the security screening and approved the applicants a badge will be provided to the individual for access to the site. This badge may be revoked at any time due to the falsification of data, or misconduct on site.

G.5.3 The Contractor shall provide an English and French speaking supervisor on site at all times. This position is considered as key personnel under this purchase order.

14 | P a g e 3 1

G.6.0 Materials and Equipment - All materials and equipment incorporated into the work shall be new and for the purpose intended, unless otherwise specified. All workmanship shall be of good quality and performed in a skillful manner that will withstand inspection by the Contracting Officer.

G.7.0 SPECIAL WARRANTIES

G.7.1 Any special warranties that may be required under the contract shall be subject to the stipulations set forth in 52.246-21, "Warranty of Construction", as long as they are not in conflict.

G.7.2 The Contractor shall obtain and furnish to the Government all information required to make any subcontractor's, manufacturer's, or supplier's guarantee or warranty legally binding and effective. The

Contractor shall submit both the information and the guarantee or warranty to the Government in sufficient time to permit the Government to meet any time limit specified in the guarantee or warranty, but not later than completion and acceptance of all work under this contract.

G.8.0 EQUITABLE ADJUSTMENTS

Any circumstance for which the contract provides an equitable adjustment that causes a change within the meaning of paragraph (a) of the "Changes" clause shall be treated as a change under that clause; provided, that the Contractor gives the Contracting Officer prompt written notice (within 20 days) stating:

(a) the date, circumstances, and applicable contract clause authorizing an equitable adjustment and

(b) that the Contractor regards the event as a changed condition for which an equitable adjustment is allowed under the contract

The Contractor shall provide written notice of a differing site condition within 10 calendar days of occurrence following FAR 52.236-2, Differing Site Conditions.

G.9.0 ZONING APPROVALS AND PERMITS

The Government shall be responsible for:

- obtaining proper zoning or other land use control approval for the project

- obtaining the approval of the Contracting Drawings and Specifications

- paying fees due for the foregoing; and,

- for obtaining and paying for the initial building permits.

15 | P a g e 3 1

SECTION H - CLAUSES

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. In addition, the full text of a clause may be accessed electronically at: Acquisition.gov this address is subject to change.

If the Federal Acquisition Regulation (FAR) is not available at the location indicated above, use the

Department of State Acquisition website at e-CFR to see the links to the FAR. You may also use an

Internet “search engine” (for example, Google, Yahoo or Excite) to obtain the latest location of the most current FAR.

THE FOLLOWING FEDERAL ACQUISITION REGULATION CLAUSE(S) IS/ARE

INCORPORATED BY REFERENCE (48 CFR CH. 1):

CLAUSE TITLE AND DATE

52.202-1 DEFINITIONS (JUN 2020)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL

(JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (DEVIATION JAN 2026)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (DEVIATION JAN 2026)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND

CERTIFICATIONS (DEC 2014)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING

WITH CONTRACTORS DEBARRED, SUSPENDED OR PROPOSED FOR

DEBARMENT OR VOLUNTARILY EXCLUDED (DEVIATION JAN 2026)

52.216-7 ALLOWABLE COST AND PAYMENT (DEVIATION FEB 2026)

52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997)

52.222-19 CHILD LABOR-COOPERATION WITH AUTHORITIES AND REMEDIES

(DEVIATION FEB 2026)

52.222-50 COMBATING TRAFFICKING IN PERSONS (DEVIATION FEB 2026)

https://acquisition.gov/browse/index/far https://gov.ecfr.io/cgi-bin/text-idx?SID=d9a7851186785ba2b1896db79b1b6b29&mc=true&tpl=/ecfrbrowse/Title48/48tab_02.tpl

16 | P a g e 3 1

52.225-5 TRADE AGREEMENTS (NOV 2023)

52.225-14 INCONSISTENCY BETWEEN ENGLISH VERSION AND TRANSLATION OF

CONTRACT (DEVIATION FEB 2026)

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE

DRIVING (MAY 2024)

52.228-3 WORKERS’ COMPENSATION INSURANCE (DEFENSE BASE ACT) (JUL 2014)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 INDIVIDUAL SURETY- PLEDGES OF ASSETS (FEB 2021)

52.228-13 ALTERNATIVE PAYMENT PROTECTION (JULY 2000)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020)

52.229-6 TAXES - FOREIGN FIXED-PRICE CONTRACTS (FEB 2013)

52.229-7 TAXES- FIXED PRICE CONTRACTS WITH FOREIGN GOVERNMENTS (FEB 2013)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-8 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)

52.232-11 EXTRAS (APR 1984)

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

52.232-22 LIMITATION OF FUNDS (DEVIATION FEB 2026)

52.232-25 PROMPT PAYMENT (DEVIATION FEB 2026)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER - SYSTEM FOR AWARD

MANAGEMENT (OCT 2018)

52.232-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER – OTHER THAN SYSTEM FOR

AWARD MANAGEMENT (JULY 2013)

52.233-1 DISPUTES (DEVIATION JAN 2026)

17 | P a g e 3 1

52.233-3 PROTEST AFTER AWARD (DEVIATION JAN 2026)

52.236-2 DIFFERING SITE CONDITIONS (DEVIATION AUG 2025)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK

(DEVIATION AUG 2025)

52.236-5 MATERIAL AND WORKMANSHIP (DEVIATION AUG 2025)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (DEVIATION AUG 2025)

52.236-7 PERMITS AND RESPONSIBILITIES ((DEVIATION AUG 2025)

52.236-8 OTHER CONTRACTS (DEVIATION AUG 2025)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS (DEVIATION AUG 2025)

52.236-10 OPERATIONS AND STORAGE AREAS (DEVIATION AUG 2025)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (DEVIATION AUG 2025)

52.236-12 CLEANING UP (DEVIATION AUG 2025)

52.236-13 ACCIDENT PREVENTION (DEVIATION AUG 2025)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (DEVIATION AUG 2025)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (DEVIATION AUG 2025)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION

(DEVIATION AUG 2025)

52.240-91 SECURITY PROHIBITIONS AND EXCLUSIONS REPRESENTATIONS AND

CERTIFICATIONS (DEVIATION JAN 2026)

52.242-14 SUSPENSION OF WORK (APR 1984)

52.243-4 CHANGES (DEVIATION JULY 2026)

52.243-5 CHANGES AND CHANGED CONDITIONS (APR 1984)

52.245-2 GOVERNMENT PROPERTY INSTALLATION OPERATION SERVICES (APR 2012)

52.245-9 USE AND CHARGES (APR 2012)

18 | P a g e 3 1

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

52.246-17 WARRANTY OF SUPPLIES OF A NONCOMPLEX NATURE (JUN 2003)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.246-26 REPORTING NONCONFORMING ITEMS (AUG 2024)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE)

(APR 2012)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.249-14 EXCUSABLE DELAYS (APR 1984)

I. FAR CLAUSES INCORPORATED IN FULL TEXT

52.213-4 TERMS AND CONDITIONS—SIMPLIFIED ACQUISITIONS (OTHER

THAN COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES)

(DEVIATION JAN 2026)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post acceptance rights—

(1) Within a reasonable period of time after the defect was discovered or should have been discovered;

and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence. Examples of occurrences include acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. When an excusable delay occurs, the Contractor shall—

(1) Notify the Contracting Officer in writing as soon as possible;

(2) Remedy the delay as quickly as possible; and

(3) Notify the Contracting Officer when the occurrence is over.

19 | P a g e 3 1

(c) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the

Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(d) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. The Government will send a cure notice to the Contractor, unless the reason for the termination is late delivery. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the

Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(e) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

II. THE FOLLOWING DEPARTMENT OF STATE ACQUISITION REGULATION (DOSAR)

CLAUSE(S) IS/ARE SET FORTH IN FULL TEXT:

CONTRACTOR IDENTIFICATION (JULY 2008)

Contract performance may require contractor personnel to attend meetings with government personnel and the public, work within government offices, and/or utilize government email.

Contractor personnel must take the following actions to identify themselves as non-federal employees:

1) Use an e-mail signature block that shows name, the office being supported and company affiliation

(e.g., “John Smith, Office of Human Resources, ACME Corporation Support Contractor”);

2) Clearly identify themselves and their contractor affiliation in meetings.

3) Identify their contractor affiliation in Departmental e-mail and phone listings whenever contractor personnel are included in those listings; and

4) Contractor personnel may not utilize Department of State logos or indicia on business cards.

20 | P a g e 3 1

652.204-70 DEPARTMENT OF STATE PERSONAL IDENTIFICATION CARD ISSUANCE

PROCEDURES (FEB 2015)

(a) The Contractor shall comply with the Department of State (DOS) Personal Identification Card Policy and Procedures for all employees performing under this contract who require frequent and continuing access to DOS facilities, or information systems. The Contractor shall insert the substance of this clause in all subcontracts when the subcontractor's employees will require frequent and continuing access to DOS facilities, or information systems.

(b) The DOS Personal Identification Card Policy and Procedures may be accessed at http://www.state.gov/m/ds/rls/rpt/c21664.htm.

652.229-71 PERSONAL PROPERTY DISPOSITION AT POSTS ABROAD (AUG 1999)

Regulations at 22 CFR Part 136 require that U.S. Government employees and their families do not profit personally from sales or other transactions with persons who are not themselves entitled to exemption from import restrictions, duties, or taxes. Should the Contractor experience importation or tax privileges in a foreign country because of its contractual relationship to the United States Government, the Contractor shall observe the requirements of 22 CFR Part 136 and all policies, rules, and procedures issued by the chief of mission in that foreign country.

(End of clause)

652.236-70 ADDITIONAL SAFETY MEASURES (OCT 2017)

In addition to the safety/accident prevention requirements of FAR 52.236-13, Accident Prevention

Alternate I, the contractor shall comply with the following additional safety measures.

(a) High Risk Activities. If the project contains any of the following high risk activities, the contractor shall follow the section in the latest edition, as of the date of the solicitation, of the U.S. Army Corps of

Engineers Safety and Health manual, EM 385-1-1, that corresponds to the high risk activity. Before work may proceed, the contractor must obtain approval from the COR of the written safety plan required by

FAR 52.236-13, Accident Prevention Alternate I (see paragraph (f) below), containing specific hazard mitigation and control techniques.

(1) Scaffolding;

(2) Work at heights above 1.8 meters;

(3) Trenching or other excavation greater than one (1) meter in depth;

(4) Earth-moving equipment and other large vehicles;

(5) Cranes and rigging;

(6) Welding or cutting and other hot work;

(7) Partial or total demolition of a structure;

(8) Temporary wiring, use of portable electric tools, or other recognized electrical hazards.

Temporary wiring and portable electric tools require the use of a ground fault circuit interrupter

(GFCI) in the affected circuits; other electrical hazards may also require the use of a GFCI;

http://www.state.gov/m/ds/rls/rpt/c21664.htm

21 | P a g e 3 1

(9) Work in confined spaces (limited exits, potential for oxygen less than 19.5 percent or combustible atmosphere, potential for solid or liquid engulfment, or other hazards considered to be immediately dangerous to life or health such as water tanks, transformer vaults, sewers, cisterns, etc.).

(10) Hazardous materials - a material with a physical or health hazard including but not limited to, flammable, explosive, corrosive, toxic, reactive or unstable, or any operations, which creates any kind of contamination inside an occupied building such as dust from demolition activities, paints, solvents, etc.; or

(11) Hazardous noise levels as required in EM 385-1 Section 5B or local standards if more restrictive.

(b) Safety and Health Requirements. The contractor and all subcontractors shall comply with the latest edition of the U.S. Army Corps of Engineers Safety and Health manual EM 385-1-1, or OSHA 29 CFR parts 1910 or 1926 if no EM 385-1-1 requirements are applicable, and the accepted contractor’s written safety program.

(c) Mishap Reporting. The contractor is required to report immediately all mishaps to the COR and the contracting officer. A “mishap” is any event causing injury, disease or illness, death, material loss or property damage, or incident causing environmental contamination. The mishap reporting requirement shall include fires, explosions, hazardous materials contamination, and other similar incidents that may threaten people, property, and equipment.

(d) Records. The contractor shall maintain an accurate record on all mishaps incident to work performed under this contract resulting in death, traumatic injury, occupational disease, or damage to or theft of property, materials, supplies, or equipment. The contractor shall report this data in the manner prescribed by the contracting officer.

(e) Subcontracts. The contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(f) Written program. The plan required by paragraph (f)(1) of the clause entitled “Accident Prevention

Alternate I” shall be known as the Site Safety and Health Plan (SSHP) and shall address any activities listed in paragraph (a) of this clause, or as otherwise required by the contracting officer/COR.

(1) The SSHP shall be submitted at least 10 working days prior to commencing any activity at the site.

(2) The plan must address developing activity hazard analyses (AHAs) for specific tasks. The AHAs shall define the activities being performed and identify the work sequences, the specific anticipated hazards, site conditions, equipment, materials, and the control measures to be implemented to eliminate or reduce each hazard to an acceptable level of risk. Work shall not begin until the AHA for the work activity has been accepted by the COR and discussed with all engaged in the activity, including the Contractor, subcontractor(s), and Government on-site representatives.

(3) The names of the Competent/Qualified Person(s) required for a particular activity (for example, excavations, scaffolding, fall protection, other activities as specified by EM 385-1-1) shall be identified and included in the AHA. Proof of their competency/qualification shall be submitted to the contracting officer or COR for acceptance prior to the start of that work activity.

22 | P a g e 3 1

The AHA shall be reviewed and modified as necessary to address changing site conditions, operations, or change of competent/qualified person(s).

652.242-73 AUTHORIZATION AND PERFORMANCE (AUG 1999)

(a) The Contractor warrants the following:

(1) That is has obtained authorization to operate and do business in the country or countries in which this contract will be performed;

(2) That is has obtained all necessary licenses and permits required to perform this contract; and,

(3) That it shall comply fully with all laws, decrees, labor standards, and regulations of said country or countries during the performance of this contract.

(b) If the party actually performing the work will be a subcontractor or joint venture partner, then such subcontractor or joint venture partner agrees to the requirements of paragraph (a) of this clause.

652.243-70 NOTICES (AUG 1999)

Any notice or request relating to this contract given by either party to the other shall be in writing. Said notice or request shall be mailed or delivered by hand to the other party at the address provided in the schedule of the contract. All modifications to the contract must be made in writing by the Contracting

Officer.

23 | P a g e 3 1

SECTION I - LIST OF ATTACHMENTS

ATTACHMENT

NUMBER DESCRIPTION OF ATTACHMENT

NUMBER OF

PAGES

Attachment 1 Statement of Work 14

Attachment 2 Drawings 2

Attachment 3 Sample Bank Letter of Guaranty 1

Attachment 4 Breakdown of Price by Divisions of Specifications 1

24 | P a g e 3 1

SECTION J – INSTRUCTIONS ON HOW TO SUBMIT A

QUOTATION

The Offeror shall include Defense Base Act (DBA) insurance premium costs covering employees. The offeror may obtain DBA insurance directly from any Department of Labor approved providers at the DOL website at http://www.dol.gov/owcp/dlhwc/lscarrier.htm

A. QUALIFICATIONS OF OFFERORS

Offerors/quoters must be technically qualified and financially responsible to perform the work described in this solicitation. At a minimum, each Offeror/Quoter must meet the following requirements:

(1) Be able to understand written and spoken English and French.

(2) Have an established business with a permanent physical address and telephone listing in Paris area- France.

(3) The offeror shall provide proof of SAM registration to include the SAM UEI number

(4) Be able to demonstrate prior construction experience with suitable references over the past

3 years in Kitchen renovation (including plumbing, tiling, painting).

(5) Have the necessary personnel, equipment and financial resources available to perform the work.

(6) Have all licenses and permits required by local law. This shall include Tax regularity certification (“URSAFF)

(7) Meet all local insurance requirements. This shall include a copy of the insurance certificate.

http://www.dol.gov/owcp/dlhwc/lscarrier.htm

25 | P a g e 3 1

B. SUBMISSION OF QUOTATIONS

This solicitation is for the performance of the construction services described in SCOPE OF WORK, and the Attachments which are a part of this request for quotation.

Each quotation must consist of the following:

VOLUME TITLE NUMBER OF

COPIES*

I Standard Form 1442

II Price proposal and completed Section A, including a completed

Attachment 3, "Breakdown of proposal price by divisions of specifications

III Performance schedule in the form of a "bar chart" and Business

Management/Technical Proposal

IV Business Management, Administrative and Technical Proposal.

Submit the complete quotation to the address indicated. If mailed, on Standard Form 18, or if hand-delivered, use the address set forth below:

The Offeror/Quoter shall identify and explain/justify any deviations, exceptions, or conditional assumptions taken with respect to any of the instructions or requirements of this request for quotation in the appropriate volume of the offer.

Volume I: SF1442

Complete Blocks 14 through 20C of the SF1442

Volume II: Price proposal and Section A

The price proposal shall consist of completion of Section A and Section J, Attachment 3, "Breakdown of proposal price by divisions of specifications”. Complete all applicable portions of this form in each relevant category (such as., labor, materials, etc.).

Volume III: Performance schedule

Present the performance schedule in the form of a "bar chart" indicating when the various portions of the work will be commenced and completed within the required schedule. This bar chart shall be in sufficient detail to clearly show each segregable portion of work and its planned commencement and completion date.

26 | P a g e 3 1

Volume IV: Business Management, administrative and technical Proposal.

The Business Management/Technical Proposal shall be in two parts, including the following information:

a) Administrative proposal

The Contractor shall provide the required information listed in Section J-A Qualifications of offerors

b) Business management and technical proposal

The offeror shall provide:

1/ A work plan taking into account all work elements in Attachment 1- Specifications, Scope of Work and Drawings, and explaining how the contractor intends to perform the work.

2/ Data sheet of all proposed products. If the offeror proposed an equal item to the brand name cited in the specification, the Contractor shall provide detailed specifications of the proposed products showing how they meet the brand name requirements.

3/ Identify types and quantities of equipment, supplies and materials required for the performance of services under this contract. Identify if the offeror already possesses the listed items and their condition for suitability and if not already possessed or inadequate for use how and when the items will be obtained.

4/ Plan of ensuring quality of services including but not limited to contract administration and oversight;

and

5/ A health and safety anticipated plan (“PPSP- plan particulier de Sécurité et de protection de la santé »)

6/ The Offeror subcontracting plan - If a subcontractor(s) is to be used, the Contractor shall provide a complete sub-contracting plan including, but not limited to:

➢ Sub-contractor qualifications as required in section…